Dated 5 January 2017

SunEdison Yieldco UK HoldCo 2, LLC, a company incorporated under the laws of the State of Delaware, whose registered office is at 7550 Wisconsin Ave, Bethesda, MD, 20814, United States of America (the “Seller”);

TerraForm Power Operating, LLC, a company incorporated under the laws of the State of Delaware and whose registered office is at 7550 Wisconsin Ave, Bethesda, MD, 20814, United States of America (the “Guarantor”); and  

Vortex Solar UK Limited, a company registered in England and Wales with company number 10473926 and whose registered office is at 6 St Andrew Street, London, EC4A 3AE, United Kingdom (the “Purchaser”),

The Seller has agreed to sell and the Purchaser has agreed to buy the Shares on the terms and subject to the conditions of this Agreement.

The Purchaser has agreed to redeem the Loan Note on behalf of the Company and pay the Other Receivables (if any) on behalf of the Company at Completion (and, for the avoidance of doubt, the Company will as a result thereof owe an amount equal to the Loan Note Redemption Amount and the Other Receivables Payment Amount (if any) to the Purchaser) in accordance with Clause 7.

The Purchaser has agreed to pay the Receivable on behalf of the Direct Subsidiary at Completion (and, for the avoidance of doubt, the Direct Subsidiary will as a result thereof owe an amount equal to the Receivable Payment Amount to the Purchaser) in accordance with Clause 7.

In this Agreement:

person that is an undertaking, any person who or which, directly or indirectly, controls, or is controlled by, or is under common control with such person and “control” (together with its correlative meanings, “controlled by” and “under common control with”) means with respect to any other person, the possession, directly or indirectly, of power to direct or cause the direction of management or policies of such person (whether through ownership of voting securities or partnership or other ownership interests, by contract or otherwise); or

individual, his or her spouse, or civil partner, and his or her grandparents (and those of his spouse or civil partner) and all descendants of those grandparents,

the OECD Convention on Combating Bribery of Foreign Public Officials in International Business Transactions;

the Foreign Corrupt Practices Act of 1977 of the United States of America, as amended by the Foreign Corrupt Practices Act Amendments of 1988 and 1998, and as may be further amended and supplemented from time to time;

the Bribery Act 2010; and

any other applicable law (including any (a) statute, ordinance, rule or regulation; (b) order of any court, tribunal or any other judicial body; and (c) rule, regulation, guideline or order of any public body, or any other administrative requirement) which:

prohibits the conferring of any gift, payment or other benefit on any person or any officer, employee, agent or adviser of such person; and/or

is broadly equivalent to (ii) or (iii) or was intended to enact the provisions of the OECD Convention described in (i) or which has as its objective the prevention of corruption;

all applicable financial recordkeeping and reporting requirements, including those of the Currency and Foreign Transactions Reporting Act of 1970, as amended; and

the applicable anti-money laundering statutes of all jurisdictions where the relevant entity conducts business, the rules and regulations thereunder and any related or similar rules, regulations or guidelines issued, administered or enforced by any governmental or regulatory agency;

the incurring of any liability or obligation by any Group Company to, or for the benefit of, the Seller or any of its Related Persons, including any management or monitoring fees, any increase in the interest payable on the Loan Note, any repayment of principal and/or payment of interest on the Loan Note and any repayment of principal and/or payment of interest on the Receivable and Other Receivables (other than the payment of the Loan Note Redemption Amount, the Receivable Payment Amount and any Other Receivables Payment Amount pursuant to Clause 7.4);

any dividend or distribution (whether in cash or in kind) declared, paid, made or agreed or required to be made by any Group Company to the Seller or any of its Related Persons;

the issue or sale of any securities of any Group Company to, on behalf of, or for the benefit of the Seller or any of its Related Persons;

any payments made or benefits conferred (whether in cash or in kind), or agreed to be made or conferred by any Group Company to, on behalf of, or for the benefit of the Seller or any of its Related Persons, including in respect of the issue, redemption, repurchase, repayment or acquisition of any share capital or other securities of any

the waiver, deferral or release or agreement to waive, defer or release by any Group Company of (a) any amount owed to that Group Company by the Seller or any of its Related Persons, or (b) any claims by a Group Company in respect of any agreement or arrangement with the Seller or any of its Related Persons;

any assumption or discharge of any liability (including in relation to any recharging of costs of any kind), or any guarantee, indemnity or security provided, by any Group Company on behalf of, or for the benefit of the Seller, or any of its Related Persons;

any costs, liabilities, fees, bonuses or expenses related to the Transaction to the extent paid, payable, assumed, indemnified or incurred by any Group Company on behalf of, or for the benefit of, the Seller or any of its Related Persons;

any amounts paid by any Group Company to any member of the Seller’s Group in respect of any Spare Parts Stock;

any payment that reduces the amount that the Seller is or would be required to pay under any Transaction Document or any Project Document;

any payment which arises solely due to or as a result of the termination of any or all of the O&M Agreements, the Management Services Agreements and/or the Transitional Services Agreement;

any agreement to make or undertake any of the payments or matters set out in (i) to (x) above; or

the payment or agreement to pay by any Group Company of any Tax, or amount on account of, or in respect of, Tax (including any Tax which would have been charged in the absence of any Purchaser’s Relief), fees, costs or expenses directly as a consequence of any of the matters set out in (i) to (xi) of this definition (inclusive);

the Seller’s Affiliates; and

the directors, officers and employees of the Seller and its Affiliates;

In this Agreement, except where the context otherwise requires:

a reference to Clauses, paragraphs, sub-paragraphs, Schedules and the Recitals is to Clauses, paragraphs, sub-paragraphs and the Recitals of, and the Schedules to, this Agreement;

a reference to this Agreement or to any specified provision of this Agreement is to this Agreement or provision as in force for the time being, as amended, modified, supplemented, varied, assigned or novated, from time to time;

a reference to this Agreement includes the Schedules to it, each of which forms part of this Agreement for all purposes;

a reference to any other agreement, deed or similar is to such agreement, deed or similar as in force for the time being, as amended, modified, supplemented, varied, assigned or novated, from time to time;

a reference to a “company” shall be construed so as to include any company, corporation or other body corporate, wherever and however incorporated or established;

a reference to a “person” shall be construed so as to include any individual, firm, body corporate, joint venture, unincorporated association, partnership, trust, government, governmental body, authority or agency (whether or not having separate legal personality), and a reference to a person includes a reference to that person’s successors and assigns;

a reference to writing shall include any mode of reproducing words in a legible and non-transitory form;

a reference to a time of the day is to London time;

if a period of time is specified as from a given day, or from the day of an act or event, it shall be calculated exclusive of that day;

a reference to “£” or “sterling” shall be construed as a reference to the lawful currency for the time being of the United Kingdom;

the expressions “subsidiary undertaking”, “undertaking” and “subsidiary”, shall have the meanings given to them in the Companies Act 2006;

any phrases introduced by the terms "including", "include", "in particular" or any similar expression are to be construed without limitation and accordingly the rule known as the ejusdem generis rule shall not apply to this Agreement;

the Parties acknowledge that they have participated jointly in the negotiation and drafting of this Agreement. In the event that a question of interpretation arises (including as to the intention of the Parties), no presumption or burden of proof shall arise in favour of or against any Party based on the authorship of any provisions;

any statement or Seller's Warranty in this Agreement qualified by the expression “so far as the Seller is aware”, or any similar expression or statement referring to the knowledge of the Seller, shall be deemed to include an additional statement that it has been made after all reasonable enquiries and shall be deemed to refer to the actual knowledge of Rebecca Cranna, Sebastian Deschler, Adam Kuehne, Lauren Gaffney, Sarah Fleckman and Toon Mols;

any statement in this Agreement qualified by the expression “so far as the Purchaser is aware”, or any similar expression or statement referring to the knowledge of the Purchaser, shall be deemed to refer to the actual knowledge of Karim Moussa, Bakr Abdel-Wahab, Edwina Kelly, Mostafa Seif el Nasr, Ahmed Al-Ariki and Hassan Khashaba and, in relation to any Purchaser’s Warranty where such expression is used, shall be deemed to include an additional statement that it has been made after all reasonable enquiries;

words importing the singular include the plural and vice versa, and words importing a gender include every gender;

headings are inserted for convenience only and shall be ignored in construing this Agreement;

references to a statute or statutory provision shall include:

the statute or statutory provision as from time to time modified, re-enacted or consolidated whether before or after the date of this Agreement; and

any subordinate legislation made from time to time under that statute or statutory provision which is in force at the date of this Agreement;

references to any English legal term shall, in respect of any jurisdiction other than England, be construed as references to the term or concept which most nearly corresponds to it in that jurisdiction; and

unless expressly stated to the contrary in this Agreement, any reference to (or requirement for) the execution of a document by a person includes execution on behalf of that person.

On and subject to the provisions of this Agreement, at Completion the Seller shall sell the Shares, and the Purchaser shall purchase the Shares. The Shares shall be sold free from all Encumbrances and together with all rights attaching to them at Completion (including the right to receive all dividends or distributions declared, made or paid on or after Completion) and with full title guarantee.

On and subject to Completion, the Seller irrevocably and unconditionally waives any and all rights of pre-emption in respect of the Shares.

The Purchaser shall not be obliged to complete the sale and purchase of any of the Shares unless the sale and purchase of all the Shares is completed simultaneously in accordance with this Agreement, but completion of the sale and purchase of some of the Shares will not affect the rights of the Purchaser with respect to the sale and purchase of the other Shares.

the Aggregate Amount less

the Loan Note Redemption Amount less

the Receivable Payment Amount less

the Other Receivables Payment Amount less

an amount equal to the Notified Leakage Amount,

As soon as reasonably practicable following the date of this Agreement:

the Purchaser shall nominate a reputable escrow bank, based in the United Kingdom, with an investment grade credit rating of at least BBB- with Standard & Poor’s or Baa3 with Moody’s to act as the Purchase Price Escrow Bank; and

the Purchaser, the Seller and the Purchase Price Escrow Bank shall enter into an escrow agreement in respect of the Purchase Price Escrow Amount on terms satisfactory to the Purchaser and Seller, provided that such terms are customary for similar escrow arrangements and reflect, among other things, the terms set out in Clause 4 below (the “Purchase Price Escrow Agreement”).

