Lease, dated January 19, 2016, as amended, by and between the Registrant and Walton Torrey Owner A, L.L.C

Exhibit 10.10

TORREY RIDGE SCIENCE CENTER

LEASE

WALTON TORREY OWNER A, L.L.C., a Delaware limited liability company

as Landlord,

and

TP THERAPEUTICS, INC., a Delaware corporation

as Tenant

SUMMARY OF BASIC LEASE INFORMATION

This Summary of Basic Lease Information (“Summary”) is hereby incorporated into and made a part of the attached Lease. Each reference in the Lease to any term of this Summary shall have the meaning as set forth in this Summary for such term. In the event of a conflict between the terms of this Summary and the Lease, the terms of the Lease shall prevail. Any capitalized terms used herein and not otherwise defined herein shall have the meaning as set forth in the Lease.

TABLE OF CONTENTS

EXHIBITS

EXTENSION OPTION RIDER

INDEX

OFFICE LEASE

This Lease, which includes the preceding Summary and the exhibits attached hereto and incorporated herein by this reference (the Lease, the Summary and the exhibits to be known sometimes collectively hereafter as the “Lease”), dated as of the date set forth in Section 1 of the Summary, is made by and between WALTON TORREY OWNER A, L.L.C., a Delaware limited liability company (“Landlord”), and TP THERAPEUTICS, INC., a Delaware corporation “Tenant”).

ARTICLE 1

PROJECT, BUILDING AND PREMISES

1.1 Project, Building and Premises.

1.1.1 Premises. Upon and subject to the terms, covenants and conditions hereinafter set forth in this Lease, Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the premises described in Section 6.1 of the Summary (the “Premises”), which Premises are located in the Building (as defined in Section 6.2 of the Summary) and located within the Project (as defined below). The floor plan of the Premises is attached hereto as Exhibit A.

1.1.2 Building and Project. The Building is part of a multi-building commercial project known as “Torrey Ridge Science Center” and located in the City of San Diego. The term “Project” as used in this Lease, shall mean, collectively: (i) the Building; (ii) the other existing buildings located at 10614 and 10578 Science Center Drive within the site which, as of the date hereof, are not owned by Landlord (collectively, the “Other Existing Buildings”); (iii) any outside plaza areas, walkways, driveways, courtyards, public and private streets, transportation facilitation areas and other improvements and facilities now or hereafter constructed surrounding and/or servicing the Building and/or the Other Existing Buildings, which are designated from time to time by Landlord (and/or any other owners of Torrey Ridge Science Center) as common areas appurtenant to or servicing the Building, the Other Existing Buildings and any such other improvements; (iv) any additional buildings, improvements, facilities and common areas which Landlord (any other owners of Torrey Ridge Science Center and/or any common area association formed by Landlord, Landlord’s predecessor-in-interest and/or Landlord’s assignee for the Project) may add thereto from time to time within or as part of the Project; and (v) the land upon which any of the foregoing are situated. The site plan depicting the current configuration of the Project is attached hereto as Exhibit A-1. The Building, as well as each of the Other Existing Buildings contain a subterranean parking facility (“Parking Facility”). Notwithstanding the foregoing or anything contained in this Lease to the contrary, (1) Landlord has no obligation to expand or otherwise make any improvements within the Project, including, without limitation, any of the outside plaza areas, walkways, driveways, courtyards, public and private streets, transportation facilitation areas and other improvements and facilities which may be depicted on Exhibit A-1 attached hereto (as the same may be modified by Landlord (and/or any other owners of Torrey Ridge Science Center) from time to time without notice to Tenant), other than Landlord’s obligations (if any) specifically set forth in the Tenant Work Letter attached hereto as Exhibit B, and (2) Landlord (and/or any other owners of Torrey Ridge Science Center) shall have the right from time to time to include or exclude any improvements or facilities within the Project, at such party’s sole election, as more particularly set forth in Section 1.1.3 below.

1.1.3 Tenant’s and Landlord’s Rights. Tenant shaft have the right to the nonexclusive use of the common corridors and hallways, stairwells, elevators (if any), restrooms and other public or common areas located within the Building, and the non-exclusive use of those areas located on the Project that are designated by Landlord (and/or any other owners of Torrey Ridge Science Center) from time to time as common areas for the Building; provided, however, that (i) Tenant’s use thereof shall be subject to (A) the provisions of any covenants, conditions and restrictions regarding the use thereof now or hereafter recorded against the Project, and (B) such reasonable, non-discriminatory rules and regulations as Landlord may make from time to time (which shall be provided in writing to Tenant), and (ii) Tenant may not go on the roof of Building or the Other Existing Buildings without Landlord’s prior consent (which may be withheld in Landlord’s sole and absolute discretion) and without otherwise being accompanied by a representative of Landlord. Landlord (and/or any other owners of Torrey Ridge Science Center) reserve the right from time to time to use any of the common areas of the Project, and the roof, risers and conduits of the Building and the Other Existing Buildings for telecommunications and/or any other purposes, and to do any of the following: (1) make any changes, additions, improvements, repairs and/or replacements in or to the Project or any portion or elements thereof, including, without limitation, (x) changes in the location, size, shape and number of driveways, entrances, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways, public and private streets, plazas, courtyards, transportation facilitation areas and common areas, and (y) expanding or decreasing the size of the Project and any common areas and other elements thereof, including adding, deleting and/or excluding buildings (including any of the Other Existing Buildings) thereon and therefrom; (2) close temporarily any of the common areas while engaged in making repairs, improvements or alterations to the Project; (3) retain and/or form a common area association or associations under covenants, conditions and restrictions to own, manage, operate, maintain, repair and/or replace all or any portion of the landscaping, driveways, walkways, public and private streets, plazas, courtyards, transportation facilitation areas and/or other common areas located outside of the Building and the Other Existing Buildings and, subject to Article 4 below, include the common area assessments, fees and taxes charged by the association(s) and the cost of maintaining, managing, administering and operating the association(s), in Operating Expenses or Tax Expenses; and (4) perform such other acts and make such other changes with respect to the Project as Landlord may, in the exercise of good faith business judgment, deem to be appropriate.

1.2 Condition of Premises. Except as expressly set forth in this Lease and in the Tenant Work Letter, Landlord shall not be obligated to provide or pay for any improvement, remodeling or refurbishment work or services

related to the improvement, remodeling or refurbishment of the Premises, and Tenant shall accept the Premises in its “As Is” condition on the Lease Commencement Date.

1.3 Rentable Square Feet. The parties hereby stipulate that the Premises contain the rentable square feet set forth in Section 6.1 of the Summary, and such square footage amount is not subject to adjustment or remeasurement by Landlord or Tenant. Accordingly, there shall be no adjustment in the Base Rent or other amounts set forth in this Lease which are determined based upon the rentable square feet of the Premises.

ARTICLE 2

LEASE TERM AND TENANT’S EARLY CANCELLATION RIGHT

2.1 Lease Term. The terms and provisions of this Lease shall be effective as of the date of this Lease except for the provisions of this Lease relating to the payment of Rent. The term of this Lease (the “Lease Term”) shall be as set forth in Section 7.1 of the Summary and shall commence on the date (the “Lease Commencement Date”) set forth in Section 7.2 of the Summary (subject, however, to the terms of the Tenant Work Letter), and shall terminate on the date (the “Lease Expiration Date”) set forth in Section 7.3 of the Summary, unless this Lease is sooner terminated as hereinafter provided. For purposes of this Lease, the term “Lease Year” shall mean each consecutive twelve (12) month period during the Lease Term, provided that the last Lease Year shall end on the Lease Expiration Date. If Landlord does not deliver possession of the Premises to Tenant Ready for Occupancy on or before the anticipated Lease Commencement Date (as set forth in Section 7.2(ii) of the Summary), Landlord shall not be subject to any liability nor shall the validity of this Lease nor the obligations of Tenant hereunder be affected. If the Lease Commencement Date is a date which is other than the anticipated Lease Commencement Date set forth in Section 7.2(ii) of the Summary, then, following the Lease Commencement Date, Landlord shall deliver to Tenant an amendment to lease in the form attached hereto as Exhibit C, attached hereto, setting forth, among other things, the Lease Commencement Date and the Lease Expiration Date, and Tenant shall execute and return such amendment to Landlord within five (5) business days after Tenant’s receipt thereof. If Tenant fails to execute and return the amendment within such 5-business day period, Tenant shall be deemed to have approved and confirmed the dates set forth therein, provided that such deemed approval shall not relieve Tenant of its obligation to execute and return the amendment (and such failure shall constitute a default by Tenant hereunder). If Landlord does not deliver such amendment to Tenant, the Lease Commencement Date shall be deemed to be the anticipated Lease Commencement Date set forth in Section 7.2(ii) of the Summary. In the event that Substantial Completion of the Premises has not occurred by August 1, 2016 (the “First Outside Date”), as such First Outside Date may be extended by the number of days of Tenant Delays (as defined in the Tenant Work Letter) and by the number of days of Force Majeure events (as defined in Section 24.17 hereof), then Landlord agrees to provide Tenant with one (1) day of abatement of Base Rent for each one (1) day past the First Outside Date (as such date may be extended as provided above) that Substantial Completion of the Premises has failed to occur. In addition, in the event that Substantial Completion of the Premises has not occurred by the “Second Outside Date,” which Second Outside Date shall be September 1, 2016, as such Second Outside Date may be extended by the number of days of Tenant Delays and by the number of days of “Force Majeure” events, then the sole remedy of Tenant shall be the right to deliver a notice to Landlord (the “Second Outside Date Termination Notice”) electing to terminate this Lease effective upon receipt of the Second Outside Date Termination Notice by Landlord (the “Effective Date”). Except as provided herein below, the Second Outside Date Termination Notice must be delivered by Tenant to Landlord, if at all, not earlier than the Second Outside Date and not later than five (5) business days after the Second Outside Date. If Tenant delivers the Second Outside Date Termination Notice to Landlord, then Landlord shall have the right to suspend the Effective Date for a period ending thirty (30) days after the original Effective Date. In order to suspend the Effective Date, Landlord must deliver to Tenant, within five (5) business days after receipt of the Second Outside Date Termination Notice, a certificate of the Contractor (as defined in the Tenant Work Letter) certifying that it is such Contractor’s best good faith judgment that Substantial Completion of the Premises will occur within thirty (30) days after the original Effective Date. If Substantial Completion of the Premises occurs within said thirty (30) day suspension period, then the Second Outside Date Termination Notice shall be of no further force and effect; if, however. Substantial Completion of the Premises does not occur within said thirty (30) day suspension period, then this Lease shall terminate as of the date of expiration of such thirty (30) day period. Upon termination of this Lease pursuant to this Section 2.1. the parties shall be relieved of all further obligations under this Lease except for those obligations under this Lease which expressly survive the expiration or sooner termination of this Lease.

2.2 Tenant’s Early Cancellation Right. The original Tenant executing this Lease (“Original Tenant”) shall have the one (1) time right to terminate and cancel this Lease as it pertains to the initial Premises leased by Tenant hereunder effective as of the date (“Termination Date”) which is the last day of the thirty-sixth (36th) month of the initial Lease Term, which right is contingent upon Tenant paying to Landlord the Termination Consideration (as defined below) in a timely manner in accordance with the following provisions of this Section 2.2. To exercise such termination right, Tenant must deliver to Landlord, on or before the date which is nine (9) months prior to the Termination Date, written notice of Tenant’s exercise of such right (the “Termination Notice”), along with the Termination Consideration. As used herein, the “Termination Consideration” shall mean an amount equal to (i) seven (7) months of monthly Base Rent calculated based on the seven (7) month period following the Termination Date (i.e., months 37 – 43 which equals Two Hundred Forty-Six Thousand Seven Hundred Ninety Nine and 56/100 Dollars ($246,799.56) in the aggregate) and (ii) Landlord’s estimate of Tenant’s Share of Operating Expenses, Tax Expenses and Utilities Costs that would have been payable by Tenant for months 37 – 44 of the initial Lease Term. If Tenant properly and timely exercises its termination option in this Section 2.2 in strict accordance with the terms hereof, this Lease shall expire at midnight on the Termination Date, and Tenant shall be required to surrender the Premises to Landlord on or prior to the Termination Date in accordance with the applicable provisions of this Lease. The termination right set forth in this Section 2.2 is personal to the Original Tenant and may only be executed by the Original Tenant (and not any sublessee or other Transferee of Original Tenant’s

interest in this Lease) if the Original Tenant occupies the entire Premises. Notwithstanding anything above to the contrary, Tenant shall have no right to exercise such early cancellation right, and Tenant’s exercise of such early cancellation right may, at Landlord’s option, be nullified by Landlord and deemed of no further force or effect, if Tenant shall be in material default under the terms of this Lease after the expiration of applicable cure periods as of Tenant’s exercise of such early cancellation right. For purposes of this Lease, a material default shall mean any monetary default or any material non-monetary default.

ARTICLE 3

BASE RENT

Tenant shall pay, without notice or demand, to Landlord or Landlord’s agent at the management office of the Building, or at such other place as Landlord may from time to time designate in writing, in currency or a check for currency which, at the time of payment, is legal tender for private or public debts in the United States of America, base rent (“Base Rent”) as set forth in Section 8 of the Summary, payable in equal monthly installments as set forth in Section 8 of the Summary in advance on or before the first day of each and every month during the Lease Term, without any setoff or deduction whatsoever. In addition to the Security Deposit, concurrently with Tenant’s execution of this Lease, Tenant shall deliver to Landlord an amount equal to Forty-One Thousand Sixteen and 90/100 Dollars ($41,016.90), which amount shall be comprised of the following: (i) the Base Rent payable by Tenant for the Premises for the first (1^st) full month of the Lease Term (i.e., Thirty-Two Thousand Two Hundred Eighty Nine and 90/100 Dollars ($32,289.90); and (ii) the Estimated Expenses (as defined below) payable by Tenant for the Premises for the first (1^st) full month of the Lease Term (i.e., Eight Thousand Seven Hundred Twenty-Seven Dollars ($8,727.00)). If any rental payment date (including the Lease Commencement Date) falls on a day of the month other than the first day of such month or if any rental payment is for a period which is shorter than one month, then the rental for any such fractional month shall be a proportionate amount of a full calendar month’s rental based on the proportion that the number of days in such fractional month bears to the number of days in the calendar month during which such fractional month occurs. All other payments or adjustments required to be made under the terms of this Lease that require proration on a time basis shall be prorated on the same basis.

Notwithstanding anything to the contrary contained herein and provided that Tenant faithfully performs all of the terms and conditions of this Lease, Landlord hereby agrees to abate Tenant’s obligation to pay fifty percent (50%) of Tenant’s monthly Base Rent for the second (2^nd), third (3^rd), fourth (4^th), fifth (5^th), sixth (6^th), and seventh (7^th), full months of the initial Lease Term. In the event that Tenant does not exercise its termination right in Section 2.2 above, then Landlord further agrees to abate fifty percent (50%) of Tenant’s Monthly Base Rent for the thirty-seventh (37^th), thirty-eighth (38^th), thirty-ninth (39^th) and fortieth (40^th) full months of the initial Lease Term (all such abated monthly Base Rent collectively, the “Abated Rent”). During such abatement period, Tenant shall still be responsible for the payment of all of its other monetary obligations under this Lease. In the event of a material default by Tenant under the terms of this Lease that results in early termination pursuant to the provisions of Article 19 of this Lease, then as a part of the recovery set forth in Article 19 of this Lease, Landlord shall be entitled to the recovery of the monthly Base Rent that was abated under the provisions of this Article 3.

ARTICLE 4

ADDITIONAL RENT

4.1 Additional Rent. In addition to paying the Base Rent specified in Article 3 above, Tenant shall pay as additional rent the sum of the following: (i) Tenant’s Share (as such term is defined below) of the annual Operating Expenses allocated to the Building (pursuant to Section 4.3.4 below); plus (ii) Tenant’s Share of the annual Tax Expenses allocated to the Building (pursuant to Section 4.3.4 below); plus (iii) Tenant’s Share of the annual Utilities Costs allocated to the Building (pursuant to Section 4.3.4 below). Such additional rent, together with any and all other amounts payable by Tenant to Landlord pursuant to the terms of this Lease (including, without limitation, pursuant to Article 6), shall be hereinafter collectively referred to as the “Additional Rent” The Base Rent and Additional Rent are herein collectively referred to as the “Rent.” All amounts due under this Article 4 as Additional Rent shall be payable for the same periods and in the same manner, time and place as the Base Rent. Without limitation on other obligations of Tenant which shall survive the expiration of the Lease Term, the obligations of Tenant to pay the Additional Rent provided for in this Article 4 shall survive the expiration of the Lease Term.

4.2 Definitions. As used in this Article 4, the following terms shall have the meanings hereinafter set forth:

4.2.1 “Calendar Year” shall mean each calendar year in which any portion of the Lease Term falls, through and including the calendar year in which the Lease Term expires.

4.2.2 “Expense Year” shall mean each Calendar Year.

4.2.3 “Operating Expenses” shall mean all expenses, costs and amounts of every kind and nature which Landlord shall pay during any Expense Year because of or in connection with the ownership, management, maintenance, repair, restoration or operation of the Project, including, without limitation, any amounts paid for: (i) the cost of operating, maintaining, repairing, renovating and managing the utility systems, lab systems, central plant, mechanical systems, sanitary and storm drainage systems, any elevator systems (if applicable) and all other “Systems and Equipment” (as defined in Section 4.2.4 of this Lease), and the cost of supplies and equipment and maintenance and

service contracts in connection therewith; (ii) the cost of licenses, certificates, permits and inspections, and the cost of contesting the validity or applicability of any governmental enactments which may affect Operating Expenses, and the costs incurred in connection with implementation and operation (by Landlord or any common area association(s) formed for the Project) of any transportation system management program or similar program; (iii) the cost of insurance carried by Landlord, in such amounts as Landlord may reasonably determine or as may be required by any mortgagees of any mortgage or the lessor of any ground lease affecting the Project; (iv) the cost of landscaping, relamping, supplies, tools, equipment and materials, and all reasonable fees, charges and other costs (including consulting fees, legal fees and accounting fees) incurred in connection with the management, operation, repair and maintenance of the Project; (v) any equipment rental agreements or management agreements (including the cost of any management fee, which fee shall not exceed four percent (4%) of the gross receipts of the Building, and the fair rental value of any office space provided thereunder); (vi) wages, salaries and other compensation and benefits of all persons engaged in the operation, management, maintenance or security of the Project, and employer’s Social Security taxes, unemployment taxes or insurance, and any other taxes which may be levied on such wages, salaries, compensation and benefits; (vii) reasonable and customary payments under any easement, license, operating agreement, declaration, restrictive covenant, underlying or ground lease (excluding rent), or instrument pertaining to the sharing of costs by the Project (including but not limited to, the CC&Rs described in Article 5 hereof); (viii) the cost of janitorial service, trash removal (provided, however, Operating Expenses shall not include the cost of janitorial services and trash removal services provided to the Premises or the premises of other tenants of the Building and/or the Project or the cost of replacing light bulbs, lamps, starters and ballasts for lighting fixtures in the Premises and the premises of other tenants in the Building and/or the Project to the extent such services are directly provided and paid for by Tenant pursuant to Section 6.6 below), alarm and security service, if any, window cleaning, replacement of wall and floor coverings, ceiling tiles and fixtures in lobbies, corridors, restrooms and other common or public areas or facilities, maintenance and replacement of curbs and walkways, repair to roofs and re-roofing; (ix) amortization over the useful life (including interest on the unamortized cost) of the cost of acquiring or the rental expense of personal property used in the maintenance, operation and repair of the Project; (x) the cost of any capital improvements or other costs (I) which are intended as a labor-saving device or to effect other economies in the operation or maintenance of the Project, (II) made to the Project or any portion thereof after the Lease Commencement Date that are required under any governmental law or regulation, or (III) which are Conservation Costs (as defined below) and/or which are reasonably determined by Landlord to be in the best interests of the Project; provided, however, that if any such cost described in (I), (II) or (Ill) above, is a capital expenditure, such cost shall be amortized on a straight-line basis over the useful life (including interest on the unamortized cost) of such item or such longer period as may be reasonable and customary; and (xi) the costs and expenses of complying with, or participating in, conservation, recycling, sustainability, energy efficiency, waste reduction or other programs or practices implemented or enacted from time to time at the Building and/or Project, including, without limitation, in connection with any LEED (Leadership in Energy and Environmental Design) rating or compliance system or program, including that currently coordinated through the U.S. Green Building Council or Energy Star rating and/or compliance system or program (collectively, “Conservation Costs”). If any of (x) the Building, (y) the Other Existing Buildings (but only during the period of time the same are included by Landlord within the Project) and (z) any additional buildings are added to the Project pursuant to Section 1.1.3 above (but only during the period of time after such additional buildings have been fully constructed and ready for occupancy and are included by Landlord within the Project) are less than ninety-five percent (95%) occupied during all or a portion of any Expense Year, Landlord shall make an appropriate adjustment to the variable components of Operating Expenses for such year or applicable portion thereof, employing sound accounting and management principles, to determine the amount of Operating Expenses that would have been paid had the Building, such Other Existing Buildings and such additional buildings (if any) been ninety-five percent (95%) occupied; and the amount so determined shall be deemed to have been the amount of Operating Expenses for such year, or applicable portion thereof.

Subject to the provisions of Section 4.3.4 below, Landlord shall have the right, from time to time, to equitably allocate some or all of the Operating Expenses (and/or Tax Expenses and Utilities Costs) between the Building and the Other Existing Buildings and/or among different tenants of the Project and/or among different buildings of the Project as and when such different buildings are constructed and added to (and/or excluded from) the Project or otherwise (the “Cost Pools”), Such Cost Pools may also include an allocation of certain Operating Expenses (and/or Tax Expenses and Utilities Costs) within or under covenants, conditions and restrictions affecting the Project, In addition, Landlord shall have the right from time to time, in its reasonable discretion, to include or exclude existing or future buildings in the Project for purposes of determining Operating Expenses, Tax Expenses and Utilities Costs and/or the provision of various services and amenities thereto, including allocation of Operating Expenses, Tax Expenses and Utilities Costs in any such Cost Pools.

Notwithstanding the foregoing, Operating Expenses shall not, however, include: (A) costs of leasing commissions, attorneys’ fees and other costs and expenses incurred in connection with negotiations or disputes with present or prospective tenants or other occupants of the Project; (B) costs (including permit, license and inspection costs) incurred in renovating or otherwise improving, decorating or redecorating rentable space for other tenants or vacant rentable space; (C) costs incurred due to the violation by Landlord of the terms and conditions of any lease of space in the Project; (D) costs of overhead or profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for services in or in connection with the Project to the extent the same exceeds the costs of overhead and profit increment included in the costs of such services which could be obtained from third parties on a competitive basis; (E) except as otherwise specifically provided in this Section 4.2.3, costs of interest on debt or amortization on any mortgages, and rent payable under any ground lease of the Project; (F) Utilities Costs; and (G) Tax Expenses.

4.2.4 “Systems and Equipment” shall mean any plant (including any central plant), machinery, transformers, duct work, cable, wires, and other equipment, facilities, and systems designed to supply heat, ventilation, air conditioning and humidity or any other services or utilities, or comprising or serving as any component or portion of the electrical, gas, steam, plumbing, sprinkler, communications, alarm, lab, security, or fire/life safety systems or

equipment, or any other mechanical, electrical, electronic, computer or other systems or equipment which serve the Building and/or any other building in the Project in whole or in part.

4.2.5 “Tax Expenses” shall mean all federal, state, county, or local governmental or municipal taxes, fees, assessments, charges or other impositions of every kind and nature, whether general, special, ordinary or extraordinary, (including, without limitation, real estate taxes, general and special assessments, transit assessments, fees and taxes, child care subsidies, fees and/or assessments, job training subsidies, fees and/or assessments, open space fees and/or assessments, housing subsidies and/or housing fund fees or assessments, public art fees and/or assessments, leasehold taxes or taxes based upon the receipt of rent, including gross receipts or sales taxes applicable to the receipt of rent, personal property taxes imposed upon the fixtures, machinery, equipment, apparatus, systems and equipment, appurtenances, furniture and other personal property used in connection with the Project), which Landlord shall pay during any Expense Year because of or in connection with the ownership, leasing and operation of the Project or Landlord’s interest therein. For purposes of this Lease, Tenant’s Share of the annual Tax Expenses shall be calculated as if (i) the tenant improvements in the Building, the Other Existing Buildings and any additional buildings added to the Project pursuant to Section 1.1.3 above (but only during the period of time that such Other Existing Buildings and additional buildings are included by Landlord within the Project) were fully constructed, and (ii) the Project, the Building, such Other Existing Buildings and such additional buildings (if any) and all tenant improvements therein were fully assessed for real estate tax purposes.

4.2.5.1 Tax Expenses shall include, without limitation:

(i) Any tax on Landlord’s rent, right to rent or other income from the Project or as against Landlord’s business of leasing any of the Project;

(ii) Any assessment, tax, fee, levy or charge in addition to, or in substitution, partially or totally, of any assessment, tax, fee, levy or charge previously included within the definition of real property tax, it being acknowledged by Tenant and Landlord that Proposition 13 was adopted by the voters of the State of California in the June 1978 election (“Proposition 13”) and that assessments, taxes, fees, levies and charges may be imposed by governmental agencies for such services as fire protection, street, sidewalk and road maintenance, refuse removal and for other governmental services formerly provided without charge to property owners or occupants. It is the intention of Tenant and Landlord that all such new and increased assessments, taxes, fees, levies, and charges and all similar assessments, taxes, fees, levies and charges be included within the definition of Tax Expenses for purposes of this Lease;

(iii) Any assessment. tax, fee, levy, or charge allocable to or measured by the area of the Premises or the rent payable hereunder, including, without limitation, any gross income tax upon or with respect to the possession, leasing, operating, management, maintenance, alteration, repair, use or occupancy by Tenant of the Premises, or any portion thereof;

(iv) Any assessment, tax, fee, levy or charge, upon this transaction or any document to which Tenant is a party, creating or transferring an interest or an estate in the Premises; and

(v) Any reasonable expenses incurred by Landlord in reasonably attempting to protest, reduce or minimize Tax Expenses.

4.2.5.2 Notwithstanding anything to the contrary contained in this Section 4.2.5, there shall be excluded from Tax Expenses (i) all excess profits taxes, franchise taxes, gift taxes, capital stock taxes, inheritance and succession taxes, estate taxes, federal and state net income taxes, and other taxes to the extent applicable to Landlord’s net income (as opposed to rents, receipts or income attributable to operations at the Project), (ii) any items included as Operating Expenses, and (iii) any items paid by Tenant under Section 4.4 below.

4.2.6 “Tenant’s Share” shall mean the percentage set forth in Section 9 of the Summary. Tenant’s Share was calculated by dividing the number of rentable square feet of the Premises by the total rentable square feet in the Building (as set forth in Section 9 of the Summary), and stating such amount as a percentage. Landlord shall have the right from time to time to redetermine the rentable square feet of the Building, and Tenant’s Share shall be appropriately adjusted to reflect any such redetermination. If Tenant’s Share is adjusted pursuant to the foregoing, as to the Expense Year in which such adjustment occurs, Tenant’s Share for such year shall be determined on the basis of the number of days during such Expense Year that each such Tenant’s Share was in effect.

4.2.7 “Utilities Costs” shall mean all actual charges for utilities for the Building and the Project (including utilities for the Other Existing Buildings and additional buildings, if any, added to the Project during the period of time the same are included by Landlord within the Project) which Landlord shall pay during any Expense Year, including, but not limited to, the costs of water, sewer, gas and electricity, and the costs of HVAC and other utilities, including any lab utilities and central plant utilities (but excluding those charges for which tenants directly reimburse Landlord or otherwise pay directly to the utility company) as well as related fees, assessments, measurement meters and devices and surcharges. Utilities Costs shall be calculated assuming the Building (and, during the period of time when such buildings are included by Landlord within the Project, the Other Existing Buildings and any additional buildings, if any, added to the Project) are at least ninety-five percent (95%) occupied. If, during all or any part of any Expense Year, Landlord shall not provide any utilities (the cost of which, if provided by Landlord, would be included in Utilities Costs) to a tenant (including Tenant) who has undertaken to provide the same instead of Landlord, Utilities Costs shall be deemed to be increased by an amount equal to the additional Utilities Costs which would reasonably have been incurred during

such period by Landlord if Landlord had at its own expense provided such utilities to such tenant. Utilities Costs shall include any costs of utilities which are allocated to the Project under any declaration, restrictive covenant, or other instrument pertaining to the sharing of costs by the Project or any portion thereof, including any covenants, conditions or restrictions now or hereafter recorded against or affecting the Project.

