Lease by and between BMR-Rogers Street LLC and the registrant

EX-10.24 5 sybx-ex1024_234.htm EX-10.24 sybx-ex1024_234.htm

 

 

 

 

 

 

 

 

 

Exhibit 10.24

LEASE

by and between

BMR-ROGERS STREET LLC,

a Delaware limited liability company

and

SYNLOGIC, INC.

a Delaware corporation

 

 

 

 


 

Table of Contents

 

1.

 

Lease of Premises

 

1

2.

 

Basic Lease Provisions

 

2

3.

 

Term

 

4

4.

 

Possession and Commencement Date

 

4

5.

 

Condition of Premises

 

6

6.

 

Rentable Area

 

6

7.

 

Rent

 

7

8.

 

Rent Adjustments

 

8

9.

 

Operating Expenses

 

8

10.

 

Taxes on Tenant’s Property

 

14

11.

 

Security Deposit

 

14

12.

 

Use

 

17

13.

 

Rules and Regulations, CC&Rs, Parking Facilities and Common Area

 

20

14.

 

Project Control by Landlord

 

21

15.

 

Quiet Enjoyment

 

22

16.

 

Utilities and Services

 

23

17.

 

Alterations

 

27

18.

 

Repairs and Maintenance

 

30

19.

 

Liens

 

31

20.

 

Estoppel Certificate

 

32

21.

 

Hazardous Materials

 

32

22.

 

Odors and Exhaust

 

35

23.

 

Insurance

 

36

24.

 

Damage or Destruction

 

40

25.

 

Eminent Domain

 

42

26.

 

Surrender

 

43

27.

 

Holding Over

 

44

28.

 

Indemnification and Exculpation

 

45

29.

 

Assignment or Subletting

 

46

30.

 

Subordination and Attornment

 

51

31.

 

Defaults and Remedies

 

51

32.

 

Bankruptcy

 

57

33.

 

Brokers

 

58

34.

 

Definition of Landlord

 

58

35.

 

Limitation of Landlord’s Liability

 

58

36.

 

Joint and Several Obligations

 

59

37.

 

Representations

 

59

38.

 

Confidentiality

 

60

39.

 

Notices

 

60

40.

 

Miscellaneous

 

61

41.

 

Rooftop Installation Area

 

63

42.

 

Option to Extend Term

 

65

 

 

i

 


 

43.

 

Early Termination

 

67

44.

 

Ground Lease.  Ground Lessor and Landlord shall execute and deliver to Tenant a recognition agreement providing that Ground Lessor will recognize this Lease and not disturb Tenant's possession of the Premises and recognize this Lease and all of Tenant’s rights hereunder, in the form of the Non-Disturbance and Attornment Agreement attached hereto as Exhibit J

 

68

 

 

 

 

ii

 


 

LEASE

THIS LEASE (this “Lease”) is entered into as of this ____ day of [_______], 2017 (the “Execution Date”), by and between BMR-ROGERS STREET LLC, a Delaware limited liability company (“Landlord”), and SYNLOGIC, INC., a Delaware corporation (“Tenant”).

RECITALS

A.WHEREAS, pursuant to that certain ground lease dated as of March 30, 1999, by and among MBA-Rogers Street, LLC (“Ground Lessor,” as successor-in-interest to O&T Realty, LLC, and MBA-Cambridge, LLC (collectively, “Initial Ground Lessor”)), as landlord, and Rogers Street, LLC, a Delaware limited liability company (“Initial Ground Lessee”), as tenant; as such ground lease has been amended by that certain letter agreement dated as of July 29, 1999, between Initial Ground Lessor and Initial Ground Lessee, and that certain Agreement Regarding Arbitration and Lease Amendments dated as of December 15, 1999, by and between Initial Ground Lessor and Initial Ground Lessee; and as such ground lease has been assigned pursuant to that certain Assignment and Assumption of Ground Lease dated as of April 4, 2007, by and between Initial Ground Lessee and Landlord (such ground lease, as so amended and assigned, and as the same may be further amended, amended and restated, supplemented or otherwise modified from time to time, the “Ground Lease”), Landlord leases certain real property described on Exhibit A-1 attached hereto (the “Property”) and the improvements located thereon, including, in part, the building at 301 Binney Street (the “Building”); and

B.WHEREAS, Landlord wishes to lease to Tenant, and Tenant desires to lease from Landlord, certain premises (the “Premises”) located primarily on the fourth (4th) floor of the Building, pursuant to the terms and conditions of this Lease, as detailed below.

AGREEMENT

NOW, THEREFORE, Landlord and Tenant, in consideration of the mutual promises contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound, agree as follows:

1.Lease of Premises.

1.1.Effective on the Term Commencement Date (as defined below), Landlord hereby leases to Tenant, and Tenant hereby leases from Landlord, the Premises, as shown on Exhibit A attached hereto, including exclusive shafts, cable runs, mechanical spaces and rooftop areas, for use by Tenant in accordance with the Permitted Use (as defined below) and no other uses.  The Property and all landscaping, parking facilities, private drives and other improvements and appurtenances related thereto, including the Building and other buildings located on the Property, are hereinafter collectively referred to as the “Project.” All portions of the Building that are for the non-exclusive use of the tenants of the Building only, and not the tenants of the Project generally, such as service corridors, stairways, elevators, public restrooms and public lobbies (all to the extent located in the Building), are hereinafter referred to as “Building Common Area.” All portions of the Project that are for the non-exclusive use of tenants of the Project generally, including driveways, sidewalks, parking areas and landscaped areas, are hereinafter referred to as “Project Common Area.” The Building Common Area and Project Common Area are collectively referred to herein as “Common Area.”  

 

 

 

 


2.Basic Lease Provisions.  For convenience of the parties, certain basic provisions of this Lease are set forth herein.  The provisions set forth herein are subject to the remaining terms and conditions of this Lease and are to be interpreted in light of such remaining terms and conditions.

2.1.This Lease shall take effect upon the Execution Date and, except as specifically otherwise provided within this Lease, each of the provisions hereof shall be binding upon and inure to the benefit of Landlord and Tenant from the date of execution and delivery hereof by all parties hereto.

2.2.In the definitions below, each current Rentable Area (as defined below) is expressed in rentable square feet.  Rentable Area and “Tenant’s Pro Rata Share” are subject to adjustment as provided in this Lease.

Definition or Provision

Means the Following (As of the Execution Date)

Approximate Rentable Area of Premises*

41,346 square feet

Approximate Rentable Area of Building

417,290 square feet

Tenant’s Pro Rata Share of Building*

9.91%

* Note:

Subject to adjustment based upon the Rentable Area of the Premises as of the Term Commencement Date.

2.3.Monthly and annual installments of Base Rent for the Premises (“Base Rent”) as of the Rent Commencement Date (as defined below), subject to adjustment under this Lease:

Dates

Square Feet of Rentable Area*

Base Rent per Square Foot of Rentable Area

Monthly Base Rent*

Annual Base Rent*

Rent Commencement Date- The day immediately prior to the first (1st) annual anniversary of the Rent Commencement Date

41,346

$76.00 annually

$261,858.00

$3,142,296.00

* Note:

Subject to adjustment based upon the Rentable Area of the Premises as of the Term Commencement Date.

 

 

2

 


2.4.Estimated Term Commencement Date:  January 22, 2018.

2.5.Estimated Term Expiration Date:  June 30, 2028.

2.6.Security Deposit:  $1,047,432, subject to increase in accordance with the terms hereof.  

2.7.Permitted Use:   General office and laboratory use in conformity with all federal, state, municipal and local laws, codes, ordinances, rules and regulations of Governmental Authorities (as defined below), committees, associations, or other regulatory committees, agencies or governing bodies having jurisdiction over the Premises, the Building, the Property, the Project, Landlord or Tenant, including both statutory and common law and hazardous waste rules and regulations (“Applicable Laws”). Tenant acknowledges and agrees that, notwithstanding anything in this Lease to the contrary, pursuant to Applicable Laws, the portion of the Premises located in the basement of the Building is not permitted to be occupied and may only be used for purposes that are included within the Permitted Use that do not involve occupancy by individual persons (which may include the placement of Tenant’s Acid Neutralization Tank).