Upon the earlier of:

an announcement in a press release that TerraForm Power has agreed to an M&A Transaction (as defined in Schedule 8); and

TerraForm Power entering into an Avoidance Action Settlement (as defined in Schedule 8),

The Purchase Price Escrow Bank shall hold the Purchase Price Escrow Amount as stakeholder on the terms of the Purchase Price Escrow Agreement in the joint names of the

Any bank or other charges arising on the Purchase Price Escrow Account shall be charged to the Purchase Price Escrow Account. Any interest or profit generated on the Purchase Price Escrow Account (subject to any deduction of tax at source or any bank or other charges properly charged to the Purchase Price Escrow Account) shall accrue to and form part of the Purchase Price Escrow Account.

Any payment under this Clause 4 shall be made to such account as the relevant Party has specified in accordance with the Purchase Price Escrow Agreement. Payment to such account shall constitute a full discharge by the Purchase Price Escrow Bank to the payee in respect of the relevant payment obligation. Both the Seller and the Purchaser undertake to each other to issue instructions for payment from the Purchase Price Escrow Account of the amounts due under this Clause 4 without delay when such instructions are due to be delivered pursuant to this Clause 4.

Subject to Clause 4.7, upon the Purchase Price Escrow Amount being paid into the Purchase Price Escrow Account it shall be held in the Purchase Price Escrow Account for a period (the “Purchase Price Escrow Period”) that shall be 90 calendar days.

If, prior to the expiry of the Purchase Price Escrow Period, an order or judgment of the Bankruptcy Court (as defined in Schedule 8) or any other court of competent jurisdiction that has been entered on the docket in the Chapter 11 Cases (as defined in the Indemnification Agreement) (or the docket of such other court) in relation to any of the matters set out in paragraph 1 of Schedule 8, the Purchase Price Escrow Period shall be extended for a further 21 calendar days.

If the Conditions are fulfilled prior to the expiry of the Purchase Price Escrow Period, then the Seller and the Purchaser shall, as soon as practicable, jointly notify the Purchase Price Escrow Bank of the fulfilment of the Conditions and the proposed Completion Date. Prior to the proposed Completion Date, the Seller and the Purchaser shall also provide the Purchase Price Escrow Bank with a draft release notice specifying:

the amount of the Purchase Price Escrow Amount that is payable to the Seller’s Solicitors’ Bank Account (or as otherwise directed by the Seller) in accordance with Clause 7.4; and

that any residual sum (if any) in the Purchase Price Escrow Account is payable on the Completion Date to such account as the Purchaser has specified in accordance with the Purchase Price Escrow Agreement.

The Purchaser and the Seller shall provide an executed version of the release notice, signed by both Parties, to the Purchase Price Escrow Bank on the Completion Date (or at such other time as the Parties agree) to enable the payments set out in Clause 4.8 to be made out of the Purchase Price Escrow Account on the Completion Date.

Without prejudice to the Purchaser’s obligations under this Agreement, any Equity Commitment Letter or any other Transaction Document, if the Conditions have not been satisfied upon expiry of the Purchase Price Escrow Period, then any funds standing to the

the Audited Accounts;

the duly executed reliance letters in favour of Vortex Solar Investments S.à r.l., in respect of each of the Certificates of Title;

written confirmation from the Security Trustee and Facility Agent that:

the Transaction constitutes a Permitted Change of Control;

the Existing Finance Parties have completed their “Know Your Client” checks in respect of the Purchaser and its Affiliates to their satisfaction (and to the extent required under the Common Terms Agreement); and

all other consents, approvals and waivers of the Existing Finance Parties required in respect of or as a result of the Transaction have been duly obtained or waived, as applicable;

written consent from the Security Trustee and Facility Agent for the termination of the existing insurance policies relating to the Group and the entry into the new insurance policies relating to the Group;

waivers from the Security Trustee and Facility Agent of all subsisting defaults under the Existing Facilities; and

due evidence of the satisfaction of the Condition set out in Schedule 8,

The Seller shall use all reasonable efforts to ensure the satisfaction of each Condition as soon as possible after the date of this Agreement.

The Purchaser shall use all reasonable efforts to ensure the satisfaction of the Conditions set out in Clauses 5.1.3 and 5.1.4.

The Seller shall promptly notify the Purchaser in writing upon the satisfaction of each Condition.

The Purchaser may at any time waive, in whole or in part and conditionally or unconditionally, any Condition by written notice to the Seller.

If any Condition is not satisfied (or waived by the Purchaser) on or before 5:00 p.m. (UK time) on the Long Stop Date, or becomes incapable of satisfaction before the Long Stop Date, the Purchaser may, in its sole discretion, terminate this Agreement and no Party (or any of its Affiliates) shall have any claim of any nature whatsoever against any other Party (or any of its Affiliates) under any Transaction Document, save in respect of any rights and/or liabilities which have accrued before termination or under any of the Surviving Clauses.

a definitive M&A Transaction (as defined in Schedule 8) has not been signed; or

an Avoidance Action Settlement (as defined in Schedule 8) has not been reached,

From the date of this Agreement until Completion, the Seller shall comply, and shall procure that the Group Companies comply, with the obligations set out in Schedule 6.

The Seller shall, no later than 8 Business Days prior to Completion, provide the Purchaser with a schedule (the “Payment Schedule”) setting out:

the amount of the Loan Note Redemption Amount;

the Receivable Payment Amount;

the Other Receivables Payment Amount (if any); and

the amount of the Notified Leakage Amount.

In the event that Completion is deferred beyond the intended Completion Date in accordance with the terms of this Agreement and a Payment Schedule has been

the Purchaser shall deliver or take (or cause to be delivered or taken) the documents and actions listed in Part A of Schedule 4 (Completion); and

the Seller shall deliver or take (or cause to be delivered and taken) the documents and actions listed in Part B of Schedule 4 (Completion).

pay (or procure payment out of the Purchase Price Escrow Account of) the Consideration in cleared funds to the Seller’s Solicitors’ Bank Account;

on behalf of the Direct Subsidiary, pay (or procure payment out of the Purchase Price Escrow Account of) the Receivable Payment Amount in cleared funds to the Seller’s Solicitors’ Bank Account (and, for the avoidance of doubt, the Direct Subsidiary will as a result thereof owe an amount equal to the Receivable Payment Amount to the Purchaser);

to the extent required, on behalf of the Company, pay (or procure payment out of the Purchase Price Escrow Account of) any Other Receivables Payment Amount in cleared funds to the Seller’s Solicitors’ Bank Account (and, for the avoidance of doubt, the Company will as a result thereof owe an amount equal to the Other Receivables Payment Amount to the Purchaser); and

on behalf of the Company, pay (or procure payment out of the Purchase Price Escrow Account of) the Loan Note Redemption Amount in cleared funds to the Seller’s Solicitors’ Bank Account, which upon such payment shall constitute full and final settlement of all liabilities owed between any Group Company and any member of the Seller’s Group (and, for the avoidance of doubt, the Company will as a result thereof owe an amount equal to the Loan Note Redemption Amount to the Purchaser).

in the case of material non-compliance with Clause 7.2, to terminate this Agreement (other than the Surviving Clauses) and each of the other Transaction Documents;

to effect Completion so far as practicable having regard to the defaults which have occurred; or

to fix a new date for Completion, not being later than four Business Days, in which case the foregoing provisions of Clause 7.4 shall apply to Completion as so deferred.

For the avoidance of doubt, payments made to SunE Greenfield in the ordinary course of business pursuant to the O&M Agreements, the Management Services Agreements and the Transitional Services Agreement for services provided thereunder are not Leakage (but, without limitation, any payment which arises solely due to or as a result of the termination of any or all of the O&M Agreements, the Management Services Agreements and/or the Transitional Services Agreement is Leakage).

The Seller agrees and acknowledges that, to the extent it has not already done so, (i) it shall pay, on behalf of the relevant Group Companies, all sums necessary to terminate any or all of the O&M Agreements, the Management Services Agreements and/or the Transitional Services Agreement pursuant to the Transitional Services Agreement; and (ii) no such payment shall give rise to any debt owed by any Group Company or the Purchaser to the Seller and if and to the extent any such debt may exist, the Seller hereby fully, unconditionally and irrevocably waives such debt.

if the Total Working Capital is less than the Estimated Total Working Capital, the Seller shall repay to the Purchaser or procure the repayment to the Purchaser of an amount equal to such difference, or

if the Total Working Capital exceeds the Estimated Total Working Capital, the Purchaser shall pay or procure the payment to the Seller of an additional amount equal to such excess amount.

If the Purchaser does not within 16 Business Days of presentation to it of the Audited Accounts pursuant to Clause 5 and notification of the Total Working Capital in accordance with Clause 9.1 give Notice to the Seller that it disagrees with the Total Working Capital, such Notice stating the reasons for the disagreement in reasonable detail and specifying the adjustments which, in the Purchaser’s opinion should be made to the Total Working Capital (the “Purchaser’s Disagreement Notice”), the Total Working Capital notified by the Seller to the Purchaser in accordance with Clause 9.1 shall be final and binding on the Parties for all purposes. If the Purchaser gives a valid Purchaser’s Disagreement Notice within such 16 Business Day period, the Seller and the Purchaser shall attempt in good faith to reach agreement in respect of the Total Working Capital and, if they are unable to do so within 16 Business Days of such notification, the Seller or the Purchaser may by Notice to the other require that the matter be referred to the Reporting Accountants.

The Reporting Accountants shall be engaged jointly by the Seller and the Purchaser on the terms set out in this Clause 9.2 and otherwise on such terms as shall be agreed; provided that neither the Seller nor the Purchaser shall unreasonably (having regard, inter alia, to the provisions of this Clause 9.2) refuse its agreement to terms proposed by the Reporting Accountants or by the other Party.