4.3 Calculation and Payment of Additional Rent.

4.3.1 Payment of Operating Expenses, Tax Expenses and Utilities Costs. For each Expense Year ending or commencing within the Lease Term, Tenant shall pay to Landlord. as Additional Rent, the following, which payment shall be made in the manner set forth in Section 4.3.2 below: (i) Tenant’s Share of Operating Expenses allocated to the Building pursuant to Section 4.3.4 below; plus (ii) Tenant’s Share of Tax Expenses allocated to the Building pursuant to Section 4.3.4 below; plus (iii) Tenant’s Share of Utilities Costs allocated to the Building pursuant to Section 4.3.4 below.

4.3.2 Statement of Actual Operating Expenses, Tax Expenses and Utilities Costs and Payment by Tenant. Landlord shall give to Tenant on or before the first (1^st) day of June following the end of each Expense Year (or as soon thereafter as reasonably possible) a statement (the “Statement”) which shall state the Operating Expenses, Tax Expenses and Utilities Costs incurred or accrued for such preceding Expense Year that are allocated to the Building pursuant to Section 4.3.4 below, and which shall indicate therein Tenant’s Share thereof. Within sixty (60) days after Tenant’s receipt of the Statement for each Expense Year ending during the Lease Term, Tenant shall pay to Landlord the full amount of the Tenant’s Share of Operating Expenses, Tax Expenses and Utilities Costs for such Expense Year, less the amounts, if any, paid during such Expense Year as the Estimated Expenses as defined in and pursuant to Section 4.3.3 below. If any Statement reflects that Tenant has overpaid Tenant’s Share of Operating Expenses and/or Tenant’s Share of Tax Expenses and/or Tenant’s Share of Utilities Costs for such Expense Year, then Landlord shall remit such overpayment to Tenant within thirty (30) days after such applicable Statement is delivered to Tenant. Even though the Lease Term has expired and Tenant has vacated the Premises, if the Statement for the Expense Year in which this Lease terminates reflects that Tenant has overpaid and/or underpaid Tenant’s Share of the Operating Expenses and/or Tenant’s Share of Tax Expenses and/or Tenant’s Share of Utilities Costs for such Expense Year, then within thirty (30) days after Landlord’s delivery of such Statement to Tenant, Landlord shall refund to Tenant any such overpayment, or Tenant shall pay to Landlord any such underpayment, as the case may be. The provisions of this Section 4.3.2 shall survive the expiration or earlier termination of the Lease Term. Notwithstanding the foregoing to the contrary, Tenant shall not be responsible for Tenant’s Share of any Direct Expenses attributable to any Expense Year which was first billed to Tenant more than two (2) Calendar Years after the date (the “Cutoff Date”) which is the earlier of (i) the expiration of the applicable Expense Year or (ii) the Lease Expiration Date, except that Tenant shall be responsible for Tenant’s Share of Direct Expenses levied by any governmental authority or by any public utility company at any time following the applicable Cutoff Date which are attributable to any Expense Year occurring prior to such Cutoff Date, so long as Landlord delivers to Tenant a bill and supplemental Statement for such amounts within two (2) years following Landlord’s receipt of the applicable bill therefor.

4.3.3 Statement of Estimated Operating Expenses, Tax Expenses and Utilities Costs. Landlord shall give Tenant a yearly expense estimate statement (the “Estimate Statement”) which shall set forth Landlord’s reasonable estimate (the “Estimate”) of the total amount of Tenant’s Share of the Operating Expenses, Tax Expenses and Utilities Costs allocated to the Building pursuant to Section 4.3.4 below for the then-current Expense Year shall be, and which shall indicate therein Tenant’s Share thereof (the “Estimated Expenses”). The failure of Landlord to timely furnish the Estimate Statement for any Expense Year shall not preclude Landlord from enforcing its rights to collect any Estimated Expenses under this Article 4 once such Estimate Statement is ultimately provided to Tenant. Following Landlord’s delivery of the Estimate Statement for the then-current Expense Year, Tenant shall pay, with its next installment of Base Rent due, a fraction of the Estimated Expenses for the then-current Expense Year (reduced by any amounts paid pursuant to the last sentence of this Section 4.3.3). Such fraction shall have as its numerator the number of months which have elapsed in such current Expense Year to the month of such payment, both months inclusive, and shall have twelve (12) as its denominator. Until a new Estimate Statement is furnished, Tenant shall pay monthly, with the monthly Base Rent installments, an amount equal to one-twelfth (1/12) of the total Estimated Expenses set forth in the previous Estimate Statement delivered by Landlord to Tenant.

4.3.4 Allocation of Operating Expenses, Tax Expenses and Utilities Costs to Building. The parties acknowledge that the Building is part of a multi-building commercial project consisting of the Building, and the Other Existing Buildings and such other buildings as Landlord (and/or any other owners of Torrey Ridge Science Center) may elect to construct and include as part of the Project from time to time (the Other Existing Buildings and any such other buildings are sometimes referred to herein, collectively, as the “Other Buildings”), and that certain of the costs and expenses incurred in connection with the Project (i.e. the Operating Expenses, Tax Expenses and Utilities Costs) shall be shared among the Building and/or such Other Buildings, while certain other costs and expenses which are solely attributable to the Building and such Other Buildings, as applicable, shall be allocated directly to the Building and the Other Buildings, respectively. Accordingly, as set forth in Sections 4.1 and 4.2 above, Operating Expenses, Tax Expenses and Utilities Costs are determined annually for the Project as a whole, and a portion of the Operating Expenses, Tax Expenses and Utilities Costs, which portion shall be determined by Landlord on an equitable basis, shall be allocated to the Building (as opposed to the tenants of the Other Buildings), and such portion so allocated shall be the amount of Operating Expenses, Tax Expenses and Utilities Costs payable with respect to the Building upon which Tenant’s Share shall be calculated. Such portion of the Operating Expenses, Tax Expenses and Utilities Costs allocated to the Building shall include all Operating Expenses, Tax Expenses and Utilities Costs which are attributable solely to the Building, and an equitable portion of the Operating Expenses, Tax Expenses and Utilities Costs attributable to the Project as a whole. As an example of such allocation with respect to Tax Expenses and Utilities Costs, it is anticipated that Landlord (and/or

any other owners of Torrey Ridge Science Center) may receive separate tax bills which separately assess the improvements component of Tax Expenses for each building in the Project and/or Landlord may receive separate utilities bills from the utilities companies identifying the Utilities Costs for certain of the utilities costs directly incurred by each such building (as measured by separate meters installed for each such building), and such separately assessed Tax Expenses and separately metered Utilities Costs shall be calculated for and allocated separately to each such applicable building. In addition, in the event Landlord (and/or any other owners of Torrey Ridge Science Center) elect to subdivide certain common area portions of the Project such as landscaping, public and private streets, driveways, walkways, courtyards, plazas, transportation facilitation areas and/or accessways into a separate parcel or parcels of land (and/or separately convey all or any of such parcels to a common area association to own, operate and/or maintain same), the Operating Expenses, Tax Expenses and Utilities Costs for such common area parcels of land may be aggregated and then reasonably allocated by Landlord to the Building and such Other Buildings on an equitable basis as Landlord (and/or any applicable covenants, conditions and restrictions for any such common area association) shall provide from time to time.

4.3.5 Cap on Controllable Operating Expenses. Notwithstanding anything to the contrary contained in this Article 4, the aggregate “Controllable Expenses” (as hereinafter defined) included in Operating Expenses in any Expense Year after the first Expense Year shall not increase by more than six percent (6%) on an annual, cumulative basis, over the actual aggregate Controllable Expenses included in Operating Expenses for any preceding Expense Year, but with no such limit on the amount of Controllable Expenses which may be included in the Operating Expenses incurred during the first Expense Year. For purposes of this Section 4.3.5, “Controllable Expenses” shall mean all Operating Expenses except: (i) government-mandated charges with respect to the Building or Real Property, or any part thereof; and (ii) insurance carried by Landlord with respect to the Real Property and/or the operation thereof. The provisions of this Section 4.3.5 do not apply to the Tax Expenses nor Utilities Costs.

4.4 Taxes and Other Charges for Which Tenant is Directly Responsible. Tenant shall reimburse Landlord upon demand for all taxes or assessments required to be paid by Landlord (except to the extent included in Tax Expenses by Landlord), excluding state, local and federal personal or corporate income taxes measured by the net income of Landlord from all sources and estate and inheritance taxes, whether or not now customary or within the contemplation of the parties hereto, when.

4.4.1 said taxes are measured by or reasonably attributable to the cost or value of Tenant’s equipment, furniture, fixtures and other personal property located in the Premises, or by the cost or value of any leasehold improvements made in or to the Premises by or for Tenant, to the extent the cost or value of such leasehold improvements exceeds the cost or value of a building standard build-out as determined by Landlord regardless of whether title to such improvements shall be vested in Tenant or Landlord;

4.4.2 said taxes are assessed upon or with respect to the possession, leasing, operation, management, maintenance, alteration, repair, use or occupancy by Tenant of the Premises or any portion of the Project; or

4.4.3 said taxes are assessed upon this transaction or any document to which Tenant is a party creating or transferring an interest or an estate in the Premises.

4.5 Late Charges. If any installment of Rent or any other sum due from Tenant shall not be received by Landlord or Landlord’s designee by the due date therefor, then Tenant shall pay to Landlord a late charge equal to ten percent (10%) of the amount due plus any attorneys’ fees incurred by Landlord by reason of Tenant’s failure to pay Rent and/or other charges when due hereunder; provided, however, that Landlord will waive the imposition of the late charge for the first late payment of rent in any twelve (12) month period. The late charge shall be deemed Additional Rent and the right to require it shall be in addition to all of Landlord’s other rights and remedies hereunder, at law and/or in equity and shall not be construed as liquidated damages or as limiting Landlord’s remedies in any manner. In addition to the late charge described above, any Rent or other amounts owing hereunder which are not paid by the date that they are due shall thereafter bear interest until paid at a rate (the “Interest Rate”) equal to the lesser of (i) the “Prime Rate” or “Reference Rate” announced from time to time by the Bank of America (or such reasonable comparable national banking institution as selected by Landlord in the event Bank of America ceases to exist or publish a Prime Rate or Reference Rate), plus four percent (4%), or (ii) the highest rate permitted by applicable law.

4.6 Audit Rights. Tenant shall have the right, at Tenant’s cost, after reasonable notice to Landlord, to have Tenant’s authorized employees or agents inspect, at Landlord’s main corporate office during normal business hours, Landlord’s books, records and supporting documents concerning the Operating Expenses, Tax Expenses and Utilities Costs set forth in any Statement delivered by Landlord to Tenant for a particular Expense Year pursuant to Section 4.3.2 above; provided, however, Tenant shall have no right to conduct such inspection or object to or otherwise dispute the amount of the Operating Expenses, Tax Expenses and/or Utilities Costs set forth in any such Statement, unless Tenant notifies Landlord of such inspection objection and dispute, and completes such inspection within twelve (12) months immediately following Landlord’s delivery of the particular Statement in question (the “Review Period”); provided, further, that notwithstanding any such timely inspection, objection, dispute, and/or audit, and as a condition precedent to Tenant’s exercise of its right of inspection, objection, dispute, and/or audit as set forth in this Section 4.6, Tenant shall not be permitted to withhold payment of, and Tenant shall timely pay to Landlord, the full amounts as required by the provisions of this Article 4 in accordance with such Statement. However, such payment may be made under protest pending the outcome of any audit. In connection with any such inspection by Tenant, Landlord and Tenant shall reasonably cooperate with each other so that such inspection can be performed pursuant to a mutually acceptable schedule, in an expeditious manner and without undue interference with Landlord’s operation and management of the Project. If after such inspection and/or request for documentation, Tenant disputes the amount of the Operating Expenses, Tax Expenses and/or Utilities Costs set forth in the Statement, Tenant shall have the right, but not the obligation, within the

Review Period, to cause an independent certified public accountant which is not paid on a contingency basis and which is mutually and reasonably approved by Landlord and Tenant (the “Accountant”) to complete an audit of Landlord’s books and records to determine the proper amount of the Operating Expenses, Tax Expenses and Utilities Costs incurred and amounts payable by Tenant for the Expense Year which is the subject of such Statement. Such audit by the Accountant shall be final and binding upon Landlord and Tenant. If Landlord and Tenant cannot mutually agree as to the identity of the Accountant within thirty (30) days after Tenant notifies Landlord that Tenant desires an audit to be performed, then the Accountant shall be one of the “Big 4” accounting firms selected by Landlord, which is not paid on a contingency basis. If such audit reveals that Landlord has over-charged Tenant, then within thirty (30) days after the results of such audit are made available to Landlord, Landlord shall reimburse to Tenant the amount of such over-charge. If the audit reveals that the Tenant was under-charged, then within thirty (30) days after the results of such audit are made available to Tenant, Tenant shall reimburse to Landlord the amount of such under-charge. Tenant agrees to pay the cost of such audit unless it is subsequently determined that Landlord’s original Statement which was the subject of such audit was in error to Tenant’s disadvantage by five percent (5%) or more of the total Operating Expenses, Tax Expenses and/or Utilities Costs which was the subject of such audit. The payment by Tenant of any amounts pursuant to this Article 4 shall not preclude Tenant from questioning the correctness of any Statement provided by Landlord at any time during the Review Period, but the failure of Tenant to object thereto, conduct and complete its inspection and have the Accountant conduct and complete the audit as described above prior to the expiration of the Review Period shall be conclusively deemed Tenant’s approval of the Statement in question and the amount of Operating Expenses. Tax Expenses and Utilities Costs shown thereon. In connection with any inspection and/or audit conducted by Tenant pursuant to this Section 4.6, Tenant agrees to keep, and to cause all of Tenant’s employees and consultants and the Accountant to keep, all of Landlord’s books and records and the audit, and all information pertaining thereto and the results thereof, strictly confidential, and in connection therewith, Tenant shall cause such employees, consultants and the Accountant to execute such reasonable confidentiality agreements as Landlord may require prior to conducting any such inspections and/or audits.

ARTICLE 5

USE OF PREMISES: HAZARDOUS MATERIALS; ODORS AND EXHAUST

5.1 Use. Tenant shall use the Premises solely for laboratory and office purposes, all to the extent consistent with the character of the Building as a first-class biotechnology building, and Tenant shall not use or permit the Premises to be used for any other purpose or purposes whatsoever. Tenant shall not use, or suffer or permit any person or persons to use, the Premises or any part thereof for any use or purpose contrary to the provisions of Exhibit D. attached hereto, or in violation of the laws of the United States of America, the state in which the Project is located, or the ordinances, regulations or requirements of the local municipal or county governing body or other lawful authorities having jurisdiction over the Project. Tenant shall comply with the Rules and Regulations and all recorded covenants, conditions, and restrictions, and the provisions of all ground or underlying leases. now or hereafter affecting the Project, including but not limited to, (i) that certain Declaration of Covenants, Conditions and Restrictions recorded August 28, 1991, as Instrument No. 1991-0440869 in the San Diego County Official Records, and (ii) that certain Declaration of Covenants, Conditions, and Restrictions for Torrey Pines Science Center [Unit 2] recorded on June 27, 1994, as Instrument No. 1994-0405385 in the San Diego County Official Records (collectively, the existing “CC&Rs”), as the same may be amended, amended and restated, supplemented or otherwise modified from time to time; provided that any such Rules and Regulations. CC&Rs and amendments, restatements, supplements or modifications thereto do not materially modify Tenant’s rights or obligations hereunder.

5.2 Hazardous Materials.

5.2.1 Definitions: As used in this Lease, the following terms have the following meanings:

(a) “Environmental Law” means any past, present or future federal, state or local statutory or common law, or any regulation, ordinance, code, plan, order, permit, grant, franchise, concession, restriction or agreement issued, entered, promulgated or approved thereunder, relating to (a) the environment, human health or safety, including, without limitation, emissions, discharges, releases or threatened releases of Hazardous Materials (as defined below) into the environment (including, without limitation, air, surface water, groundwater or land), or (b) the manufacture, generation, refining, processing, distribution, use, sale, treatment, receipt, storage, disposal, transport, arranging for transport, or handling of Hazardous Materials.

(b) “Environmental Permits” mean collectively, any and all permits, consents, licenses, approvals and registrations of any nature at any time required pursuant to, or in order to comply with, any Environmental Law or otherwise desired by Landlord including, but not limited to, any Spill Control Countermeasure Plan and any Hazardous Materials Management Plan.

(c) “Hazardous Materials” shall mean and include any hazardous or toxic materials, substances or wastes as now or hereafter designated or regulated under any Environmental Law, including, without limitation, asbestos, petroleum, petroleum hydrocarbons and petroleum based products, urea formaldehyde foam insulation, polychlorinated biphenyls (“PCBs”), Freon and other chlorofluorocarbons, “biohazardous waste,” “medical waste,” “infectious agent”, “mixed waste” or other waste under California Health and Safety Code §§ 117600 et, seq.

(d) “Release” shall mean with respect to any Hazardous Materials, any release, deposit, discharge, emission, leaking, pumping, leaching, spilling, seeping, migrating, injecting, pumping, pouring, emptying, escaping, dumping, disposing or other movement of Hazardous Materials.

5.2.2 Tenant’s Obligations – Environmental Permits. Tenant will (i) obtain and maintain in full force and effect all Environmental Permits that may be required from time to time under any Environmental Laws applicable to Tenant or the Premises and (ii) be and remain in compliance with all terms and conditions of all such Environmental Permits and with all other limitations, restrictions, conditions, standards, prohibitions, requirements, obligations, schedules and timetables contained in all Environmental Laws applicable to Tenant or the Premises. On or before the date Tenant commences business operations in the Premises and thereafter from time to time upon Landlord’s written request, Tenant shall provide to Landlord all Environmental Permits pertaining to the Premises and Tenant’s business operations therein.

5.2.3 Tenant’s Obligations – Hazardous Materials. Except as expressly permitted herein, Tenant agrees not to cause or permit any Hazardous Materials to be brought upon, stored, used, handled, generated, released or disposed of on, in, under or about the Premises. or any other portion of the Property by Tenant, its agents, employees, subtenants, assignees, licensees, contractors or invitees (collectively, “Tenant’s Parties”), without the prior written consent of Landlord, which consent Landlord may withhold in its sole and absolute discretion. Landlord hereby acknowledges and agrees that it is not the intent of this Section 5.2 to prohibit Tenant from operating its business for the uses permitted hereunder and that Tenant shall be permitted to operate its business according to the custom of Tenant’s industry so long as the use or presence of Hazardous Materials is strictly and properly monitored in accordance with applicable Environmental Laws. As a material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees to deliver to Landlord prior to the Lease Commencement Date a list identifying each type of Hazardous Material to be present at the Premises and setting forth any and all governmental approvals or permits required in connection with the presence of such Hazardous Material at the Premises (the “Hazardous Materials List”). Tenant shall deliver to Landlord an updated Hazardous Materials List on or prior to each annual anniversary of the Lease Commencement Date and shall also deliver an updated Hazardous Materials List before any new Hazardous Materials are brought to the Premises. Tenant shall deliver to Landlord true and correct copies of the following documents (hereinafter referred to as the “Documents”) relating to the handling, storage, disposal and emission of Hazardous Materials prior to the Lease Commencement Date or, if unavailable at that time, concurrently with the receipt from or submission to any Governmental Authority: permits; approvals; reports and correspondence; storage and management plans; notices of violations of applicable Environmental Laws; plans relating to the installation of any storage tanks to be installed in, on, under or about the Premises (provided that installation of storage tanks shall only be permitted after Landlord has given Tenant its written consent to do so, which consent Landlord may withhold in its sole and absolute discretion); and all closure plans or any other documents required by any and all governmental authorities for any storage tanks installed in, on, under or about the Premises for the closure of any such storage tanks. Tenant shall not be required, however, to provide Landlord with any portion of the Documents containing information of a proprietary nature, which Documents, in and of themselves, do not contain a reference to any Hazardous Materials or activities related to Hazardous Materials. Upon the expiration or earlier termination of this Lease, Tenant agrees to promptly remove from the Premises, the Building and the Project, at its sole cost and expense, any and all Hazardous Materials, including any equipment or systems containing Hazardous Materials which are installed, brought upon, stored, used, generated or released upon, in, under or about the Premises, the Building and/or the Project or any portion thereof by Tenant or any of Tenant’s Parties during the Term of this Lease.

5.2.4 Landlord’s Right to Conduct Environmental Assessment. At any time during the Lease Term, Landlord shall have the right to conduct an environmental assessment of the Premises (as well as any other areas in, on or about the Project that Landlord reasonably believes may have been affected adversely by Tenant’s use of the Premises (collectively, the “Affected Areas”) in order to confirm that the Premises and the Affected Areas do not contain any Hazardous Materials in violation of applicable Environmental Laws or under conditions constituting or likely to constitute a Release of Hazardous Materials. Such environmental assessment shall be a so-called “Phase I” assessment or such other level of investigation which shall be the standard of diligence in the purchase or lease of similar property at the time, together with any additional investigation and report which would customarily follow any discovery contained in such initial Phase 1 assessment (including, but not limited to, any so-called “Phase II” report). Such right to conduct such environmental assessment shall not be exercised more than once per calendar year unless Tenant is in default under this Section 5.2 (beyond the expiration of all applicable notice and cure periods). Tenant shall reimburse Landlord for the cost of all environmental assessments of Affected Areas that indicate a conclusive and proximate connection between Tenant’s use and occupancy of the Premises and the presence of Hazardous Materials in violation of applicable Environmental Laws that did not exist on the Premises prior to Tenant’s possession thereof,

5.2.5 Tenant’s Obligations to perform Corrective Action. If the data from any environmental assessment authorized and undertaken by Landlord pursuant to Section 5.2.4 indicates that (i) there has been a Release. threatened Release or other conditions with respect to Hazardous Materials on, under or emanating from the Premises and the Affected Areas in violation of applicable Environmental Laws caused by Tenant (“Tenant Release”), and (ii) such Tenant Release requires any investigation and/or active response action, including without limitation active or passive remediation and monitoring or any combination of these activities (“Corrective Action”), then Tenant shall immediately undertake Corrective Action with respect to contamination if, and to the extent, required by the governmental authority exercising jurisdiction over the matter. Any Corrective Action performed by Tenant will be performed with Landlord’s prior written approval and in accordance with applicable Environmental Laws, at Tenant’s sole cost and expense and by an environmental consulting firm (reasonably acceptable to Landlord) Tenant may perform the Corrective Action before or after the expiration or earlier termination of this Lease, to the extent permitted by governmental agencies with jurisdiction over the Premises, the Building and the Project (provided, however, that any Corrective Action performed after the expiration or earlier termination of this Lease shall be subject to the access fee provisions set forth below). If Tenant undertakes or continues Corrective Action after the expiration or earlier termination of this Lease, Landlord, upon being given forty-eight (48) hours’ advance notice, may, in Landlord’s sole discretion, elect (without limiting any of the Landlord’s other rights and remedies under this Lease, at law and/or in equity), to provide, at an “access fee” equal to one

hundred fifty percent (150%) of the Monthly Rent in effect for the last month immediately preceding the expiration or earlier termination of this Lease, plus all other sums due under this Lease, access to the Premises, the Building and the Project as may be requested by Tenant and its consultant to accomplish the Corrective Action. Tenant or its consultant may install, inspect, maintain, replace and operate remediation equipment and conduct the Corrective Action as it considers necessary, subject to Landlord’s reasonable approval. Tenant and Landlord shall, in good faith, cooperate with each other with respect to any Corrective Action after the expiration or earlier termination of this Lease so as not to interfere unreasonably with the conduct of Landlord’s or any third party’s business on the Premises, the Building and the Project. Landlord shall provide access until Tenant delivers evidence reasonably satisfactory to Landlord that Tenant’s Corrective Action activities on the Premises and the Affected Areas satisfy applicable Environmental Laws. It shall be reasonable for Landlord to require Tenant to deliver a “no further action” letter or substantially similar document from the applicable governmental agency. Landlord shall continue to provide access and Tenant shall continue to pay the access fee until such time as Landlord is able to use the Premises and the Affected Areas for such purposes as Landlord reasonably desires, Landlord’s “reasonableness” as used in the immediately preceding sentence shall be based on (i) the zoning of the Premises as of the date in question, and (ii) the logical uses of the Premises as of the date in question. If Landlord desires to situate a tenant in the Premises, the Building and the Project and remediation of the Premises and the Affected Areas is ongoing, Landlord shall be deemed to be unable to use the Premises, the Building and the Project in the way Landlord reasonably desires and Tenant shall be obligated to continue paying the access fee until such time as Landlord is able to situate said tenant in the Premises, the Building and/or the Project. Tenant agrees, to the extent applicable and reasonably practicable, to install, at Tenant’s sole cost and expense, screening around its remediation equipment so as to protect the aesthetic appeal of the Premises, the Building and the Project. Tenant also agrees to use reasonable efforts to locate its remediation and/or monitoring equipment, if any (subject to the requirements of Tenant’s consultant and governmental agencies with jurisdiction over the Premises, the Building and the Project) in a location which will allow Landlord, to the extent reasonably practicable, the ability to lease the Premises, the Building and the Project to a subsequent user. Any Hazardous Materials contamination on, in, under or about the Premises and the Affected Areas at the expiration or earlier termination of this Lease which is not disclosed by Tenant prior to the effective date of this Lease shall be presumed to have arisen in connection with Tenant’s environmental activities under the Lease. Notwithstanding anything above to the contrary, if any clean-up or monitoring procedure is required by any applicable governmental authorities in, on, under or about the Premises and the Affected Areas during the Lease Term as a consequence of any Hazardous Materials contamination and the procedure for clean-up is not completed (to the satisfaction of Landlord and/or the governmental authorities) prior to the expiration or earlier termination of this Lease then, at Landlord’s election, (i) this Lease shall be deemed renewed for a term commencing on the expiration or earlier termination of this Lease and ending on the date the clean-up procedure is anticipated to be completed; or (ii) Tenant shall be deemed to have impermissibly held over (and Article 16 of this Lease shall apply with full force and effect) and Landlord shall be entitled to all damages directly or indirectly incurred, including, without limitation, damages occasioned by the inability to relet the Premises and/or any other portion of the Building or a reduction of the fair market or rental value of the Premises and/or the Building.

5.2.6 Tenant’s Duty to Notify Landlord Regarding Releases. Tenant agrees to promptly notify Landlord of any Release of Hazardous Materials in the Premises, the Building or any other portion of the Project which Tenant becomes aware of during the Term of this Lease, whether caused by Tenant or any other persons or entities. In the event of any release of Hazardous Materials caused or permitted by Tenant or any of Tenant’s Parties, Landlord shall have the right, but not the obligation, to cause Tenant, at Tenant’s sole cost and expense, to immediately take all reasonable steps Landlord deems necessary or appropriate to remediate such Release and prevent any similar future release to the satisfaction of Landlord and Landlord’s mortgagee(s). Tenant will, upon the request of Landlord at any time during which Landlord has reason to believe that Tenant is not in compliance with this Section 5.2 (and in any event no earlier than sixty (60) days and no later than thirty (30) days prior to the expiration of this Lease), cause to be performed an environmental audit of the Premises at Tenant’s expense by an established environmental consulting firm reasonably acceptable to Landlord. In the event the audit provides that Corrective Action is required then Tenant shall immediately perform the same at its sole cost and expense.