2.8.Address for Rent Payment:

BMR-Rogers Street LLC

Attention Entity 635

P.O. Box 511415

Los Angeles, California  90051-7970

2.9.Address for Notices to Landlord:

BMR-Rogers Street LLC

17190 Bernardo Center Drive

San Diego, California  92128

Attn:  Legal Department

2.10.Address for Notices to Tenant:

Synlogic, Inc.
200 Sidney Street
Cambridge, MA 02139
Attention:  [____________]

2.11.Address for Invoices to Tenant:

Synlogic, Inc.
200 Sidney Street
Cambridge, MA 02139
Attention:  [____________]

 

 

3

 


2.12.The following Exhibits are attached hereto and incorporated herein by reference:

 

Exhibit A

 

Premises

Exhibit A-1

 

Property

Exhibit B

 

Work Letter

Exhibit B, Schedule 1

 

Preliminary Schedule

Exhibit B, Schedule 2

 

Schematic Design Plans and Basis of Design

Exhibit B, Schedule 3

 

Preliminary Budget

Exhibit B-1

 

Tenant Work Insurance Schedule

Exhibit C

 

Acknowledgement of Term Commencement Date and Term Expiration Date

Exhibit D

 

[Intentionally omitted]

Exhibit E

 

Form of Letter of Credit

Exhibit F

 

Rules and Regulations

Exhibit G

 

PTDM

Exhibit H

 

Tenant’s Personal Property

Exhibit I

 

Form of Estoppel Certificate

Exhibit J

 

Form of Ground Lease Non-Disturbance and Attornment Agreement

 

3.Term  The actual term of this Lease (as the same may be extended pursuant to Article 42 hereof, and as the same may be earlier terminated in accordance with this Lease, the “Term”) shall commence on the actual Term Commencement Date (as defined in Article 4) and end on the date (the “Term Expiration Date”) that is one hundred twenty (120) months after the Rent Commencement Date, subject to extension or earlier termination of this Lease as provided herein.  

4.Possession and Commencement Date.

4.1.Landlord shall use commercially reasonable efforts to tender possession of the Premises to Tenant on the Estimated Term Commencement Date, with the work (the “Tenant Improvements”) required of Landlord described in the Work Letter attached hereto as Exhibit B (the “Work Letter”) Substantially Complete (as defined below).  Tenant agrees that in the event such work is not Substantially Complete on or before the Estimated Term Commencement Date for any reason, then (a) this Lease shall not be void or voidable, (b) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, (c) the Term Expiration Date shall be extended accordingly and (d) Tenant shall not be responsible for the payment of any Base Rent or Tenant’s Adjusted Share of Operating Expenses (as defined below) until the actual Term Commencement Date as described in Section 4.2 occurs.  The term “Substantially Complete” or “Substantial Completion” means that (i) the Tenant Improvements are substantially complete in

 

 

4

 


accordance with the Approved Plans (as defined in the Work Letter), except for minor punch list items that do not interfere with Tenant’s ability to occupy and use the Premises for the Permitted Use and (ii) the Premises has received a certificate of occupancy or a temporary certificate of occupancy or its functional equivalent from the City of Cambridge Inspectional Services Department (or other applicable governmental agency) (except that no such certificate or functional equivalent shall be required for the portion of the Premises located in the basement of the Building). Notwithstanding anything in this Lease (including the Work Letter) to the contrary, Landlord’s obligation to timely achieve Substantial Completion shall be subject to extension on a day-for-day basis as a result of Force Majeure (as defined below).

4.2.The “Term Commencement Date” shall be the day Landlord tenders possession of the Premises to Tenant with the Tenant Improvements Substantially Complete.  If possession is delayed by action of Tenant, then the Term Commencement Date shall be the date that the Term Commencement Date would have occurred but for such delay.  Tenant shall execute and deliver to Landlord written acknowledgment of the actual Term Commencement Date and the Term Expiration Date within ten (10) days after Tenant takes occupancy of the Premises, in the form attached as Exhibit C hereto.  Failure to execute and deliver such acknowledgment, however, shall not affect the Term Commencement Date or Landlord’s or Tenant’s liability hereunder.  Failure by Tenant to obtain validation by any medical review board or other similar governmental licensing of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date.

4.3.Landlord shall endeavor to allow Tenant to enter upon the Premises after the date that is thirty (30) days prior to the Term Commencement Date for the purpose of installing trade fixtures, equipment and the placement of personal property; provided that, Tenant shall furnish to Landlord evidence satisfactory to Landlord in advance that insurance coverages required of Tenant under the provisions of Article 23 are in effect, and such entry shall be subject to all the terms and conditions of this Lease (except that Tenant shall have no obligation to pay Base Rent or  Operating Expenses hereunder except to the extent of the cost of utilities consumed by and building services provided to Tenant); and provided, further, that to the extent the Term Commencement Date is delayed due to such early access, then the Term Commencement Date shall be the date that the Term Commencement Date would have occurred but for such delay.

4.4.Landlord shall cause the Tenant Improvements to be constructed in the Premises pursuant to the Work Letter at a cost to Landlord not to exceed (a) Six Million Two Hundred One Thousand Nine Hundred Dollars ($6,201,900.00) (based upon One Hundred Fifty Dollars ($150.00) per square foot of Rentable Area (as defined below and subject to change based upon the Rentable Area of the Premises as of the Term Commencement Date)) (the “TI Allowance”). The TI Allowance may be applied to the costs of (m) construction, (n) Landlord’s out-of-pocket expenses related to project management of the Tenant Improvements (which fee shall not exceed two percent (2%) of the cost of the Tenant Improvements, including the TI Allowance), (o) commissioning of mechanical, electrical and plumbing systems by a licensed, qualified commissioning agent hired by Landlord, and review of such party’s commissioning report by a licensed, qualified commissioning agent hired by Tenant, (p) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant, (q) building permits and other taxes, fees, charges and levies by Governmental Authorities (as defined below) for permits or for inspections of the Tenant Improvements, (r) costs and expenses

 

 

5

 


for labor, material, equipment and fixtures, and (s) submetering and demising costs on the 4th floor.  In no event shall the TI Allowance be used for (w) payments to Tenant or any affiliates of Tenant, (x) the purchase of any furniture, personal property or other non-building system equipment, (y) costs arising from any default by Tenant of its obligations under this Lease or (z) costs that are recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors).

4.5.Tenant shall have until June 1, 2018 (the “TI Deadline”), to expend the unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire.

4.6.Notwithstanding anything to the contrary in this Lease, Landlord and Tenant agree that all Tenant Improvements shall be programmed in accordance with the lab and office zones identified on Exhibit A-1 attached hereto.

5.Condition of Premises.  Landlord represents to Tenant that, on the date on which Landlord delivers the Premises to Tenant with the Tenant Improvements (or the applicable portion thereof) Substantially Complete, all base building systems within the Premises (or the applicable portion thereof), including the HVAC (as hereinafter defined), electrical, life safety and plumbing systems, shall be in good working order (provided that the sole remedy for any breach of the foregoing representation shall be that Landlord shall promptly repair or remedy the violation of the foregoing representation at its sole cost, provided that Landlord may include the costs thereof in Operating Expenses to the extent that Landlord is permitted to do so under Article 9 below, and Tenant shall not be entitled to any monetary damages for any breach of such representation).  Except as set forth in the immediately foregoing sentence, Tenant acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Project, or with respect to the suitability of the Premises, the Building or the Project for the conduct of Tenant’s business. Without in any way derogating from Landlord’s ongoing maintenance, repair and restoration obligations set forth elsewhere in this Lease, Tenant acknowledges that (a) it is fully familiar with the condition of the Premises and subject to Landlord’s obligation to complete the Tenant Improvements, agrees to take the same in its condition “as is” as of the Term Commencement Date and (b) except for the Tenant Improvements, Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises, except for performance of the Tenant Improvements and with respect to payment of the TI Allowance.  Tenant’s taking of possession of the Premises shall, except as otherwise agreed to in writing by Landlord and Tenant, conclusively establish that the Premises, the Building and the Project were at such time in good, sanitary and satisfactory condition and repair.