Except to the extent that the Seller and the Purchaser agree otherwise, the Reporting Accountants shall determine their own procedure but:

apart from procedural matters and as otherwise set out in this Agreement shall determine only:

whether any of the arguments for an alteration to the Total Working Capital put forward in the Purchaser’s Disagreement Notice is correct in whole or in part; and

if so, what alterations should be made to the Total Working Capital in order to correct the relevant inaccuracy in it;

shall make their determination pursuant to Clause 9.2.3(i) above as soon as is reasonably practicable;

the procedure of the Reporting Accountants shall:

give the Seller and the Purchaser a reasonable opportunity to make written representations to them, which shall not exceed 8 Business Days; and

require the Reporting Accountant to supply the Seller and the Purchaser with a copy of any written representations made by the other upon the expiry of the period given to them pursuant to Clause 9.2.3(iii)(a);

for the avoidance of doubt, the Reporting Accountants shall not be entitled to determine the scope of their own jurisdiction.

The determination of the Reporting Accountants pursuant to Clause 9.2.3(i):

shall be made available to the Seller and the Purchaser in writing; and

unless otherwise agreed by the Seller and the Purchaser shall include reasons for each relevant determination.

The Reporting Accountants shall act as experts and not as arbitrators and their determination of any matter falling within their jurisdiction shall be final and binding on the Seller and the Purchaser save in the event of fraud or manifest error (when the relevant part of their determination shall be void and the matter shall be remitted to the Reporting Accountants for correction).

The expenses (including amounts in respect of VAT) of the Reporting Accountants shall be borne as they shall direct at the time they make any determination under Clause 9.2.3(i) or, failing such direction, equally between the Purchaser and the Seller.

The Seller and Purchaser shall co-operate with the Reporting Accountants and comply with their reasonable requests made in connection with the carrying out of their duties under this Agreement. In particular, the Purchaser shall keep up-to-date and, subject to reasonable notice, make available during normal office hours to the Reporting Accountants all books and records relating to the Group as the Reporting Accountants may reasonably request during the period from the appointment of the Reporting Accountants down to the making of the relevant determination.

Nothing in this Clause 9.2 shall entitle a Party or the Reporting Accountants access to any information or document which is protected by legal professional privilege or litigation privilege, provided that neither the Seller nor the Purchaser shall be entitled to refuse to supply such part or parts of documents as contain only the facts on which the relevant claim or argument is based.

Each of the Seller and the Purchaser and the Reporting Accountants shall, and shall procure that its accountants and other advisers shall, keep all information and documents provided to them pursuant to this Clause 9.2 confidential and shall not use the same for any purpose, except for disclosure or use in connection with the derivation of the Total Working Capital, the proceedings of the Reporting Accountants or another matter arising out of this Agreement.

All sums payable under this Agreement or the Indemnification Agreement shall be paid free and clear of all deductions, withholdings, set-offs or counterclaims whatsoever save only as may be required by law. If any deductions or withholdings are required by law to be made from any payment under this Agreement or the Indemnification Agreement (except (i) of interest, (ii) of Consideration paid under Clause 3.2, (iii) pursuant to Clause 8.2 or Clause 9.1, (iv) of the Receivable Payment Amount or Other Receivables Payment Amount or (v) to the extent that the relevant withholding or deduction has already been taken into account in determining the amount of the payment or the recipient has otherwise been compensated therefor):

to the Purchaser; or

by the Purchaser to the Seller,

If, and to the extent that, any relevant Tax Authority notifies any party that it considers that any amount (including, for these purposes, where such amount is nil) deducted or withheld from a payment under this Agreement or the Indemnification Agreement is less than the amount required by law:

the parties shall co-operate in order to ensure that the correct amount is accounted for to the relevant Tax Authority; and

either:

where, had the correct amount been deducted or withheld, the payer would not, pursuant to Clause 9.5.1, have been obliged to increase the amount of the payment to the recipient as a result of the deduction or

in all other cases, the payer shall indemnify the recipient and the recipient’s Affiliates against any Losses suffered as a result thereof,

The recipient or expected recipient of an amount paid under this Agreement or the Indemnification Agreement shall take (and, where relevant, procure that its Affiliates take) all reasonable measures to claim from the appropriate Tax Authority any exemption, rate reduction, refund, credit or similar benefit (including pursuant to any relevant double tax treaty) to which it is entitled in respect of any deduction or withholding in respect of which a payment has been made or would otherwise be required to be made pursuant to Clause 9.5.1 and, for such purposes, shall, within any applicable time limits, submit any claims, notices, returns or applications and send a copy thereof to the payer.

If the recipient of a payment made under this Agreement or the Indemnification Agreement (or any of its Affiliates) receives a credit for or refund of any Taxation payable by it or similar benefit by reason of any deduction or withholding for or on account of Taxation then it shall reimburse to the payer such part of such additional amounts paid to it pursuant to Clause 9.5.1 above as the recipient of the payment certifies to the payer will leave it (after such reimbursement) in no better and no worse position than it would have been if the payer had not been required to make such deduction or withholding.

Where any payment is made under this Agreement or the Indemnification Agreement (a) by the Seller to the Purchaser pursuant to an indemnity, compensation or reimbursement provision (including, for the avoidance of doubt, pursuant to Clause 8.2 or Clause 12; but not including, for the avoidance of doubt, any payment (i) of interest or (ii) pursuant to Clause 9.1), or as a result of a breach of a Seller’s Warranty or (b) by the Purchaser to the Seller pursuant to an indemnity, compensation or reimbursement provision (not including, for the avoidance of doubt, any payment (i) of interest, (ii) of Consideration paid under Clause 3.2 or (iii) pursuant to Clause 9.1), or as a result of a breach of a Purchaser’s Warranty, and that sum is subject to a charge to Taxation in the hands of the recipient or would be in the absence of any Purchaser’s Reliefs then the sum payable shall be increased to such sum as will ensure that after payment of such Taxation (including any Taxation which would have been charged in the absence of any Purchaser’s Reliefs), the recipient shall be left with a sum equal to the sum that it would have received in the absence of such a charge to Taxation provided that if the recipient shall have transferred (for the avoidance of doubt, by whatever means, including by way of a declaration of trust or anything that amounts in substance to a transfer) the benefit in whole or in part of this Agreement or the Indemnification Agreement or shall have changed its tax residence or the permanent establishment to which the rights under this Agreement or the Indemnification Agreement are allocated the liability of the payer under this Clause

Clause 9.5.5 shall not apply to Taxation (i) to the extent that the amount of the indemnity, compensation or reimbursement payment has already been increased to take account of the Taxation that will or would be charged on receipt, or (ii) to the extent that the amount of the payment or refund has already been increased to take account of the Taxation that will or would be charged on receipt.

Clause 9.5.5 shall apply (for the avoidance of doubt, subject to the exclusions in Clause 9.5.6) to any amount deducted, withheld, set off or counterclaimed as contemplated by Clause 9.5.1 as it applies in respect of sums paid to the person entitled.

Where under the terms of this Agreement one party is liable to indemnify or reimburse another party in respect of any costs, charges or expenses, the payment shall include any amount in respect of VAT included within such costs, charges or expenses not otherwise recoverable by the other party or the representative member of any VAT group of which it forms part, but excluding any such amount in receipt of VAT that is so recoverable by that person or representative member.

If any payment under this Agreement constitutes the consideration for a taxable supply for VAT purposes, then (i) the recipient shall provide to the payer a valid VAT invoice, and (ii) except where the reverse charge procedure applies, and subject to the provision of a valid VAT invoice in accordance with (i), in addition to that payment the payer shall pay to the recipient an amount equal to any VAT due for which the recipient is liable to account.

The Seller’s Warranties are subject to any matter which is fairly disclosed in this Agreement, in the Disclosure Letter or in the Data Room.

References in the Disclosure Letter to paragraph numbers shall be to the paragraphs in Schedule 2 (Seller’s Warranties) to which the disclosure is most likely to relate. Such references are given for convenience only and shall not limit the effect of any of the disclosures, all of which are made against the Seller’s Warranties as a whole.

The Purchaser undertakes that following Completion it shall promptly confirm to the Seller the satisfaction of SunE Greenfield’s obligations pursuant to clause 6.1.2 of the Transitional Services Agreement in respect of each Relevant Project (as defined in the Transitional Services Agreement).

The Seller undertakes that following Completion it shall use its reasonable endeavours to assist the Direct Subsidiary with its compliance with the obligations set out in clauses 5.2.2 and 5.3.3 of the Remedial Works Agreement.

given Notice of such Claim, specifying reasonable information in relation to the matter which gives rise to the Claim, the nature of the Claim and (to the extent reasonably available to the Purchaser) a bona fide estimate of the amount claimed (on a without prejudice basis), as soon as reasonably practicable after the Purchaser became aware of such Claim and in any event by no later than the date falling:

in relation to a claim under Clause 8, four months after the Completion Date; or

in relation to any Fundamental Warranty Claim, four years after the Completion Date; or

in relation to a Claim (other than a Fundamental Warranty Claim, Tax Deed Claim or Tax Warranty Claim), 18 months after the Completion Date; or

in relation to a Tax Deed Claim or a Tax Warranty Claim, seven years after the Completion Date.

in the case of any Claim, other than a Tax Deed Claim (if it has not been previously satisfied, settled or withdrawn), issued and served Proceedings in respect of the relevant Claim within six months of the date of notification of such Claim in accordance with Clause 11.1.1, provided that:

in the case of a Claim, other than a Tax Deed Claim, which relates to a contingent liability, this six month period shall instead commence on the date the relevant contingent liability becomes an actual liability and is due and payable; or

in the case of a Claim, other than a Tax Deed Claim, which is notified in accordance with Clause 11.1.1 at a time when the relevant amount or threshold specified in Clause 11.2 or 11.3, as applicable, has not been exceeded, this six month period shall instead commence on the date of any subsequent notification of one or more such Claim(s) in accordance with Clause 11.1.1 which result(s) in the total amount claimed pursuant to such Claims exceeding the relevant amount or threshold specified in Clause 11.2 or 11.3, as applicable.

The Seller shall not be liable for any individual claim (or a series of claims arising from substantially identical facts or circumstances) under or in respect of the Seller’s Warranties (other than the Fundamental Warranties) where the liability agreed or determined for any such claim or series of claims does not exceed £100,000.

Where the liability agreed or determined in respect of any such claim or series of claims under or in respect of the Seller’s Warranties (other than the Fundamental Warranties) exceeds £100,000, the liability of the Seller shall be for the whole amount of such claim(s) and not limited to the amount of the excess.