5.2.7 Tenant’s Environmental Indemnity. To the fullest extent permitted by law, Tenant agrees to promptly indemnify, protect, defend and hold harmless Landlord and Landlord’s members, partners, subpartners, independent contractors, officers, directors, shareholders, employees, agents, successors and assigns (collectively, “Landlord Parties”) from and against any and all claims, damages, judgments, suits, causes of action, losses, liabilities, penalties, fines, expenses and costs (including, without limitation, clean-up, removal, remediation and restoration costs, sums paid in settlement of claims, attorneys’ fees, consultant fees and expert fees and court costs) which arise or result from the presence of Hazardous Materials on, in, under or about the Premises, the Building or any other portion of the Property and which are caused or permitted by Tenant or any of Tenant’s Parties during the Term of this Lease, including arising from or caused in whole or in part, directly or indirectly, by (i) the presence in, on, under or about the Premises and the Affected Areas, of any Hazardous Materials; (ii) Tenant’s or other user’s actual, proposed or threatened use, treatment, storage, transportation, holding, existence, disposition, manufacturing, control, management, abatement, removal, handling, transfer, generation or Release (past, present or threatened) of Hazardous Materials to, in, on, under, about or from the Premises and the Affected Areas; (iii) any past, present or threatened non-compliance or violations of any Environmental Laws in connection with Tenant and/or the Premises and/or the Affected Areas, (iv) personal injury claims (v) the payment of any environmental liens, or the disposition, recording, or filing or threatened disposition, recording or filing of any environmental lien encumbering or otherwise affecting the Premises and/or the Affected Areas, (vi) diminution in the value of the Premises and/or the Project, (vii) damages for the loss or restriction of use of the Premises and/or the Project, including prospective rent, lost profits and business opportunities, (viii) sums paid in settlement of claims, (ix) reasonable attorneys’ fees, consulting fees and expert fees, (x) the cost of any investigation of site conditions, and (xi) the cost of any repair, clean-up or remediation ordered by any governmental or quasi-governmental agency or body or otherwise deemed necessary in Landlord’s reasonable judgment. Tenant’s obligations

hereunder shall include, without limitation, and whether foreseeable or unforeseeable, all costs of any required or necessary repair, cleanup or detoxification or decontamination of the Premises, the Building and/or the Project, or the preparation and implementation of any closure, remedial action or other required plans in connection therewith. For purposes of the indemnity provisions in this Section 5.2, any acts or omissions of Tenant and/or Tenant’s Parties or others acting for or on behalf of Tenant (whether or not they are negligent, intentional, willful or unlawful) shall be strictly attributable to Tenant. The provisions of this Section 5.2.7 will survive the expiration or earlier termination of this Lease.

5.2.8 Tenant warrants, represents, acknowledges and agrees that Tenant has performed all investigations appropriate under the circumstances to determine whether any violations of Hazardous Materials Laws currently exist. Tenant shall have no right or remedy against Landlord with respect to any such violation and Tenant hereby releases, waives and forever discharges Landlord and the Landlord Parties from any and all claims, demands and causes of action, whether known or unknown to Tenant, which Tenant may now or hereafter have arising out of connected with or incidental to the existence of any Hazardous Material now or hereafter on or about the Premises or the Project. Tenant is aware of the provisions of Section 1542 of the California Civil Code which provides as follows:

“A GENERAL RELEASE DOES NOT EXTEND TO CLAIMS WHICH THE CREDITOR DOES NOT KNOW OR SUSPECT TO EXIST IN HIS OR HER FAVOR AT THE TIME OF EXECUTING THE RELEASE WHICH IF KNOWN BY HIM OR HER MUST HAVE MATERIALLY AFFECTED HIS OR HER SETTLEMENT WITH THE DEBTOR.”

and, after consultation with counsel concerning the meaning and effect of such waiver, Tenant specifically waives the benefit of the provisions of Section 1542 of the California Civil Code.

5.2.9 Landlord’s Termination Option for Certain Environmental Problems. If Hazardous Materials are present at the Premises that are required by Environmental Law to be remediated and Tenant is not responsible therefor pursuant to Section 5.2, Landlord may, at its option, either (i) remediate such Hazardous Materials, in which event this Lease shall continue in full force and effect or if the estimated cost to remediate such Hazardous Materials exceeds One Million Five Hundred Thousand Dollars ($1,500,000.00) (the “Threshold Amount”), give written notice to Tenant, within thirty (30) days after receipt by Landlord of knowledge of the existence of such Hazardous Materials, of Landlord’s desire to terminate this Lease as of the date ninety (90) days following the date of such notice. In the event Landlord elects to give such a termination notice. Tenant may, within ten (10) days thereafter, give written notice to Landlord of Tenant’s commitment to pay the amount by which the cost of the remediation of such Hazardous Materials exceeds the Threshold Amount, Tenant shall provide Landlord with such funds or satisfactory assurance thereof within thirty (30) days following such commitment. In such event, this Lease shall continue in full force and effect, and Landlord shall proceed to make such remediation as soon as reasonably possible after the required funds are available. If Tenant does not give such notice and provide the required funds or assurance thereof within the time provided, this Lease shall terminate as the date specified in Landlords termination notice.

5.3 Odors and Exhaust. Tenant acknowledges that Landlord would not enter into this Lease with Tenant unless Tenant assured Landlord that under no circumstances will the Premises be damaged by any exhaust from Tenant’s operations. Landlord and Tenant therefore agree as follows:

5.3.1 Tenant shall not cause or permit (or conduct any activities that would cause) any release of any odors or fumes of any kind from the Premises that would be offensive or objectionable.

5.3.2 If the Building has a ventilation system that, in Landlord’s judgment, is adequate, suitable, and appropriate to vent the Premises in a manner that does not release odors affecting any indoor or outdoor part of the Premises, Tenant shall vent the Premises through such system. If Landlord at any time determines that any existing ventilation system is inadequate, or if no ventilation system exists, Tenant shall in compliance with applicable laws vent all fumes and odors from the Premises (and remove odors from Tenant’s exhaust stream) as Landlord requires. The placement and configuration of all ventilation exhaust pipes, louvers and other equipment shall be subject to Landlord’s approval. Tenant acknowledges Landlord’s legitimate desire to maintain the Premises (indoor and outdoor areas) in an odor-free manner, and Landlord may require Tenant to abate and remove all odors in a manner that goes beyond the requirements of Applicable Laws.

5.3.3 Tenant shall, at Tenant’s sole cost and expense, provide odor eliminators and other devices (such as filters, air cleaners, scrubbers and whatever other equipment may in Landlord’s judgment be necessary or appropriate from time to time) to completely remove, eliminate and abate any odors, fumes or other substances in Tenant’s exhaust stream that, in Landlord’s judgment, emanate from the Premises. Any work Tenant performs under this Section 5.3 shall constitute Alterations,

5.3.4 Tenant’s responsibility to remove, eliminate and abate odors, fumes and exhaust shall continue throughout the Term.

5.3.5 If Tenant fails to install satisfactory odor control equipment within ten (10) business days after Landlord’s demand made at any time, then Landlord may, without limiting Landlord’s other rights and remedies, require Tenant to cease and suspend any operations in the Premises that, in Landlord’s determination, cause odors, fumes or exhaust.

5.4 Control Areas. At Landlord’s option and discretion, Tenant shall be allowed to utilize up to its pro rata share of the Hazardous Materials inventory within any control area or zone (located within the Premises), as designated by the applicable building code, for chemical use or storage. As used in the preceding sentence, Tenant’s pro rata share of any control areas or zones located within the Premises shall be determined based on the rentable square footage that Tenant leases within the applicable control area or zone. For purposes of example only, if a control area or zone contains 10,000 rentable square feet and 2,000 rentable square feet of a tenant’s premises are located within such control area or zone (while such premises as a whole contains 5,000 rentable square feet), the applicable tenant’s pro rata share of such control area would be 20%,

ARTICLE 6

SERVICES AND UTILITIES

6.1 Standard Tenant Services. Landlord shall provide the following services on all days during the Lease Term, unless otherwise stated below.

6.1.1 Subject to reasonable changes implemented by Landlord and to all governmental rules, regulations and guidelines applicable thereto, Landlord shall, with respect to the office portions of the Premises, provide heating and air conditioning when necessary for normal comfort for normal office use in the Premises from Monday through Friday, during the period from 8:00 a.m. to 6:00 p.m., except for the date of observation of New Year’s Day, Presidents’ Day, Memorial Day, Independence Day. Labor Day, Thanksgiving Day, Christmas Day and other locally or nationally recognized holidays as designated by Landlord (collectively, the “Holidays”). Landlord shall provide heating and air conditioning to the lab portions of the Premises on a 24/7 basis.

6.1.2 Landlord shall provide Building-standard electrical wiring and facilities for use for Building-standard lighting and standard equipment, as determined by Landlord. Landlord shall designate the electricity utility provider from time to time.

6.1.3 Landlord shall provide city water from the regular Building outlets for drinking, lavatory and toilet purposes; Tenant, at Tenant’s sole cost, shall be responsible for the installation of any required RO/DI water system in the Premises.

6.1.4 Landlord shall provide nonexclusive automatic passenger elevator service at all times.

6.2 Overstandard Tenant Use. Tenant shall not, without Landlord’s prior written consent, use heat-generating machines or equipment or lighting other than Building standard lights in the Premises, which may affect the temperature otherwise maintained by the air conditioning system or increase the need for water normally furnished for the Premises by Landlord pursuant to the terms of Section 6.1 above, If such consent is given, Landlord shall have the right to install supplementary air conditioning systems or equipment in the Premises, including supplementary or additional metering devices, and the cost thereof, including the cost of installation, operation and maintenance, increased wear and tear on existing equipment and other similar charges, shall be paid by Tenant to Landlord upon billing by Landlord. If Tenant desires to use heat, ventilation or air conditioning (“HVAC”) during hours other than those for which Landlord is obligated to supply such utilities pursuant to the terms of Section 6.1 of this Lease, (i) Tenant shall give Landlord such prior notice, as Landlord shall from time to time establish as appropriate, of Tenant’s desired use, (ii) Landlord shall supply such utilities to Tenant at such hourly cost to Tenant as Landlord shall from time to time establish, and (iii) Tenant shall pay such cost to Landlord within ten (10) days after billing, as additional rent.

6.3 Separate Metering. Tenant shall be separately submetered for all of the electricity and water and/or (if Landlord elects) other utilities and Tenant shall pay for the cost of all such utilities so separately metered, or which are billed directly to Tenant, within ten (10) business days after Tenant’s receipt of invoice therefor. Tenant acknowledges that Landlord and/or Tenant may from time to time be requested or required to obtain, report and/or disclose certain energy consumption information with regard to the Premises, which may include, without limitation, benchmarking data for the U.S. Environmental Protection Agency’s ENERGY STAR^® Portfolio Manager and information relating to compliance with “green building” initiatives, including, if applicable, the Leadership in Energy & Environmental Design (LEED) certification program. Tenant shall throughout the Term of this Lease, comply with all Federal, State or local laws, rules and regulations relating to consumption of utilities, energy or energy efficiency (as they may be in enacted or in effect from time to time. “Energy Regulations”), and Tenant shall, upon request by Landlord or Landlord’s lender, deliver and/or disclose such information regarding the consumption of utilities at the Premises as may be required to comply with applicable Energy Regulations. Further, Tenant authorizes Landlord to disclose such information and data regarding the Premises as may be requested or required from time to time to comply with Energy Regulations.

6.4 Interruption of Use. Tenant agrees that Landlord shall not be liable for damages, by abatement of Rent or otherwise, for failure to furnish or delay in furnishing any service (including, but not limited to, any central plant or other lab system, telephone and telecommunication services), or for any diminution in the quality or quantity thereof, when such failure or delay or diminution is occasioned, in whole or in part, by repairs, replacements, or improvements, by any strike, lockout or other labor trouble, by inability to secure electricity, gas, water, or other fuel at the Building or Project after reasonable effort to do so, by any accident or casualty whatsoever, by act or default of Tenant or other parties, or by any other cause beyond Landlord’s reasonable control; and such failures or delays or diminution shall never be deemed to constitute an eviction or disturbance of Tenant’s use and possession of the Premises or relieve Tenant from paying Rent or performing any of its obligations under this Lease. Furthermore, Landlord shall not be liable under any

circumstances for a loss of, or injury to, property (including scientific research and any intellectual property) or for injury to, or interference with, Tenant’s business, including, without limitation, loss of profits, however occurring, through or in connection with or incidental to a failure to furnish any of the services or utilities as set forth in this Article 6; provided, however, Tenant shall be afforded the benefit of Tenant’s pro rata share of the Project’s backup/emergency generators Available Power. As used herein, “Available Power” means Tenant’s Share of such Generator’s electricity which is in excess of the power required by Landlord to operate the Project’s and/or Building’s fire/life safety equipment from the Generator (and Tenant shall only be allowed to draw Tenant’s Share of power in excess of Available Power).

6.5 Additional Services. Landlord shall also have the exclusive right, but not the obligation, to provide any additional services which may be required by Tenant, including, without limitation, locksmithing and additional repairs and maintenance, provided that Tenant shall pay to Landlord within ten (10) days after billing and as Additional Rent hereunder, the sum of all costs to Landlord of such additional services plus a five percent (5%) administration fee.

6.6 Janitorial Service. Landlord shall not be obligated to provide any janitorial services to the Premises or replace any light bulbs, lamps, starters and ballasts for lighting fixtures within the Premises. Tenant shall be solely responsible, at Tenant’s sole cost and expense, for (i) performing all janitorial services, trash removal and other cleaning of the Premises, and (ii) replacement of all light bulbs, lamps, starters and ballasts for lighting fixtures within the Premises, all as appropriate to maintain the Premises in a first-class manner consistent with the first-class nature of the Building and Project. Such services to be provided by Tenant shall be performed by contractors and pursuant to service contracts approved by Landlord. Landlord shall have the right to inspect the Premises upon reasonable notice to Tenant and to require Tenant to provide additional cleaning, if necessary. In the event Tenant shall fail to provide any of the services described in this Section 6.6 to be performed by Tenant within five (5) days after notice from Landlord, which notice shall not be required in the event of an emergency, Landlord shall have the right to provide such services and any charge or cost incurred by Landlord in connection therewith shall be deemed Additional Rent due and payable by Tenant upon receipt by Tenant of a written statement of cost from Landlord.

6.7 Building Air Compressor and Vacuum Systems. Tenant, at Tenant’s sole cost, shall have the right to utilize Tenant’s Share of Building compressor air and vacuum systems.

ARTICLE 7

REPAIRS

7.1 Tenant’s Repairs. Subject to Landlord’s repair obligations in Sections 7.2 and 11.1 below, Tenant shall, at Tenant’s own expense, keep the Premises, including all improvements, fixtures and furnishings therein, in good order, repair and condition at all times during the Lease Term, which repair obligations shall include, without limitation, the obligation to promptly and adequately repair all damage to the Premises and replace or repair all damaged or broken fixtures and appurtenances, together with all portions of the HVAC, electrical, mechanical plumbing, life safety and lab systems from the point that such systems solely serves the Premises and all portions of all fume hoods and other exhaust systems (all such systems collectively being referred to as the “Premises Systems”), in a first-class condition. Tenant’s obligations shall include restorations, replacements or renewals, including capital expenditures for restorations, replacements or renewals which will have an expected life beyond the Term, when necessary to keep the Premises and all improvements thereon or a part thereof and the Premises Systems in first-class order, condition and repair and in compliance with all applicable laws. Except as expressly set forth in this Lease, it is intended by the parties hereto that Landlord shall have no obligation, in any manner whatsoever, to repair or maintain the Premises, the improvements located therein or the equipment therein, or the Premises Systems whether structural or nonstructural, all of which obligations are intended to be the expense of Tenant (whether or not such repairs, maintenance or restoration shall have an expected life extending beyond the Term). Tenant’s maintenance of the Premises Systems shall comply with the manufacturers’ recommended operating and maintenance procedures. Tenant shall enter into and pay for maintenance contracts (in forms satisfactory to Landlord in its sole discretion) for the Premises Systems in accordance with the manufacturers’ recommended operating and maintenance procedures. Such maintenance contracts shall be with reputable contractors, satisfactory to Landlord in its sole discretion, who shall have not less than ten (10) years of experience in maintaining such systems in biotechnical facilities. Tenant shall be solely responsible for the cost of all improvements or alterations to the Premises or the Premises Systems required by law. Notwithstanding the foregoing, at Landlord’s option, or if Tenant fails to make such repairs, Landlord may, but need not, make such repairs and replacements, and Tenant shall pay Landlord the cost thereof, including a percentage of the cost thereof (to be uniformly established for the Building) sufficient to reimburse Landlord for all overhead, general conditions, fees and other costs or expenses arising from Landlord’s involvement with such repairs and replacements forthwith upon being billed for same.

7.2 Landlord’s Repairs. Anything contained in Section 7.1 above to the contrary notwithstanding, and subject to Articles 11 and 12 below, Landlord shall, as part of Operating Expenses, repair and maintain the structural portions of the Building, including the basic plumbing, HVAC and electrical systems serving the Building and not located in the Premises; provided, however. to the extent such maintenance and repairs are caused by the act, neglect, fault of or omission of any duty by Tenant, its agents, servants, employees or invitees, Tenant shall pay to Landlord as Additional Rent, the reasonable cost of such maintenance and repairs. Landlord shall not be liable for any failure to make any such repairs, or to perform any maintenance. There shall be no abatement of rent and no liability of Landlord by reason of any injury, to or interference with Tenant’s business arising from the making of any repairs, alterations or improvements in or to any portion of the Project, Building or the Premises or in or to fixtures, appurtenances and equipment therein. Tenant hereby waives and releases its right to make repairs at Landlord’s expense under Sections 1941 and 1942 of the California Civil Code; or under any similar law, statute, or ordinance now or hereafter in effect.

ARTICLE 8

ADDITIONS AND ALTERATIONS

8.1 Landlord’s Consent to Alterations. Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than thirty (30) days prior to the commencement thereof, and which consent shall not be unreasonably withheld by Landlord; provided, however, Landlord may withhold its consent in its sole and absolute discretion with respect to any Alterations which may affect the structural components of the Building or the Systems and Equipment or which can be seen from outside the Premises. Tenant shall pay for all overhead, general conditions, fees and other costs and expenses of the Alterations, and shall pay to Landlord a Landlord supervision fee of ten percent (10%) of the cost of the Alterations. The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.

8.2 Manner of Construction. Landlord may impose, as a condition of its consent to all Alterations or repairs of the Premises, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, materials, mechanics and materialmen approved by Landlord; provided, however, Landlord may impose such requirements as Landlord may determine, in its sole and absolute discretion, with respect to any work affecting the structural components of the Building or Systems and Equipment (including designating specific contractors to perform such work). In any event, all of Tenant’s contractors and subcontractors shall maintain the applicable insurance required in Exhibit E and Tenant shall ensure that Tenant’s contractors and subcontractors comply with the requirements set forth therein. Tenant shall construct such Alterations and perform such repairs in compliance with any and all applicable rules and regulations of any federal, state, county or municipal code or ordinance and pursuant to a valid building permit, issued by the city in which the Building is located, and in conformance with Landlord’s construction rules and regulations. Landlord’s approval of the plans, specifications and working drawings for Tenant’s Alterations shall create no responsibility or liability on the part of Landlord for their completeness, design sufficiency, or compliance with all laws, rules and regulations of governmental agencies or authorities. All work with respect to any Alterations must be done in a good and workmanlike manner and diligently prosecuted to completion to the end that the Premises shall at all times be a complete unit except during the period of work. Tenant shall cause all Alterations to be performed in such manner as not to obstruct access by any person to the Building or Project or the common areas, and as not to obstruct the business of Landlord or other tenants of the Project, or interfere with the labor force working at the Project. If Tenant makes any Alterations, Tenant agrees to carry “Builder’s All Risk” insurance in an amount approved by Landlord covering the construction of such Alterations, and such other insurance as Landlord may require, it being understood and agreed that all of such Alterations shall be insured by Tenant pursuant to Article 10 below immediately upon completion thereof. Landlord may, in its discretion, require Tenant to obtain a lien and completion bond or some alternate form of security satisfactory to Landlord in an amount sufficient to ensure the lien-free completion of such Alterations and naming Landlord as a co-obligee. Upon completion of any Alterations, Tenant shall (i) cause a Notice of Completion to be recorded in the office of the Recorder of the county in which the Project is located in accordance with Section 3093 of the Civil Code of the State of California or any successor statute, (ii) deliver to the management office of the Building a reproducible copy of the “as built” drawings of the Alterations, and (iii) deliver to Landlord evidence of payment, contractors’ affidavits and full and final waivers of all liens for labor, services or materials.

8.3 Landlord’s Property. All Alterations, improvements, fixtures and/or equipment which may be installed or placed in or about the Premises shall be at the sole cost of Tenant and shall be and become the property of Landlord. Furthermore, Landlord may require that Tenant remove any improvement (including any portion of the Tenant Improvements) or Alteration upon the expiration or early termination of the Lease Term, and repair any damage to the Premises and Building caused by such removal. If Tenant fails to complete such removal and/or to repair by the end of the Lease Term, Landlord may do so and may charge the cost thereof to Tenant.

8.4 Wi-Fi Network. Without limiting the generality of the foregoing, if Tenant desires to install wireless internet, Internet and communications network (“Wi-Fi Network”) in the Premises for the use by Tenant and its employees, then the same shall be subject to the provisions of this Section 8.4 (in addition to the other provisions of this Article 8). In the event Landlord consents to Tenant’s installation of such Wi-Fi Network, Tenant shall, in accordance with Article 15 below, remove the Wi-Fi Network from the Premises prior to the termination of the Lease. Tenant shall use the Wi-Fi Network so as not to cause any interference to other tenants in the Building or to other tenants at the Project or with any other tenant’s communication equipment, and not to damage the Building or Project or interfere with the normal operation of the Building or Project, and Tenant hereby agrees to indemnify, defend and hold Landlord harmless from and against any and all claims, costs, damages, expenses and liabilities (including attorneys’ fees) arising out of Tenant’s failure to comply with the provisions of this Section 8.4, except to the extent same is caused by the gross negligence or willful misconduct of Landlord and which is not covered by the insurance carried by Tenant under this Lease (or which would not be covered by the insurance required to be carried by Tenant under this Lease). Should any interference occur, Tenant shall take all necessary steps as soon as reasonably possible and no later than three (3) calendar days following such occurrence to correct such interference. If such interference continues after such three (3) day period, Tenant shall immediately cease operating such Wi-Fi Network until such interference is corrected or remedied to Landlord’s satisfaction. Tenant acknowledges that Landlord has granted and/or may grant telecommunication rights to other tenants and occupants of the Building and Project and to telecommunication service providers and in no event shall Landlord be liable to Tenant for any interference of the same with such Wi-Fi Network. Landlord makes no representation that the Wi-Fi Network will be able to receive or transmit communication signals without interference or disturbance. Tenant shall (i) be solely responsible for any damage caused as a result of the Wi-Fi Network, (ii) promptly pay any tax, license or permit fees charged pursuant to any laws or regulations in connection with the installation, maintenance or use

of the Wi-Fi Network and comply with all precautions and safeguards recommended by all governmental authorities, (iii) pay for all necessary repairs, replacements to or maintenance of the Wi-Fi Network, and (iv) be responsible for any modifications, additions or repairs to the Building or Project, including without limitation, Building or Project systems or infrastructure, which are required by reason of the installation, operation or removal of Tenant’s Wi-Fi Network, Should Landlord be required to retain professionals to research any interference issues that may arise and confirm Tenant’s compliance with the terms of this Section 8.4, Tenant shall reimburse Landlord for the costs incurred by Landlord in connection with Landlord’s retention of such professionals, the research of such interference issues and confirmation of Tenant’s compliance with the terms of this Section 8.4 within twenty (20) days after the date Landlord submits to Tenant an invoice for such costs. This reimbursement obligation is in addition to, and not in lieu of, any rights or remedies Landlord may have in the event of a breach or default by Tenant under this Lease.

ARTICLE 9

COVENANT AGAINST LIENS

Tenant has no authority or power to cause or permit any lien or encumbrance of any kind whatsoever, whether created by act of Tenant, operation of law or otherwise, to attach to or be placed upon the Project, Building or Premises, and any and all liens and encumbrances created by Tenant shall attach to Tenant’s interest only. Landlord shall have the right at all times to post and keep posted on the Premises any notice which it deems necessary for protection from such liens. Tenant shall not cause or permit any lien of mechanics or materialmen or others to be placed against the Project, the Building or the Premises with respect to work or services claimed to have been performed for or materials claimed to have been furnished to Tenant or the Premises, and, in case of any such lien attaching or notice of any lien, Tenant shall cause it to be immediately released and removed of record. If any such lien is not released and removed within five (5) business days after notice of such lien is delivered by Landlord to Tenant, then Landlord may, at its option, take all action necessary to release and remove such lien, without any duty to investigate the validity thereof, and all sums, costs and expenses, including reasonable attorneys’ fees and costs, incurred by Landlord in connection with such lien shall be deemed Additional Rent under this Lease and shall immediately be due and payable by Tenant.

ARTICLE 10

INDEMNIFICATION AND INSURANCE

10.1 Indemnification and Waiver. Tenant hereby assumes all risk of damage to property and injury to persons, in, on, or about the Premises from any cause whatsoever and agrees that Landlord and the Landlord Parties shall not be liable for, and are hereby released from any responsibility for, any damage to property or injury to persons or resulting from the loss of use thereof, which damage or injury is sustained by Tenant or by other persons claiming through Tenant. Tenant shall indemnify, defend, protect, and hold harmless the Landlord Parties from any and all loss, cost, damage, expense and liability (including without limitation court costs and reasonable attorneys’ fees) incurred in connection with or arising from any cause in, on or about the Premises (including, without limitation, Tenant’s installation, placement and removal of Alterations, improvements, fixtures and/or equipment in, on or about the Premises), and any acts, omissions or negligence of Tenant or of any person claiming by, through or under Tenant, or of the contractors, agents, servants, employees, licensees or invitees of Tenant or any such person, in, on or about the Premises, the Building and Project; provided, however, that the terms of the foregoing indemnity shall not apply to the gross negligence or willful misconduct of Landlord. The provisions of this Section 10.1 shall survive the expiration or sooner termination of this Lease. Notwithstanding anything in this Lease to the contrary, Landlord shall not be liable to Tenant for, and Tenant assumes all risk of, damage to personal property or scientific research or intellectual property, including loss of records kept by Tenant within the Premises and damage or losses caused by fire, electrical malfunction, gas explosion or water damage of any type (including broken water lines, malfunctioning fire sprinkler systems, malfunctioning lab systems including any malfunction of the central plant systems, roof leaks or stoppages of lines). Tenant further waives any claim for injury to Tenant’s business or loss of income relating to any such damage or destruction of personal property as described above.

10.2 Tenant’s Compliance with Landlord’s Fire and Casualty Insurance. Tenant shall, at Tenant’s expense, comply as to the Premises with all insurance company requirements pertaining to the use of the Premises, If Tenant’s conduct or use of the Premises causes any increase in the premium for such insurance policies, then Tenant shall reimburse Landlord for any such increase.