6.Rentable Area.

6.1.The term “Rentable Area” shall reflect such areas as reasonably calculated by Landlord’s architect in a manner consistent with Landlord’s determination of Rentable Area for the remainder of the Building and Project, as the same may be reasonably adjusted from time to time by Landlord in consultation with Landlord’s architect only to reflect a physical change to the outer walls, roof or basement of the Building, a physical change to those areas of the Building

 

 

6

 


not utilized as usable area, including that portion of the Building devoted to corridors, equipment rooms, restrooms, elevator lobby, atrium and mailroom, or a physical change to the demising walls of the Premises.

6.2.The Rentable Area of the Building is generally determined by making separate calculations of Rentable Area applicable to each floor within the Building and totaling the Rentable Area of all floors within the Building.  The Rentable Area of a floor is computed by measuring to the outside finished surface of the permanent outer Building walls.  The full area calculated as previously set forth is included as Rentable Area, without deduction for columns and projections or vertical penetrations, including stairs, elevator shafts, flues, pipe shafts, vertical ducts and the like, as well as such items’ enclosing walls.

6.3.The term “Rentable Area,” when applied to the Premises, is that area equal to the usable area of the Premises, plus an equitable allocation of Rentable Area within the Building that is not then utilized or expected to be utilized as usable area, including that portion of the Building devoted to corridors, equipment rooms, restrooms, elevator lobby, atrium and mailroom.

7.Rent.

7.1.Tenant shall pay to Landlord as Base Rent for the Premises, commencing on the date that is six (6) months after the Term Commencement Date (the “Rent Commencement Date”), the sums set forth in Section 2.3, subject to the rental adjustments provided in Article 8 hereof.  Base Rent shall be paid in equal monthly installments as set forth in Section 2.3, subject to the rental adjustments provided in Article 8 hereof, each in advance on the first day of each and every calendar month during the Term.

7.2.In addition to Base Rent, Tenant shall pay to Landlord as additional rent (“Additional Rent”) at times hereinafter specified in this Lease (a) Tenant’s Adjusted Share (as defined below) of Operating Expenses (as defined below), (b) the Property Management Fee (as defined below), and (c) any other amounts that Tenant assumes or agrees to pay under the provisions of this Lease that are owed to Landlord, including any and all other sums that may become due by reason of any default of Tenant or failure on Tenant’s part to comply with the agreements, terms, covenants and conditions of this Lease to be performed by Tenant, after notice and the lapse of any applicable cure periods.  

7.3.Base Rent and Additional Rent shall together be denominated “Rent.”  Rent shall be paid to Landlord, without abatement, deduction or offset, in lawful money of the United States of America to the address set forth in Section 2.8 or to such other person or at such other place as Landlord may from time designate in writing.  In the event the Term commences or ends on a day other than the first day of a calendar month, then the Rent for such fraction of a month shall be prorated for such period on the basis of the number of days in the month and shall be paid at the then-current rate for such fractional month.

7.4.Tenant’s obligation to pay Rent shall not be discharged or otherwise affected by (a) any Applicable Laws now or hereafter applicable to the Premises, (b) any other restriction on

 

 

7

 


Tenant’s use, (c) except as expressly provided herein, any casualty or taking or (d) any other occurrence; and Tenant waives all rights now or hereafter existing to terminate or cancel this Lease or quit or surrender the Premises or any part thereof, or to assert any defense in the nature of constructive eviction to any action seeking to recover rent.  Tenant’s obligation to pay Rent with respect to any period or obligations arising, existing or pertaining to the period prior to the date of the expiration or earlier termination of the Term or this Lease shall survive any such expiration or earlier termination; provided, however, that nothing in this sentence shall in any way affect Tenant’s obligations with respect to any other period. Subject to the provisions of this Lease, Tenant shall have the right to injunctive relief or to seek judgements for direct money damages occasioned by Landlord’s breach of its Lease covenants beyond notice and applicable cure periods (but may not set-off any such judgement against Rent or other amount owing hereunder). Nothing in this Section 7.4 shall limit the exercise of Tenant’s express remedies on the terms and conditions set forth in Section 16.2 below.

8.Rent Adjustments.  Base Rent shall be subject to an annual upward adjustment of three percent (3%) of the then-current Base Rent.  The first such adjustment shall become effective commencing on the first (1st) annual anniversary of the Rent Commencement Date, and subsequent adjustments shall become effective on every successive annual anniversary for so long as this Lease continues in effect.

9.Operating Expenses.

9.1.As used herein, the term “Operating Expenses” shall include:

(a)Government impositions, including property tax costs consisting of real and personal property taxes (including amounts due under any improvement bond upon the Building or the Project (including the parcel or parcels of real property upon which the Building, the other buildings in the Project and areas serving the Building and the Project are located)) or assessments in lieu thereof imposed by any federal, state, regional, local or municipal governmental authority, agency or subdivision (each, a “Governmental Authority”); taxes on or measured by gross rentals received from the rental of space in the Project; taxes based on the square footage of the Premises, the Building or the Project, as well as any parking charges, utilities surcharges or any other costs levied, assessed or imposed by, or at the direction of, or arising from Applicable Laws or interpretations thereof, promulgated by any Governmental Authority in connection with the use or occupancy of the Project or the parking facilities serving the Project; taxes on this transaction or any document to which Tenant is a party creating or transferring an interest in the Premises; any fee for a business license to operate an office building; and any expenses, including the reasonable cost of attorneys or experts, reasonably incurred by Landlord in seeking reduction by the taxing authority of the applicable taxes, less tax refunds obtained as a result of an application for review thereof; and

(b)All other costs of any kind paid or incurred by Landlord in connection with the operation or maintenance of the Building and the Project, which shall include costs of repairs and replacements to improvements within the Project as appropriate to maintain the Project as required hereunder; costs of utilities furnished to the Common Area; sewer fees; cable

 

 

8

 


television; trash collection; cleaning, including windows; heating, ventilation and air-conditioning (“HVAC”); maintenance of landscaping and grounds; snow removal; maintenance of drives and parking areas; maintenance of the roof; security services and devices; building supplies; maintenance or replacement of equipment utilized for operation and maintenance of the Project; license, permit and inspection fees; sales, use  and excise taxes on goods and services purchased by Landlord in connection with the operation, maintenance or repair of the Building or Project systems and equipment; telephone, postage, stationery supplies and other expenses incurred in connection with the operation, maintenance or repair of the Project; accounting, legal and other professional fees and expenses incurred in connection with the Project; costs of furniture, draperies, carpeting, landscaping supplies, snow removal and other customary and ordinary items of personal property provided by Landlord for use in the Common Area or the Project office; capital expenditures but only to the extent permitted by Section 9.1(c) below; costs of complying with Applicable Laws (except to the extent such costs are incurred to remedy non-compliance as of the Execution Date with Applicable Laws); costs to keep the Project in compliance with, or costs or fees otherwise required under or incurred pursuant to any Property Operations Documents (as defined below), including condominium fees; insurance premiums, including premiums for commercial general liability, property casualty, earthquake, terrorism and environmental coverages; portions of insured losses paid by Landlord as part of the deductible portion of a loss pursuant to the terms of insurance policies; service contracts; costs of services of independent contractors retained to do work of a nature referenced above; and costs of compensation (including employment taxes and fringe benefits) of all persons who perform regular and recurring duties connected with the day-to-day operation and maintenance of the Project, its equipment, the adjacent walks, landscaped areas, drives and parking areas, including janitors, floor waxers, window washers, watchmen, gardeners, sweepers, plow truck drivers, handymen, and engineering/maintenance/facilities personnel.