The Seller shall not be liable for any claim (or a series of claims arising from substantially identical facts or circumstances) under or in respect of the Seller’s Warranties (other than the Fundamental Warranties) unless the aggregate amount of all such claims for which the Seller would otherwise be liable (disregarding the provisions of this Clause 11.3) exceeds an amount equal to £1,250,000.

Where the liability agreed or determined in respect of all claims referred to in Clause 11.3.1 exceeds an amount equal to £1,250,000, the liability of the Seller shall be for the whole amount of such claim(s) and not limited to the amount of the excess.

The maximum aggregate liability of the Seller in relation to any claims under or in respect of the Seller’s Warranties (other than the Fundamental Warranties) shall not exceed an amount equal to 30 per cent. of the Aggregate Amount.

The maximum aggregate liability of the Seller in relation to all claims arising out of or in connection with any Transaction Document shall not in any circumstances exceed the Aggregate Amount.

any matter or thing done or omitted to be done pursuant to and in compliance with this Agreement or any other Transaction Document or otherwise at the request in writing or with the approval in writing of the Purchaser;

any act, omission or transaction of the Purchaser or any member of the Purchaser’s Group, or their respective directors, officers, employees or agents or successors in title, after Completion;

the passing of, or any change in, after the date of this Agreement, any law, rule, regulation or administrative practice of any Governmental Authority including (without prejudice to the generality of the foregoing) any increase in the rates of Taxation or any imposition of Taxation or any withdrawal of relief from Taxation not actually (or prospectively) in effect at the date of this Agreement;

any change after the date of this Agreement of any generally accepted interpretation or application of any legislation;

any change after the date of this Agreement of any generally accepted accounting principles, procedure or practice; or

any change in accounting or Taxation policy, bases or practice of the Purchaser or the Purchaser’s Group (except where such change was necessary to comply with law or generally accepted accounting principles).

The limitations of liability contained in this Clause 11 shall not apply to the warranty or the undertaking given by the Seller in Clause 8.1 above (other than that specified in Clause 11.1.1(i)).

The limitations of liability contained in this Clause 11 shall not apply to the Guarantor’s liability pursuant to, and in connection with, the Indemnification Agreement save that the provisions of Clause 11.13 shall operate to prevent any double recovery under this Agreement and the Indemnification Agreement.

acts or omissions of Lightsource in its capacity as asset management and/or operation and maintenance provider to the Group Companies; or

any event, circumstance, effect, occurrence or state of affairs or any combination of them (whether existing or occurring on or before the Completion Date) but not before the date of this Agreement that is outside of the control (whether directly or indirectly) of any member of the Seller’s Group,

On the Completion Date, the Seller shall pay the sum of £1,000,000 (the “Spare Parts Escrow Amount”) into the Seller’s Solicitors’ Bank Account (for this purpose, the “Spare Parts Escrow Account”) and irrevocably release it to the order of the Seller’s Solicitors (the “Spare Parts Escrow Agent”) subject to the provisions of this Clause 12.

The Spare Parts Escrow Agent shall hold the Spare Parts Escrow Amount as stakeholder on the terms of the Spare Parts Escrow Agreement in the joint names of the Purchaser and the Seller. The Spare Parts Escrow Agent shall not release any of the Spare Parts Escrow Amount except as provided in this Clause 12 and the Spare Parts Escrow Agreement.

Any bank or other charges arising on the Spare Parts Escrow Account shall be charged to the Spare Parts Escrow Account. Any interest or profit generated on the Spare Parts Escrow Account (subject to any deduction of tax at source or any bank or other charges properly charged to the Spare Parts Escrow Account) (the “Income”) shall accrue to and form part of the Spare Parts Escrow Account. Each time part of the Spare Parts Escrow Amount is paid out it shall have added to it the corresponding proportion of the Income.

Any payment under this Clause 12 shall be made to such account as the relevant Party has specified in accordance with the Spare Parts Escrow Agreement. Payment to such account shall constitute a full discharge by the Spare Parts Escrow Agent to the payee in respect of the relevant payment obligation. Both the Seller and the Purchaser undertake to each other to issue instructions for payment from the Spare Parts Escrow Account of the amounts due under this Clause 12 without delay.

As soon as practicable following Completion, the Purchaser shall procure that Lightsource shall perform an inventory of the Spare Parts Stock which are owned by and in the possession of the Group Companies and shall provide a written report, which shall consist of:

a reconciliation between the Spare Parts Stock and the Spare Parts Required Stock; and

an estimate of the aggregate value in pounds sterling of the spare parts on each of the list of Spare Parts Stock and the list of Spare Parts Required Stock (the “Estimate”),

If, on the other hand, the Seller or the Purchaser notifies the other in writing that it does not agree with the Estimate, then the Seller and the Purchaser shall jointly instruct the Independent Technical Adviser to perform its own inventory of the Spare Parts Stock and to provide a written report thereon, which shall also include a report on the aggregate value of the Spare Parts Required Stock (the “Independent Inventory Report”), to the Seller and the Purchaser. The Seller and Purchaser agree that the Independent Inventory Report shall be binding on them, save in the case of manifest error. Subject to the foregoing, no later than two Business Days following receipt by the Seller and the Purchaser of the Independent Inventory Report, the Seller and Purchaser shall jointly instruct the Spare Parts Escrow Agent in writing as follows:

if the valuation of the Spare Parts Required Stock exceeds the valuation of the Spare Parts Stock (in each case as set out in the Independent Inventory Report), to pay an amount equal to the difference out of the Spare Parts Escrow Account to the Purchaser (together with the relevant proportion of Income accrued thereon in accordance with Clause 12.3) and immediately thereafter to cause the balance (if any) remaining in the Spare Parts Escrow Account to be paid to the Seller; or

if the valuation of the Spare Parts Stock is equal to or exceeds the valuation of the Spare Parts Required Stock (in each case as set out in the Independent Inventory Report) to pay all sums in the Spare Parts Escrow Account to the Seller.

In no circumstances shall the Seller be obliged to pay the Purchaser any sums in excess of the amount standing to the credit of the Spare Parts Escrow Account in respect of the matters set out in this Clause 12.

The Guarantor unconditionally and irrevocably guarantees to the Purchaser the due and punctual performance and observance by the Seller of all its obligations, commitments, undertakings, warranties and indemnities under or pursuant to the Transaction Documents (the “Guaranteed Obligations”) and agrees that if any Guaranteed Obligation is or becomes unenforceable, invalid or illegal it will, as an independent and primary obligation, indemnify the Purchaser immediately on demand against all Losses which the Purchaser suffers through or arising from any act or omission that would be a breach by the Seller of the Guaranteed Obligations if the relevant Guaranteed Obligation were not unenforceable, invalid or illegal, to the extent of any limit on the liability of the Seller in this Agreement.

If and whenever the Seller defaults for any reason whatsoever in the performance of any of the Guaranteed Obligations, the Guarantor shall forthwith upon demand unconditionally perform (or procure performance of) and satisfy (or procure the satisfaction of) the Guaranteed Obligations in regard to which such default has been made in the manner prescribed by the relevant Transaction Document and so that the same benefits shall be conferred on the Purchaser as it would have received if the Guaranteed Obligations had been duly performed and satisfied by the Seller.

This guarantee is to be a continuing guarantee and accordingly is to remain in force until all the Guaranteed Obligations shall have been performed or satisfied. This guarantee is in addition to and without prejudice to and not in substitution for any rights or security which the

As a separate and independent stipulation the Guarantor agrees that any of the Guaranteed Obligations (including any moneys payable) which may not be enforceable against or recoverable from the Seller by reason of any legal limitation, disability or incapacity on or of the Seller or the dissolution, amalgamation or reconstruction of the Seller or any other fact or circumstances (other than any limitation imposed by this Agreement) shall nevertheless be enforceable against and recoverable from the Guarantor as though the same had been incurred by the Guarantor and the Guarantor were the sole or principal obligor in respect thereof and shall be performed or paid by the Guarantor on demand.

The liability of the Guarantor under this Clause 13 shall not be affected, impaired, reduced or released by:

any variation of the Guaranteed Obligations;

any forbearance, neglect or delay in seeking performance of the Guaranteed Obligations or any granting of time for such performance;

the illegality, invalidity, unenforceability or, or any defect in, any provision of a Transaction Document or the Seller’s obligations under any of them;

any insolvency or similar proceeding; or

any other fact or event which in the absence of this provision would or might constitute or afford a legal or equitable discharge or release or a defence to a guarantor.

On the date of this Agreement:

the Seller shall procure that the Legal Opinion is issued to the Purchaser; and

the Purchaser shall procure that the Equity Commitment Letters are delivered to the Seller.

The Seller shall use its reasonable endeavours to deliver an electronic copy of the contents of the Data Room to the Purchaser prior to execution of this Agreement and to the extent it has not been able to do so, shall use reasonable endeavours to do so as soon as practicable following the date of this Agreement.

The Parties hereby agree to the release of the Press Announcements promptly following the execution and delivery of this Agreement by or on behalf of the Parties.

Save for the Press Announcements (and any announcement that is consistent in all material respects with the Press Announcements or any other announcement made in accordance with this Clause 16.2) and subject to Clause 16.4, no public announcement concerning the existence or subject matter of this Agreement shall be made by or on behalf of any Party or any member of the Seller’s Group or the Purchaser’s Group without the prior written approval of the Purchaser and the Seller.

Subject to Clause 16.4, the Purchaser undertakes to the Seller that it shall not, and following Completion shall procure that each Group Company shall not, between the date of this Agreement and the date falling nine months after the Completion Date, disclose the purchase price, or any information from which the purchase price could be readily ascertained, for:

the sale of any Shares, or assets directly held by the Company, unless the Seller has provided its prior written consent (such consent not to be unreasonably withheld, conditioned or delayed) to such disclosure; or

the sale of any shares in, or assets directly held by, Vortex Solar UK4 Limited, Vortex Solar UK3 Limited, Vortex Solar UK2 Limited or the Purchaser without first consulting with and taking into account any reasonable requests made by the Seller in relation to such disclosure.