10.3 Tenant’s Insurance. Tenant shall maintain the following coverages in the following amounts.

10.3.1 Commercial general liability insurance written on the current ISO CG 00 01 occurrence form or an equivalent acceptable to Landlord (the “CGL”), (i) covering liability arising from bodily injury (including mental anguish and death), property damage, premises (including the use or occupancy of the Premises, the Building and all areas appurtenant to the Premises and the Building, including any parking areas and areas outside the Premises that Tenant is authorized to use temporarily), operations, independent contractors, personal and advertising injury, and liability assumed under an insured contract, (ii) with limits of not less than $1,000,000 each occurrence, $1,000,000 personal and advertising injury, $2,000,000 general aggregate, and $2,000,000 products-completed operations aggregate, (iii) with defense provided in addition to policy limits, (iv) with a standard ISO separation of insureds provision or a substantially similar provision, and (v) including the Landlord Parties (as defined below) as additional insureds, using ISO additional insured endorsement CG 20 11 or an equivalent acceptable to Landlord. If the additional insured endorsement restricts the Landlord Parties’ coverage under the CGL to liability arising out of the ownership, maintenance or use of premises described in the endorsement, then the description of these premises in the endorsement must include the Premises, any

parking areas at the Property that Tenant is authorized to use, and any other areas of the Property outside the Premises that Tenant is authorized to use temporarily. Tenant shall ensure that the CGL policy provides coverage for the Landlord Parties’ own acts related to the Premises, and does not limit their coverage to liability arising from Tenant’s acts. The CGL must not include a “designated premises” endorsement that limits Tenant’s coverage under the CGL to matters related to the Premises. The CGL must apply as primary and non-contributing insurance with respect to any other insurance or self-insurance programs afforded to the Landlord Parties. If the CGL contains a general aggregate limit, it must apply separately to the Premises on a “per project” or “per location” basis.

10.3.2 Commercial excess or umbrella liability insurance with respect to Tenant’s CGL, business autoliability and employers liability insurance, with a limit of not less than $4,000,000 each occurrence. This insurance must (i) provide coverage at least as broad as the applicable primary coverages (and. if excess, must be “true follow form”), (ii) include the Landlord Parties as additional insureds with respect to the CGL, (iii) apply on a primary basis with respect to any commercial general liability insurance carried by the Landlord Parties, (iv) provide that aggregate limits of liability apply separately with respect to the Premises, and (v) provide that if the allocations of minimum primary and excess/umbrella limits established in this Section, Tenant may provide lower minimum limits of primary insurance so long as the minimum limit of the excess/umbrella insurance is increased by the amount of the primary reduction.

10.3.3 Physical Damage Insurance – Commercial property insurance covering (i) all furniture, trade fixtures, equipment, merchandise and all other items of Tenant’s property on the Premises installed by, for, or at the expense of Tenant, (ii) the Tenant Improvements, including any Tenant Improvements which Landlord permits to be installed above the ceiling of the Premises or below the floor of the Premises, and (iii) all other improvements, alterations and additions to the Premises, including any improvements, alterations or additions installed at Tenant’s request above the ceiling of the Premises or below the floor of the Premises. Such insurance shall be written on a “physical loss or damage” basis under a “special form” policy, for the full replacement cost value new without deduction for depreciation of the covered items and in amounts that meet any co-insurance clauses of the policies of insurance and shall include a vandalism and malicious mischief endorsement, sprinkler leakage coverage and earthquake sprinkler leakage coverage.

10.3.4 Loss-of-income, business interruption and extra-expense insurance in such amounts as will reimburse Tenant for direct and indirect loss of earnings attributable to all perils commonly insured against by prudent tenants or attributable to prevention of loss of access to the Premises or to the Building as a result of such perils.

10.3.5 Workers compensation and employers liability insurance for all persons Tenant employers or uses as labor. The workers compensation insurance must fulfill applicable statutory requirements. The employers liability insurance must have limits of not less than $1,000,000 each accident for bodily injury by accident, $1,000,000 each employee for bodily injury by disease, and $1,000,000 policy limit for bodily injury by disease. Policy shall also include a waiver of subrogation in favor of Landlord and Landlord Parties.

10.3.6 Business automobile liability insurance on ISO form CA 00 01 to cover liability insurance arising out of any auto (including owned, hired and non-owned autos), with a limit of not less than $1,000,000 each accident.

10.3.7 Environmental Liability insurance (in form and substance satisfactory to Landlord) with limits of coverage not less than Four Million Dollars ($4,000,000.00) combined per occurrence and in the aggregate insuring against any and all liability with respect to the Premises and all areas appurtenant thereto arising out of any death or injury to any person, damage or destruction of any property, other loss, cost or expense resulting from any release, spill, leak or other contamination of the Premises, or any other property surrounding the Premises attributable to the presence of Hazardous Materials. Upon Landlord’s request, Tenant shall also obtain (at Tenant’s sole cost and expense) environmental impairment liability insurance and environmental remediation liability insurance (in form and substance (including limits) acceptable to Landlord). If, at any time it reasonably appears to Landlord that Tenant is not maintaining sufficient insurance or other means of financial capacity to enable Tenant to fulfill its obligations to Landlord hereunder, whether or not then accrued, liquidated, conditional or contingent, Tenant shall procure and thereafter maintain in full force and effect such insurance or other form of financial assurance, with or from companies or persons and in form and substance reasonably acceptable to Landlord, as Landlord may from time to time reasonably request. Without limiting the generality of the foregoing, all such environmental liability insurance shall specifically insure the performance by Tenant of the indemnity provisions set forth in this Lease.

10.3.8 Form of Policies. The minimum limits of policies of insurance required of Tenant under this Lease shall in no event limit the liability of Tenant under this Lease. Such insurance shall: (i) name Landlord, and any other party it so specifies, as an additional insured; (ii) specifically cover the liability assumed by Tenant under this Lease, including, but not limited to, Tenant’s obligations under Section 10.1 above; (iii) be issued by an insurance company having a rating of not less than A-VII in Best’s Insurance Guide or which is otherwise acceptable to Landlord and licensed to do business in she state in which the Project is located; (iv) be primary insurance as to all claims thereunder and provide that any insurance carried by Landlord is excess and is non-contributing with any insurance requirement of Tenant; (v) provide that said insurance shall not be canceled or coverage changed unless thirty (30) days’ prior written notice shall have been given to Landlord and any mortgagee or ground or underlying lessor of Landlord; (vi) contain a cross-liability endorsement or severability of interest clause acceptable to Landlord; and (vii) with respect to the insurance required in Sections 10.3.1 and 10.3.3 above, have deductible amounts not exceeding Twenty Five Thousand Dollars ($25,000.00) unless Landlord approves the higher amount in writing. Tenant shall deliver such policies or certificates thereof to Landlord on or before the Lease Commencement Date and at least ten (10) days before the expiration dates thereof. If Tenant shall fail to procure such insurance, or to deliver such policies or certificate, within such time periods, Landlord may, at its option, in addition to all of its other rights and remedies under this Lease, and without regard to any notice and

cure periods set forth in Section 19.1, procure such policies for the account of Tenant, and the cost thereof shall be paid to Landlord as Additional Rent within ten (10) days after delivery of bills therefor. Landlord may from time to time ask Tenant to seek or obtain other coverages or higher limits or broader coverage for required coverages, including adjustments required by holders of indebtedness secured by the Project, and Tenant shall then use its best efforts promptly to obtain the coverages or limits.

10.4 Subrogation. Landlord and Tenant agree to have their respective insurance companies issuing property damage insurance waive any rights of subrogation that such companies may have against Landlord or Tenant, as the case may be. Landlord and Tenant hereby waive any right that either may have against the other on account of any loss or damage to their respective property to the extent such loss or damage is insurable under policies of insurance for fire and all risk coverage, theft, public liability, or other similar insurance.

10.5 Additional Insurance Obligations. Tenant shall carry and maintain during the entire Lease Term, at Tenant’s sole cost and expense, increased amounts of the insurance required to be carried by Tenant pursuant to this Article 10, and such other reasonable types of insurance coverage and in such reasonable amounts covering the Premises and Tenant’s operations therein, as may be reasonably requested by Landlord.

ARTICLE 11

DAMAGE AND DESTRUCTION

11.1 Repair of Damage to Premises by Landlord. Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any common areas of the Building or Project serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the base, shell, and core of the Premises and such common areas. Such restoration shall be to substantially the same condition of the base, shell, and core of the Premises and common areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Project and/or the Building, or the lessor of a ground or underlying lease with respect to the Building, or any other modifications to the common areas deemed desirable by Landlord, provided access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any damage to the tenant improvements and alterations installed in the Premises and shall return such tenant improvements and alterations to their original condition; provided that if the costs of such repair of such tenant improvements and Alterations by Landlord exceeds the amount of insurance proceeds received by Landlord therefor from Tenant’s insurance carrier, as assigned by Tenant, the excess costs of such repairs shall be paid by Tenant to Landlord prior to Landlord’s repair of the damage. In connection with such repairs and replacements of any such tenant improvements and Alterations, Tenant shall, prior to Landlord’s commencement of such improvement work, submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or common areas necessary to Tenant’s occupancy, and if such damage is not the result of the negligence or willful misconduct of Tenant or Tenant’s employees, contractors, licensees, or invitees, Landlord shall allow Tenant a proportionate abatement of Base Rent and Tenant’s Share of Operating Expenses, Tax Expenses and Utilities Costs to the extent Landlord is reimbursed from the proceeds of rental interruption insurance purchased by Landlord as part of Operating Expenses, during the time and to the extent the Premises are unfit for occupancy for the purposes permitted under this Lease, and not occupied by Tenant as a result thereof.

11.2 Landlord’s Option to Repair. Notwithstanding Section 11.1 above to the contrary, Landlord may elect not to rebuild and/or restore the Premises, the Building and/or any other portion of the Project and instead terminate this Lease by notifying Tenant in writing of such termination within sixty (60) days after the date Landlord becomes aware of such damage, such notice to include a termination date giving Tenant ninety (90) days to vacate the Premises, but Landlord may so elect only if the Building shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) repairs cannot reasonably be substantially completed within one hundred twenty (120) days after the date of such damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Project and/or the Building or ground or underlying lessor with respect to the Project and/or the Building shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground or underlying lease, as the case may be; or (iii) the damage is not fully covered, except for deductible amounts, by Landlord’s insurance policies. In addition, if the Premises or the Building is destroyed or damaged to any substantial extent during the last year of the Lease Term, then notwithstanding anything contained in this Article 11, Landlord shall have the option to terminate this Lease by giving written notice to Tenant of the exercise of such option within thirty (30) days after such damage, in which event this Lease shall cease and terminate as of the date of such notice. Upon any such termination of this Lease pursuant to this Section 11.2, Tenant shall pay the Base Rent and Additional Rent, properly apportioned up to such date of termination, and both parties hereto shall thereafter be discharged of all further obligations under this Lease, except for those obligations which expressly survive the expiration or earlier termination of the Lease Term.

11.3 Waiver of Statutory Provisions. The provisions of this Lease, including this Article 11, constitute an express agreement between Landlord and Tenant with respect to any and all damage to, or destruction of, all or any part of the Premises, the Building or any other portion of the Project, and any statute or regulation of the state in which the

Project is located, including, without limitation, Sections 1932(2) and 1933(4) of the California Civil Code, with respect to any rights or obligations concerning damage or destruction in the absence of an express agreement between the parties, and any other statute or regulation, now or hereafter in effect, shall have no application to this Lease or any damage or destruction to all or any part of the Premises, the Building or any other portion of the Project.

ARTICLE 12

CONDEMNATION

12.1 Permanent Taking. If the whole or any part of the Premises, Building or Project shall be taken by power of eminent domain or condemned by any competent authority for any public or quasi-public use or purpose, or if any adjacent property or street shall be so taken or condemned, or reconfigured or vacated by such authority in such manner as to require the use, reconstruction or remodeling of any part of the Premises, Building or Project, or if Landlord shall grant a deed or other instrument in lieu of such taking by eminent domain or condemnation, Landlord shall have the option to terminate this Lease upon ninety (90) days’ notice, provided such notice is given no later than one hundred eighty (180) days after the date of such taking, condemnation, deed or other instrument. If more than twenty-five percent (25%) of the rentable square feet of the Premises is taken, or if access to the Premises is substantially impaired. Tenant shall have the option to terminate this Lease upon ninety (90) days’ notice, provided such notice is given no later than one hundred eighty (180) days after the date of such taking. Landlord shall be entitled to receive the entire award or payment in connection therewith, except that Tenant shall have the right to file any separate claim available to Tenant for any taking of Tenant’s personal property and fixtures belonging to Tenant and removable by Tenant upon expiration of the Lease Term pursuant to the terms of this Lease, and for moving expenses, so long as such claim does not diminish the award available to Landlord, or its ground lessor or mortgagee with respect to the Project, and such claim is payable separately to Tenant, All Rent shall be apportioned as of the date of such termination, or the date of such taking, whichever shall first occur. If any part of the Premises shall be taken, and this Lease shall not be so terminated, the Base Rent and Tenant’s Share of Operating Expenses, Tax Expenses and Utilities Costs shall be proportionately abated. Tenant hereby waives any and all rights it might otherwise have pursuant to Section 1265.130 of The California Code of Civil Procedure.

12.2 Temporary Taking. Notwithstanding anything to the contrary contained in this Article 12, in the event of a temporary taking of all or any portion of the Premises for a period of one hundred and eighty (180) days or less, then this Lease shall not terminate but the Base Rent and Tenant’s Share of Operating Expenses, Tax Expenses and Utilities Costs shall be abated for the period of such taking in proportion to the ratio that the amount of rentable square feet of the Premises taken bears to the total rentable square feet of the Premises. Landlord shall be entitled to receive the entire award made in connection with any such temporary taking.

ARTICLE 13

COVENANT OF QUIET ENJOYMENT

Landlord covenants that Tenant, on paying the Rent, charges for services and other payments herein reserved and on keeping, observing and performing all the other terms, covenants, conditions, and agreements herein contained on the part of Tenant to be kept, observed and performed, shall, during the Lease Term, peaceably and quietly have, hold and enjoy the Premises subject to the terms, covenants, conditions, and agreements hereof without interference by any persons lawfully claiming by or through Landlord. The foregoing covenant is in lieu of any other covenant express or implied.

ARTICLE 14

ASSIGNMENT AND SUBLETTING

14.1 Transfers. Tenant shall not, without the prior written consent of Landlord, assign, mortgage, pledge, hypothecate, encumber, or permit any lien to attach to. or otherwise transfer, this Lease or any interest hereunder, permit any assignment or other such foregoing transfer of this Lease or any interest hereunder by operation of law, sublet the Premises or any part thereof, or permit the use of the Premises by any persons other than Tenant and its employees (all of the foregoing are hereinafter sometimes referred to collectively as “Transfers” and any person to whom any Transfer is made or sought to be made is hereinafter sometimes referred to as a “Transferee”). If Tenant shall desire Landlord’s consent to any Transfer, Tenant shall notify Landlord in writing, which notice (the “Transfer Notice”) shall include (i) the proposed effective date of the Transfer, which shall not be less than thirty (30) days nor more than one hundred eighty (180) days after the date of delivery of the Transfer Notice, (ii) a description of the portion of the Premises to be transferred (the “Subject Space”), (iii) all of the terms of the proposed Transfer, the name and address of the proposed Transferee, and a copy of all existing and/or proposed documentation pertaining to the proposed Transfer, (iv) current financial statements of the proposed Transferee certified by an officer, partner or owner thereof, (v) a list of Hazardous Materials, certified by the proposed Transferee to be true and correct, that the proposed Transferee intends to use or store in the Premises, and (vi) such other information as Landlord may reasonably require. Any Transfer made without Landlord’s prior written consent shall, at Landlord’s option, be null, void and of no effect, and shall, at Landlord’s option, constitute a default by Tenant under this Lease. Whether or not Landlord shall grant consent, within thirty (30) days after written request by Landlord, Tenant shall pay to Landlord Two Thousand Five Hundred Dollars ($2,500.00) to reimburse Landlord for its review and processing fees, and Tenant shall also reimburse Landlord for any reasonable legal fees incurred by Landlord in connection with Tenant’s proposed Transfer.

14.2 Landlord’s Consent. Landlord shall not unreasonably withhold its consent to any proposed Transfer on the terms specified in the Transfer Notice. In no event shall Landlord be deemed to be unreasonable for declining to consent to a Transfer to a transferee jeopardizing directly or indirectly the status of Landlord or any of Landlord’s affiliates as a Real Estate Investment Trust under the Internal Revenue Code of 1986 (as the same may be amended from time to time, the “Revenue Code”). Notwithstanding anything contained in this Lease to the contrary, (w) no Transfer shall be consummated on any basis such that the rental or other amounts to be paid by the occupant, assignee, manager or other transferee thereunder would be based, in whole or in part, on the income or profits derived by the business activities of such occupant, assignee, manager or other transferee; (x) Tenant shall not furnish or render any services to an occupant, assignee, manager or other transferee with respect to whom transfer consideration is required to be paid, or manage or operate the Premises or any capital additions so transferred, with respect to which transfer consideration is being paid; (y) Tenant shall not consummate a Transfer with any person in which Landlord owns an interest, directly or indirectly (by applying constructive ownership rules set forth in Section 856(d)(5) of the Revenue Code); and (z) Tenant shall not consummate a Transfer with any person or in any manner that could cause any portion of the amounts received by Landlord pursuant to this Lease or any sublease, license or other arrangement for the right to use, occupy or possess any portion of the Premises to fail to qualify as “rents from real property” within the meaning of Section 856(d) of the Revenue Code, or any similar or successor provision thereto or which could cause any other income of Landlord to fail to qualify as income described in Section 856(c)(2) of the Revenue Code. The parties hereby agree that it shall be reasonable under this Lease and under any applicable law for Landlord to withhold consent to any proposed Transfer where one or more of the following apply, without limitation as to other reasonable grounds for withholding consent:

14.2.1 The Transferee is of a character or reputation or engaged in a business which is not consistent with the quality of the Building or Project;

14.2.2 The Transferee intends to use the Subject Space for purposes which are not permitted under this Lease;

14.2.3 The Transferee is either a governmental agency or instrumentality thereof;

14.2.4 The Transfer will result in more than a reasonable and safe number of occupants per floor within the Subject Space;

14.2.5 The Transferee is not a party of reasonable financial worth and/or financial stability in light of the responsibilities involved under the Lease on the date consent is requested;

14.2.6 The proposed Transfer would cause Landlord to be in violation of another lease or agreement to which Landlord is a party, or would give an occupant of the Project a right to cancel its lease;

14.2.7 The terms of the proposed Transfer will allow the Transferee to exercise a right of renewal, right of expansion, right of first offer, or other similar right held by Tenant (or will allow the Transferee to occupy space leased by Tenant pursuant to any such right); or

14.2.8 Either the proposed Transferee, or any person or entity which directly or indirectly, controls, is controlled by, or is under common control with, the proposed Transferee, (i) occupies space in the Project at the time of the request for consent, (ii) is negotiating with Landlord to lease space in the Project at such time, or (iii) has negotiated with Landlord during the twelve (12)-month period immediately preceding the Transfer Notice.

If Landlord consents to any Transfer pursuant to the terms of this Section 14.2 (and does not exercise any recapture rights Landlord may have under Section 14.4 below), Tenant may within six (6) months after Landlord’s consent, enter into such Transfer of the Premises or portion thereof, upon substantially the same terms and conditions as are set forth in the Transfer Notice furnished by Tenant to Landlord pursuant to Section 14.1 above, provided that if there are any changes in the terms and conditions from those specified in the Transfer Notice (i) such that Landlord would initially have been entitled to refuse its consent to such Transfer under this Section 14.2, or (ii) which would cause the proposed Transfer to be more favorable to the Transferee than the terms set forth in Tenant’s original Transfer Notice, Tenant shall again submit the Transfer to Landlord for its approval and other action under this Article 14 (including Landlord’s right of recapture, if any, under Section 14.4 of this Lease).

14.3 Transfer Premium. If Landlord consents to a Transfer, as a condition thereto which the parties hereby agree is reasonable, Tenant shall pay to Landlord fifty percent (50%) of any Transfer Premium received by Tenant from such Transferee. “Transfer Premium” shall mean all rent, additional rent or other consideration payable by such Transferee in excess of the Rent and Additional Rent payable by Tenant under this Lease on a per rentable square foot basis if less than all of the Premises is transferred, after deducting the reasonable expenses incurred by Tenant for (i) any reasonable changes, alterations and improvements to the Premises in connection with the Transfer (but only to the extent approved by Landlord), and (ii) any reasonable brokerage commissions in connection with the Transfer (collectively, the “Subleasing Costs”). Transfer Premium shall also include, but not be limited to, key money and bonus money paid by Transferee to Tenant in connection with such Transfer, and any payment in excess of fair market value for services rendered by Tenant to Transferee or for assets, fixtures, inventory, equipment, or furniture transferred by Tenant to Transferee in connection with such Transfer.

14.4 Landlord’s Option as to Subject Space. Notwithstanding anything to the contrary contained in this Article 14, Landlord shall have the option, by giving written notice to Tenant within thirty (30) days after receipt of any

Transfer Notice, to recapture the Subject Space. Such recapture notice shall terminate this Lease with respect to the Subject Space as of the date stated in the Transfer Notice as the effective date of the proposed Transfer until the last day of the term of the Transfer as set forth in the Transfer Notice. If this Lease is terminated with respect to less than the entire Premises, the Rent reserved herein shall be prorated on the basis of the rentable square feet retained by Tenant in proportion to the rentable square feet contained in the Premises, and this Lease as so amended shall continue thereafter in full force and effect, and upon request of either party, the parties shall execute written confirmation of the same. If Landlord declines, or fails to elect in a timely manner to recapture the Subject Space under this Section 14.4, then, provided Landlord has consented to the proposed Transfer, Tenant shall be entitled to proceed to transfer the Subject Space to the proposed Transferee, subject to provisions of the last paragraph of Section 14.2 above.

14.5 Effect of Transfer. If Landlord consents to a Transfer: (i) the terms and conditions of this Lease shall in no way be deemed to have been waived or modified; (ii) such consent shall not be deemed consent to any further Transfer by either Tenant or a Transferee; (iii) Tenant shall deliver to Landlord, promptly after execution, an original executed copy of all documentation pertaining to the Transfer in form reasonably acceptable to Landlord; and (iv) no Transfer relating to this Lease or agreement entered into with respect thereto, whether with or without Landlord’s consent, shall relieve Tenant or any guarantor of the Lease from liability under this Lease. Landlord or its authorized representatives shall have the right at all reasonable times to audit the books, records and papers of Tenant relating to any Transfer, and shall have the right to make copies thereof. If the Transfer Premium respecting any Transfer shall be found understated, Tenant shall, within thirty (30) days after demand, pay the deficiency and Landlord’s costs of such audit.

14.6 Additional Transfers. For purposes of this Lease, the term “Transfer” shall also include: (i) if Tenant is a partnership or limited liability company, the withdrawal or change, voluntary, involuntary or by operation of law, of more than fifty percent (50%) of the partners or members, or transfer of more than fifty percent (50%) of the partnership or membership interests, within a twelve (12)-month period, or the dissolution of the partnership without immediate reconstitution thereof; and (ii) if Tenant is a closely held corporation (i.e., whose stock is not publicly held and not traded through an exchange or over the counter), (A) the dissolution, merger, consolidation or other reorganization of Tenant, (B) the sale or other transfer of more than an aggregate of fifty percent (50%) of the voting shares of Tenant (other than to immediate family members by reason of gift or death), within a twelve (12) month period, or (C) the sale, mortgage, hypothecation or pledge of more than an aggregate of fifty percent (50%) of the value of the unencumbered assets of Tenant within a twelve ( l2) month period.

ARTICLE 15

SURRENDER; OWNERSHIP AND REMOVAL OF PERSONAL PROPERTY

15.1 Surrender of Premises. No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in a writing signed by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Tenant, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises.

15.2 Removal of Tenant Property by Tenant. Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Tenant’s restoration obligations may also include satisfying Landlord’s commercially reasonable procedures regarding the cleaning of any lab systems and sealing any connection points of any such lab systems to the Premises, all at Tenant’s sole cost and expense. At least one hundred twenty (120) days prior to Tenant’s surrender of possession of any part of the Premises, Tenant shall provide Landlord with a facility decommissioning and Hazardous Materials closure plan for the Premises prepared by an independent third party reasonably acceptable to Landlord (“Surrender Plan”). Within ten (10) days prior to Tenant’s surrender of possession of any part of the Premises, Tenant shall provide Landlord with written evidence that Tenant has fulfilled Tenant’s obligations set forth in the Surrender Plan and that Tenant has obtained all appropriate governmental releases pertaining to the Premises in accordance with applicable laws, including laws pertaining to the surrender of the Premises (“Exit Survey”). In addition, Tenant agrees to remain responsible after the surrender of the Premises for the remediation of any recognized environmental conditions set forth in the Surrender Plan and Exit Survey and compliance with any recommendations set forth in the Exit Survey. Tenant shall, upon the expiration or earlier termination of this Lease, furnish to Landlord evidence that Tenant has closed all governmental permits and licenses, if any, issued in connection with Tenant’s or Tenant’s Parties’ activities at the Premises. If any such governmental permits or licenses have been issued and Tenant fails to provide evidence of such closure on or before the expiration or earlier termination of this Lease, then until Tenant does so, the holdover provisions of Article 16 of this Lease shall apply to the entire Premises. Upon such expiration or termination, Tenant shall, without expense to Landlord, satisfy any surrender obligations pursuant to Section 8.3 of this Lease and shall, in any event, remove or cause to be removed from the Premises all telephone, data, and other cabling and wiring (including any cabling and wiring associated with the Wi-Fi Network, if any) installed or caused to be installed by Tenant (including any cabling and wiring, installed above the ceiling of the Premises or below the floor of the Premises), all debris and rubbish, and such items of furniture, equipment, free-standing cabinet work, and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under

Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal. Tenant’s obligations under this Section 15.2 shall survive the expiration or earlier termination of this Lease.

ARTICLE 16

HOLDING OVER

If Tenant holds over after the expiration of the Lease Term hereof, with or without the express or implied consent of Landlord, such tenancy shall be from month-to-month only, and shall not constitute a renewal hereof or an extension for any further term, and in such case Base Rent shall be payable at a monthly rate equal to one hundred fifty percent (150%) of the greater of (i) the Base Rent applicable during the last rental period of the Lease Term under this Lease, and (ii) the fair market rental rate of the Premises as of the commencement of such holdover period. Such month-to-month tenancy shall be subject to every other term, covenant and agreement contained herein. Landlord hereby expressly reserves the right to require Tenant to surrender possession of the Premises to Landlord as provided in this Lease upon the expiration or other termination of this Lease. The provisions of this Article 16 shall not be deemed to limit or constitute a waiver of any other rights or remedies of Landlord provided herein or at law. If Tenant fails to surrender the Premises upon the termination or expiration of this Lease, in addition to any other liabilities to Landlord accruing therefrom, Tenant shall protect, defend, indemnify and hold Landlord harmless from all loss, costs (including reasonable attorneys’ fees) and liability resulting from such failure, including, without limiting the generality of the foregoing, any claims made by any succeeding tenant founded upon such failure to surrender, and any lost profits to Landlord resulting therefrom.

ARTICLE 17

ESTOPPEL CERTIFICATES

Within ten (10) days following a request in writing by Landlord, Tenant shall execute and deliver to Landlord an estoppel certificate, which, as submitted by Landlord, shall be in the form as may be required by any prospective mortgagee or purchaser of the Project (or any portion thereof), indicating therein any exceptions thereto that may exist at that time, and shall also contain any other information reasonably requested by Landlord or Landlord’s Mortgagee or Landlords prospective mortgagees. Tenant shall execute and deliver whatever other instruments may be reasonably required for such purposes. Failure of Tenant to timely execute and deliver such estoppel certificate or other instruments shall constitute an acceptance of the Premises and an acknowledgment by Tenant that statements included in the estoppel certificate are true and correct, without exception. Failure by Tenant to so deliver such estoppel certificate shall be a material default of the provisions of this Lease. In addition, Tenant shall be liable to Landlord, and shall indemnify Landlord from and against any loss, cost, damage or expense, incidental, consequential, or otherwise, including attorneys’ fees, arising or accruing directly or indirectly, from any failure of Tenant to execute or deliver to Landlord any such estoppel certificate. Upon request from time to time, Tenant agrees to provide to Landlord, within twenty (20) days after Landlord’s delivery of written request therefor, current financial statements for Tenant, dated no earlier than one (1) year prior to such written request, certified as accurate by Tenant or, if available, audited financial statements prepared by an independent certified public accountant with copies of the auditor’s statement. If any Guaranty is executed in connection with this Lease, Tenant also agrees to deliver to Landlord, within twenty (20) days after Landlord’s delivery of written request therefor, current financial statements of the Guarantor in a form consistent with the foregoing criteria.