(c)Notwithstanding the foregoing, Operating Expenses shall not include any net income, franchise, capital stock, estate or inheritance taxes, or taxes that are the personal obligation of Tenant or of another tenant of the Project; any leasing commissions; expenses (including attorney fees and court costs) incurred in connection with (i) negotiations or disputes with tenants of the Property or other occupants or prospective tenants or other occupants, (ii) the enforcement of any leases or (iii) the defense of Landlord’s title to, or interest in, the Building or any part thereof; costs (including permit, license, and inspection fees) incurred in connection with preparing rental space for a tenant, that relate to preparation of rental space for a tenant; expenses of initial development and construction, including grading, paving, landscaping and decorating (as distinguished from maintenance, repair and replacement of the foregoing); Landlord's costs of any services provided to tenants or other occupants for which Landlord is actually reimbursed by such tenants or other occupants (other than reimbursement through Operating Expenses) as an additional charge or rental over and above the basic rent (and escalations thereof) payable under the lease with such tenant or other occupant; costs in connection with services that are provided to another tenant or occupant of the Building, but are not offered to Tenant; capital expenditures, except for those incurred (i) in replacing obsolete equipment, (ii) for the primary purpose of reducing Operating Expenses, or (iii) required to comply with changes in Applicable Laws that take effect after the Execution Date of the Lease, in each case amortized over the useful life thereof (but in no event more than ten (10) years), as

 

 

9

 


reasonably determined by Landlord; costs (i.e., interest and penalties) incurred due to Landlord's default of this Lease or any other lease, mortgage, or other agreement, in each case affecting the Building or Property; payments to subsidiaries or affiliates of Landlord, or to any other party, in each case as a result of a non-arm's length transaction, for management or other services for the Building, or for supplies or other materials for the Building, to the extent that such payments exceed arm's length competitive prices in the Cambridge, Massachusetts market for the services, supplies or materials provided; Landlord's legal existence and general corporate overhead and general administrative expenses; legal expenses relating to other tenants; costs of repairs to the extent reimbursed by payment of insurance proceeds received by Landlord; advertising and promotional expenditures directly related to Landlord’s efforts to lease space in the Building; the cost of repairs of other work occasioned by fire, windstorm or other insured casualty, to the extent Landlord actually receives proceeds of such insurance for such repairs or other work; debt service; interest upon loans to Landlord or secured by mortgage or deed of trust covering the Project or a portion thereof or any other debt of Landlord (provided that interest upon a government assessment or improvement bond payable in installments shall constitute an Operating Expense under Subsection 9.1(a)); rental payments under any ground lease; the cost of correcting defects in the construction of the Building, Building equipment, parking lot or other site improvements, but only to the extent such costs are covered by and actually reimbursed to Landlord under any applicable warranty or service contract held by Landlord; costs incurred directly and solely as a result of Landlord's gross negligence or willful misconduct; salaries of executive officers of Landlord; depreciation claimed by Landlord for tax purposes (provided that this exclusion of depreciation is not intended to delete from Operating Expenses actual costs of repairs and replacements); taxes that are excluded from Operating Expenses by the last sentence of Subsection 9.1(a); costs or expenses incurred in connection with the financing or sale of the Project or any portion thereof; costs expressly excluded from Operating Expenses elsewhere in this Lease or that are charged to or paid by Tenant under other provisions of this Lease; professional fees and disbursements and other costs and expenses related to the ownership (as opposed to the use, occupancy, operation, maintenance or repair) of the Project; political and charitable contributions; and any item that, if included in Operating Expenses, would involve a double collection for such item by Landlord.  To the extent that Tenant uses more than Tenant’s Pro Rata Share of any item of Operating Expenses, Tenant shall pay Landlord for such excess in addition to Tenant’s obligation to pay Tenant’s Pro Rata Share of Operating Expenses (such excess, together with Tenant’s Pro Rata Share, “Tenant’s Adjusted Share”).

9.2.Tenant shall pay to Landlord on the first day of each calendar month of the Term from and after the Rent Commencement Date, as Additional Rent, (a) the Property Management Fee (as defined below) and (b) Landlord’s estimate of Tenant’s Adjusted Share of Operating Expenses with respect to the Building and the Project, as applicable, for such month.

(x)The “Property Management Fee” shall equal two and five tenths percent (2.5%) of Base Rent due from Tenant.  Tenant shall pay the Property Management Fee in accordance with Section 9.2 with respect to the entire Term, including any extensions thereof or any holdover periods, regardless of whether Tenant is obligated to pay Base Rent, Operating Expenses or any other Rent with respect to any such period or portion thereof.

 

 

10

 


(y)Within ninety (90) days after the conclusion of each calendar year (or such longer period as may be reasonably required by Landlord not to exceed one hundred eighty (180) days), Landlord shall furnish to Tenant a statement showing in reasonable detail the actual Operating Expenses, Tenant’s Adjusted Share of Operating Expenses, and the cost of providing utilities to the Premises for the previous calendar year (“Landlord’s Statement”).  Any additional sum due from Tenant to Landlord shall be due and payable within thirty (30) days after receipt of an invoice therefor.  If the amounts paid by Tenant pursuant to this Section exceed Tenant’s Adjusted Share of Operating Expenses for the previous calendar year, then Landlord shall credit the difference against the Rent next due and owing from Tenant; provided that, if the Lease term has expired, Landlord shall accompany Landlord’s Statement with payment for the amount of such difference.

(z)Any amount due under this Section for any period that is less than a full month shall be prorated for such fractional month on the basis of the number of days in the month.

9.3.Landlord may, from time to time, modify Landlord’s calculation and allocation procedures for Operating Expenses, so long as such modifications produce Dollar results substantially consistent with Landlord’s then-current practice at the Project.  Landlord or an affiliate(s) of Landlord currently own other property(ies) adjacent to the Project or its neighboring properties (collectively, “Neighboring Properties”).  In connection with Landlord performing services for the Project pursuant to this Lease, similar services may be performed by the same vendor(s) for Neighboring Properties.  In such a case, Landlord shall reasonably allocate to each Building and the Project the costs for such services based upon the ratio that the square footage of the Building or the Project (as applicable) bears to the total square footage of all of the Neighboring Properties or buildings within the Neighboring Properties for which the services are performed, unless the scope of the services performed for any building or property (including the Building and the Project) is disproportionately more or less than for others, in which case Landlord shall equitably allocate the costs based on the scope of the services being performed for each building or property (including the Building and the Project).  Since the Project consists of multiple buildings, certain Operating Expenses may pertain to a particular building(s) and other Operating Expenses to the Project as a whole.  Landlord reserves the right in its sole discretion to allocate any such costs applicable to any particular building within the Project to such building, and other such costs applicable to the Project to each building in the Project (including the Building), with the tenants in each building being responsible for paying their respective proportionate shares of their buildings to the extent required under their leases.  Landlord shall allocate such costs to the buildings (including the Building) in a reasonable, non-discriminatory manner, and such allocation shall be binding on Tenant.

9.4.Landlord’s annual statement shall be final and binding upon Tenant unless Tenant, within thirty (30) days after Tenant’s receipt thereof, shall contest any item therein by giving written notice to Landlord, specifying each item contested and the reasons therefor; provided that Tenant shall in all events pay the amount specified in Landlord’s annual statement, pending the results of the Independent Review and determination of the Accountant(s), as applicable and as each such term is defined below.  If, during such thirty (30)-day period, Tenant

 

 