A Party may make an announcement concerning the existence or the subject matter of any of the transactions described in Clause 16.3 if required by:

any applicable law or enactment; or

any securities exchange or Governmental Authority to which that Party or any of its Affiliates is subject or submits, wherever situated.

A Party may make an announcement concerning the existence or the subject matter of this Agreement if required by:

any applicable law or enactment; or

any securities exchange or Governmental Authority to which that Party or any of its Affiliates is subject or submits, wherever situated,

Subject to Clauses 17.2 and 17.4, each Party shall treat as strictly confidential and shall not disclose to any other person any information received or obtained as a result of entering into or performing this Agreement which relates to the existence of this Agreement, the provisions of this Agreement, the negotiations and subject matter of this Agreement and the other Parties (“Confidential Information”) (including written information and information transferred or obtained orally, visually, electronically or by any other means).

A Party may disclose information which would otherwise be subject to the provisions of Clause 17.1 if and to the extent:

it is required by applicable law or enactment to which such Party is subject;

it is an announcement made in accordance with the provisions of Clause 15;

it is required by any securities exchange or Governmental Authority to which the Party or any of its Affiliates is subject or submits, wherever situated, whether or not the requirement for information has the force of law;

it is disclosed on a strictly confidential basis to that Party’s Affiliates, Representatives and the Representatives of its Affiliates;

it is disclosed to such Party’s third party financing sources and their professional advisers in connection with the Transaction, provided that such financing sources and their professional advisers are bound by confidentiality obligations in respect of the Confidential Information that are substantially in the form contained in the Loan Market Association’s standard form non-disclosure agreement, save for any professional advisors who are subject to a professional duty of confidentiality;

it was lawfully in its possession or in the possession of any of its Affiliates, Representatives or Representatives of its Affiliates (in either case as evidenced by written records or other reasonable evidence), free of any restriction as to its use or disclosure prior to it being so disclosed;

the information has come into the public domain through no fault of that Party or its Affiliates, Representatives or Representatives of its Affiliates;

that the Seller (in relation to disclosure by the Purchaser) or the Purchaser (in relation to disclosure by the Seller) has given prior written consent to the disclosure;

the information is disclosed to a Tax Authority and such disclosure is reasonably required in connection with that Party’s Tax affairs;

it is required to enable that Party to perform this Agreement or enforce its rights under this Agreement or disclosure is required for the purposes of any Proceedings; or

it is disclosed on a strictly confidential basis to the SunEdison Debtors (as defined in the Indemnification Agreement) or the Creditors’ Committee,

Each of the Parties hereby agrees that it shall not use Confidential Information for any purpose other than in relation to the proper performance of its obligations and exercise of its rights under this Agreement (and the transactions contemplated hereby) or in connection with the business of the Group Companies.

Each of the Parties undertakes that it shall, and shall procure that its Affiliates shall, only disclose Confidential Information to any of its Representatives if it is reasonably required for purposes connected with this Agreement (or the other Transaction Documents) and only if the Representative is informed of the confidential nature of the Confidential Information and accepts equivalent restrictions to those accepted by the Party who discloses the information.

Any notice or other communication to be given under or in connection with this Agreement (a “Notice”) shall be:

in writing in the English language;

signed by or on behalf of the Party giving it; and

delivered personally by hand or courier (using an internationally recognised courier company) or sent by first class post (or by airmail if overseas) or recorded delivery or by email, to the Party due to receive the Notice, to the address and for the attention of the relevant Party set out in this Clause 18 (or to such other address and for such other person’s attention as shall have been notified to the giver of the relevant Notice and become effective in accordance with this Clause 18 prior to dispatch of the Notice).

In the absence of evidence of earlier receipt, any Notice served in accordance with Clause 18.1 shall be deemed given and received:

in the case of personal delivery by hand or courier, at the time of delivery at the address referred to in Clause 18.4;

in the case of first class post (other than airmail) or recorded delivery, at 10.00 a.m. on the second Business Day after posting;

in the case of airmail, at 10.00 a.m. on the fifth Business Day after posting; and

in the case of email, at the time of sending, provided that receipt shall not occur if the sender receives an automated message that the email has not been delivered to the recipient.

For the purposes of this Clause 18:

all times are to be read as local time in the place of deemed receipt;

if deemed receipt under this Clause 18 is not within business hours (meaning 9.00 a.m. to 5.30 p.m. Monday to Friday on a day that is not a public holiday in the place of receipt), the Notice is deemed to have been received at 9.00 a.m. on the next Business Day in the place of receipt; and

in the case of a Notice sent by email, the place of receipt is the place in which the Party to whom Notice is sent has its postal address under this Agreement.

The addresses of the Parties for the purpose of this Clause 18 are as follows:

The Seller and the Guarantor: SunEdison Yieldco UK HoldCo 2, LLC

In proving receipt or deemed receipt, it shall be sufficient to prove that the envelope containing the Notice or communication was properly addressed to the address shown thereon or that

Any Party may notify the other Party of any change to its name, address or email address for the purpose of this Clause 18 provided that such Notice shall only be effective on:

the date specified in the Notice as the date on which the change is to take effect; or

if no date is so specified or the date specified is less than three Business Days after which such Notice was given (or deemed to be given), the fourth Business Day after the Notice was given or deemed to be given.

This Clause 18 shall not apply to the service of, or any step in, Proceedings.

No Party may assign the benefit of this Agreement (in whole or in part), transfer, declare a trust of or otherwise dispose of in any manner whatsoever its rights and obligations under this Agreement or sub-contract or delegate its performance under this Agreement (each of the above a “Dealing”) without the prior written consent of either the Seller (in the event of intended assignment by the Purchaser) or the Purchaser (in the event of intended assignment by the Seller), such consent to be at the absolute discretion of the other Party to withhold provided that:

the Seller may assign the benefit of this Agreement (in whole or in part) to another member of the Seller’s Group without the consent of the Purchaser provided that if the assignee ceases to be a member of the Seller’s Group, it shall before ceasing to be so assign the benefit, so far as assigned to it, back to the Seller or to another member of the Seller’s Group;

following the Completion Date, the Purchaser may assign the benefit of this Agreement (in whole or in part), or transfer any or all obligations or liabilities of the Purchaser under this Agreement, to another member of the Purchaser’s Group without the consent of the Seller provided that if the assignee ceases to be a member of the Purchaser’s Group, it shall before ceasing to be so assign the benefit, so far as assigned to it, back to the Purchaser or to another member of the Purchaser’s Group; and

the Purchaser may assign its rights under this Agreement (by way of security only) to any bank or financial institution lending money or making other facilities available to the Purchaser (or one of the members of the Purchaser’s Group), the principal purposes of which is to fund (i) the acquisition or the refinancing of the acquisition of the Shares, (ii) the refinancing of the existing indebtedness of the Group or (iii) any capital expenditure, acquisitions and general working capital of the Group.

If there is a Dealing under Clause 19.1:

the liability of a non-assigning Party to any assignee cannot be greater than its liability to the original Party; and

the assignee may enforce this Agreement as if it were a party to it, but the assignor will remain liable for its obligations under this Agreement.

Any Dealing or purported Dealing in contravention of this Clause 19 shall be ineffective.

Each Party that has rights under this Agreement hereby confirms that it is acting on its own behalf and not for the benefit of another person.

Save as otherwise expressly provided in this Agreement, each Party shall pay its own costs and expenses in relation to the negotiation, preparation, execution and carrying into effect of this Agreement and all other documents mentioned herein.

All stamp duty and SDRT payable on or in respect of the transfer of the Shares shall be borne by the Purchaser. The Purchaser shall be responsible for arranging the payment of such stamp duty and SDRT, including fulfilling any administrative or reporting obligation imposed by the jurisdiction in question in connection with such payment. The Purchaser shall indemnify the Seller or any other member of the Seller’s Group against any Losses suffered by the Seller or member of the Seller’s Group as a result of the Purchaser failing to comply with its obligations under this Clause 20.2.

If at any time any provision of this Agreement shall be held to be illegal, void, invalid or unenforceable, in whole or in part, under any enactment or rule of law in any jurisdiction, then:

such provision shall:

to the extent that it is illegal, void, invalid or unenforceable, be given no effect and shall be deemed not to be included in this Agreement; and

not affect or impair the legality, validity or enforceability in that jurisdiction of any other provision of this Agreement or the legality, validity or enforceability under the law of any other jurisdiction of such provision or any other provision of this Agreement; and

the Parties shall use all reasonable endeavours to replace such a provision with a valid and enforceable substitute provision which carries out, as closely as possible, the intentions of the Parties under this Agreement.

A person who is not a party to this Agreement has no right under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of or enjoy any benefit under, this Agreement except to the extent set out in this Clause 22.

An assignee pursuant to Clause 19.1 may enforce and rely on this Agreement as if it were a Party.

The Noteholder may enforce and rely on Clause 7.4.2 to the same extent as if it were a party to this Agreement.

Notwithstanding the provisions of Clause 22.2 or any benefits conferred by this Agreement on any third party by virtue of the Contracts (Rights of Third Parties) Act 1999, the Parties

Each of the Parties to this Agreement confirms that the content of this Agreement as expressly set out herein, together with the content of the Transaction Documents as expressly set out therein, represents the entire understanding, and constitutes the whole agreement, in relation to its subject matter and the transactions contemplated by it and supersedes all previous agreements, understandings or arrangements (whether express, implied, oral or written (whether or not in draft form)) between the Parties with respect thereto which shall cease to have any further force or effect, notwithstanding the existence of any provision of any such prior agreement or understanding that any such rights or provisions shall survive its termination and, without prejudice to the generality of the foregoing, excludes any warranty, condition or other undertaking implied at law or by custom, usage or course of dealing.