ARTICLE 18

SUBORDINATION

This Lease is subject and subordinate to all present and future ground leases of the Project and to the lien of any mortgages or trust deeds, now or hereafter in force against the Project, if any, and to all renewals, extensions, modifications, consolidations and replacements thereof, and to all advances made or hereafter to be made upon the security of such mortgages or trust deeds, unless the holders of such mortgages or trust deeds, or the lessors under such ground lease, require in writing that this Lease be superior thereto. Tenant covenants and agrees in the event any proceedings are brought for the foreclosure of any such mortgage, or if any ground lease is terminated, to attorn, without any deductions or set-offs whatsoever, to the purchaser upon any such foreclosure sale, or to the lessor of such ground lease, as the case may be. if so requested to do so by such purchaser or lessor, and to recognize such purchaser or lessor as the lessor under this Lease. Tenant shall, within five (5) days of request by Landlord, execute such further instruments or assurances as Landlord may reasonably deem necessary to evidence or confirm the subordination or superiority of this Lease to any such mortgages. trust deeds, or ground leases. Tenant hereby irrevocably authorizes Landlord to execute and deliver in the name of Tenant any such instrument or instruments if Tenant fails to do so, provided that such authorization shall in no way relieve Tenant from the obligation of executing such instruments of subordination or superiority. Tenant waives the provisions of any current or future statute, rule or law which may give or purport to give Tenant any right or election to terminate or otherwise adversely affect this Lease and the obligations of the Tenant hereunder in the event of any foreclosure proceeding or sale.

ARTICLE 19

TENANT’S DEFAULTS; LANDLORD’S REMEDIES

19.1 Events of Default by Tenant. All covenants and agreements to be kept or performed by Tenant under this Lease shall be performed by Tenant at Tenant’s sole cost and expense and without any reduction of Rent. The occurrence of any of the following shall constitute a default of this Lease by Tenant:

19.1.1 Any failure by Tenant to pay any Rent or any other charge required to be paid under this Lease, or any part thereof, when due; or

19.1.2 Any failure by Tenant to observe or perform any other provision, covenant or condition of this Lease to be observed or performed by Tenant where such failure continues for fifteen (15) days after written notice thereof from Landlord to Tenant; provided however, that any such notice shall be in lieu of, and not in addition to, any notice required under California Code of Civil Procedure Section 1161 or any similar or successor law: and provided further that if the nature of such default is such that the same cannot reasonably be cured within a fifteen (15)-day period. Tenant shall not be deemed to be in default if it diligently commences such cure within such period and thereafter diligently proceeds to rectify and cure said default as soon as possible; or

19.1.3 Abandonment or vacation of the Premises by Tenant. Abandonment is herein defined to include, but is not limited to, any absence by Tenant from the Premises for three (3) business days or longer while in default of any provision of this Lease.

19.2 Landlord’s Remedies Upon Default. Upon the occurrence of any such default by Tenant. Landlord shall have, in addition to any other remedies available to Landlord at law or in equity, the option to pursue any one or more of the following remedies, each and all of which shall be cumulative and nonexclusive, without any notice or demand whatsoever.

19.2.1 Terminate this Lease, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy which it may have for possession or arrearages in rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim or damages therefor; and Landlord may recover from Tenant the following:

(i) the worth at the time of award of any unpaid rent which has been earned at the time of such termination; plus

(ii) the worth at the time of award of the amount by which the unpaid rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(iii) the worth at the time of award of the amount by which the unpaid rent for the balance of the Lease Term after the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(iv) any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including but not limited to, brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion thereof for a new tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant; plus

(v) at Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by applicable law.

The term “rent” as used in this Section 19.2 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 19.2.1(i) and (ii), above, the “worth at the time of award” shall be computed by allowing interest at the Interest Rate set forth in Section 4.5 above. As used in Section 19.2.1(iii) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus one percent (1%).

19.2.2 Landlord shall have the remedy described in California Civil Code Section 1951.4 (lessor may continue lease in effect after lessees breach and abandonment and recover rent as it becomes due, if lessee has the right to sublet or assign, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease on account of any default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies under this Lease, including the right to recover all rent as it becomes due.

19.2.3 Landlord may, but shall not be obligated to, make any such payment or perform or otherwise cure any such obligation, provision, covenant or condition on Tenant’s part to be observed or performed (and may enter the Premises for such purposes). In the event of Tenant’s failure to perform any of its obligations or covenants under this Lease, and such failure to perform poses a material risk of injury or harm to persons or damage to or loss of property, then

Landlord shall have the right to cure or otherwise perform such covenant or obligation at any time after such failure to perform by Tenant, whether or not any such notice or cure period set forth in Section 19.1 above has expired. Any such actions undertaken by Landlord pursuant to the foregoing provisions of this Section 19.2.3 shall not be deemed a waiver of Landlord’s rights and remedies as a result of Tenant’s failure to perform and shall not release Tenant from any of its obligations under this Lease.

19.3 Payment by Tenant. Tenant shall pay to Landlord, within ten (10) days after delivery by Landlord to Tenant of statements therefor: (i) sums equal to expenditures reasonably made and obligations incurred by Landlord in connection with Landlord’s performance or cure of any of Tenant’s obligations pursuant to the provisions of Section 19.2.3 above; and (ii) sums equal to all expenditures made and obligations incurred by Landlord in collecting or attempting to collect the Rent or in enforcing or attempting to enforce any rights of Landlord under this Lease or pursuant to law, including, without limitation, all legal fees and other amounts so expended. Tenant’s obligations under this Section 19.3 shall survive the expiration or sooner termination of the Lease Term.

19.4 Sublessees of Tenant. Whether or not Landlord elects to terminate this Lease on account of any default by Tenant, as set forth in this Article 19, Landlord shall have the right to terminate any and all subleases, licenses, concessions or other consensual arrangements for possession entered into by Tenant and affecting the Premises or may, in Landlord’s sole discretion, succeed to Tenant’s interest in such subleases, licenses, concessions or arrangements. If Landlord elects to succeed to Tenant’s interest in any such subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of such election, have no further right to or interest in the rent or other consideration receivable thereunder.

19.5 Waiver of Default. No waiver by Landlord of any violation or breach by Tenant of any of the terms, provisions and covenants herein contained shall be deemed or construed to constitute a waiver of any other or later violation or breach by Tenant of the same or any other of the terms, provisions, and covenants herein contained. Forbearance by Landlord in enforcement of one or more of the remedies herein provided upon a default by Tenant shall not be deemed or construed to constitute a waiver of such default, The acceptance of any Rent hereunder by Landlord following the occurrence of any default, whether or not known to Landlord, shall not be deemed a waiver of any such default, except only a default in the payment of the Rent so accepted.

19.6 Efforts to Relet. For the purposes of this Article 19, Tenant’s right to possession shall not be deemed to have been terminated by efforts of Landlord to relet the Premises, by its acts of maintenance or preservation with respect to the Premises, or by appointment of a receiver to protect Landlord’s interests hereunder. The foregoing enumeration is not exhaustive, but merely illustrative of acts which may be performed by Landlord without terminating Tenant’s right to possession.

ARTICLE 20

SECURITY DEPOSIT

Concurrent with Tenant’s execution of this Lease, Tenant shall deposit with Landlord a security deposit (the “Security Deposit”) in the amount set forth in Section 10 of the Summary. The Security Deposit shall be held by Landlord as security for the faithful performance by Tenant of all the terms, covenants, and conditions of this Lease to be kept and performed by Tenant during the Lease Term. If Tenant defaults with respect to any provisions of this Lease, including, but not limited to, the provisions relating to the payment of Rent, Landlord may, but shall not be required to, use, apply or retain all or any part of the Security Deposit for the payment of any Rent or any other sum in default, or for the payment of any amount that Landlord may spend or become obligated to spend by reason of Tenant’s default, or to compensate Landlord for any other loss or damage that Landlord may suffer by reason of Tenant’s default. If any portion of the Security Deposit is so used or applied, Tenant shall, within five (5) business days after written demand therefor, deposit cash with Landlord in an amount sufficient to restore the Security Deposit to its original amount, and Tenant’s failure to do so shall be a default under this Lease. If Tenant shall fully and faithfully perform every provision of this Lease to be performed by it, the Security Deposit, or any balance thereof, shall be returned to Tenant, or, at Landlord’s option, to the last assignee of Tenant’s interest hereunder, within thirty (30) days following the expiration of the Lease Term. Tenant shall not be entitled to any interest on the Security Deposit. Tenant hereby waives the provisions of Section 1950.7 of the California Civil Code, and all other provisions of law, now or hereafter in force, which provide that Landlord may claim from a security deposit only those sums reasonably necessary to remedy defaults in the payment of rent, to repair damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums reasonably necessary to compensate Landlord for any other loss or damage, foreseeable or unforeseeable, caused by the act or omission of Tenant or any officer, employee, agent or invitee of Tenant.

ARTICLE 21

COMPLIANCE WITH LAW

Tenant shall not do anything or suffer anything to be done in or about the Premises which will in any way conflict with any law, statute, ordinance or other governmental rule, regulation or requirement now in force or which may hereafter be enacted or promulgated. At its sole cost and expense, Tenant shall promptly comply with all such governmental measures, other than the making of structural changes or changes to the Building’s life safety system (collectively the “Excluded Changes”); provided, however, to the extent such Excluded Changes are required due to or triggered by Tenant’s improvements or alterations to and/or manner of use of the Premises, Landlord shall perform such work, at Tenant’s cost (which shall be paid by Tenant to Landlord within ten (10) days after Tenant’s receipt of invoice therefor

from Landlord). In addition, Tenant shall fully comply with all present or future programs intended to manage parking, transportation or traffic in and around the Project, and in connection therewith, Tenant shall take responsible action for the transportation planning and management of all employees located at the Premises by working directly with Landlord, any governmental transportation management organization or any other transportation-related committees or entities. The judgment of any court of competent jurisdiction or the admission of Tenant in any judicial action, regardless of whether Landlord is a party thereto, that Tenant has violated any of said governmental measures, shall be conclusive of that fact as between Landlord and Tenant.

ARTICLE 22

ENTRY BY LANDLORD

Landlord reserves the right at all reasonable times and upon reasonable notice to Tenant to enter the Premises to: (i) inspect them; (ii) show the Premises to prospective purchasers, mortgagees or tenants, or to the ground lessors; (iii) to post notices of nonresponsibility; or (iv) alter, improve or repair the Premises or the Building if necessary to comply with current building codes or other applicable laws, or for structural alterations, repairs or improvements to the Building, or as Landlord may otherwise reasonably desire or deem necessary. Notwithstanding anything to the contrary contained in this Article 22, Landlord may enter the Premises at any time, without notice to Tenant, in emergency situations and/or to perform janitorial or other services required of Landlord pursuant to this Lease. Any such entries shall be without the abatement of Rent and shall include the right to take such reasonable steps as required to accomplish the stated purposes. Tenant hereby waives any claims for damages or for any injuries or inconvenience to or interference with Tenant’s business, lost profits, any loss of occupancy or quiet enjoyment of the Premises, and any other loss occasioned thereby. For each of the above purposes, Landlord shall at all times have a key with which to unlock all the doors in the Premises, excluding Tenant’s vaults, safes and special security areas designated in advance by Tenant. In an emergency, Landlord shall have the right to enter without notice and use any means that Landlord may deem proper to open the doors in and to the Premises. Any entry into the Premises in the manner hereinbefore described shall not be deemed to be a forcible or unlawful entry into, or a detainer of, the Premises, or an actual or constructive eviction of Tenant from any portion of the Premises.

ARTICLE 23

PARKING

Throughout the Lease Term, Tenant shall, at no additional cost, have the right to use (i) eight (8) reserved parking spaces set forth in Section 12 of the Summary (in a location in reasonably close proximity to the Building elevator) and (ii) on a “first-come, first-serve” basis, in common with other tenants of the Building and free of parking charges, sixteen (16) unreserved parking spaces set forth in Section 12 of the Summary, which parking spaces are located in the subterranean Parking Facility and the surface parking lot serving the Building as shall be designated by Landlord from time to time for parking for the tenants of the Building. Tenant’s continued right to use the parking spaces is conditioned upon (i) Tenant abiding by (A) the Parking Rules and Regulations which are in effect on the date hereof, as set forth in the attached Exhibit D and all modifications and additions thereto which are prescribed from time to time for the orderly operation and use of the Parking Facility by Landlord, and/or Landlord’s Parking Operator (as defined below), and (B) all recorded covenants, conditions and restrictions affecting the Building, and (ii) upon Tenant’s cooperation in seeing that Tenant’s employees and visitors also comply with the Parking Rules and Regulations (and all such modifications and additions thereto, as the case may be), any such other rules and regulations and covenants, conditions and restrictions. Landlord (and/or any other owners of Torrey Ridge Science Center) specifically reserve the right to change the size, configuration, design, layout, location and all other aspects of the Parking Facility (including without limitation, implementing paid visitor parking), and Tenant acknowledges and agrees that Landlord may, without incurring any liability to Tenant and without any abatement of Rent under this Lease, from time to time, close-off or restrict access to the Parking Facility. Landlord may delegate its responsibilities hereunder to a parking operator (the “Parking Operator”) in which case the Parking Operator shall have all the rights of control attributed hereby to Landlord. Any parking tax or other charges imposed by governmental authorities in connection with the use of such parking shall be paid directly by Tenant or the parking users, or, if directly imposed against Landlord, Tenant shall reimburse Landlord for all such taxes and/or charges within ten (10) days after Landlord’s demand therefor. The parking rights provided to Tenant pursuant to this Article 23 are provided solely for use by Tenant’s own personnel and such rights may not be transferred, assigned, subleased or otherwise alienated by Tenant without Landlord’s prior approval, except in connection with an assignment of this Lease or sublease of the Premises made in accordance with Article 14 above. All visitor parking by Tenant’s visitors shall be subject to availability, as reasonably determined by Landlord (and/or the Parking Operator, as the case may be), parking in such visitor parking areas as may be designated by Landlord (and/or the Parking Operator from time to time, and payment by such visitors of the prevailing visitor parking rate (if any) charged by Landlord (and/or the Parking Operator) from time to time.

ARTICLE 24

MISCELLANEOUS PROVISIONS

24.1 Terms: Captions. The necessary grammatical changes required to make the provisions hereof apply either to corporations or partnerships or individuals, men or women, as the case may require, shall in all cases be assumed as though in each case fully expressed. The captions of Articles and Sections are for convenience only and shall not be deemed to limit, construe, affect or alter the meaning of such Articles and Sections.

24.2 Binding Effect. Each of the provisions of this Lease shall extend to and shall, as the case may require, bind or inure to the benefit not only of Landlord and of Tenant, but also of their respective successors or assigns, provided this clause shall not permit any assignment by Tenant contrary to the provisions of Article 14 above.

24.3 No Waiver. No waiver of any provision of this Lease shall be implied by any failure of a party to enforce any remedy on account of the violation of such provision, even if such violation shall continue or be repeated subsequently, any waiver by a party of any provision of this Lease may only be in writing, and no express waiver shall affect any provision other than the one specified in such waiver and that one only for the time and in the manner specifically stated. No receipt of monies by Landlord from Tenant after the termination of this Lease shall in any way alter the length of the Lease Term or of Tenant’s right of possession hereunder or after the giving of any notice shall reinstate, continue or extend the Lease Term or affect any notice given Tenant prior to the receipt of such monies, it being agreed that after the service of notice or the commencement of a suit or after final judgment for possession of the Premises, Landlord may receive and collect any Rent due, and the payment of said Rent shall not waive or affect said notice, suit or judgment.

24.4 Modification of Lease. If any current or prospective mortgagee or ground lessor for the Project requires modifications to this Lease, which modifications will not cause an increased cost or expense to Tenant or in any other way materially and adversely change the rights and obligations of Tenant hereunder, then and in such event, Tenant agrees that this Lease may be so modified and agrees to execute whatever documents are required therefor and deliver the same to Landlord within ten (10) days following the request therefor. If Landlord or any such current or prospective mortgagee or ground lessor require execution of a short form of Lease for recording, containing, among other customary provisions, the names of the parties, a description of the Premises and the Lease Term, Tenant shall execute such short form of Lease and to deliver the same to Landlord within ten (10) days following the request therefor.

24.5 Transfer of Landlord’s Interest. Landlord has the right to transfer all or any portion of its interest in the Project, the Building and/or in this Lease, and upon any such transfer, Landlord shall automatically be released from all liability under this Lease and Tenant shall look solely to such transferee for the performance of Landlord’s obligations hereunder after the date of transfer. The liability of any transferee of Landlord shall be limited to the interest of such transferee in the Project and such transferee shall be without personal liability under this Lease, and Tenant hereby expressly waives and releases such personal liability on behalf of itself and all persons claiming by, through or under Tenant. Landlord may also assign its interest in this Lease to a mortgage lender as additional security but such assignment shall not release Landlord from its obligations hereunder and Tenant shall continue to look to Landlord for the performance of its obligations hereunder.

24.6 Prohibition Against Recording. Except as provided in Section 24.4 of this Lease, neither this Lease, nor any memorandum, affidavit or other writing with respect thereto, shall be recorded by Tenant or by anyone acting through, under or on behalf of Tenant, and the recording thereof in violation of this provision shall make this Lease null and void at Landlord’s election.

24.7 Landlord’s Title; Air Rights. Landlord’s title is and always shall be paramount to the title of Tenant. Nothing herein contained shall empower Tenant to do any act which can, shall or may encumber the title of Landlord. No rights to any view or to light or air over any property, whether belonging to Landlord or any other person, are granted to Tenant by this Lease.

24.8 Tenant’s Signs.

24.8.1 Interior Signs. Tenant shall be entitled, at its sole cost and expense, to one (1) identification sign on or near the entry doors of the Premises, and for multi-tenant floors, one (1) identification or directional sign, as designated by Landlord, in the elevator lobby on the floor on which the Premises are located. Such signs shall be installed by a signage contractor designated by Landlord. The location, quality, design, style, lighting and size of such signs shall be consistent with the Landlord’s Building standard signage program and shall be subject to Landlord’s prior written approval, in its reasonable discretion. Upon the expiration or earlier termination of this Lease, Tenant shall be responsible, at its sole cost and expense, for the removal of such signage and the repair of all damage to the Building caused by such removal. Except for such identification signs, Tenant may not install any signs on the exterior or roof of the Building, the Other Existing Buildings or the common areas of the Building or the Project. Any signs, window coverings, or blinds (even if the same are located behind the Landlord approved window coverings for the Building), or other items visible from the exterior of the Premises or Building are subject to the prior approval of Landlord, in its sole and absolute discretion.

24.8.2 Rail Signage and Stairwell Landing Wall Sign. Subject to the approval of all applicable governmental and quasi- governmental entities, and subject to all applicable governmental and quasi-governmental laws, rules, regulations and codes and any covenants, conditions and restrictions affecting the Real Property, Landlord hereby grants Tenant the non-exclusive right (i) to have one (1) name sign containing the name “TP Therapeutics” on the rail sign system serving the Building (the “Tenant’s Rail Sign”) and (ii) to have one (1) wall sign on the stairwell landing (the “Wall Sign”). The design, size, specifications, graphics, materials, manner of affixing, exact location, colors and lighting (if applicable) of Tenant’s Rail Sign and Wall Sign shall be (i) consistent with the quality and appearance of the Project, (ii) subject to the approval of all applicable governmental and quasi-governmental authorities, and subject to all applicable governmental and quasi-governmental laws, rules, regulations and codes and any covenants, conditions and restrictions affecting the Real Property, and (iii) subject to Landlord’s approval (which shall not be unreasonably withheld, conditioned or delayed). Landlord shall install Tenant’s Rail Sign and Wall Sign at Tenant’s sole cost and expense. In addition, Tenant shall be responsible for all other costs attributable to the fabrication, insurance, lighting (if applicable),

maintenance, repair and removal of Tenant’s Rail Sign and Wall Sign. The signage right granted to Tenant under this Section 24.8.2 are personal to the original Tenant executing this Lease (“Original Tenant”) and may not be exercised or used by or assigned to any other person or entity. In addition, Original Tenant shall no longer have any right to Tenant’s Rail Sign and Wall Sign if at any time during the Term the Original Tenant does not lease and occupy the entire Premises then leased by Tenant hereunder. Upon the expiration or sooner termination of this Lease, or upon the earlier termination of Tenant’s signage right under this Section 24.8.2, Landlord shall have the right to permanently remove Tenant’s Rail Sign and Wall Sign from the Building and/or the Project and to repair all damage to the Building and/or the Project resulting from such removal and restore the affected area to its original condition existing prior to the installation of Tenant’s Rail Sign and Wall Sign, and Tenant shall reimburse Landlord for the costs thereof.

24.9 Relationship of Parties. Nothing contained in this Lease shall be deemed or construed by the parties hereto or by any third party to create the relationship of principal and agent, partnership, joint venturer or any association between Landlord and Tenant, it being expressly understood and agreed that neither the method of computation of Rent nor any act of the parties hereto shall be deemed to create any relationship between Landlord and Tenant other than the relationship of landlord and tenant.

24.10 Application of Payments. Landlord shall have the right to apply payments received from Tenant pursuant to this Lease, regardless of Tenant’s designation of such payments, to satisfy any obligations of Tenant hereunder, in such order and amounts as Landlord, in its sole discretion, may elect.

24.11 Time of Essence. Time is of the essence of this Lease and each of its provisions.

24.12 Partial Invalidity. If any term, provision or condition contained in this Lease shall, to any extent, be invalid or unenforceable, the remainder of this Lease, or the application of such term. provision or condition to persons or circumstances other than those with respect to which it is invalid or unenforceable, shall not be affected thereby, and each and every other term, provision and condition of this Lease shall be valid and enforceable to the fullest extent possible permitted by law.

24.13 No Warranty. In executing and delivering this Lease, Tenant has not relied on any representation, including, but not limited to, any representation whatsoever as to the amount of any item comprising Additional Rent or the amount of the Additional Rent in the aggregate or that Landlord is furnishing the same services to other tenants, at all, on the same level or on the same basis, or any warranty or any statement of Landlord which is not set forth herein or in one or more of the Exhibits attached hereto.

24.14 Landlord Exculpation. Notwithstanding anything in this Lease to the contrary, and notwithstanding any applicable law to the contrary, the liability of Landlord and the Landlord Parties under this Lease (including any successor landlord) and any recourse by Tenant against Landlord or the Landlord Parties shall be limited solely and exclusively to an amount which is equal to the ownership interest of Landlord in the Project (excluding any proceeds thereof), and neither Landlord, nor any of the Landlord Parties shall have any personal liability therefor, and Tenant hereby expressly waives and releases such personal liability on behalf of itself and all persons claiming by, through or under Tenant.

24.15 Entire Agreement. There are no oral agreements between the parties hereto affecting this Lease and this Lease supersedes and cancels any and all previous negotiations, arrangements, brochures, agreements and understandings, if any, between the parties hereto or displayed by Landlord to Tenant with respect to the subject matter thereof, and none thereof shall be used to interpret or construe this Lease. This Lease and any side letter or separate agreement executed by Landlord and Tenant in connection with this Lease and dated of even date herewith contain all of the terms, covenants, conditions, warranties and agreements of the parties relating in any manner to the rental, use and occupancy of the Premises, shall be considered to be the only agreement between the parties hereto and their representatives and agents, and none of the terms, covenants, conditions or provisions of this Lease can be modified, deleted or added to except in writing signed by the parties hereto. All negotiations and oral agreements acceptable to both parties have been merged into and are included herein. There are no other representations or warranties between the parties, and all reliance with respect to representations is based totally upon the representations and agreements contained in this Lease.

24.16 Right to Lease. Landlord reserves the absolute right to effect such other tenancies in the Building, the Other Existing Buildings and/or in any other building and/or any other portion of the Project as Landlord in the exercise of its sole business judgment shall determine to best promote the interests of the Project. Tenant does not rely on the fact, nor does Landlord represent, that any specific tenant or type or number of tenants shall, during the Lease Term, occupy any space in the Building, the Other Existing Buildings or Project.

24.17 Force Majeure. Any prevention, delay or stoppage due to strikes, lockouts, labor disputes, acts of God, inability to obtain services, labor, or materials or reasonable substitutes therefor, governmental actions, civil commotions, fire or other casualty, and other causes beyond the reasonable control of the party obligated to perform, except with respect to the obligations imposed with regard to Rent and other charges to be paid by Tenant pursuant to this Lease and except with respect to Tenant’s obligations under the Tenant Work Letter (collectively, the “Force Majeure”), notwithstanding anything to the contrary contained in this Lease, shall excuse the performance of such party for a period equal to any such prevention, delay or stoppage and, therefore, if this Lease specifies a time period for performance of an obligation of either party, that time period shall be extended by the period of any delay in such party’s performance caused by a Force Majeure.

24.18 Waiver of Redemption by Tenant. Tenant hereby waives for Tenant and for all those claiming under Tenant all right now or hereafter existing to redeem by order or judgment of any court or by any legal process or writ, Tenant’s right of occupancy of the Premises after any termination of this Lease.

24.19 Notices. All notices, demands, statements or communications (collectively, “Notices”) given or required to be given by either party to the other hereunder shall be in writing, shall be sent by United States certified or registered mail, postage prepaid, return receipt requested, or delivered personally (i) to Tenant at the appropriate address set forth in Section 5 of the Summary, or to such other place as Tenant may from time to time designate in a Notice to Landlord; or (ii) to Landlord at the addresses set forth in Section 3 of the Summary, or to such other firm or to such other place as Landlord may from time to time designate in a Notice to Tenant. Any Notice will be deemed given on the date it is mailed as provided in this Section 24.19 or upon the date personal delivery is made or rejected. If Tenant is notified of the identity and address of Landlord’s mortgagee or ground lessor, Tenant shall give to such mortgagee or ground lessor written notice of any default by Landlord under the terms of this Lease by registered or certified mail, and such mortgagee or ground lessor shall be given a reasonable opportunity to cure such default prior to Tenant’s exercising any remedy available to Tenant.

24.20 Joint and Several. If there is more than one person or entity executing this Lease as Tenant, the obligations imposed upon such persons and entities under this Lease are and shall be joint and several.

24.21 Authority. Each individual executing this Lease on behalf of Tenant hereby represents and warrants that Tenant is a duly formed and existing entity qualified to do business in the state in which the Project is located and that Tenant has full right and authority to execute and deliver this Lease and that each person signing on behalf of Tenant is authorized to do so. Tenant confirms that it is not in violation of any executive order or similar governmental regulation or law, which prohibits terrorism or transactions with suspected or confirmed terrorists or terrorist entities or with persons or organizations that are associated with, or that provide any form of support to, terrorists. Neither Tenant nor any of its affiliates, nor to its knowledge any of their respective brokers or other agents acting in any capacity in connection with the transactions contemplated by this Lease, is or will be (a) conducting any business or engaging in any transaction or dealing with any person appearing on the U.S. Treasury Department’s OFAC list of prohibited countries, territories, “specifically designated nationals” (“SDNs”) or “blocked person” (each a “Prohibited Person”) (which lists can be accessed at the following web address: http://www.ustreas.gov/offices/enforcement/ofac/), including the making or receiving of any contribution of funds, goods or services to or for the benefit of any such Prohibited Person; (b) engaging in certain dealings with countries and organizations designated under Section 311 of the USA PATRIOT Act as warranting special measures due to money laundering concerns; (c) dealing in, or otherwise engaging in any transaction relating to, any property or interests in property blocked pursuant to Executive Order No. 13224 dated September 24, 2001, relating to “Blocking Property and Prohibiting Transactions With Persons Who Commit, Threaten to Commit, or Support Terrorism”; (d) a foreign shell bank or any person that a financial institution would be prohibited from transacting with under the USA PATRIOT Act; or (e) engaging in or conspiring to engage in any transaction that evades or avoids, or has the purpose of evading or avoiding, or attempting to violate, any of the prohibitions set forth in (i) any U.S. anti-money laundering law, (ii) the Foreign Corrupt Practices Act, (iii) the U.S. mail and wire fraud statutes, (iv) the Travel Act, (v) any similar or successor statutes or (vi) any regulations promulgated under the foregoing statutes.