11

 


reasonably and in good faith questions or contests the correctness of Landlord’s statement of Tenant’s Adjusted Share of Operating Expenses, Landlord shall provide Tenant with reasonable access to Landlord’s books and records to the extent relevant to determination of Operating Expenses, and such information as Landlord reasonably determines to be responsive to Tenant’s written inquiries.  In the event that, after Tenant’s review of such information, Landlord and Tenant cannot agree upon the amount of Tenant’s Adjusted Share of Operating Expenses, then Tenant shall have the right to have an independent public accounting firm hired by Tenant on an hourly basis and not on a contingent-fee basis (at Tenant’s sole cost and expense) and approved by Landlord (which approval Landlord shall not unreasonably withhold or delay) audit and review such of Landlord’s books and records for the year in question as directly relate to the determination of Operating Expenses for such year (the “Independent Review”), but not books and records of entities other than Landlord.  Landlord shall make such books and records available at the location where Landlord maintains them in the ordinary course of its business.  Landlord need not provide copies of any books or records.  Tenant shall commence the Independent Review within thirty (30) days after the date Landlord has given Tenant access to Landlord’s books and records for the Independent Review.  Tenant shall complete the Independent Review and notify Landlord in writing of Tenant’s specific objections to Landlord’s calculation of Operating Expenses (including Tenant’s accounting firm’s written statement of the basis, nature and amount of each proposed adjustment) no later than sixty (60) days after Landlord has first given Tenant access to Landlord’s books and records for the Independent Review.  Landlord shall review the results of any such Independent Review.  The parties shall endeavor to agree promptly and reasonably upon Operating Expenses taking into account the results of such Independent Review.  If, as of the date that is sixty (60) days after Tenant has submitted the Independent Review to Landlord, the parties have not agreed on the appropriate adjustments to Operating Expenses, then the parties shall engage a mutually agreeable independent third party accountant with at least ten (10) years’ experience in commercial real estate accounting in the Cambridge, Massachusetts area (the “Accountant”).  If the parties cannot agree on the Accountant, each shall within ten (10) days after such impasse appoint an Accountant (different from the accountant and accounting firm that conducted the Independent Review) and, within ten (10) days after the appointment of both such Accountants, those two Accountants shall select a third (which cannot be the accountant and accounting firm that conducted the Independent Review).  If either party fails to timely appoint an Accountant, then the Accountant the other party appoints shall be the sole Accountant.  Within ten (10) days after appointment of the Accountant(s), Landlord and Tenant shall each simultaneously give the Accountants (with a copy to the other party) its determination of Operating Expenses, with such supporting data or information as each submitting party determines appropriate.  Within ten (10) days after such submissions, the Accountants shall by majority vote select either Landlord’s or Tenant’s determination of Operating Expenses.  The Accountants may not select or designate any other determination of Operating Expenses.  The determination of the Accountant(s) shall bind the parties.  If the parties agree or the Accountant(s) determine that the Operating Expenses actually paid by Tenant for the calendar year in question exceeded Tenant’s obligations for such calendar year, then Landlord shall, at Tenant’s option, either (a) credit the excess to the next succeeding installments of estimated Additional Rent or (b) pay the excess to Tenant within thirty (30) days after delivery of such results.  If the parties agree or the Accountant(s) determine that Tenant’s payments of Operating Expenses for such calendar year were less than Tenant’s obligation for the calendar year, then Tenant shall pay the deficiency to Landlord within thirty (30) days after delivery of such results.  If the Independent Review reveals or the Accountant(s)

 

 

12

 


determine that the Operating Expenses billed to Tenant by Landlord and paid by Tenant to Landlord for the applicable calendar year in question exceeded by more than ten percent (10%) what Tenant should have been billed during such calendar year, then Landlord shall pay the reasonable cost of the Independent Review.  In all other cases Tenant shall pay the cost of the Independent Review and the Accountant(s).

9.5.Tenant shall not be responsible for Operating Expenses with respect to any time period prior to the Term Commencement Date; provided, however, that if Landlord shall permit Tenant possession of the Premises prior to the Term Commencement Date other than for the sole purpose of installing its trade fixtures, equipment or personal property (in which case, Tenant shall pay those charges specified in Section 4.3 of this Lease), Tenant shall be responsible for Operating Expenses from such earlier date of possession (the Term Commencement Date or such earlier date, as applicable, the “Expense Trigger Date”); and provided, further, that Landlord may annualize certain Operating Expenses incurred prior to the Expense Trigger Date over the course of the budgeted year during which the Expense Trigger Date occurs, and Tenant shall be responsible for the annualized portion of such Operating Expenses corresponding to the number of days during such year, commencing with the Expense Trigger Date, for which Tenant is otherwise liable for Operating Expenses pursuant to this Lease.  Tenant’s responsibility for Tenant’s Adjusted Share of Operating Expenses shall continue to the latest of (a) the date of termination of the Lease, (b) the date Tenant has fully vacated the Premises and (c) if termination of the Lease is due to a default by Tenant, the date of rental commencement of a replacement tenant.

9.6.Operating Expenses for the calendar year in which Tenant’s obligation to share therein commences and for the calendar year in which such obligation ceases shall be prorated based upon the number of days in the applicable month.  Expenses such as taxes, assessments and insurance premiums that are incurred for an extended time period shall be prorated based upon the time periods to which they apply so that the amounts attributed to the Premises relate in a reasonable manner to the time period wherein Tenant has an obligation to share in Operating Expenses.

9.7.Within thirty (30) days after the end of each calendar year quarter (i.e. by April 30, July 30, October 30 and January 30) in which Tenant believes it is entitled to reimbursement from Landlord pursuant to the terms of this Lease, Tenant shall submit to Landlord an invoice, or, in the event an invoice is not available, an itemized list, of all costs and expenses that (a) Tenant has incurred (either internally or by employing third parties) during the prior month and (b) for which Tenant reasonably believes it is entitled to reimbursements from Landlord pursuant to the terms of this Lease or the Work Letter. Tenant’s failure to send any submittal required by this Section 9.7 shall not be a default of Tenant hereunder nor shall it constitute a waiver of Tenant’s right to seek reimbursement from Landlord, however, Tenant shall promptly respond to any written requests from Landlord requesting any such submittal, and to the extent Tenant is seeking any such reimbursement it shall provide the information required under this Section 9.7 in connection with any request for reimbursement.

9.8.In the event that the Building or Project is less than fully occupied during a calendar year, Tenant acknowledges that Landlord may extrapolate Operating Expenses that vary

 

 

13

 


depending on the occupancy of the Building or Project, as applicable, to equal Landlord’s reasonable estimate of what such Operating Expenses would have been had the Building or Project, as applicable, been ninety-five percent (95%) occupied during such calendar year; provided, however, that Landlord shall not recover more than one hundred percent (100%) of Operating Expenses.

 

10.Taxes on Tenant’s Property.

10.1.Tenant shall pay prior to delinquency any and all taxes levied against (a) personal property and trade fixtures located at the Premises and (b) any gross or net receipts of or sales by Tenant.

10.2.If any such taxes on Tenant’s personal property or trade fixtures are levied against Landlord or Landlord’s property or, if the assessed valuation of the Building, the Property or the Project is increased by inclusion therein of a value attributable to Tenant’s personal property or trade fixtures, and if Landlord, after written notice to Tenant, pays the taxes based upon any such increase in the assessed value of the Building, the Property or the Project, then Tenant shall, upon demand, repay to Landlord the taxes so paid by Landlord.

10.3.If any improvements in or alterations to the Premises, made or requested by Tenant, whether owned by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, are assessed for real property tax purposes at a valuation higher than the valuation at which improvements conforming to Landlord’s building standards (the “Building Standard”) in other spaces in the Building are assessed, then the real property taxes and assessments levied against Landlord or the Building, the Property or the Project by reason of such excess assessed valuation shall be deemed to be taxes levied against personal property of Tenant and shall be governed by the provisions of Section 10.2.  Any such excess assessed valuation due to improvements in or alterations to space in the Project leased by other tenants at the Project shall not be included in Operating Expenses.  If the records of the applicable governmental assessor’s office are available and sufficiently detailed to serve as a basis for determining whether such Tenant improvements or alterations are assessed at a higher valuation than the Building Standard, then such records shall be binding on both Landlord and Tenant.

11.Security Deposit.

11.1.Tenant shall deposit with Landlord on or before the Execution Date the sum set forth in Section 2.6 (the “Security Deposit”), which sum shall be held by Landlord as security for the faithful performance by Tenant of all of the terms, covenants and conditions of this Lease to be kept and performed by Tenant during the Term and ending upon the expiration or termination of Tenant’s obligations under this Lease.  If Tenant Defaults (as defined below) with respect to any provision of this Lease, including any provision relating to the payment of Rent, then Landlord may (but shall not be required to) use, apply or retain all or any part of the Security Deposit for the payment of any Rent or any other sum in default, or to compensate Landlord for any other loss or damage that Landlord may suffer by reason of Tenant’s default.  If any portion

 

 

14

 


of the Security Deposit is so used or applied, then Tenant shall, within ten (10) days following demand therefor, deposit cash with Landlord in an amount sufficient to restore the Security Deposit to its original amount, and Tenant’s failure to do so shall be a material breach of this Lease.  The provisions of this Article shall survive the expiration or earlier termination of this Lease.