Each of the Purchaser (for itself and on behalf of each other member of the Purchaser’s Group) and the Seller (for itself and on behalf of each other member of the Seller’s Group) confirms that:

in entering into this Agreement and the other Transaction Documents it has agreed not to rely on any representation (including any misrepresentation or any misstatement), warranty, collateral contract, assurance, covenant, indemnity, undertaking or commitment which is not expressly set out in this Agreement and the other Transaction Documents; and

in any event, without prejudice to any liability for fraudulent misrepresentation or fraudulent misstatement, the only rights or remedies in relation to any representation (including any misrepresentation or any misstatement), warranty, collateral contract, assurance, covenant, indemnity, undertaking or commitment given or action taken in connection with this Agreement, or with any of the Transaction Documents, shall be for breach of the terms of this Agreement or such Transaction Document, and for the avoidance of doubt, no Party has any other right or remedy (whether by way of a claim for contribution or otherwise) in tort (including negligence) or for misrepresentation (whether negligent or otherwise, and whether made prior to, or in, this Agreement), and to the extent that any such claim exists or may exist, each of the Purchaser (for itself and on behalf of each other member of the Purchaser’s Group) and the Seller (for itself and on behalf of each other member of the Seller’s Group) hereby irrevocably waives such claim and releases the Seller and the Seller’s Group (in the case of the Purchaser) and the Purchaser and the Purchaser’s Group (in the case of the Seller) from any liability whatsoever in respect thereof.

No variation of this Agreement shall be effective unless it is in writing and signed by or on behalf of each of the Parties. The expression “variation” shall, in each case, include any variation, supplement, deletion or replacement however effected.

Any waiver or any right or default hereunder shall be effective only in the instance given and will not operate as or imply a waiver of any other or similar right or default on any subsequent occasion. No waiver of this Agreement or of any provision hereof will be effective unless it is in writing and signed by the Party against whom such waiver is sought to be enforced.

Any delay by any Party in exercising, or failure to exercise, any right or remedy under this Agreement shall not constitute a waiver of the right or remedy or a waiver of any other rights or remedies, and no single or partial exercise of any rights or remedy under this Agreement or otherwise shall prevent any further exercise of the right or remedy or the exercise of any other right or remedy.

This Agreement and any dispute or claim (including non-contractual disputes or claims) arising out of, or in connection with, it or its subject matter shall be governed by, and construed in accordance with, English law.

The Parties irrevocably agree to submit to the exclusive jurisdiction of the courts of England to settle any claim, dispute or difference (including non-contractual claims, disputes or differences) which may arise out of, or in connection with, this Agreement or its subject matter (including a dispute regarding the existence, validity, formation, effect, interpretation, performance or termination of this Agreement) and that, accordingly, any Proceedings be brought in such courts.

Each Party waives (and agrees not to raise) any objection, on the ground of inconvenient forum or on any other ground, to the bringing of Proceedings in the English courts.

Each Party irrevocably agrees that a judgment or order against it in Proceedings brought in England shall (provided there is no appeal pending or open) be conclusive and binding upon it and may be enforced against it in the courts of any other jurisdiction.

Each Party which is not a company incorporated in England and Wales shall at all times maintain an agent for service of process in England. The Seller and the Guarantor irrevocably appoint Hackwood Secretaries Limited of One Silk Street, London EC2Y 8HQ, United Kingdom (such entity or any replacement agent appointed pursuant to Clause 29.3 being an “Agent”) as its agent for such purpose.

Without prejudice to any other permitted mode of service, each Party agrees that service of any claim form, notice or other document for the purpose of any Proceedings begun in England shall be duly served upon it if served on its Agent in any manner permitted by the Civil Procedure Rules, whether or not it is forwarded to the relevant Party.

If for any reason the Agent appointed by any Party at any time ceases to act as such, the Party shall promptly appoint another such agent and promptly notify the other Parties of the appointment and the new agent’s name and address. If the Party concerned does not make such an appointment within five Business Days of such cessation, then any other Party may do so on its behalf and shall notify the other Parties if it does so.

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Eversheds House, 70 Great Bridgewater Street, Manchester, United Kingdom, M1 5ES

Each of the Seller and the Guarantor is validly existing and duly registered under the laws of its jurisdiction of incorporation and the Seller is the sole legal and beneficial owner of the Shares and all of the Shares are fully paid and free from all Encumbrances and there is no liability to pay any additional contributions on the Shares.

The Company is the sole legal and beneficial owner of the entire issued share capital of the Direct Subsidiary and all of the issued shares in the Direct Subsidiary are fully paid and free from all Encumbrances.

The Company is the sole indirect legal and beneficial owner of the entire issued share capital of each of the Holding Companies and each of the Project Companies and all of the issued shares in the Holding Companies and the Project Companies are fully paid and free from all Encumbrances.

No person has the right (whether exercisable now or in the future and whether contingent or not) to call for the allotment, issue, sale, transfer or conversion of any share or loan capital of a Group Company under any option or other agreement (including conversion rights and rights of pre-emption).

Each of the Seller and the Guarantor has the requisite power and authority to enter into and perform each Transaction Document to which it is a party.

Each Transaction Document to which the Seller or the Guarantor is a party constitutes or will, when executed, constitute legally valid and binding obligations on the Seller or the Guarantor as applicable and shall, upon its execution and/or delivery, be legally enforceable against the Seller or the Guarantor as applicable.

Compliance with the terms of each Transaction Document to which the Seller or the Guarantor is a party does not and will not conflict with or constitute a default or breach under any provision of:

the Seller’s or the Guarantor’s memorandum or articles of association (or equivalent documents); or

any order, judgment, award, injunction, decree, ordinance or regulation or any other restriction of any kind or character by which the Seller or the Guarantor is bound or submits.

The Audited Project and Holding Companies Accounts give a true and fair view of the state of affairs of the Group Companies to which they relate, and their respective assets and liabilities as at the Locked Box Date and of the results thereof for the financial year ended on the Locked Box Date and have been prepared in accordance with IFRS and applicable laws and on a basis consistent with the equivalent audited financial statements for the financial year ended

The monthly management accounts of the Group Companies from the Locked Box Date to 30 June 2016 have been prepared with a reasonable degree of accuracy and on a basis consistent with the management accounts prepared for the equivalent period in the prior year to the extent such management accounts exist.

Since the Locked Box Date, there has been no Material Adverse Change, each Group Company has carried on business in the ordinary and usual course and no Group Company has made or agreed to make any payment other than routine or customary payments in the ordinary and usual course.

No Group Company has lent any money to any entity other than a Group Company which is due to be repaid and as at the date of this Agreement has not been repaid to it and no Group Company owns the benefit of any debt owed by an entity other than (a) debt owed by a Group Company and (b) any trade debts incurred in the ordinary and usual course of business.

No Group Company owes any Financial Debt to any entity other than a Group Company other than the debt outstanding under the Existing Facilities, the Receivable, any Other Receivable and the Loan Note and no Group Company has granted (or agreed to grant) any Encumbrance in respect of its securities, assets or undertaking save for the Encumbrances granted in respect of the Existing Facilities.

No Financial Debt of any Group Company has become due and payable, or capable of being declared due and payable, before its normal or originally stated maturity and no Group Company or member of the Seller’s Group has received a demand or other notice requiring any Financial Debt of any Group Company to be paid or repaid before its normal or originally stated maturity.

No event of default or any other event or circumstance which would entitle any person to call for early repayment of any Financial Debt of any Group Company or to enforce any security given by any Group Company (or, in either case, any event or circumstance which with the giving of notice would constitute such an event or circumstance) has occurred.

The Noteholder is beneficially entitled to all of the interest payable under the Loan Note.

No amount is required by law to be deducted or withheld on account of Tax from the Receivable Payment Amount or any Other Receivable Payment Amounts.

The Group Companies are duly formed private limited companies in existence and are validly existing and duly registered under the laws of England and Wales and are licensed or qualified to do business under the laws of England and Wales and have been in continuous existence since their formation.

The information set out in Schedule 1 (Group Details) is true, accurate and not misleading.

The copies of the memoranda (if applicable) and articles of association of the Group Companies made available to the Purchaser in the Data Room are correct, complete and in full force and effect and have not been amended or superseded as at the date of this

Except for the Direct Subsidiary, the Holding Companies and the Project Companies, the Company does not have any interest in any undertaking or in the share capital of any body corporate, nor has it agreed to acquire such an interest.

No Group Company is a party to any joint venture agreement or arrangement or any other agreement or arrangement under which it is to participate with any other person in any business or profit or loss sharing arrangement.

No Group Company has, and has never had, any branch, agency, place of business or establishment outside England and Wales.

Each Project Company has full corporate power to carry on its business and to own and operate its assets, the Properties and its business as now carried on and owned and operated.

No person is entitled to receive from the Group Companies any introduction fee, brokerage or other commission in connection with the sale of the Shares.

Since incorporation, the Company has not carried on any trade and the only activity of the Company has been holding the shares in the Direct Subsidiary.

No Project Company is in material breach of any of its duties or obligations under its relevant O&M Agreement or Management Services Agreement.

Each Project Company’s material obligations under its relevant O&M Agreement and Management Services Agreement due to be discharged prior to Completion in accordance with the terms of such agreements have been discharged in full.

No Project Company has any full-time or part-time employees or consultants.

Since the date of each of the Certificates of Title, there has been no material adverse change in the title to the Properties subject to the Certificates of Title.

So far as the Seller is aware, the information provided to Eversheds, DAC Beachcroft, Burges Salmon and Simmons & Simmons for the purposes of the Certificates of Title was true, complete and accurate in all respects at the time it was provided and since the date of each of the Certificates of Title (a) there has been no material change to the Project Company confirmations given in the Certificates of Title, which is likely to have a material adverse effect on the operation of any of the Projects and (b) no material new title matters have been registered against the leasehold titles to the Properties other than those set out in schedule 15 (Additional Property Conditions Subsequent) of the Common Terms Agreement.

The Properties comprise all the freehold and leasehold properties owned, occupied or used by the Group Companies or in which the Group Companies have any interest and the Group Companies are not party to any uncompleted agreement or arrangement (written or otherwise) to acquire or dispose of any freehold or leasehold property.

The Group Companies have, except in relation to the Properties, no liability (whether actual or contingent) in relation to any freehold or leasehold property that have at any time before the date of this Agreement been owned (under whatever tenure) or occupied or used by the Group Companies but which are no longer owned occupied or used by the Group Companies and have not disposed of any property in respect of which it has entered into any obligations for which it may continue to be liable notwithstanding such disposal.

All covenants, conditions, restrictions and stipulations contained in each of the Leases have been observed and performed in all material respects, including covenants to obtain consents, and there has not been any waiver of or acquiescence to any breach of them.