24.22 Jury Trial; Attorneys’ Fees. IF EITHER PARTY COMMENCES LITIGATION AGAINST THE OTHER FOR THE SPECIFIC PERFORMANCE OF THIS LEASE, FOR DAMAGES FOR THE BREACH HEREOF OR OTHERWISE FOR ENFORCEMENT OF ANY REMEDY HEREUNDER, THE PARTIES HERETO AGREE TO AND HEREBY DO WAIVE ANY RIGHT TO A TRIAL BY JURY. In the event of any such commencement of litigation, the prevailing party shall be entitled to recover from the other party such costs and reasonable attorneys’ fees as may have been incurred, including any and all costs incurred in enforcing, perfecting and executing such judgment.

24.23 Governing Law. This Lease shall be construed and enforced in accordance with the laws of the state in which the Project is located.

24.24 Submission of Lease. Submission of this instrument for examination or signature by Tenant does not constitute a reservation of or an option for lease, and it is not effective as a lease or otherwise until execution and delivery by both Landlord and Tenant.

24.25 Brokers. Landlord and Tenant each hereby represents and warrants to the other party that it (i) has had no dealings with any real estate broker or agent in connection with the negotiation of this Lease, excepting only the real estate brokers or agents specified in Section 11 of the Summary (collectively, the “Brokers”), and (ii) knows of no other real estate broker or agent who is entitled to a commission in connection with this Lease. Each party agrees to indemnify and defend the other party against and hold the other party harmless from any and all claims, demands, losses, liabilities, lawsuits, judgments, and costs and expenses (including without limitation reasonable attorneys’ fees) with respect to any leasing commission or equivalent compensation alleged to be owing on account of the indemnifying party’s dealings with any real estate broker or agent in connection with this Lease other than the Brokers.

24.26 Independent Covenants. This Lease shall be construed as though the covenants herein between Landlord and Tenant are independent and not dependent and Tenant hereby expressly waives the benefit of any statute to the contrary and agrees that if Landlord fails to perform its obligations set forth herein, Tenant shall not be entitled to make any repairs or perform any acts hereunder at Landlord’s expense or to any setoff of the Rent or other amounts owing hereunder against Landlord; provided, however, that the foregoing shall in no way impair the right of Tenant to commence a separate action against Landlord for any violation by Landlord of the provisions hereof so long as notice is first given to Landlord and any holder of a mortgage or deed of trust covering the Building, Project or any portion thereof, of whose

address Tenant has theretofore been notified, and an opportunity is granted to Landlord and such holder to correct such violations as provided above.

24.27 Building Name and Signage. Landlord shall have the right at any time to change the name(s) of the Building, the Other Existing Buildings and Project and to install, affix and maintain any and all signs on the exterior and on the interior of the Building, the Other Existing Buildings and any portion of the Project as Landlord may, in Landlord’s sole discretion, desire. Tenant shall not use the names of the Building, the Other Existing Buildings or Project or use pictures or illustrations of the Building, the Other Existing Buildings or Project in advertising or other publicity, without the prior written consent of Landlord.

24.28 Building Directory. Landlord shall include Tenant’s name and location in the Building on one (1) line on the Building directory. The initial cost of such directory signage shall be paid for by Landlord, but any subsequent charges thereto shall be at Tenant’s cost.

24.29 Confidentiality. Tenant acknowledges that the content of this Lease and any related documents are confidential information. Tenant shall keep such confidential information strictly confidential and shall not disclose such confidential information to any person or entity other than Tenant’s financial, legal, and space planning consultants.

24.30 Landlord’s Construction. Except as specifically set forth in this Lease or in the Tenant Work Letter: (i) Landlord has no obligation to alter, remodel, improve, renovate, repair or decorate the Premises, the Building, the Other Existing Buildings, the Project, or any part thereof; and (ii) no representations or warranties respecting the condition of the Premises, the Building, the Other Existing Buildings or the Project have been made by Landlord to Tenant. Tenant acknowledges that prior to and during the Lease Term, Landlord (and/or any common area association) will be completing construction and/or demolition work pertaining to various portions of the Building, the Other Existing Buildings, the Premises, and/or the Project, including without limitation, landscaping and tenant improvements for premises for other tenants and, at Landlord’s sole election, such other buildings, improvements, landscaping and other facilities within or as part of the Project as Landlord (and/or such common area association) shall from time to time desire (collectively, the “Construction”). In connection with such Construction, Tenant acknowledges that Landlord may, among other things, erect scaffolding or other necessary structures in the Building and/or the Other Existing Buildings, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, the Other Existing Buildings and/or the Project, which work may create noise, dust or leave debris in the Building, the Other Existing Buildings and/or the Project.

IN WITNESS WHEREOF, Landlord and Tenant have caused this Lease to be executed the day and date first above written.

*** If Tenant is a CORPORATION, the authorized officers must sign on behalf of the corporation and indicate the capacity in which they are signing. The Lease must be executed by the president or vice president and the secretary or assistant secretary, unless the bylaws or a resolution of the board of directors shall otherwise provide, in which event, the bylaws or a certified copy of the resolution, as the case may be, must be attached to this Lease.

EXHIBIT A

OUTLINE OF FLOOR PLAN OF PREMISES

EXHIBIT A-1

SITE PLAN OF PROJECT

EXHIBIT B

TENANT WORK LETTER

This Tenant Work Letter (“Tenant Work Letter”) sets forth the terms and conditions relating to the construction of improvements for the Premises. All references in this Tenant Work Letter to the “Lease” shall mean the relevant portions of the Lease to which this Tenant Work Letter is attached as Exhibit B.

SECTION 1

BASE, SHELL AND CORE

Landlord has previously constructed the base, shell and core (i) of the Premises and (ii) of the floor(s) of the Building on which the Premises are located (collectively, the “Base, Shell and Core”), and Tenant shall accept the Base, Shell and Core in its current “As-Is” condition existing as of the date of the Lease and the Lease Commencement Date. Except as otherwise provided below, Landlord shall not be obligated to make or pay for any alterations or improvements to the Premises, the Building or the Project.

SECTION 2

CONSTRUCTION DRAWINGS FOR THE PREMISES

Prior to the execution of the Lease, Landlord and Tenant have approved a detailed space plan for the construction of certain improvements in the Premises, (the “Final Space Plan”), which Final Space Plan is dated January 14, 2016 and was prepared by DGA; such Final Space Plan is attached hereto as Schedule “I”. Based upon and in conformity with the Final Space Plan, Landlord shall cause its architect and engineers to prepare and deliver to Tenant, for Tenant’s approval, detailed specifications and engineered working drawings for the tenant improvements shown on the Final Space Plan (the “Working Drawings”). The Working Drawings shall incorporate modifications to the Final Space Plan as necessary to comply with the floor load and other structural and system requirements of the Building. To the extent that the finishes and specifications are not completely set forth in the Final Space Plan for any portion of the tenant improvements depicted thereon, the actual specifications and finish work shall be in accordance with the specifications for the Building’s standard tenant improvement items, as determined by Landlord. Within three (3) business days after Tenant’s receipt of the Working Drawings, Tenant shall approve or disapprove the same, which approval shall not be unreasonably withheld; provided, however, that Tenant may only disapprove the Working Drawings to the extent such Working Drawings are inconsistent with the Final Space Plan and only if Tenant delivers to Landlord, within such three (3) business day period, specific changes proposed by Tenant which are consistent with the Final Space Plan and do not constitute changes which would result in any of the circumstances described in items (i) through (iv) hereinbelow. If any such revisions are timely and properly proposed by Tenant, Landlord shall cause its architect and engineers to revise the Working Drawings to incorporate such revisions and submit the same for Tenant’s approval in accordance with the foregoing provisions, and the parties shall follow the foregoing procedures for approving the Working Drawings until the same are finally approved by Landlord and Tenant. Upon Landlord’s and Tenant’s approval of the Working Drawings, the same shall be known as the “Approved Working Drawings”. The tenant improvements shown on the Approved Working Drawings shall be referred to herein as the “Tenant Improvements”. Once the Approved Working Drawings have been approved by Landlord and Tenant, Tenant shall make no changes, change orders or modifications thereto without the prior written consent of Landlord, which consent may be withheld in Landlord’s sole discretion if such change or modification would: (i) delay the Substantial Completion of the Premises (as defined below); (ii) increase the costs of the design, permitting and construction of the Tenant Improvements above the costs of the design, permitting and construction of those tenant improvements depicted in the Final Space Plan; (iii) be of a quality lower than the quality of the standard tenant improvement items for the Building; and/or (iv) require any changes to the Base, Shell and Core or structural improvements or systems of the Building. The Final Space Plan, Working Drawings and Approved Working Drawings shall be collectively referred to herein as, the “Construction Drawings”.

SECTION 3

CONSTRUCTION AND PAYMENT FOR COSTS OF TENANT IMPROVEMENTS

Landlord and Tenant hereby agree that Landlord shall, at Landlord’s expense (except as provided in this Section 3) cause a general contractor designated by Landlord (the “Contractor”) to (i) obtain all applicable building permits for construction of the Tenant Improvements (collectively, the “Permits”), and (ii) construct the Tenant Improvements as depicted on the Approved Working Drawings, in compliance with such building permits and all applicable laws in effect at the time of construction, and in good workmanlike manner; provided, however, if (A) the Approved Working Drawings differ with respect to the quality and quantity of those tenant improvements depicted on the Final Space Plan, and/or (B) Tenant shall request any changes or substitutions to any of the Construction Drawings, and such differences, changes and/or substitutions result in increased costs of the design, permitting and construction of the Tenant Improvements in excess of the costs of the design, permitting and construction of those tenant improvements depicted on the Final Space Plan, then Tenant shall pay such excess costs (which shall include a Landlord’s supervision fee of five percent (5%) of such costs) to Landlord in cash within ten (10) days after Landlord’s request therefor. Notwithstanding the foregoing to the contrary, in no event shall Landlord be obligated to pay for the costs of any of Tenant’s furniture, computer systems, telephone systems, equipment or other personal property which may be depicted on the Construction Drawings; the costs of such items shall be paid for by Tenant from Tenant’s own funds.

SECTION 4

READY FOR OCCUPANCY; SUBSTANTIAL COMPLETION OF THE TENANT IMPROVEMENTS

4.1 Ready for Occupancy; Substantial Completion. For purposes of the Lease, including for purposes of determining the Lease Commencement Date (as set forth in Section 7.2 of the Summary); (i) the Premises shall be “Ready for Occupancy” upon Substantial Completion of the Premises; and (ii) “Substantial Completion of the Premises” shall occur upon the completion of construction of the Tenant Improvements in the Premises pursuant to the Approved Working Drawings, with the exception of any punch list items that do not materially and adversely affect Tenant’s use and occupancy of the Premises and any tenant fixtures, work-stations, built-in furniture, or equipment to be installed by Tenant or under the supervision of the Contractor.

4.2 Delay of the Substantial Completion of the Premises. If there shall be a delay or there are delays in the Substantial Completion of the Premises as a result of any of the following (collectively, “Tenant Delays”):

4.2.1 Tenant’s failure to timely approve the Working Drawings or any other matter requiring Tenant’s approval;

4.2.2 a breach by Tenant of the terms of this Tenant Work Letter or the Lease;

4.2.3 Tenant’s request for changes in any of the Construction Drawings;

4,2.4 Tenant’s requirement for materials, components, finishes or improvements which are not available in a commercially reasonable time given the estimated date of Substantial Completion of the Premises, as set forth in the Lease, or which are different from, or not included in, Landlords standard tenant improvement items for the Building;

4.2.5 changes to the Base. Shell and Core, structural components or structural components or systems of the Building required by the Approved Working Drawings;

4.2.6 any changes in the Construction Drawings and/or the Tenant Improvements required by applicable laws if such changes are directly attributable to Tenant’s use of the Premises or Tenant’s specialized tenant improvement(s) (as determined by Landlord); or

4.2.7 any other acts or omissions of Tenant, or its agents, or employees;

then, notwithstanding anything to the contrary set forth in the Lease and regardless of the actual date of Substantial Completion of the Premises, the Lease Commencement Date (as set forth in Section 7.2 of the Summary) shall be deemed to be the date the Lease Commencement Date would have occurred if no Tenant Delays, as set forth above, had occurred.

SECTION 5

MISCELLANEOUS

5.1 Tenant’s Entry Into the Premises Prior to Substantial Completion. Subject to the terms hereof and provided that Tenant and its agents do not materially interfere with the Contractor’s work in the Project, the Building and the Premises, at Landlord’s reasonable discretion, Tenant shall have access to the Premises prior to the anticipated Substantial Completion of the Premises for the purpose of Tenant inspecting the Contractor’s work and installing equipment and/or fixtures (including Tenant’s data and telephone equipment) and Tenant’s furniture in the Premises. Prior to Tenant’s entry into the Premises as permitted by the terms of this Section 5.1, Tenant shall submit a schedule to Landlord and the Contractor, for their approval, which schedule shall detail the timing and purpose of Tenant’s entry. In connection with any such entry, Tenant acknowledges and agrees that Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees shall fully cooperate, work in harmony and not, in any manner, interfere with Landlord or Landlord’s contractors (including the Contractor), agents or representatives in performing work in the Project, the Building and the Premises, or interfere with the general operation of the Building and/or the Project. If at any time any such person representing Tenant shall not be cooperative or shall otherwise cause or threaten to cause any such disharmony or interference, including, without limitation, labor disharmony, and Tenant fails to immediately institute and maintain corrective actions as directed by Landlord in writing, then Landlord may revoke Tenant’s entry rights upon twenty-four (24) hours’ prior written notice to Tenant. Tenant acknowledges and agrees that any such entry into and occupancy of the Premises or any portion thereof by Tenant or any person or entity working for or on behalf of Tenant shall be deemed to be subject to all of the terms, covenants, conditions and provisions of the Lease, excluding only the covenant to pay Rent (until the occurrence of the Lease Commencement Date). Tenant further acknowledges and agrees that Landlord shall not be liable for any injury, loss or damage which may occur to any of Tenant’s work made in or about the Premises in connection with such entry or to any property placed therein prior to the Lease Commencement Date, the same being at Tenant’s sole risk and liability. Tenant shall be liable to Landlord for any damage to any portion of the Premises, including the Tenant Improvement work, caused by Tenant or any of Tenant’s employees, agents, contractors, consultants, workmen, mechanics, suppliers and invitees. If the performance of Tenant’s work in connection with such entry causes extra costs to be incurred by Landlord or requires the use of any Building services, Tenant shall promptly reimburse Landlord for such extra costs and/or shall pay Landlord for such Building services at Landlord’s standard rates then in effect. In addition, Tenant shall hold Landlord harmless from and indemnify, protect and defend Landlord against

any loss or damage to the Premises or Project and against injury to any persons caused by Tenant’s actions pursuant to this Section 5.1.

5.2 Tenant’s Representative. Tenant has designated Peter Li as its sole representative with respect to the matters set forth in this Tenant Work Letter, who shall have full authority and responsibility to act on behalf of the Tenant as required in this Tenant Work Letter,

5.3 Landlord’s Representative. Landlord has designated Samantha Lagman as its sole representative with respect to the matters set forth in this Tenant Work Letter, who, until further notice to Tenant, shall have full authority and responsibility to act on behalf of the Landlord as required in this Tenant Work Letter.

5.4 Time of the Essence in This Tenant Work Letter. Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord. Both Landlord and Tenant shall use commercially reasonable, good faith, efforts and all due diligence to cooperate with each other to complete all phases of the Construction Drawings and the permitting process and to receive the permits, as soon as possible after the execution of the Lease, and, in that regard, shall meet on a scheduled basis to be determined by Landlord and Tenant, to discuss progress in connection with the same.

5.5 Tenant’s Lease Default. Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant of this Tenant Work Letter or the Lease has occurred at any time on or before the Substantial Completion of the Premises and remains after the expiration of applicable notice and cure periods, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to cause the Contractor to suspend the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 4.2 above), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to a default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter, in addition to any other remedies available to Landlord under the Lease, at law and/or in equity, Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) business days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.

Schedule “I”

FINAL SPACE PLAN

EXHIBIT C

AMENDMENT TO LEASE

This AMENDMENT TO LEASE (“Amendment”) is made and entered into effective as of                                 , 20    , by and between WALTON TORREY OWNER A, L.L.C., a Delaware limited liability company (“Landlord”) and TP THERAPEUTICS, INC., a Delaware corporation (“Tenant”).

R E C I T A L S:

A. Landlord and Tenant entered into that certain Lease dated as of                                  (the “Lease”) pursuant to which Landlord leased to Tenant and Tenant leased from Landlord certain “Premises”, as described in that Lease, in that certain building located at                                 , San Diego, California             .

B. Except as otherwise set forth herein, all capitalized terms used in this Amendment shall have the same meaning as such terms have in the Lease.

C. Landlord and Tenant desire to amend the Lease to confirm the commencement and expiration dates of the term, as hereinafter provided.

NOW, THEREFORE, in consideration of the foregoing Recitals and the mutual covenants contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:

1. Confirmation of Dates. The parties hereby confirm that (a) the Premises are Ready for Occupancy, and (b) the term of the Lease commenced as of                                          for a term of                                          ending on                                          (unless sooner terminated as provided in the Lease.

2. No Further Modification. Except as set forth in this Amendment, all of the terms and provisions the Lease shall remain unmodified and in full force and effect.

IN WITNESS WHEREOF, this Amendment has been executed as of the day and year first above written.

EXHIBIT D

RULES AND REGULATIONS

Tenant shall faithfully observe and comply with the following Rules and Regulations and the Parking Rules and Regulations. Landlord shall not be responsible to Tenant for the nonperformance of any of said Rules and Regulations and/or the Parking Rules and Regulations by or otherwise with respect to the acts or omissions of any other tenants or occupants of the Building and/or the Project.

1. Tenant shall not place any lock(s) on any door, or install any security system (including, without limitation, card key systems, alarms or security cameras), in the Premises without Landlord’s prior written consent, which consent shall not be unreasonably withheld, and Landlord shall have the right to retain at all times and to use keys or other access codes or devices to all locks and/or security systems within and to the Premises. A reasonable number of keys to the locks on the entry doors of the Premises shall be furnished by Landlord to Tenant at Tenant’s cost, and Tenant shall not make any duplicate keys. All keys shall be returned to Landlord at the expiration or earlier termination of the Lease. Further, if and to the extent Tenant re-keys, re-programs or otherwise changes any locks in or for the Premises, all such locks and key systems must be consistent with the master lock and key system at the Building, all at Tenant’s sole cost and expense.

2. All doors opening to public corridors shall be kept closed at all times except for normal ingress and egress to the Premises, unless electrical hold backs have been installed. Sidewalks, doorways, passages, entrances, vestibules, halls, stairways and other Common Areas shall not be obstructed by Tenant or used by Tenant for any purpose other than ingress and egress to and from the Premises, and Tenant, its employees and agents shall not loiter in the entrances or corridors.

3. Landlord reserves the right to close and keep locked all entrance and exit doors of the Building during such hours as are customary for comparable buildings in the vicinity of the Building. Tenant and its employees and agents shall ensure that the doors to the Building are securely closed and locked when leaving the Premises if it is after the normal hours of business for the Building. Any tenant, its employees, agents or any other persons entering or leaving the Building at any time when it is so locked, or any time when it is considered to be after normal business hours for the Building, may be required to sign the Building register when so doing. After-hours access by Tenant’s authorized employees may be provided by hard-key, card-key access or other procedures adopted by Landlord from time to time; Tenant shall pay for the costs of all access cards provided to Tenant’s employees and all replacements thereof for lost, stolen and/or damaged cards. Access to the Building and/or the Project may be refused unless the person seeking access has proper identification or has a previously arranged pass for such access. Landlord and its agents shall in no case be liable for damages for any error with regard to the admission to or exclusion from the Building and/or the Project of any person. In case of invasion, mob, riot, public excitement, or other commotion, Landlord reserves the right to prevent access to the Building and/or the Project during the continuance of same by any means it deems appropriate for the safely and protection of life and property.

4. Landlord shall have the right to prescribe the weight, size and position of all safes and other heavy property brought into the Building. Safes and other heavy objects shall, if considered necessary by Landlord, stand on supports of such thickness as is necessary to properly distribute the weight. Landlord will not be responsible for loss of or damage to any such safe or property in any case. All damage done to any part of the Building, its contents, occupants and/or visitors by moving or maintaining any such safe or other property shall be the sole responsibility of Tenant and any expense of said damage or injury shall be borne by Tenant.

5. No furniture, freight, packages, supplies, equipment or merchandise will be brought into or removed from the Building or carried up or down in the elevators, except upon prior notice to Landlord, and in such manner, in such specific elevator, and between such hours as shall be designated by Landlord. Tenant shall provide Landlord with not less than 24 hours prior notice of the need to utilize an elevator for any such purpose, so as to provide Landlord with a reasonable period to schedule such use and to install such padding or take such other actions or prescribe such procedures as are appropriate to protect against damage to the elevators or other parts of the Building. Tenant shall assume all risk for damage to articles moved and injury to any persons resulting from such activity described herein. If equipment, property, or personnel of Landlord or of any other party is damaged or injured as a result of or in connection with such activity described herein, Tenant shall be solely liable for any resulting damage or loss.

6. Landlord shall have the right to control and operate the public portions of the Building and Project, the public facilities, the heating and air conditioning, and any other facilities furnished for the common use of tenants, in such manner as is customary for comparable buildings in the vicinity of the Building.

7. No signs, advertisements or notices shall be painted or affixed to windows, doors or other parts of the Building, except those of such color, size, style and in such places as are first approved in writing by Landlord. Landlord shall have the right to remove any signs, advertisements, and notices not approved in writing by Landlord without notice to and at the expense of Tenant. Landlord may provide and maintain in the first floor (main lobby) of the Building an alphabetical directory board or other directory device listing tenants, and no other directory shall be permitted unless previously consented to by Landlord in writing.

8. The requirements of Tenant will be attended to only upon application at the management office of the Project or at such office location designated by Landlord.

9. Tenant shall not disturb (by use of any television, radio or musical instrument, making loud or disruptive noises, creating offensive odors or otherwise), solicit or canvass any occupant of the Building and/or the Project and shall cooperate with Landlord or Landlord’s agents to prevent same.

10. The toilet rooms, urinals, wash bowls and other apparatus shall not be used for any purpose other than that for which they were constructed, and no foreign substance of any kind whatsoever shall be thrown therein. The expense of any breakage, stoppage or damage resulting from the violation of this rule shall be borne by the tenant who, or whose employees or invitees, shall have caused it.

11. Tenant shall not overload the floor of the Premises. Tenant shall not mark, drive nails or screws, or drill into the partitions, woodwork or plaster or in any way deface the Premises or any part thereof without Landlord’s consent first had and obtained; provided, however, Landlord’s prior consent shall not be required with respect to Tenant’s placement of pictures and other normal office wall hangings on the interior walls of the Premises (but at the end of the Lease Term, Tenant shall repair any holes and other damage to the Premises resulting therefrom).

12. Except for vending machines intended for the sole use of Tenant’s employees and invitees. no vending machine or machines of any description other than fractional horsepower office machines shall be installed, maintained or operated upon the Premises without the written consent of Landlord. Tenant shall not install, operate or maintain in the Premises or in any other area of the Building, electrical equipment that would overload the electrical system beyond its capacity for proper, efficient and safe operation as determined solely by Landlord.

13. Tenant shall not use any method of heating or air conditioning other than that which may be supplied by Landlord, without the prior written consent of Landlord. Tenant shall not furnish cooling or heating to the Premises, including, without limitation, the use of electronic or gas heating devices, portable coolers (such as “move n cools”) or space heaters, without Landlord’s prior written consent, and any such approval will be for devices that meet federal, state and local code.

14. No inflammable, explosive or dangerous fluids or substances shall be used or kept by Tenant in the Premises, Building and/or about the Project, except for those substances as are typically found in similar premises used for general office purposes and are being used by Tenant in a safe manner and in accordance with all applicable Laws, rules and regulations. Tenant shall not, without Landlord’s prior written consent, use, store, install, spill, remove, release or dispose of, within or about the Premises or any other portion of the Project, any asbestos-containing materials or any solid, liquid or gaseous material now or subsequently considered toxic or hazardous under the provisions of 42 U.S.C. Section 9601 et seq. or any other applicable environmental Laws which may now or later be in effect. Tenant shall comply with all Laws pertaining to and governing the use of these materials by Tenant, and shall remain solely liable for the costs of abatement and removal.

15. Tenant shall not use, keep or permit to be used or kept, any foul or noxious gas or substance in or on the Premises, or permit or allow the Premises to be occupied or used in a manner offensive or objectionable to Landlord or other occupants of the Building and/or the Project by reason of noise, odors, or vibrations, or interfere in any way with other tenants or those having business therewith.

16. Tenant shall not bring into or keep within the Project, the Building or the Premises any animals (except those assisting handicapped persons), birds, fish tanks, bicycles or other vehicles.

17. Tenant shall not use or occupy the Premises in any manner or for any purpose which might injure the reputation or impair the present or future value of the Premises, the Building and/or the Project. Tenant shall not use, or permit any part of the Premises to be used, for lodging, sleeping or for any illegal purpose.

18. No cooking shall be done or permitted by Tenant on the Premises, nor shall the Premises be used for the storage of merchandise or for any improper, objectionable or immoral purposes. Notwithstanding the foregoing, Underwriters’ laboratory-approved equipment and microwave ovens may be used in the Premises for heating food and brewing coffee, tea, hot chocolate and similar beverages, provided that such use is in accordance with all applicable federal, state and city laws, codes, ordinances, rules and regulations, and does not cause odors which are objectionable to Landlord and other tenants.

19. Landlord will approve where and how telephone and telegraph wires and other cabling are to be introduced to the Premises. No boring or cutting for wires shall be allowed without the consent of Landlord. The location of telephone, call boxes and other office equipment and/or systems affixed to the Premises shall be subject to the approval of Landlord. Tenant shall not use more than its proportionate share of telephone lines and other telecommunication facilities available to service the Building.

20. Landlord reserves the right to exclude or expel from the Building and/or the Project any person who, in the judgment of Landlord, is intoxicated or under the influence of liquor or drugs, or who shall in any manner do any act in violation of any of these Rules and Regulations or cause harm to Building occupants and/or property.

21. All contractors, contractor’s representatives and installation technicians performing work in the Building or at the Project shall be subject to Landlord’s prior approval, which approval shall not be unreasonably withheld, and shall be required to comply with Landlord’s standard rules, regulations, policies and procedures, which may be revised from time to time.

22. Tenant shall not employ any person other than the janitor of Landlord for the purpose of cleaning the Premises without prior written consent of Landlord, and without Landlord’s consent, no person or persons shall be permitted to enter the Building for the purpose of cleaning the same. Tenant shall not cause any unnecessary labor by reason of Tenant’s carelessness or indifference in the preservation of good order and cleanliness.

23. Tenant at all times shall maintain the entire Premises in a neat and clean, first class condition, free of debris. Tenant shall not place items, including, without limitation, any boxes, files, trash receptacles or loose cabling or wiring, in or near any window to the Premises which would be visible anywhere from the exterior of the Premises.

24. Tenant shall not waste electricity, water or air conditioning and agrees to cooperate fully with Landlord to ensure the most effective operation of the Building’s heating and air conditioning system, including, without limitation, the use of window blinds to block solar heat load, and shall refrain from attempting to adjust any controls. Tenant shall comply with and participate in any program for metering or otherwise measuring the use of utilities and services, including, without limitation, programs requiring the disclosure or reporting of the use of any utilities or services. Tenant shall also cooperate and comply with, participate in, and assist in the implementation of (and take no action that is inconsistent with, or which would result in Landlord, the Building and/or the Project failing to comply with the requirements of) any conservation, sustainability, recycling, energy efficiency, and waste reduction programs, environmental protection efforts and/or other programs that are in place and/or implemented from time to time at the Building and/or the Project, including, without limitation, any required reporting, disclosure, rating or compliance system or program (including, but not limited to, any LEED [Leadership in Energy and Environmental Design] rating or compliance system, including those currently coordinated through the U.S. Green Building Council).