11.2.In the event of bankruptcy or other debtor-creditor proceedings against Tenant, the Security Deposit shall be deemed to be applied first to the payment of Rent and other charges due Landlord for all periods prior to the filing of such proceedings.

11.3.Landlord may deliver to any purchaser of Landlord’s interest in the Premises the funds deposited hereunder by Tenant, and thereupon Landlord shall be discharged from any further liability with respect to such deposit.  This provision shall also apply to any subsequent transfers.

11.4.If Tenant shall fully and faithfully perform every provision of this Lease to be performed by it, then the Security Deposit, or any balance thereof, shall be returned to Tenant (or, at Landlord’s option, to the last assignee of Tenant’s interest hereunder) within thirty (30) days after the expiration or earlier termination of this Lease.

11.5.If the Security Deposit shall be in cash, Landlord shall hold the Security Deposit in an account at a banking organization selected by Landlord; provided, however, that Landlord shall not be required to maintain a separate account for the Security Deposit, but may intermingle it with other funds of Landlord.  Landlord shall be entitled to all interest and/or dividends, if any, accruing on the Security Deposit.  Landlord shall not be required to credit Tenant with any interest for any period during which Landlord does not receive interest on the Security Deposit.

11.6.The Security Deposit may be in the form of cash, a letter of credit or any other security instrument acceptable to Landlord in its sole discretion.  Tenant may at any time, except when Tenant is in Default (as defined below), deliver a letter of credit (the “L/C Security”) as the entire Security Deposit, as follows:

(a)If Tenant elects to deliver L/C Security, then Tenant shall provide Landlord, and maintain in full force and effect throughout the Term and until the date that is six (6) months after the then-current Term Expiration Date, a letter of credit in the form of Exhibit E issued by an issuer reasonably satisfactory to Landlord, in the amount of the Security Deposit, with an initial term of at least one year.  Landlord may require the L/C Security to be re-issued by a different issuer at any time during the Term if Landlord reasonably believes that the issuing bank of the L/C Security is or may soon become insolvent; provided, however, Landlord shall return the existing L/C Security to the existing issuer immediately upon receipt of the substitute L/C Security.  If any issuer of the L/C Security shall become insolvent or placed into FDIC receivership, then Tenant shall immediately deliver to Landlord (without the requirement of notice from Landlord) substitute L/C Security issued by an issuer reasonably satisfactory to Landlord, and otherwise conforming to the requirements set forth in this Article.  As used herein with respect to the issuer of the L/C Security, “insolvent” shall mean the determination of insolvency as made by such issuer’s primary bank regulator (i.e., the state bank supervisor for state chartered banks; the OCC or OTS, respectively, for federally chartered banks or thrifts; or

 

 

15

 


the Federal Reserve for its member banks).  If, at the Term Expiration Date, any Rent remains uncalculated or unpaid, then (i) Landlord shall with reasonable diligence complete any necessary calculations, (ii) Tenant shall extend the expiry date of such L/C Security from time to time as Landlord reasonably requires and (iii) in such extended period, Landlord shall not unreasonably refuse to consent to an appropriate reduction of the L/C Security.  Tenant shall reimburse Landlord’s legal costs (as estimated by Landlord’s counsel and not to exceed $3,000) in handling Landlord’s acceptance of L/C Security or its replacement or extension.

(b)If Tenant delivers to Landlord satisfactory L/C Security in place of the entire Security Deposit, Landlord shall remit to Tenant any cash Security Deposit Landlord previously held.

(c)Landlord may draw upon the L/C Security, and hold and apply the proceeds in the same manner and for the same purposes as the Security Deposit, if (i) an uncured Default (as defined below) exists, (ii) as of the date that is forty-five (45) days before any L/C Security expires (even if such scheduled expiry date is after the Term Expiration Date) Tenant has not delivered to Landlord an amendment or replacement for such L/C Security, reasonably satisfactory to Landlord, extending the expiry date to the earlier of (1) six (6) months after the then-current Term Expiration Date or (2) the date that is one year after the then-current expiry date of the L/C Security, (iii) the L/C Security provides for automatic renewals, Landlord asks the issuer to confirm the current L/C Security expiry date, and the issuer fails to do so within ten (10) business days, (iv) Tenant fails to pay (when and as Landlord reasonably requires) any bank charges for Landlord’s transfer of the L/C Security or (v) the issuer of the L/C Security ceases, or announces that it will cease, to maintain an office in the city where Landlord may present drafts under the L/C Security (and fails to permit drawing upon the L/C Security by overnight courier or facsimile).  This Section does not limit any other provisions of this Lease allowing Landlord to draw the L/C Security under specified circumstances.

(d)Tenant shall not seek to enjoin, prevent, or otherwise interfere with Landlord’s draw under L/C Security, even if it violates this Lease.  Tenant acknowledges that the only effect of a wrongful draw would be to substitute a cash Security Deposit for L/C Security, causing Tenant no legally recognizable damage.  Landlord shall hold the proceeds of any draw in the same manner and for the same purposes as a cash Security Deposit.  In the event of a wrongful draw, the parties shall cooperate to allow Tenant to post replacement L/C Security simultaneously with the return to Tenant of the wrongfully drawn sums, and Landlord shall upon request confirm in writing to the issuer of the L/C Security that Landlord’s draw was erroneous.

(e)If Landlord transfers its interest in the Premises, then Tenant shall at Tenant’s expense, within five (5) business days after receiving a request from Landlord, deliver (and, if the issuer requires, Landlord shall consent to) an amendment to the L/C Security naming Landlord’s grantee as substitute beneficiary.  If the required Security Deposit changes while L/C Security is in force, then Tenant shall deliver (and, if the issuer requires, Landlord shall consent to) a corresponding amendment to the L/C Security.

 

 

16

 


12.Use.

12.1.Tenant shall use the Premises for the Permitted Use, and shall not use the Premises, or permit or suffer the Premises to be used, for any other purpose without Landlord’s prior written consent, which consent Landlord may withhold in its sole and absolute discretion.

12.2.Tenant shall not use or occupy the Premises in violation of Applicable Laws; zoning ordinances; or the certificate of occupancy (or its substantial equivalent) issued for the Building or the Project, and shall, upon five (5) days’ written notice from Landlord, discontinue any use of the Premises that is declared or claimed by any Governmental Authority having jurisdiction to be a violation of any of the above, or that in Landlord’s reasonable opinion violates any of the above.  Tenant shall comply with any direction of any Governmental Authority having jurisdiction that shall, by reason of the nature of Tenant’s use or occupancy of the Premises, impose any duty upon Tenant or Landlord with respect to the Premises or with respect to the use or occupation thereof, and shall indemnify, defend (at Landlord’s option and with counsel reasonably acceptable to Landlord) and hold harmless (collectively, “Indemnify,” “Indemnity” or “Indemnification,” as the case may require) the Landlord and its affiliates, employees, agents and contractors; and any lender, mortgagee, ground lessor or beneficiary (each, a “Lender” and, collectively with Landlord and its affiliates, employees, agents and contractors, the “Landlord Indemnitees”) harmless from and against any and all demands, claims, liabilities, losses, costs, expenses, actions, causes of action, damages, suits or judgments, and all reasonable expenses (including reasonable attorneys’ fees, charges and disbursements, regardless of whether the applicable demand, claim, action, cause of action or suit is voluntarily withdrawn or dismissed) incurred in investigating or resisting the same (collectively, “Claims”) of any kind or nature that arise before, during or after the Term as a result of Tenant’s breach of this Section.

12.3.Tenant shall not do or permit to be done anything that will invalidate or increase the cost of any fire, environmental, extended coverage or any other insurance policy covering the Building or the Project, and shall comply with all reasonable rules, orders, regulations and requirements of the insurers of the Building and the Project, and Tenant shall promptly, upon demand, reimburse Landlord for any additional premium charged for such policy by reason of Tenant’s failure to comply with the provisions of this Article.

12.4.Tenant shall keep all doors opening onto public corridors closed, except when in use for ingress and egress.