All rents and other sums payable under each of the Leases (including any sums due in respect of reinstatement security) have been paid as and when they became due and no such sums have been set off, withheld, commuted, waived, paid in advance of the due date for payment or accepted or agreed beyond what is legally permitted or subject to any qualification.

So far as the Seller is aware, there is no outstanding dispute with the landlord of any of the Leases and, since the date of each of the Certificates of Title, no forfeiture proceedings have been commenced and, so far as the Seller is aware, none are contemplated in relation to any of the Properties.

Since the date of the Certificates of Title each Project Company continues to exercise all of the rights required for the operation of the Projects freely and without interruption or objection

For each Project where the Leases have been varied, all necessary consents to the variation have been obtained.

Since the date of the Certificates of Titles there are no outstanding rent reviews under any of the Leases and none of the Leases have been surrendered whether in whole or part.

So far as the Seller is aware, there has been no change to the matters set out in the disclosures in schedule 3 paragraph 1.1 of the Certificates of Title regarding the title deeds and documents for each of the Properties.

Since the dates of the Certificates of Title, no new mortgage, debenture, charge (whether legal or equitable and whether fixed or floating) or other security affecting the Properties, has been put in place other than that as disclosed in favour of Santander UK Plc.

All sums for the benefit of a community payable by a Project Company in connection with the construction and/or operation of a Project have been paid as and when they became due or have subsequently been settled (including without limitation by the Says Court ProjectCo under the letter to Westerleigh Parish Council dated 15 August 2013).

The deed of variation to the Brynteg Lease and lease supplemental to the Brynteg Lease in connection with access rights and rent have been entered into by the Brynteg ProjectCo with the landlord of the Brynteg Property and have been registered at the Land Registry.

The portion of the leasehold premises at Sundorne Grove, Shrewsbury registered at the Land Registry with Title Number SL235858 which has not been developed by the relevant Project Company and which the landlord has a right to reclaim under the Sundorne Grove Lease is not required as at the date of this Agreement and is not likely to be required in the future, for the operation and performance of the existing project at the Sundorne Grove site.

The Group maintains, and, for the period during which the Seller has owned each other Group Company, has maintained, valid public liability insurance cover in respect of their respective businesses and assets.

The relevant Group Companies have at all times since the date of the Common Terms Agreement maintained the insurances required under the Common Terms Agreement, no claims are outstanding under or in respect of the validity of such insurances and, so far as the Seller is aware, there is no fact or circumstance that is reasonably likely to give rise to a claim under or in respect of such insurances.

All material consents which are necessary to develop, build, connect and operate the Projects, have been obtained by the Project Companies and the Seller is not aware of any reason that would affect the validity of any such consents.

So far as the Seller is aware, all reports, returns and information required by law or as a condition of any such consent to be made or given to any person or authority in connection with the Projects and/or the business of the Project Companies have been made or given to the appropriate person or authority.

The Group Companies are not and, so far as the Seller is aware, no person for whose acts a Group Company may be liable is, engaged in any material litigation, arbitration, administrative or criminal proceedings, whether as claimant, defendant or otherwise.

No litigation, arbitration, administrative, investigative or criminal proceedings by or against any Group Company or, so far as the Seller is aware, against any person for whose acts any Group Company may be liable, are threatened or expected or pending, and no order or judgment in relation to such matters is outstanding.

So far as the Seller is aware, there are no facts or circumstances reasonably likely to give rise to any litigation, arbitration, administrative or criminal proceedings against any of the Group Companies.

No order has been made, no resolution has been passed, no petition presented and no meeting convened for the winding up of the Seller, the Guarantor, any Group Company or any other member of the Seller’s Group, or for the appointment of any provisions liquidator or in relation to any other process whereby the business is terminated and the assets of the company concerned are distributed amongst creditors and/or shareholders or other contributors, and there are no cases or proceedings under any applicable insolvency,

No person has taken any step, legal proceeding or other procedure with a view to the appointment of an administrator, whether out of court or otherwise, in relation to the Seller, the Guarantor, any Group Company or any other member of the Seller’s Group, and no receiver (including any administrative receiver) has been appointed in respect of the whole or any part of any of the property, assets and/or undertaking of any Group Company nor has any such order been made (including, in any relevant jurisdiction, any other order by which, during the period it is in force, the affairs, business and assets of the company concerned are managed by a person appointed for the purpose by a court, governmental agency or similar body).

None of the Seller, the Guarantor, the Group Companies or any other member of the Seller’s Group has taken any step with a view to a suspension of payments or a moratorium of any indebtedness or has made any voluntary arrangement with any of its creditors or is insolvent or unable to pay its debts as they fall due.

So far as the Seller is aware, each Group Company has duly and punctually paid all Tax which it has become liable to pay. No Group Company has paid, within the period of seven years ending on the date of this Agreement, any material penalty, fine, surcharge or interest in relation to any Tax.

All material notices, returns (including any land transaction returns), reports, accounts, computations, statements, assessments, elections and registrations and any other necessary material information required to be submitted by any Group Company to any Taxation Authority for the purposes of Taxation have been made on a proper basis, were punctually submitted, were accurate, correct and complete in all material respects when supplied and remain accurate, correct and complete in all material respects. None of such notices, returns (including any land transaction returns), reports, accounts, computations, statements, assessments and registrations and any other necessary material information are the subject of any material dispute and, so far as the Seller is aware, none is expected to be the subject of any material dispute, in each case with any Taxation Authority.

Each Group Company is and always has been resident for Tax purposes only in the jurisdiction in which it is incorporated. No Group Company is liable to pay, nor has at any time incurred any liability to, Tax chargeable under the laws of any jurisdiction other than the jurisdiction in which it is incorporated. No Group Company is required to be registered for any Tax purpose in any jurisdiction other than the jurisdiction in which it is incorporated.

Each Group Company has complied within applicable time limits with all notices served on it and any other requirements imposed on it, in each case lawfully by any Taxation Authority.

The Audited Project and Holding Companies Accounts make full provision in accordance with IFRS for all Taxation assessed or liable to be assessed on each Group Company in respect of any period ending on or before the Locked Box Date or for which any Group Company is accountable at that date, whether or not any Group Company has (or may have) any right of reimbursement against any other person.

Proper provision has been made and shown in the Audited Project and Holding Companies Accounts for deferred taxation in accordance with IFRS.

Each Group Company has made all deductions and withholdings in respect or on account of any Tax required by any applicable law to be made from any payments made by it before the date of this Agreement and has accounted in full to the relevant Taxation Authority for all amounts so deducted and/or withheld on or before the date on which it is required to do so.

Each Group Company has kept and maintained such records, invoices and other information in relation to Tax as it is required to keep and maintain, and which are required to enable it to complete its Tax returns in respect of periods ending on or before Completion, calculate its liabilities to Tax in respect of periods ending on or before Completion and establish its entitlement to any Relief which has been shown as an asset or taken into account in reducing a provision for deferred tax in the Audited Project and Holding Companies Accounts.

No Group Company has surrendered or claimed the surrender of, or has entered into a commitment to surrender or claim the surrender of, any Relief under Part 5 of the Corporation Tax Act 2010 or of any amounts of Tax refund under section 963 of the Corporation Tax Act 2010 (other than to or from another Group Company).

No Group Company is party to any arrangements or agreement to which any company other than another Group Company is party in respect of which a payment or repayment may need to be made at the date of this Agreement in respect of any surrender of, any Relief under Part 5 of the Corporation Tax Act 2010 or of any amounts of Tax refund under section 963 of the Corporation Tax Act 2010.

No Group Company is a qualifying Company within the meaning of Schedule 46 to the Finance Act 2009.

Neither the execution nor completion of this Agreement, nor any other event since the Locked Box Date, will result in any asset being deemed to have been disposed of and reacquired by any Group Company for Tax purposes.

Each Group Company is registered for VAT purposes and has complied in all material respects with its obligations in relation to VAT. No Group Company has ever been a member of a group for VAT purposes (other than one which includes only other Group Companies).

Each Group Company has complied in all material respects with its obligations under section 59 of the Finance Act 2004.

Any document that may be necessary or desirable in proving the title of a Group Company to any asset which is owned by a Group Company at the date of this Agreement, and each document which a Group Company may wish to enforce or produce in evidence, is, where stampable, duly stamped for stamp duty purposes.

No arrangements have been entered into with HM Revenue & Customs pursuant to Section 59F Taxes Management Act 1970 to which both any Group Company and any company which is not a Group Company are a party.

There are no material breaches of the planning permissions or any planning agreement at any of the Properties, nor, so far as the Seller is aware, are there any material breaches of any non-material amendments to such planning permissions or planning agreements.

No enforcement action has been taken or, so far as the Seller is aware, threatened by any relevant local planning authority at any of the Properties and the Seller is not aware of any circumstance that is reasonably likely to give rise to enforcement action.

For the period during which the Seller has owned (directly or indirectly) each Group Company, each Group Company and each of its directors and officers has at all times complied in all material respects with all Environmental Laws.

So far as the Seller is aware, there are no facts or circumstances which are reasonably likely to give rise to an Environmental Claim against any of the Group Companies.

So far as the Seller is aware, there are no facts or circumstances which could give rise to Environmental Claims or a requirement for Remedial Works at the Sundorne Grove site or the Hill House Farm site.

Each Project Company has the benefit of a legally valid, binding and enforceable connection agreement.

There are no material breaches of the connection agreements and each Project Company’s payment and other material obligations under each connection agreement have been discharged prior to the Completion Date.

So far as the Seller is aware no material disconnections, de-energisations or outages have occurred pursuant to the connection agreements (other than in respect of Crundale).

Each Project Company has the benefit of the manufacturer’s warranties which should have been assigned to it pursuant to the terms of the EPC Contract to which it is a party and such warranties reflect the agreed terms, if any.

There has been no material breach by any Project Company or EPC Contractor of its duties or obligations under an EPC Contract to which it is a party.

Each Project Company’s payment and other material obligations under each EPC Contract have been fully discharged.

No payments or claims are outstanding under any EPC Contract.

The liability caps under each EPC Contract and associated warranty bond have not been depleted.