25. Tenant shall store all its recyclables. trash and garbage within the interior of the Premises. No material shall be placed in the trash boxes or receptacles if such material is of such nature that it may not be disposed of in the ordinary and customary manner of removing and disposing of recyclables, trash and garbage in the city in which the Project is located without violation of any law or ordinance governing such disposal. All trash, garbage and refuse disposal shall be made only through entry-ways and elevators provided for such purposes at such times as Landlord shall designate.

26. Tenant shall comply with all safety, fire protection and evacuation procedures and regulations established by Landlord or any governmental agency.

27. Tenant shall assume any and all responsibility for protecting the Premises from theft, robbery and pilferage, which includes keeping doors locked and other means of entry to the Premises closed, when the Premises are not occupied, or when the entry to the Premises is not manned by Tenant on a regular basis.

28. No awnings or other projection shall be attached to the outside walls of the Building without the prior written consent of Landlord. No curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the Premises without the prior written consent of Landlord. The sashes, sash doors, skylights, windows, and doors that reflect or admit light and air into the halls, passageways or other public places in the Building shall not be covered or obstructed by Tenant, nor shall any bottles, parcels or other articles be placed on the windowsills. All electrical ceiling fixtures hung in offices or spaces along the perimeter of the Building must be fluorescent and/or of a quality, type, design and bulb color approved by Landlord.

29. The washing and/or detailing of or, the installation of windshields, radios, telephones in or general work on, automobiles shall not be allowed on the Project, except under specific arrangement with Landlord.

30. Food vendors shall be allowed in the Building upon receipt of a written request from Tenant delivered to Landlord. The food vendor shall service only the tenants that have a written request on file in the management office of the Project. Under no circumstance shall the food vendor display their products in a public or Common Area including corridors and elevator lobbies. Any failure to comply with this rule shall result in immediate permanent withdrawal of the vendor from the Building. Tenant shall obtain ice, drinking water, linen, barbering, shoe polishing, floor polishing, cleaning, janitorial, plant care or other similar services only from vendors who have registered in the management office of the Project and who have been approved by Landlord for provision of such services in the Premises.

31. Tenant must comply with requests by the Landlord concerning the informing of their employees of items of importance to the Landlord.

32. Tenant shall comply with any non-smoking ordinance adopted by any applicable governmental authority. Neither Tenant nor its agents, employees, contractors, guests or invitees shall smoke or permit smoking in the Premises and/or the Common Areas, unless the Common Areas have been declared a designated smoking area by Landlord, nor shall the above parties allow smoke from the Premises to emanate into the Common Areas or any other part of the Building. Landlord shall have the right to designate the Building (including the Premises) as a non-smoking building.

33. Tenant shall not take any action which would violate Landlord’s labor contracts or which would cause a work stoppage, picketing, labor disruption or dispute, or interfere with Landlord’s or any other tenant’s or occupant’s business or with the rights and privileges of any person lawfully in the Building (“Labor Disruption”). Tenant shall take the actions necessary to resolve the Labor Disruption, and shall have pickets removed and, at the request of Landlord, immediately terminate any work in the Premises that gave rise to the Labor Disruption, until

Landlord gives its written consent for the work to resume, and Tenant shall have no claim for damages against Landlord or any of its trustees, members, principals, beneficiaries, partners, officers, directors, employees, mortgagees, or agents in connection therewith.

34. No tents, shacks, temporary or permanent structures of any kind shall be allowed on the Project. No personal belongings may be left unattended in any Common Areas.

35. Landlord shall have the right to prohibit the use of the name of the Building or Project or any other publicity by Tenant that in Landlord’s sole opinion may impair the reputation of the Building or Project or the desirability thereof. Upon written notice from Landlord. Tenant shall refrain from and discontinue such publicity immediately.

36. Landlord shall have the right to designate and approve standard window coverings for the Premises and to establish rules to assure that the Building presents a uniform exterior appearance. Tenant shall ensure, to the extent reasonably practicable, that window coverings are closed on windows in the Premises while they are exposed to the direct rays of the sun.

37. The work of cleaning personnel shall not be hindered by Tenant after 5:30 P.M., and cleaning work may be done at any time when the offices are vacant. Windows, doors and fixtures may be cleaned at any time. Tenant shall provide adequate waste and rubbish receptacles to prevent unreasonable hardship to the cleaning service.

38. Tenant shall comply with all Building security procedures as Landlord may effectuate,

39. Tenant shall at all times cooperate with Landlord in preserving a first-class image for the Building.

PARKING RULES AND REGULATIONS

1. Landlord reserves the right to establish and reasonably change the hours for the Parking Facility, on a non-discriminatory basis, from time to time. Tenant shall not store or permit its employees to store any automobiles in the Parking Facility without the prior written consent of Landlord (and/or the Parking Operator, as the case may be). Except for emergency repairs, Tenant and its employees shall not perform any work on any automobiles while located in the Parking Facility or on the Project. The Parking Facility may not be used by Tenant or its agents for overnight parking of vehicles. If it is necessary for Tenant or its employees to leave an automobile in the Parking Facility overnight, Tenant shall provide Landlord (or the Parking Operator as the case may be) with prior notice thereof designating the license plate number and model of such automobile.

2. Tenant (including Tenant’s employees and agents) will use the parking spaces solely for the purpose of parking passenger model cars, small vans and small trucks and will comply in all respects with any rules and regulations that may be promulgated by Landlord and/or the Parking Operator from time to time with respect to the Parking Facility.

3. Vehicles must be parked entirely within the stall lines painted on the floor, and only small cars may be parked in areas reserved for small cars.

4. All directional signs and arrows must be observed.

5. The speed limit shall be 5 miles per hour.

6. Parking spaces reserved for handicapped persons must be used only by vehicles properly designated.

7. Parking is prohibited in all areas not expressly designated for parking, including without limitation:

(a) areas not striped for parking:

(b) aisles;

(c) where “no parking” signs are posted:

(d) ramps: and

(e) loading zones.

8. Parking stickers, key cards and any other devices or forms of identification or entry supplied by Landlord or the Parking Operator shall remain the property of Landlord (or the Parking Operator as the case may be). Such device must be displayed as requested and may not be mutilated in any manner. The serial number of the parking identification device may not be obliterated. Parking passes and devices are not transferable and any pass or device in the possession of an unauthorized holder will be void.

9. Parking managers or attendants are not authorized to make or allow any exceptions to these Parking Rules and Regulations.

10. Every parker is required to park and lock his/her own car.

11. Loss or theft of parking passes, identification, key cards or other such devices must be reported to Landlord (and/or to the Parking Operator as the case may be) immediately. Any parking devices reported lost or stolen found on any authorized car will be confiscated and the illegal holder will be subject to prosecution. Lost or stolen

passes and devices found by Tenant or its employees must be reported to Landlord (and to the Parking Operator, as the case may be) immediately.

12. Washing, waxing, cleaning or servicing of any vehicle by the customer and/or its agents is prohibited.

13. Tenant agrees to acquaint all persons to whom Tenant assigns a parking space with these Parking Rules and Regulations.

14. Neither Landlord nor the Parking Operator (as the case may be), from time to time will be liable for loss of or damage to any vehicle or any contents of such vehicle or accessories to any such vehicle, or any property left in any of the Parking Facility, resulting from fire, theft, vandalism, accident, conduct of other users of the Parking Facility and other persons, or any other casualty or cause. Further, Tenant understands and agrees that: (i) Landlord will not be obligated to provide any traffic control, security protection or Parking Operator for the Parking Facility; (ii) Tenant uses the Parking Facility at its own risk; and (iii) Landlord will not be liable for personal injury or death, or theft, loss of or damage to property. Tenant indemnifies and agrees to hold Landlord, any Parking Operator and their respective agents and employees harmless from and against any and all claims, demands, and actions arising out of the use of the Parking Facility by Tenant and its employees and agents, whether brought by any of such persons or any other person.

15. Tenant will ensure that any vehicle parked in any of the parking spaces will be kept in proper repair and will not leak excessive amounts of oil or grease or any amount of gasoline. If any of the parking spaces are at any time used (i) for any purpose other than parking as provided above, (ii) in any way or manner reasonably objectionable to Landlord, or (iii) by Tenant after default by Tenant under the Lease, Landlord, in addition to any other rights otherwise available to Landlord, may consider such default an event of default under the Lease.

16. Tenant’s right to use the Parking Facility will be in common with other tenants of the Building and with other parties permitted by Landlord to use the Parking Facility. Landlord reserves the right to assign and reassign, from time to time, particular parking spaces for use by persons selected by Landlord, provided that Tenant’s rights under the Lease are preserved. Landlord will not be liable to Tenant for any unavailability of Tenant’s designated spaces, if any, nor will any unavailability entitle Tenant to any refund, deduction, or allowance. Tenant will not park in any numbered space or any space designated as: RESERVED, HANDICAPPED, VISITORS ONLY, or LIMITED TIME PARKING (or similar designation).

17. If the Parking Facility is damaged or destroyed, or if the use of the Parking Facility is limited or prohibited by any governmental authority, or the use or operation of the Parking Facility is limited or prevented by strikes or other labor difficulties or other causes beyond Landlord’s reasonable control, Tenant’s inability to use the parking spaces will not subject Landlord (and/or the Parking Operator. as the case may be) to any liability to Tenant and will not relieve Tenant of any of its obligations under the Lease and the Lease will remain in full force and effect. Tenant will pay to Landlord upon demand, and Tenant indemnifies Landlord against, any and all loss or damage to the Parking Facility, or any equipment, fixtures, or signs used in connection with the Parking Facility and any adjoining buildings or structures caused by Tenant or any of its employees and agents.

18. Tenant has no right to assign or sublicense any of its rights in the parking passes, except as part of a permitted assignment or sublease of the Lease; however, Tenant may allocate the parking passes among its employees.

Tenant shall be responsible for the observance of all of the Rules and Regulations and Parking Rules and Regulations in this Exhibit D by Tenant’s employees, agents, clients, customers, invitees and guests. Landlord may waive any one or more of the Rules and Regulations and/or Parking Rules and Regulations for the benefit of any particular tenant or tenants, but no such waiver by Landlord shall be construed as a waiver of such Rules and Regulations and/or Parking Rules and Regulations in favor of any other tenant or tenants, nor prevent Landlord from thereafter enforcing any such Rules or Regulations and/or Parking Rules and Regulations against any or all tenants of the Building and/or the Project. Landlord reserves the right at any time to change or rescind any one or more of these Rules and Regulations and/or the Parking Rules and Regulations, or to make such other and further reasonable Rules and Regulations and/or Parking Rules and Regulations as in Landlord’s judgment may from time to time be necessary for the management, safety, care and cleanliness of the Premises, Building and Project, and for the preservation of good order therein, as well as for the convenience of other occupants and tenants therein. Tenant shall be deemed to have read these Rules and Regulations and Parking Rules and Regulations and to have agreed to abide by them as a condition of its occupancy of the Premises.

COMMON AREA AMENITIES

1. Tenant understands that Landlord has provided or will provide certain common area amenities for Tenant’s non-exclusive use. Such amenities are for the use of tenants during regular business hours and shall be reserved through the management office in advance. Tenant and Tenant’s agents, employees and invitees shall adhere to all rules Landlord sets forth in respect to use of the amenities, which may change from time to time.

2. Tenant understands and agrees that: (i) Tenant uses the amenities at its own risk; and (ii) Landlord will not be liable for personal injury or death, or theft, loss of or damage to property. Tenant indemnifies and agrees to hold Landlord and its agents and employees harmless from and against any and all claims, demands, and actions arising out of the use of the amenities by Tenant and its agents, employees and invitees, whether brought by any of such persons or any other person.

3. All amenities offered shall remain at the locations designated by Landlord all times. Tenant must use the equipment only in the manner intended. Landlord reserves the right to limit Tenant’s use of any equipment or amenities to ensure the equitable use of the equipment and amenities by all tenants. Tenant shall not move or modify the equipment in any manner whatsoever. If Tenant has reason to believe that any equipment is malfunctioning, Tenant shall notify Landlord immediately.

4. Tenant shall be responsible for the cost or repairs or replacements of any amenities that are not returned to management after use or are damaged during the use of any such amenity by Tenant or Tenant’s agents, employees or invitees and Tenant shall reimburse Landlord for any such cost within thirty (30) days after receipt of an invoice therefor.

5. Tenant shall conduct themselves in a quiet and well-mannered fashion when on or about the amenities and not cause any disturbances or interfere with the use or enjoyment of the amenities by other tenants.

6. Tenant shall not bring any food or beverages into the bocce ball area.

7. No alcoholic beverages shall be permitted at the amenities at any time.

8. Neither Tenant nor its agents, employees or invitees shall smoke or permit smoking in the amenity areas at any time.

EXHIBIT E

INSURANCE REQUIRED OF CONTRACTORS

1. Required Insurance. Contractor shall maintain the following insurance without interruption through final completion, at any time thereafter when Contractor enters the site to perform work, and during any additional periods specified herein:

(a) Commercial general liability insurance on the current ISO CG 00 01 occurrence form or an equivalent acceptable to Owner (the “CGL”), [look at the following, grammatically] (i) covering liability arising from premises operations, independent contractors, products-completed operations, personal and advertising injury, and liability assumed under an insured contract (including the tort liability of another assumed in a business contract), (ii) with limits of not less than $1,000,000 each occurrence, $1,000,000 personal and advertising injury, $2,000,000 general aggregate, and a separate $2,000,000 products-completed operations aggregate, (iii) including the Additional Insureds (as defined in Section 6 of this Exhibit) as additional insureds, using one or more additional insured endorsements (such as a combination of CG 20 10 (or CG 20 15 for vendors) and CG 20 37) that provides coverage for both ongoing and completed operations and is acceptable to Owner, (iv) that applies as primary and non-contributing insurance with respect to any other insurance or self-insurance program afforded to the Additional Insureds, (v) that provides that any general aggregate limit applies separately to the work on a “per project” basis, (vi) that does not limit the scope of coverage for liability arising from “XCU” (explosion, collapse, or underground) hazards, and (vii) that includes a standard ISO separation of insureds provision or a substantially similar provision. Contractor shall maintain its products-completed operations coverage for at least three years after substantial completion of the work or the earlier termination of the Lease.

(b) Business automobile liability insurance to cover liability arising out of any auto (including owned, hired and non-owned autos), with a limit of not less than $1,000,000 each accident. Contractor waives all rights against the Additional Insureds for recovery of damages to the extent those damages are covered under its business automobile liability insurance (and, if applicable, commercial excess or umbrella liability insurance).

(c) Workers compensation and employers liability insurance, for all persons Contractor employs in carrying out any work. The workers compensation insurance must fulfill applicable statutory requirements. The employers liability insurance must have limits of not less than $1,000,000 each accident for bodily injury by accident, $1,000,000 each employee for bodily injury by disease, and $1,000,000 policy limit for bodily injury by disease. Contractor waives all rights against Landlord for recovery of damages covered by the workers compensation and employers liability insurance obtained by Contractor, and shall obtain an endorsement to allow this waiver. If Contractor uses borrowed employees (including employees from a temporary employment agency) to perform work, it shall require the primary employer to provide an alternate employer endorsement showing Contractor in the schedule as the alternate employer.

(d) Commercial excess or umbrella liability insurance with respect to Contractor’s CGL, business auto liability, and employers liability insurance, with a limit of not less than $3,000,000 [*Adjust as appropriate*] each occurrence. This insurance must be “true follow form,” must include the Additional Insureds as additional insureds with respect to Contractor’s CGL, must apply on a primary and noncontributing basis with respect to any other insurance or self-insurance program afforded to the Additional Insureds, and must provide that aggregate limits of liability apply separately with respect to the work.

2. Insurance Carried by Subcontractors. Contractor shall by written agreement require each of its subcontractors and consultants of every tier (“Subcontractors”) to maintain as if they were “Contractor” the insurance required in Section 1 (including naming the Additional Insureds as additional insureds), except that for Subcontractors with a contract value of less than $50,000 that are performing minor and non-hazardous work Contractor may, in its reasonable business judgment, (a) permit auto insurance limits of not less than $500,000 each accident, and (b) permit employers liability limits of not less than $500,000 per type of claim, (c) waive the requirement for a waiver of subrogation for workers compensation and employers liability insurance, and (d) waive the requirement for commercial excess or umbrella liability insurance.

3. Design Services or Design-Build Services. If any portion of the work includes any design services or design-build work, the entity or individual providing the design services shall provide professional liability insurance with a limit of not less than $1,000,000 each claim and $1,000,000 aggregate. This insurance must be retroactive to the date of the commencement of the design services, and must be maintained for three years after substantial completion of the work or the earlier termination of the Lease.

4. General Requirements. Each insurance policy required under this Exhibit E (together with the other requirements of this Exhibit E, the “Required Insurance”) must, unless otherwise agreed in writing by Landlord, be issued by reputable insurance carriers having a Best’s rating of at least A- VIII. Each policy and certificate will be subject to reasonable approval by Landlord, and Contractor shall deliver to Landlord certified copies of policies within 15 days after Landlord’s request. Except as may be specifically provided in this Agreement, the cost (including deductibles and self-insured retentions) of the Required Insurance, as well as the cost of any other insurance carried by Contractor with respect to the work, will be borne solely by Contractor, without additional reimbursement by Landlord. By requiring the Required Insurance, Landlord does not represent that the required coverage and limits will be adequate to protect Contractor, and unless otherwise specifically provided in the Lease the required coverage and limits will not limit Contractor’s other obligations under the Lease.

5. Evidence of Insurance. Concurrently with the execution of the Lease, and in any event before commencing work at the site, Contractor shall provide to Landlord (i) an insurance certificate evidencing the Required Insurance, and (ii) an endorsement to Contractor’s CGL adding the Additional Insureds as additional insureds. Contractor shall ensure that Landlord is notified at least 30 days before the cancellation or non-renewal of any Required Insurance, or 10 days prior in the case of cancellation due to non-payment. Contractor shall provide an updated certificate of insurance before the expiration of the term of any Required Insurance. Landlord’s failure to require Contractor to provide evidence of Required Insurance, or Landlord’s acceptance of evidence that indicates insurance that fails to satisfy the requirements of this Exhibit E, will not constitute a waiver of those requirements.

6. Additional Insureds. The “Additional Insureds” are as follows: all individuals and entities that have any direct or indirect interest in Landlord; any holders of indebtedness secured by the Project; Tenant (if this is a build-out) and any entities that Landlord, per any other project-related agreement, is required to list as an additional insured, and, with respect to each of the foregoing, its managers, officers, directors, employees, and agents.

7. Risk of Loss; Property Insurance. Except to the extent a loss is covered by applicable insurance, Contractor bears the risk of loss and damage to the work (including any materials incorporated or to be incorporated as part of the work) until the date when the work is completed. Contractor and its Subcontractors are responsible to carry, at their own expense, property insurance covering the full replacement value of their machinery, tools, and equipment, and of work (including materials) until the risk of loss for Work passes to Landlord. To the fullest extent permitted by law Contractor hereby waives, and shall require Subcontractors (including equipment lessors) to waive, all claims against Landlord, the other Additional Insureds, tenants at the Project, and Landlord’s separate contractors and consultants and their subcontractors and subconsultants, for loss or damage to these items, regardless of the cause.

RIDER

EXTENSION OPTION RIDER

This Extension Option Rider (“Extension Rider”) is attached to and made a part of the Lease by and between Landlord and Tenant. The agreements set forth in this Extension Rider shall have the same force and effect as if set forth in the Lease. To the extent the terms of this Extension Rider are inconsistent with the terms of the Lease, the terms of this Extension Rider shall control.

1. Extension Options. Landlord hereby grants Tenant one (1) option (the “Extension Option”) to extend the Lease Term for a period of five (5) years (the “Option Term”), which option shall be exercisable only by written Exercise Notice (as defined below) delivered by Tenant to Landlord as provided below. Upon the proper exercise of the Extension Option, the Lease Term shall be extended for the Option Term. Notwithstanding the foregoing, at Landlord’s option, in addition to any other remedies available to Landlord under the Lease, at law or in equity, the Extension Option shall not be deemed properly exercised if as of the date of delivery of the Exercise Notice (as defined below) by Tenant: (i) Tenant has previously been in material default under the Lease beyond all applicable notice and cure periods; and/or (ii) Landlord does not reasonably approve of Tenant’s then-existing financial condition and/or Landlord’s lender does not approve of the terms for the Option Term, including, without limitation, the Option Rent (as those terms are defined below). The Extension Option is personal to the Original Tenant and may only be exercised by the Original Tenant (and not any assignee, sublessee or other transferee of Tenant’s interest in the Lease) if the Original Tenant occupies the entire Premises as of the date of Tenant’s delivery of the Exercise Notice.

2. Option Rent. The annual Base Rent payable by Tenant during the Option Term (the “Option Rent”) shall be equal to the greater of: (i) the annual Base Rent payable by Tenant during the last year of the initial Lease Term; or (ii) the Fair Market Rental Rate for the Premises. As used herein, the “Fair Market Rental Rate” shall mean the annual base rent at which tenants, as of the commencement of the Option Term, will be leasing non-sublease space comparable in size, location (including views) and quality to the Premises for a comparable term as the Option Term, which comparable space is located in the Building, the Other Existing Buildings in the Project and in other comparable first-class biotechnology buildings in the Torrey Pines area of San Diego County, taking into consideration all free rent and other out-of-pocket concessions generally being granted at such time for such comparable space for the Option Term (including, without limitation, any tenant improvement allowance provided for such comparable space, with the amount of such tenant improvement allowance to be provided for the Premises during the Option Term to be determined after taking into account the age, quality and layout of the tenant improvements in the Premises as of the commencement of the Option Term with consideration given to the fact that the improvements existing in the Premises are specifically suitable to Tenant). All other terms and conditions of the Lease shall apply throughout the Option Term; however, Tenant shall, in no event, have the option to extend the Lease Term beyond the Option Term described in Section 1 above.

3. Exercise of Option. The Extension Option shall be exercised by Tenant, if at all, only in the following manner: (i) Tenant shall deliver written notice (“Interest Notice”) to Landlord not more than fifteen (15) months nor less than twelve (12) months prior to the expiration of the initial Lease Term stating that Tenant may be interested in exercising the Extension Option; (ii) Landlord, after receipt of Tenant’s notice, shall deliver notice (the “Option Rent Notice”) to Tenant not less than ten (10) months prior to the expiration of the initial Lease Term setting forth the Option Rent; and (iii) if Tenant wishes to exercise the Extension Option, Tenant shall, on or before the date (the “Exercise Date”) which is nine (9) months prior to the expiration of the initial Lease Term, exercise the Extension Option by delivering written notice (“Exercise Notice”) thereof to Landlord. Tenant’s failure to deliver the Interest Notice or Exercise Notice on or before the applicable delivery dates therefore specified hereinabove shall be deemed to constitute Tenant’s waiver of the Extension Option.

4. Determination of Option Rent. Tenant shall have no right to object to the Option Rent provided by Landlord, and if Tenant disagrees with Landlord’s determination of the Option Rent but Landlord and Tenant are unable to resolve such disagreement as to the Option Rent prior to the Exercise Date, then either (i) Tenant shall accept Landlord’s determination of the Option Rent by exercising the Extension Option by delivering Tenant’s Exercise Notice to Landlord on or before the Exercise Date, or (ii) Tenant shall be deemed to have relinquished the Extension Option, in which event the Extension Option shall be null and void as of the Exercise Date, and Landlord and Tenant shall have no further liability to the other under this Extension Rider.

FIRST AMENDMENT TO LEASE

This FIRST AMENDMENT TO LEASE (“Amendment”) is made and entered into effective as of July 11, 2016, by and between WALTON TORREY OWNER A, L.L.C., a Delaware limited liability company (“Landlord”) and TP THERAPEUTICS, INC., a Delaware corporation (“Tenant”).

RECITALS:

A. Landlord and Tenant entered into that certain Lease dated as of January 19, 2016 (the “Lease”) pursuant to which Landlord leased to Tenant and Tenant leased from Landlord certain “Premises”, as described in the Lease, in that certain building located at 10628 Science Center Drive, San Diego, California 92121.

B. Except as otherwise set forth herein, all capitalized terms used in this Amendment shall have the same meaning as such terms have in the Lease.

C. Landlord and Tenant desire to amend the Lease to confirm the commencement an expiration dates of the term, as hereinafter provided.

NOW, THEREFORE, in consideration of the foregoing Recitals and the mutual covenants contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the parties hereto agree as follows:

l. Confirmation of Dates. The parties hereby confirm that (a) the Premises are Ready for Occupancy, and (b) the term of the Lease commenced as of July 11, 2016 for a term of five (5) years and five (5) months ending on December 31, 2021 (unless sooner terminated as provided in the Lease).

2. No Further Modification. Except as set forth in this Amendment, all of the terms and provisions of the Lease shall remain unmodified and in full force and effect.

IN WITNESS WHEREOF, this Amendment has been executed as of the day and year first above written.

-1-

-2-

SECOND AMENDMENT TO LEASE

THIS SECOND AMENDMENT TO LEASE (this “Second Amendment”) is made as of June 8th, 2018, by and between ARE-SD REGION NO. 44, LLC, a Delaware limited liability company (“Landlord”), and TP THERAPEUTICS, INC., a Delaware corporation (“Tenant”).

RECITALS

A. Landlord and Tenant are now parties to that certain Office Lease dated as of January 19, 2016, as amended by that certain First Amendment to Lease dated as of July 11, 2016 (the “Lease”). Pursuant to the Lease, Tenant leases certain premises consisting of approximately 8,727 rentable square feet (“Original Premises”) on the second floor of that certain building located at 10628 Science Center Drive, San Diego, California (the “Building”). The Original Premises are more particularly described in the Lease. Capitalized terms used herein without definition shall have the meanings defined for such terms in the Lease.

B. Landlord and Tenant desire, subject to the terms and conditions set forth below, to amend the Lease to, among other things, expand the size of the Original Premises by adding that portion of the first floor of the Building consisting of approximately 9,302 rentable square feet, as shown on Exhibit A attached to this Second Amendment (“Expansion Premises”).

NOW, THEREFORE, in consideration of the foregoing Recitals, which are incorporated herein by this reference, the mutual promises and conditions contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Landlord and Tenant hereby agree as follows:

The “Expansion Premises Commencement Date” shall be the earlier to occur of: (i) the date that Landlord delivers the Expansion Premises to Tenant, or (ii) the date that Landlord could have delivered the Expansion Premises to Tenant but for Tenant Delays. The “Target Expansion Premises Commencement Date” shall be September 1, 2018.

For the period of 30 consecutive days after the Expansion Premises Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to the Building systems (including HVAC, mechanical, electrical and plumbing) serving the Expansion Premises, unless Tenant, or any of Tenant’s assignees, sublessees, licensees, agents, servants, employees, invitees and contractors

1

(or any of Tenant’s assignees’, sublessees’ and/or licensees’ respective agents, servants, employees, invitees and contractors), was responsible for the cause of such repair, in which case Tenant shall pay the cost of such repair.

Except as set forth in the Second Amendment Work Letter: (i) Tenant shall accept the Expansion Premises in their condition as of the Expansion Premises Commencement Date; (ii) Landlord shall have no obligation for any defects in the Expansion Premises; and (iii) Tenant’s taking possession of the Expansion Premises shall be conclusive evidence that Tenant accepts the Expansion Premises and that the Expansion Premises were in good condition at the time possession was taken.

Tenant agrees and acknowledges that, except as otherwise expressly set forth in this Second Amendment, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Expansion Premises, and/or the suitability of the Expansion Premises for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Expansion Premises are suitable for the Permitted Use.