12.5.No additional locks or bolts of any kind shall be placed upon any of the doors or windows by Tenant, nor shall any changes be made to existing locks or the mechanisms thereof without Landlord’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed.  Tenant shall, upon termination of this Lease, return to Landlord all keys to offices and restrooms either furnished to or otherwise procured by Tenant.  In the event any key so furnished to Tenant is lost, Tenant shall pay to Landlord the cost of replacing the same or of changing the lock or locks opened by such lost key if Landlord shall deem it necessary to make such change.

 

 

17

 


12.6.No awnings or other projections shall be attached to any outside wall of the Building.  No curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the Premises other than Landlord’s standard window coverings.  Neither the interior nor exterior of any windows shall be coated or otherwise sunscreened without Landlord’s prior written consent, nor shall any bottles, parcels or other articles be placed on the windowsills or items attached to windows that are visible from outside the Premises.  No equipment, furniture or other items of personal property shall be placed on any exterior balcony without Landlord’s prior written consent.

12.7.No sign, advertisement or notice (“Signage”) shall be exhibited, painted or affixed by Tenant on any part of the Premises or the Building without Landlord’s prior written consent.  Signage shall conform to Landlord’s design criteria.  For any Signage, Tenant shall, at Tenant’s own cost and expense, (a) acquire all permits for such Signage in compliance with Applicable Laws and (b) design, fabricate, install and maintain such Signage in a first-class condition.  Tenant shall be responsible for reimbursing Landlord for costs incurred by Landlord in removing any of Tenant’s Signage upon the expiration or earlier termination of the Lease.  Interior signs in the Building lobby and the directory tablet shall be inscribed, painted or affixed for Tenant by Landlord at Landlord’s sole cost and expense, and shall be of a size, color and type and be located in a place acceptable to Landlord.  The directory tablet shall be provided exclusively for the display of the name and location of tenants only.  Tenant shall not place anything on the exterior of the corridor walls or corridor doors other than Landlord’s standard lettering.  Tenant, at Tenant’s sole cost and expense, shall have Signage rights for the primary entrance to the Premises substantially consistent with the Signage permitted for comparable Tenants in the Project, as Landlord reasonably determines.  At Landlord’s option, Landlord may install any Tenant Signage, and Tenant shall pay all costs associated with such installation within thirty (30) days after demand therefor.  Landlord, at its expense shall place a sign panel identifying Tenant on the Landlord’s monument sign outside of the Building similar to and consistent with the design and location of other sign panels identifying tenants in the Building.  Tenant shall not have any such monument signage rights if it assigns this Lease (excluding an assignment of this Lease that is an Exempt Transfer) or if Tenant subleases more than fifty percent (50%) of the Rentable Area of the Premises.  Tenant shall pay as Additional Rent all costs and expenses incurred by Landlord in changing the identification of Tenant on such monument sign arising after the Commencement Date, including any removal of Tenant’s identification from such monument sign pursuant to the immediately foregoing sentence.    

12.8.Tenant may only place equipment within the Premises with floor loading consistent with the Building’s structural design unless Tenant obtains Landlord’s prior written approval.  Tenant may place such equipment only in a location designed to carry the weight of such equipment.

12.9.Tenant shall cause any equipment or machinery to be installed in the Premises so as to reasonably prevent sounds or vibrations therefrom from extending into the Common Area or other offices in the Project.

12.10.Tenant shall not (a) do or permit anything to be done in or about the Premises that shall in any way obstruct or interfere with the rights of other tenants or occupants of the Project, or injure or annoy them, (b) use or allow the Premises to be used for immoral, unlawful or

 

 

18

 


objectionable purposes, (c) cause, maintain or permit any nuisance or waste in, on or about the Project or (d) take any other action that would in Landlord’s reasonable determination in any manner adversely affect other tenants’ quiet use and enjoyment of their space or adversely impact their ability to conduct business in a professional and suitable work environment.  Notwithstanding anything in this Lease to the contrary, Tenant may not install any security systems (including cameras) outside the Premises or that record sounds or images outside the Premises without Landlord’s prior written consent, which Landlord may withhold in its sole and absolute discretion.

12.11.Notwithstanding any other provision herein to the contrary, from and after the Term Commencement Date, Tenant shall be responsible for all liabilities, costs and expenses arising out of or in connection with the compliance of the Premises with the Americans with Disabilities Act, 42 U.S.C. § 12101, et seq., and any state and local accessibility laws, codes, ordinances and rules (collectively, and together with regulations promulgated pursuant thereto, the “ADA”) (except to the extent that any such non-compliance of the Premises with the ADA (as in effect and interpreted as of the Term Commencement Date) existed as of the Term Commencement Date), and Tenant shall Indemnify the Landlord Indemnitees from and against Claims arising out of any such failure of the Premises to comply with the Tenant’s obligations with respect to the ADA under this Section.  Landlord shall be responsible for all liabilities, costs and expenses arising out of or in connection with the compliance of the Common Areas with the ADA (which costs may be included in Operating Expenses to the extent permitted in Article 9 except to the extent that any such non-compliance of the Common Areas with the ADA (as in effect and interpreted as of the Term Commencement Date) existed as of the Term Commencement Date).  This Section (as well as any other provisions of this Lease dealing with Indemnification of the Landlord Indemnitees by Tenant) shall be deemed to be modified in each case by the insertion in the appropriate place of the following:  “except as otherwise provided in Mass. G.L. Ter. Ed., C. 186, Section 15.” For the avoidance of doubt, “Lenders” shall also include historic tax credit investors and new market tax credit investors.  The provisions of this Section shall survive the expiration or earlier termination of this Lease.

12.12.Tenant shall maintain temperature and humidity in the Premises in accordance with ASHRAE standards at all times.

12.13.Tenant shall establish and maintain a chemical safety program administered by a licensed, qualified individual in accordance with the requirements of the Massachusetts Water Resources Authority (“MWRA”) and any other applicable Governmental Authority.  Tenant shall be solely responsible for all costs incurred in connection with such chemical safety program, and Tenant shall provide Landlord with such documentation as Landlord may reasonably require evidencing Tenant’s compliance with the requirements of (a) the MWRA and any other applicable Governmental Authority with respect to such chemical safety program and (b) this Section.  Tenant shall be required to obtain and maintain during the Term (m) any permit required by the MWRA (“MWRA Permit”) and (n) a wastewater treatment operator license from the Commonwealth of Massachusetts with respect to Tenant’s Acid Neutralization Tank (as defined below) in the Building.  Tenant shall not introduce anything into the Acid Neutralization Tank (x) in violation of the terms of the MWRA Permit, (y) in violation of Applicable Laws or (z) that would interfere with the proper functioning of the Acid Neutralization Tank.  Landlord

 

 

19

 


agrees to reasonably cooperate with Tenant in order for Tenant to obtain the MWRA Permit and the wastewater treatment operator license, without any obligation for Landlord to incur any costs in connection therewith.  Tenant shall reimburse Landlord within ten (10) business days after demand for any costs incurred by Landlord pursuant to this Section.

13.Rules and Regulations, CC&Rs, Parking Facilities and Common Area.

13.1.Tenant shall have the non-exclusive right, in common with others, to use the Common Area in conjunction with Tenant’s use of the Premises for the Permitted Use, and such use of the Common Area and Tenant’s use of the Premises shall be subject to the rules and regulations adopted by Landlord and attached hereto as Exhibit F, together with such other reasonable and nondiscriminatory rules and regulations as are hereafter reasonably promulgated by Landlord in its sole and absolute discretion (the “Rules and Regulations”).  Tenant shall ensure that its contractors, subcontractors, employees, subtenants and invitees faithfully observe and comply with the Rules and Regulations.  Landlord shall not be responsible to Tenant for the violation or non-performance by any other tenant or any agent, employee or invitee thereof of any of the Rules and Regulations.