There has been no material breach by any Project Company or, so far as the Seller is aware, any other party to a PPA of its material duties or obligations under a PPA to which it is a party.

No material payments or claims are outstanding under any PPA or guarantee provided in respect of a PPA.

In respect of each PPA to which Statkraft Markets GmbH is a party, no Floor Price Rebates (as defined in those PPAs) have been (a) paid or (b) claimed but not yet paid, to Statkraft Markets GmbH.

In respect of each PPA to which Total Gas & Power Limited is a party, no notices have been served by Total Gas & Power Limited with regard to a variation of the calculation of the Index Price as defined in and under those PPAs.

All material agreements relating to the Project which have been entered into by one of more of the Group Companies (each a “Project Agreement”) are contained in the Data Room.

Each Project Company’s payment obligations that have become due and payable under its relevant Project Agreements have been fully satisfied.

Neither the Seller, nor any member of the Seller’s Group, nor any of the directors, officers or employees of any member of the Seller’s Group, nor, so far as the Seller is aware, any other person acting on behalf of the Seller’s Group has engaged in any activity or conduct that has resulted or will result in a potential violation of:

any Anti-Corruption Laws;

any Anti-Money Laundering Laws; or

any applicable laws relating to economic or trade sanctions, including the laws or regulations implemented by the Office of Foreign Assets Controls of the United States Department of the Treasury and any similar laws or regulations in other jurisdictions,

No action, suit or proceeding by or before any court or Governmental Authority or regulatory agency, authority or body or any arbitrator, nor any internal allegation, involving the Seller or any member of the Seller’s Group with respect to the Anti-Corruption Laws, Anti-Money

The Purchaser is validly existing and duly registered under the laws of its jurisdiction of incorporation and has the requisite power and authority to enter into and to perform each Transaction Document to which it is a party.

Each Transaction Document to which the Purchaser is a party constitutes or will, when executed, constitute legally valid and binding obligations of the Purchaser.

Compliance with the terms of each Transaction Document to which the Purchaser is a party does not and will not conflict with or constitute a default or a breach under any provision of:

the memorandum or articles of association or equivalent constitutional documents of the Purchaser; or

any order, judgment, award, injunction, decree, ordinance or regulation or any other restriction of any kind or character by which the Purchaser is bound or submits.

Neither the Purchaser, nor any member of the Purchaser’s Group, nor any of the directors, officers or employees of any member of the Purchaser’s Group, nor, so far as the Purchaser is aware, any other person acting on behalf of the Purchaser’s Group has engaged in any activity or conduct that has resulted or will result in a potential violation of:

any Anti-Corruption Laws;

any Anti-Money Laundering Laws; or

any applicable laws relating to economic or trade sanctions, including the laws or regulations implemented by the Office of Foreign Assets Controls of the United States Department of the Treasury and any similar laws or regulations in other jurisdictions,

So far as the Purchaser is aware, neither EFG Hermes UAE Limited nor any of its subsidiaries that has a direct or indirect interest in the Purchaser has engaged in any activity or conduct in connection with this Transaction that has resulted or will result in a potential violation of any of the matters set out in paragraph 2.1 of this Schedule 3.

No action, suit or proceeding by or before any court or Governmental Authority or regulatory agency, authority or body or any arbitrator, nor any internal allegation, involving the Purchaser or any member of the Purchaser’s Group with respect to the Anti-Corruption Laws, Anti-Money Laundering Laws, or any applicable laws relating to economic or trade sanctions is pending or, so far as the Purchaser is aware, threatened.     

The Purchaser shall:

comply with Clause 3.2; and

deliver to the Seller:

evidence that the Purchaser is authorised to execute this Agreement and each of the Transaction Documents to be executed by the Purchaser;

consents from Karim Moussa, Bakr Abdel-Wahab and Edwina Kelly to their appointment as directors of the Company;

a certified copy of any power of attorney under which any of the foregoing documents are executed; and

a copy of the Tax Deed duly executed and delivered by or on behalf of the Purchaser and the Guarantor.

The Seller shall:

procure the delivery to the Purchaser of:

a copy of the duly executed Transitional Service Agreement redacted only in respect of pricing;

duly executed transfer by the Seller in favour of the Purchaser of all the Shares;

the share certificates representing the Shares;

a copy of the Loan Note Redemption Deed duly executed and delivered by the Company and the Noteholder;

a power of attorney in the Agreed Form duly executed and delivered as a deed by the Seller in favour of the Purchaser in respect of the Shares;

evidence that the Seller is authorised to execute this Agreement and each of the Transaction Documents to be executed by the Seller;

the certificate of incorporation, common seal (if any), people with significant control register, share register or ledger and share certificate book and all minute books and other statutory books (written up to but not including Completion) of each Group Company;

the resignation of Rebecca Cranna as director of the Company and its subsidiaries (as applicable) in the Agreed Form to take effect at Completion;

evidence of the appointment of the Agent by the Seller and the Guarantor pursuant to Clause 29.1;

a copy of the Tax Deed duly executed and delivered by or on behalf of the Seller;

a copy of any power of attorney under which any of the foregoing documents are executed; and

evidence that the Noteholder has consented to repayment of the Loan Note at Completion in accordance with Clause 7.4.4 and waived the notice period prescribed by the terms of the Loan Note;

procure that a written resolution of the sole director of the Company be passed prior to or at Completion pursuant to which it is resolved in the Agreed Form that:

Karim Moussa, Bakr Abdel-Wahab and Edwina Kelly are appointed as replacement directors of the Company with effect from Completion;

the redemption of the Loan Note and payment of the Loan Note Redemption Amount to the Noteholder on the Completion Date and the cancellation of the Loan Note by the Company upon its repayment; and

subject to the payment of applicable stamp duty, the transfer referred to in paragraph 2(a)(ii) of this Schedule 4 is approved for registration.

From the date of this Agreement until the Completion Date (both dates inclusive), the Seller shall ensure that (except: (i) as expressly permitted by this Agreement; (ii) as may be required to give effect to and comply with this Agreement; (iii) as may be required by applicable law; or (iv) with the Purchaser's prior written consent):

each Group Company carries on its business in the ordinary and usual course and that no Group Company makes or agrees to make any material payment other than routine payments in the ordinary and usual course of business (for this purpose any payment in excess of £30,000.00 shall be deemed material);

all reasonable steps are taken to preserve and protect the assets of each Group Company and to preserve and retain its goodwill (including the existing relationships with customers and suppliers);

subject to Clause 17 (Confidentiality), the Purchaser's Representatives shall be allowed such access as is reasonably requested, upon reasonable notice and during normal working hours, to (i) the statutory books and records of each Group Company and (ii) the premises used by, and management of, each Group Company;

no Group Company or other member of the Seller’s Group does, allows or procures any act or omission which would constitute or give rise to a breach of any Seller's Warranty if the Seller's Warranties were repeated at any time before Completion by reference to the facts and circumstances then existing as if references in the Seller's Warranties to the date of this Agreement were references to the relevant date;

all relevant information which comes to its notice or that of any other member of the Seller’s Group in relation to any fact or matter (whether existing on or before the date of this Agreement or arising afterwards) which may constitute a breach of any Seller's Warranty if the Seller's Warranties were to be repeated on or at any time before Completion by reference to the facts and circumstances then existing as if references in the Warranties to the date of this Agreement were references to the relevant date, is promptly disclosed to the Purchaser;

no Group Company declares, authorises, makes or pays any dividend or other distribution (whether in cash, stock or in kind) other than any dividend or distribution which is Leakage for the purposes of this Agreement or reduces, purchases or redeems any part of its paid-up share or loan capital;

no Group Company (i) creates, allots or issues or agrees to create, allot, or issue any share or loan capital or other security or (ii) grants any option over or right to subscribe for any of its share or loan capital or other security;

no Group Company or member of the Seller's Group sells or purchases or disposes of any interest in any share or loan capital or other security of any Group Company;

all transactions between a Group Company and a member of the Seller's Group take place on arm's length terms;

no Group Company employs or agrees to employ any person, whether full-time or part-time basis;

no Group Company changes residence for Tax purposes or makes or changes any election, claim or similar in circumstances where that change is likely to materially impact any Group Company’s Tax position in an adverse manner;

no action is taken by any member of the Seller’s Group or any Group Company which is inconsistent with the provisions of any Transaction Document or the implementation of the Transaction;

no Group Company fails to settle in accordance with the payment procedures and timescales normally observed by the Group Companies any debts incurred by the Group Companies in the normal course of trading;

no Group Company enters into or terminates any contract or arrangement (whether written or otherwise) other than (i) in connection with the new management services agreements and operation and maintenance agreements to be entered into in order to replace the Management Services Agreements and the O&M Agreements, including any associated direct agreements and (ii) an agreement substantively in the form of the Remedial Works Agreement (provided that the Purchaser’s prior written consent may not be unreasonably withheld for any substantive amendments to such agreement);

no Group Company gives any guarantee, indemnity or other agreement to secure an obligation of a third party which if called or enforced would result in a cost to one or more Group Companies of £20,000 or more;

no Group Company enters into or modifies any Third Party Assurance;

the institution or settlement of any litigation, arbitration or other proceeding which could result in a payment to or by a Group Company of £20,000 (exclusive of VAT) or more;

no Group Company institutes or settles any material litigation, arbitration or other proceeding (for this purpose material shall mean any litigation, arbitration or other proceeding with a claim value in excess of £20,000);

no Group Company creates any Encumbrance over any of the Shares, the Receivable, any Other Receivable, the Loan Note or the share or loan capital or any asset of a Group Company;

no Group Company acquires or disposes of any material asset or material stocks, in each case, involving consideration, expenditure or liabilities in excess of £20,000 (exclusive of VAT);

no Group Company shall in connection with the Properties (i) terminate or serve any notice to terminate, surrender or accept any surrender of or vary or waive the terms of any of the Leases, (including any grazing licences granted in respect of the Properties) or (ii) enter into or vary any material agreement, lease, tenancy, licence or other commitment or (iii) agree any rent reviews under the Leases or the amount of any reinstatement securities without the prior written consent of the Purchaser; and

no Group Company enters into any arrangement or agreement of the kind described in paragraphs 14.10 or 14.16 of Schedule 2.

Prior to Completion, the Seller shall provide;