“Premises: That portion of the Building containing approximately 18,029 rentable square feet, consisting of (i) approximately 8,727 rentable square feet on the second floor of the Building commonly known as Suite 225 (the “Original Premises”), and (ii) approximately 9,302 rentable square feet on the second floor of the Building commonly known as Suite 200 (the “Expansion Premises”), all as determined by Landlord, as shown on Exhibit A.”

As of the Expansion Premises Commencement Date, Exhibit A to the Lease shall be amended to include the Expansion Premises as shown on Exhibit A attached to this Second Amendment.

a. Original Premises. Tenant shall continue to pay Base Rent for the Original Premises as provided for in the Lease through December 31, 2021. For the avoidance of doubt, Tenant shall continue to be entitled to the Abated Rent provided for in the second paragraph of Article 3 of the Lease with respect to the Original Premises only.

b. Expansion Premises. Commencing on the Expansion Premises Commencement Date through December 31, 2021, Tenant shall (in addition to Base Rent for the Original Premises) commence paying Base Rent on a per rentable square foot basis with respect to the Expansion Premises at the same Monthly Rental Rate per Rentable Square Foot that Tenant is then paying with respect to the Original Premises pursuant to Section 9 of the Summary of Basic Lease Information, as adjusted pursuant to Section 9 of the Summary of Basic Lease Information. Notwithstanding anything to the contrary contained herein or in the Lease, in no event shall Tenant be entitled to any Abated Rent with respect to the Expansion Premises.

a. Commencing on the Expansion Premises Commencement Date, the defined term “Tenant’s Share of Operating Expenses, Tax Expenses and Utility Costs” set forth in Section 9 of the Summary of Basic Lease Information shall be deleted in its entirety and replaced with the following:

“Tenant’s Share of Operating Expenses: 19.87%”

2

b. Notwithstanding anything to the contrary contained in the Lease and for the avoidance of any doubt, (i) “Operating Expenses” shall include (x) capital repairs, improvements and replacements amortized over the lesser of 10 years and the useful life of such capital items, (y) the cost (including, without limitation, any subsidies which Landlord may provide in connection with the Project Amenities) of the common area amenities (the “Project Amenities”) now or hereafter located at the Project which Project Amenities may include, without limitation, the common area fitness center, cafe, conference center, bocce ball court, barbeque pits and ping pong, and (z) with respect to the Expansion Premises, administration rent in the amount of 3.0% of Base Rent payable with respect to the Expansion Premises, and (ii) subsection (x) of Section 4.2.3 of the Lease is hereby deleted in its entirety. Increases in Controllable Expenses (as defined in Section 4.3.5 of the Lease) shall continue to be capped as provided in Section 4.3.5 of the Lease with respect to the Original Premises only through the Expiration Date. For the avoidance of doubt, Tenant shall continue, as part of Operating Expenses, to pay a management fee with respect to the Original Premises as provided in Section 4.2.3 of the Lease.

“Security Deposit: $68,690.49”

Landlord currently holds a cash Security Deposit in the amount of $37,438.83 under the Lease. Concurrently with Tenant’s delivery of a signed original of this Second Amendment to Landlord, Tenant shall deliver to Landlord an unconditional and irrevocable letter of credit (the “Letter of Credit”): (i) in form and substance reasonably satisfactory to Landlord, (ii) naming Landlord as beneficiary, (iii) expressly allowing Landlord to draw upon it at any time from time to time by delivering to the issuer notice that Landlord is entitled to draw thereunder, (iv) issued by an FDIC-insured financial institution satisfactory to Landlord, and (v) redeemable by presentation of a sight draft in the state of Landlord’s choice. Landlord shall reimburse Tenant the cash Security Deposit currently being held by Landlord within 30 days after Landlord’s receipt of the Letter of Credit.

a. Generally. ARE-SD Region No. 17, LLC, a Delaware limited liability company (“The Alexandria Landlord”) has constructed certain amenities at the property owned by The Alexandria Landlord located at 10996 Torreyana Road, San Diego, California (“The Alexandria”), which, as of the date of this Second Amendment, include, without limitation, shared conference facilities (“Shared Conference Facilities”), a fitness center and restaurant (collectively, the “Amenities”) for non-exclusive use by (a) Tenant, (b) other tenants of the Project, (c) Landlord, (d) the tenants of The Alexandria Landlord, (e) The Alexandria Landlord, (e) other affiliates of Landlord, The Alexandria Landlord and Alexandria Real Estate Equities, Inc. (“ARE”), (f) the tenants of such other affiliates of Landlord, The Alexandria Landlord and ARE, and (g) any other parties permitted by The Alexandria Landlord (collectively, “Users”). Landlord, The Alexandria Landlord, ARE, and all affiliates of Landlord, The Alexandria Landlord and ARE may be referred to collectively herein as the “ARE Parties.” Notwithstanding anything to the contrary contained herein, Tenant acknowledges and agrees that The Alexandria Landlord shall have the right, at the sole discretion

3

of The Alexandria Landlord, to not make the Amenities available for use by some or all currently contemplated Users (including Tenant). The Alexandria Landlord shall have the sole right to determine all matters related to the Amenities including, without limitation, relating to the reconfiguration, relocation, modification or removal of any of the Amenities at The Alexandria and/or to revise, expand or discontinue any of the services (if any) provided in connection with the Amenities. Tenant acknowledges and agrees that Landlord has not made any representations or warranties regarding the availability of the Amenities and that Tenant is not entering into this Second Amendment relying on the continued availability of the Amenities to Tenant.

b. License. Commencing on the Expansion Premises Commencement Date, and so long as The Alexandria and the Project continue to be owned by affiliates of ARE, Tenant shall have the non-exclusive right to the use of the available Amenities in common with other Users pursuant to the terms of this Section 9. Tenant shall be entitled to 2.5 passes to the fitness center located at The Alexandria per 1,000 rentable square feet of the Expansion Premises for use by employees of Tenant employed at the Premises. If any employee of Tenant to whom a fitness center pass has been issued ceases to be an employee of Tenant at the Premises or any employee to whom an access card (which does not include a fitness center pass) has been issued ceases to be an employee of Tenant at the Premises, Tenant shall immediately upon such employee’s change in status collect such employee’s pass or access card, as applicable, and deliver it to Landlord along with written notice of such employee’s change in status.

Commencing on the Expansion Premises Commencement Date, Tenant shall pay to Landlord a monthly fixed fee equal to $0.18 per rentable square foot of the Expansion Premises per month (“Amenities Fee”), which Amenities Fee shall by payable on the first day of each month during the Term whether or not Tenant elects to use any or all of the Amenities. The Amenities Fee shall be increased annually on each anniversary of the Expansion Premises Commencement Date by 3%. Notwithstanding anything to the contrary contained herein, if Tenant exercises its Extension Option under the Lease, then commencing on the commencement date of the Option Term, in addition to the Amenities Fee payable with respect to the Expansion Premises, Tenant will commence paying an Amenities Fee with respect to the Original Premises on a per rentable square foot basis equal to the Amenities Fee then payable by Tenant on a per rentable square foot basis with respect to the Original Premises (as adjusted pursuant to this paragraph). If all of the Amenities at The Alexandria become materially unavailable for use by Tenant (for any reason other than a default by Tenant under the Lease or the default by Tenant of any agreement(s) relating to the use of the Amenities by Tenant) for a period in excess of 60 consecutive days, then, commencing on the date that the Amenities in their entirety become materially unavailable for use by Tenant and continuing for the period that the Amenities in their entirety remain materially unavailable for use by Tenant, the Amenities Fee then-currently payable by Tenant shall be abated.

c. Shared Conference Facilities. Use by Tenant of the Shared Conference Facilities and restaurant at The Alexandria shall be in common with other Users with scheduling procedures reasonably determined by The Alexandria Landlord or The Alexandria Landlord’s then designated event operator (“Event Operator”). Tenant’s use of the Shared Conference Facilities shall be subject to the payment by Tenant to The Alexandria Landlord of a fee equal to The Alexandria Landlord’s quoted rates for the usage of the Shared Conference Facilities in effect at the time of Tenant’s scheduling. Tenant’s use of the conference rooms in the Shared Conference Area shall be subject to availability and The Alexandria Landlord (or, if applicable, Event Operator) reserves the right to exercise its reasonable discretion in the event of conflicting scheduling requests among Users. Tenant hereby acknowledges that (i) Biocom/San Diego, a California non-profit corporation (“Biocom”) has the right to reserve the Shared Conference Facilities and any reservable dining area(s) included within the Amenities for up to 50% of the time that such Shared Conference Facilities and reservable dining area(s) are available for use by Users each calendar month, and (ii) Illumina, Inc., a Delaware corporation, has the exclusive use of the main conference room within the Shared Conference Facilities for up to 4 days per calendar month.

4

Tenant shall be required to use the food service operator designated by The Alexandria Landlord at The Alexandria (the “Designated Food and Beverage Operator”) for any food and/or beverage service or catered events held by Tenant in the Shared Conference Facilities. As of the date of this Second Amendment, the Designated Food and Beverage Operator is The Farmer and the Seahorse. The Alexandria Landlord has the right, in its sole and absolute discretion, to change the Designated Food and Beverage Operator at any time. Tenant may not use any vendors other than the Designated Food and Beverage Operator nor may Tenant supply its own food and/or beverages in connection with any food and/or beverage service or catered events held by Tenant in the Shared Conference Facilities. If Landlord notifies Tenant in writing that there is no Designated Food and Beverage operator, then Tenant may use a food operator selected by Tenant and reasonably acceptable to Landlord.

Tenant shall, at Tenant’s sole cost and expense, (i) be responsible for the set-up of the Shared Conference Facilities in connection with Tenant’s use (including, without limitation ensuring that Tenant has a sufficient number of chairs and tables and the appropriate equipment), and (ii) surrender the Shared Conference Facilities after each time that Tenant uses the Shared Conference Facilities free of Tenant’s personal property, in substantially the same set up and same condition as received, and free of any debris and trash. If Tenant fails to restore and surrender the Shared Conference Facilities as required by sub-section (ii) of the immediately preceding sentence, such failure shall constitute a “Shared Facilities Default.” Each time that Landlord reasonably determines that Tenant has committed a Shared Facilities Default, Tenant shall be required to pay Landlord a penalty within 5 days after notice from Landlord of such Shared Facilities Default. The penalty payable by Tenant in connection with the first Shared Facilities Default shall be $200. The penalty payable shall increase by $50 for each subsequent Shared Facilities Default (for the avoidance of doubt, the penalty shall be $250 for the second Shared Facilities Default, shall be $300 for the third Shared Facilities Default, etc.). In addition to the foregoing, Tenant shall be responsible for reimbursing The Alexandria Landlord or Landlord, as applicable, for all costs expended by The Alexandria Landlord or Landlord, as applicable, in repairing any damage to the Shared Conference Facilities, the Amenities, or The Alexandria caused by Tenant or any Tenant Related Party. The provisions of this Section 9(c) shall survive the expiration or earlier termination of the Lease.

d. Restaurant. Tenant’s employees that have been issued an access card to The Alexandria shall have the right, along with other Users, to access and use the restaurant located at The Alexandria.

e. Rules and Regulations. Tenant shall be solely responsible for paying for any and all ancillary services (e.g., audio visual equipment) provided to Tenant, all food services operators and any other third party vendors providing services to Tenant at The Alexandria. Tenant shall use the Amenities (including, without limitation, the Shared Conference Facilities) in compliance with all applicable laws and any rules and regulations imposed by The Alexandria Landlord or Landlord from time to time and in a manner that will not interfere with the rights of other Users. The use of Amenities other than the Shared Conference Facilities by employees of Tenant shall be in accordance with the terms and conditions of the standard licenses, indemnification and waiver agreement required by The Alexandria Landlord or the operator of the Amenities to be executed by all persons wishing to use such Amenities. Neither The Alexandria Landlord nor Landlord (nor, if applicable, any other affiliate of Landlord) shall have any liability or obligation for the breach of any rules or regulations by other Users with respect to the Amenities. Tenant shall not make any alterations, additions, or improvements of any kind to the Shared Conference Facilities, the Amenities or The Alexandria.

Tenant acknowledges and agrees that The Alexandria Landlord shall have the right at any time and from time to time to reconfigure, relocate, modify or remove any of the Amenities at The Alexandria and/or to revise, expand or discontinue any of the services (if any) provided in connection with the Amenities.

5

f. Waiver of Liability and Indemnification. Tenant warrants that it will use reasonable care to prevent damage to property and injury to persons while on The Alexandria. Tenant waives any claims it or any Tenant Parties may have against any ARE Parties relating to, arising out of or in connection with the Amenities and any entry by Tenant and/or any Tenant Parties onto The Alexandria, and Tenant releases and exculpates all ARE Parties from any liability relating to, arising out of or in connection with the Amenities and any entry by Tenant and/or any Tenant Parties onto The Alexandria. Tenant hereby agrees to indemnify, defend, and hold harmless the ARE Parties from any claim of damage to property or injury to person relating to, arising out of or in connection with (i) the use of the Amenities by Tenant or any Tenant Parties, and (ii) any entry by Tenant and/or any Tenant Parties onto The Alexandria, except to the extent caused by the negligence or willful misconduct of ARE Parties. The provisions of this Section 9(f) shall survive the expiration or earlier termination of the Lease.

g. Insurance. As of the Expansion Premises Commencement Date, Tenant shall cause The Alexandria Landlord to be named as an additional insured under the commercial general liability policy of insurance that Tenant is required to maintain pursuant to Section 10.3 of the Lease.

“5.4 Control Areas. Tenant shall have the use of 100% of the control area designated as control area 3 on Exhibit C attached hereto. For the avoidance of doubt, Tenant shall not have rights with respect to any other control areas at the Project.”

6

7

a. This Second Amendment is the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous oral and written agreements and discussions. This Second Amendment may be amended only by an agreement in writing, signed by the parties hereto.

b. This Second Amendment is binding upon and shall inure to the benefit of the parties hereto, and their respective successors and assigns.

c. This Second Amendment may be executed in 2 or more counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument. Counterparts may be delivered via facsimile, electronic mail (including pdf or any electronic signature process complying with the U.S. federal ESIGN Act of 2000) or other transmission method and any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes. Electronic signatures shall be deemed original signatures for purposes of this Second Amendment and all matters related thereto, with such electronic signatures having the same legal effect as original signatures.

d. Except as amended and/or modified by this Second Amendment, the Lease is hereby ratified and confirmed and all other terms of the Lease shall remain in full force and effect, unaltered and unchanged by this Second Amendment. In the event of any conflict between the provisions of this Second Amendment and the provisions of the Lease, the provisions of this Second Amendment shall prevail. Whether or not specifically amended by this Second Amendment, all of the terms and provisions of the Lease are hereby amended to the extent necessary to give effect to the purpose and intent of this Second Amendment.

[Signatures are on the next page.]

8

IN WITNESS WHEREOF, the parties hereto have executed this Second Amendment as of the day and year first above written.

9

EXHIBIT A

EXPANSION PREMISES

EXHIBIT B

SECOND AMENDMENT WORK LETTER

THIS SECOND AMENDMENT WORK LETTER dated June 8th, 2018 (this “Second Amendment Work Letter”) is made and entered into by and between ARE-SD REGION NO. 44, LLC, a Delaware limited liability company (“Landlord”), and TP THERAPEUTICS, INC., a Delaware corporation (“Tenant”), and is attached to and made a part of that certain Office Lease dated as of January 19, 2016, as amended by that certain First Amendment to Lease dated as of July 11, 2016, and as further amended by that certain Second Amendment of even date herewith (as amended, the “Lease”), by and between Landlord and Tenant. Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.

1. General Requirements.

(a) Tenant’s Authorized Representative. Tenant designates Brian Baker and Yishan (Peter) Li (either such individual acting alone, “Tenant’s Representative”) as the only persons authorized to act for Tenant pursuant to this Second Amendment Work Letter. Landlord shall not be obligated to respond to or act upon any request, approval, inquiry or other communication (“Communication”) from or on behalf of Tenant in connection with this Second Amendment Work Letter unless such Communication is in writing from Tenant’s Representative. Tenant may change either Tenant’s Representative at any time upon not less than 5 business days advance written notice to Landlord. Neither Tenant nor Tenant’s Representative shall be authorized to direct Landlord’s contractors in the performance of Landlord’s Work (as hereinafter defined).

(b) Landlord’s Authorized Representative. Landlord designates Michael Harrison and John Cavanagh (either such individual acting alone, “Landlord’s Representative”) as the only persons authorized to act for Landlord pursuant to this Second Amendment Work Letter. Tenant shall not be obligated to respond to or act upon any request, approval, inquiry or other Communication from or on behalf of Landlord in connection with this Second Amendment Work Letter unless such Communication is in writing from Landlord’s Representative. Landlord may change either Landlord’s Representative at any time upon not less than 5 business days advance written notice to Tenant. Landlord’s Representative shall be the sole persons authorized to direct Landlord’s contractors in the performance of Landlord’s Work.

(c) Architects, Consultants and Contractors. Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) DGA shall be the architect (the “TI Architect”) for the Tenant Improvements.

2. Tenant Improvements.

(a) Tenant Improvements Defined. As used herein, “Tenant Improvements” shall mean all improvements to the Expansion Premises of a fixed and permanent nature as shown on the TI Construction Drawings, as defined in Section 2(c) below. Other than Landlord’s Work (as defined in Section 3(a) below), Landlord shall not have any obligation whatsoever with respect to the finishing of the Expansion Premises for Tenant’s use and occupancy. Notwithstanding anything to the contrary contained in the Lease, Tenant shall not be required to remove or restore the Tenant Improvements at the expiration or earlier termination of the Term, nor shall Tenant have the right to remove any of the Tenant Improvements at any time during the Term or upon the expiration or earlier termination of the Lease Term except as part of Alterations approved by Landlord, in its sole and absolute discretion.

(b) Tenant’s Space Plans. The schematic drawings and outline specifications attached to this Second Amendment Work Letter as Schedule 1 (the “Space Plans”) have been approved by Landlord and Tenant.

B-1

(c) Working Drawings. Landlord shall cause the TI Architect to prepare and deliver to Tenant for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the Space Plans. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Tenant shall deliver its written comments on the TI Construction Drawings to Landlord not later than 10 business days after Tenant’s receipt of the same; provided, however, that Tenant may not disapprove any matter that is consistent with the Space Plans without submitting a Change Request. Landlord and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Tenant how Landlord proposes to respond to such comments, but Tenant’s review rights pursuant to the foregoing sentence shall not delay the design or construction schedule for the Tenant Improvements. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the Space Plans, Tenant shall approve the TI Construction Drawings submitted by Landlord, unless Tenant submits a Change Request. Once approved by Tenant, subject to the provisions of Section 4 below, Landlord shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(b) below).

(d) Approval and Completion. Upon any dispute regarding the design of the Tenant Improvements, which is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Landlord may make the final decision regarding the design of the Tenant Improvements provided that such final decision is consistent with the Space Plans. Any changes to the TI Construction Drawings by Tenant shall be processed as provided in Section 4 hereof.

3. Performance of Landlord’s Work.

(a) Definition of Landlord’s Work. As used herein, “Landlord’s Work” shall mean (i) the work of constructing the Tenant Improvements, (ii) the work of constructing the common area restroom improvements shown on Schedule 1 attached hereto, and (iii) the work of constructing a door separating the laboratory portion of the Premises from the office portion of the Premises as shown on Schedule 2 attached hereto (the “Door Improvements”).

(b) Commencement and Permitting. Landlord shall commence construction of the Tenant Improvements upon obtaining a building permit (the “TI Permit”) authorizing the construction of the Tenant Improvements consistent with the TI Construction Drawings approved by Tenant. The cost of obtaining the TI Permit shall be payable by Landlord. Tenant shall assist Landlord in obtaining the TI Permit. If any governmental authority having jurisdiction over the construction of Landlord’s Work or any portion thereof shall impose terms or conditions upon the construction thereof that: (i) are inconsistent with Landlord’s obligations hereunder, (ii) increase the cost of constructing Landlord’s Work, or (iii) will materially delay the construction of Landlord’s Work, Landlord and Tenant shall reasonably and in good faith seek means by which to mitigate or eliminate any such adverse terms and conditions.

(c) Completion of Landlord’s Work. Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, in accordance with Legal Requirements and the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Expansion Premises and with a certificate or temporary certificate of occupancy (or an equivalent approval having been issued) for the Expansion Premises permitting lawful occupancy of the Expansion Premises (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenant’s operations in the Expansion Premises) (“Substantial Completion” or “Substantially Complete”). Upon Substantial Completion of Landlord’s Work, Landlord shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704. For purposes of this Second Amendment Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comply with any request by Tenant for modifications to Landlord’s Work; (iii) to comport with

B-2

good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments for field deviations or conditions encountered during the construction of Landlord’s Work.

(d) Selection of Materials. Where more than one type of material or structure is indicated on the TI Construction Drawings approved by Landlord and Tenant, the option will be selected at Landlord’s sole and absolute subjective discretion. As to all building materials and equipment that Landlord is obligated to supply under this Second Amendment Work Letter, Landlord shall select the manufacturer thereof in its reasonable discretion.

(e) Delivery of the Expansion Premises. When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Expansion Premises. Tenant’s taking possession and acceptance of the Expansion Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period. If the contractor fails to remedy such Construction Defect within such 30-day period, Landlord shall use reasonable efforts to remedy the Construction Defect within a reasonable period.

Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Expansion Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely by Tenant. Landlord shall promptly undertake and use reasonable efforts to complete, or cause to be completed, all punch list items within 30 days after the Commencement Date.

(f) Commencement Date Delay. Except as otherwise provided in the Lease, Delivery of the Expansion Premises shall occur when Landlord’s Work in the Expansion Premises has been Substantially Completed, except to the extent that completion of Landlord’s Work in the Expansion premises shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):

(i) Tenant’s Representative was not available within 2 business days to give or receive any Communication or to take any other action required to be taken by Tenant hereunder;

(ii) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;

(iii) Construction of any Change Requests;

(iv) Tenant’s request for materials, finishes or installations (excluding those specifically identified in the approved TI Construction Drawings) requiring unusually long lead times, provided that promptly after Landlord learns of such long lead times, Landlord informs Tenant in writing that the requested items will require unusually long lead times;

(v) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;

B-3

(vi) Tenant’s delay in providing information critical to the normal progression of the Project. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;

(vii) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below); or

(viii) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons.

If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be the date of Delivery.

4. Changes. Any changes requested by Tenant to the Tenant Improvements shall be requested and instituted in accordance with the provisions of this Section 4 and shall be subject to the written approval of Landlord and the TI Architect, such approval not to be unreasonably withheld, conditioned or delayed.

(a) Tenant’s Request For Changes. If Tenant shall request changes to the Tenant Improvements (“Changes”), Tenant shall request such Changes by notifying Landlord in writing in substantially the same form as the AIA standard change order form (a “Change Request”), which Change Request shall detail the nature and extent of any such Change. Such Change Request must be signed by Tenant’s Representative. Landlord shall, before proceeding with any Change, use commercially reasonable efforts to respond to Tenant as soon as is reasonably possible with an estimate of: (i) the time it will take, and (ii) the architectural and engineering fees and costs that will be incurred, to analyze such Change Request (which costs shall be paid by Tenant to the extent actually incurred, whether or not such change is implemented). Landlord shall thereafter submit to Tenant in writing, within 5 business days of receipt of the Change Request (or such longer period of time as is reasonably required depending on the extent of the Change Request), an analysis of the additional cost or savings involved, including, without limitation, architectural and engineering costs and the period of time, if any, that the Change will extend the date on which Landlord’s Work will be Substantially Complete. Any such delay in the completion of Landlord’s Work caused by a Change, including any suspension of Landlord’s Work while any such Change is being evaluated and/or designed, shall be Tenant Delay.

(b) Implementation of Changes. If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for completion of Landlord’s Work, if any, and (ii) deposits with Landlord any Excess TI Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by Tenant of any estimate of the delay caused by such proposed Change, the TI Architect’s determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant.

5. Costs.

(a) Cost of Tenant Improvements. Except as otherwise provided in this Work Letter, Landlord shall be responsible for the payment of design, permits and construction costs in connection with the construction of the Tenant Improvements, including, without limitation, the cost of preparing the TI Construction Drawings and the Space Plans, all costs set forth in the budget for the Tenant Improvements and Landlord’s out-of-pocket expenses (collectively, “TI Costs”). Notwithstanding anything to the contrary contained herein, in no event shall Landlord be required to pay for the Door Improvements or the purchase of any furniture, personal property or other non-Building system materials or equipment, including, but not limited to, Tenant’s voice or data cabling equipment.

(b) Excess TI Costs. Tenant acknowledges and agrees that Landlord shall have no responsibility for any costs arising from or related to Tenant’s Changes to the Space Plan or to the TI

B-4

Construction Drawings approved by Tenant and Landlord, the cost of the Door Improvements (which the parties anticipate will cost approximately $15,000), Tenant Delays and the cost of Changes (collectively, “Excess TI Costs”). Tenant shall deliver to Landlord, 100% of the Excess TI Costs within 10 days after Landlord’s written invoice therefor following the Substantial Completion of the Tenant Improvements. If Tenant fails to deliver any Excess TI Costs to Landlord within such 10-day period, Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including, but not limited to, the right to interest at the Default Rate and the right to assess a late charge). For purposes of any litigation instituted with regard to such amounts, those amounts will be deemed Rent under the Lease. Funds deposited by Tenant shall be disbursed to pay Excess TI Costs. Notwithstanding anything to the contrary set forth in this Work Letter, Tenant shall be fully and solely liable for Excess TI Costs.

6. Tenant Access.

(a) Tenant’s Access Rights. Landlord hereby agrees to permit Tenant access, at Tenant’s sole risk and expense, to the Expansion Premises (i) 30 days prior to the Expansion Premises Commencement Date to perform any work (“Tenant’s Work”) required by Tenant other than Landlord’s Work, provided that such Tenant’s Work is coordinated with the TI Architect and the general contractor, and complies with the Lease and all other reasonable restrictions and conditions Landlord may impose, and (ii) prior to the completion of Landlord’s Work, to inspect and observe work in process; all such access shall be during normal business hours or at such other times as are reasonably designated by Landlord. Any entry by Tenant shall comply with all established safety practices of Landlord’s contractor and Landlord until completion of Landlord’s Work and acceptance thereof by Tenant.

(b) No Interference. Neither Tenant nor any Tenant Party (as defined in the Lease) shall interfere with the performance of Landlord’s Work, nor with any inspections or issuance of final approvals by applicable governmental authorities, and upon any such interference, Landlord shall have the right to exclude Tenant and any Tenant Party from the Expansion Premises until Substantial Completion of Landlord’s Work.

(c) No Acceptance of Expansion Premises. The fact that Tenant may, with Landlord’s consent, enter into the Expansion Premises prior to the date Landlord’s Work is Substantially Complete for the purpose of performing Tenant’s Work shall not be deemed an acceptance by Tenant of possession of the Expansion Premises, but in such event Tenant shall defend with counsel reasonably acceptable by Landlord, indemnify and hold Landlord harmless from and against any loss of or damage to Tenant’s property, completed work, fixtures, equipment, materials or merchandise, and from liability for death of, or injury to, any person, caused by the act or omission of Tenant or any Tenant Party.

7. Miscellaneous.

(a) Consents. Whenever consent or approval of either party is required under this Second Amendment Work Letter, that party shall not unreasonably withhold, condition or delay such consent or approval, unless expressly set forth herein to the contrary.

(b) Modification. No modification, waiver or amendment of this Second Amendment Work Letter or of any of its conditions or provisions shall be binding upon Landlord or Tenant unless in writing signed by Landlord and Tenant.

(c) Default. Notwithstanding anything set forth herein or in the Lease to the contrary, Landlord shall not have any obligation to perform any work hereunder or to fund any portion of the TI Costs during any period that there is a Default by Tenant under the Lease.

B-5

Schedule 1

Space Plans

B-6

Schedule 2

Door Improvements

B-7

EXHIBIT C

CONTROL ZONES

C-1