13.2.This Lease is subject to any recorded covenants, conditions or restrictions on the Project or Property (including the Parking and Transportation Demand Management Plan Ordinance- Final Amendment Decision, issued on May 24, 2002, by the City of Cambridge (as the same may be amended from time to time, the “PTDM”) , as the same may be amended, amended and restated, supplemented or otherwise modified from time to time (the “CC&Rs”) and Tenant shall, at its sole cost and expense, comply with and cause the Project to comply with the CC&Rs and the documents listed on Exhibit G attached hereto (together with the PTDM, the “Property Operations Documents”).  Tenant acknowledges that Tenant, at its sole cost and expense, shall comply with the tenant requirements in the PTDM, including the requirements set forth in the “Alternative Work Programs,” “Public Transportation Incentives,” “Ridesharing Programs” and “Provisions of Bicycle and Pedestrian Amenities” sections thereof.  Tenant, at its sole cost and expense, shall also comply with the reporting requirements set forth in the PTDM at Landlord’s request.  Any costs incurred by Landlord in connection with the PTDM shall constitute an Operating Expense.

13.3. The Charles River Transportation Management Association (of which Landlord or an affiliate of Landlord is currently a member) provides certain programs to help improve transportation in the Cambridge area.  Their website is www.charlesrivertma.org.

13.4. Tenant shall have a non-exclusive, irrevocable license to use forty (40) parking spaces in the facilities serving the Building and the Project in common on an unreserved basis with other tenants of the Building and the Project during the Term at a cost of Three Hundred Twenty Dollars ($320.00) per parking space per month (subject to market rate adjustment by Landlord from time to time throughout the Term), which Tenant shall pay simultaneously with payments of Base Rent as Additional Rent.  Tenant, at any time and from time to time during the Term, may elect to waive its right to use some or all or its parking spaces upon written notice to Landlord.  If Tenant so elects, then it shall forfeit for the then-remainder of the Term (including any extension thereof) any and all rights to such waived parking spaces.

 

 

20

 


13.5.Tenant agrees not to unreasonably overburden the parking facilities and agrees to cooperate with Landlord and other tenants in the use of the parking facilities, and Landlord hereby agrees that Tenant shall not be deemed to be overburdening the parking facilities if Tenant is using the number of spaces (or fewer) then allocated to Tenant and Tenant is otherwise complying with any rules and regulations concerning the parking facilities.  Landlord reserves the right to determine that parking facilities are becoming overcrowded and to limit Tenant’s use thereof.  Upon such determination, Landlord may reasonably allocate parking spaces among Tenant and other tenants of the Building or the Project; provided, however, that Landlord shall not be permitted to reduce the number of parking spaces to which Tenant is then entitled to use under this Lease.  Nothing in this Section, however, is intended to create an affirmative duty on Landlord’s part to monitor parking.

13.6.Subject to the terms of this Lease including the Rules and Regulations and the rights of other tenants of the Building, Tenant shall have the non-exclusive right, at no additional cost and on an unreserved basis, subject to Section 4 of the Rules and Regulations, to access the freight loading dock and freight elevator twenty-four (24) hours per day, seven (7) days per week, at no additional cost.  Landlord shall not be responsible for any coordination of the use of the freight elevator or the loading dock by tenants at the Building.  Landlord shall provide a dumpster and/or trash compactor at the loading dock for Tenant’s use for the disposal of non-Hazardous Materials, and Tenant shall pay Tenant’s Adjusted Share of the cost of said dumpster and/or trash compactor.  Tenant shall be solely responsible for the disposal of any Hazardous Materials in accordance with Applicable Laws.

14.Project Control by Landlord.

14.1.Landlord reserves full control over the Building and the Project to the extent not inconsistent with Tenant’s enjoyment of the Premises as provided by this Lease.  This reservation includes Landlord’s right to subdivide the Project; convert the Building and the other buildings within the Project to condominium units; change the size of the Project by selling all or a portion of the Project or adding real property and any improvements thereon to the Project; grant easements and licenses to third parties; maintain or establish ownership of the Building separate from fee title to the Property; make additions to or reconstruct portions of the Building and the Project; install, use, maintain, repair, replace and relocate for service to the Premises and other parts of the Building or the Project pipes, ducts, conduits, wires and appurtenant fixtures, wherever located in the Premises, the Building or elsewhere at the Project; and alter or relocate any other Common Area or facility, including private drives, lobbies, entrances and landscaping; provided, however, that such rights shall be exercised in a way that does not materially adversely affect Tenant’s beneficial use and occupancy of the Premises, including the Permitted Use and Tenant’s access to the Premises.  Tenant acknowledges that Landlord specifically reserves the right to allow the exclusive use of corridors and restroom facilities located on specific floors to one or more tenants occupying such floors; provided, however, that Tenant shall not be deprived of the use of the corridors reasonably required to serve the Premises or of restroom facilities serving the floor upon which the Premises are located.

 

 

21

 


14.2.Possession of areas of the Premises necessary for utilities, services, safety and operation of the Building is reserved to Landlord.

14.3.Tenant shall, at Landlord’s request, promptly execute such further documents as may be reasonably appropriate to assist Landlord in the performance of its obligations hereunder; provided that Tenant need not execute any document that creates additional liability for Tenant or that deprives Tenant of the quiet enjoyment and use of the Premises as provided for in this Lease.

14.4.Landlord may, at any and all reasonable times during non-business hours (or during business hours, if (a) with respect to Subsections 14.4(u) through 14.4(y), Tenant so requests, and (b) with respect to Subsection 14.4(z), if Landlord so requests), and upon twenty-four (24) hours’ prior notice (which may be oral or by email to the office manager or other Tenant-designated individual at the Premises; but provided that no time restrictions shall apply or advance notice be required if an emergency necessitates immediate entry), enter the Premises to (u) inspect the same and to determine whether Tenant is in compliance with its obligations hereunder, (v) supply any service Landlord is required to provide hereunder, (w) alter, improve or repair any portion of the Building other than the Premises for which access to the Premises is reasonably necessary, (x) post notices of nonresponsibility, (y) access the telephone equipment, electrical substation and fire risers and (z) show the Premises to prospective tenants during the final year of the Term and current and prospective purchasers and lenders at any time.  In connection with any such alteration, improvement or repair as described in Subsection 14.4(w), Landlord may erect in the Premises or elsewhere in the Project scaffolding and other structures reasonably required for the alteration, improvement or repair work to be performed.  In no event shall Tenant’s Rent abate as a result of Landlord’s activities pursuant to this Section; provided, however, that all such activities shall be conducted in such a manner so as to cause as little interference to Tenant as is reasonably possible.  Landlord shall at all times retain a key with which to unlock all of the doors in the Premises.  If an emergency necessitates immediate access to the Premises, Landlord may use whatever force is necessary to enter the Premises, and any such entry to the Premises shall not constitute a forcible or unlawful entry to the Premises, a detainer of the Premises, or an eviction of Tenant from the Premises or any portion thereof.

15.Quiet Enjoyment

.  Landlord covenants that, so long as no Default (as hereinafter defined) has occurred, Tenant may peacefully and quietly have, hold and enjoy the Premises, free from any claim by Landlord or persons claiming under Landlord, but subject to all of the terms and provisions hereof, provisions of Applicable Laws and rights of record to which this Lease is or may become subordinate.  This covenant is in lieu of any other quiet enjoyment covenant, either express or implied.

 

 

22

 


16.Utilities and Services.

16.1.Tenant shall pay for all water (including the cost to service, repair and replace reverse osmosis, de-ionized and other treated water), gas, heat, light, power, telephone, internet service, cable television, other telecommunications and other utilities supplied to the Premises, together with any fees, surcharges and taxes thereon.  Power shall be separately sub-metered to Tenant.  If any such utility is not separately metered or sub-metered to Tenant, Tenant shall pay Tenant’s Adjusted Share of all charges of such utility jointly metered with other premises as part of Tenant’s Adjusted Share of Operating Expenses or, in the alternative, Landlord may, at its option, monitor the usage of such utilities by Tenant and charge Tenant with the cost of purchasing, installing and monitoring such metering equipment, which cost shall be paid by Tenant as Additional Rent.  Landlord may base its bills for utilities on reasonable estimates; provided that Landlord adjusts such billings promptly thereafter or as part of the next Landlord’s Statement to reflect the actual cost of providing utilities to the Premises.  To the extent that Tenant uses more than Tenant’s Pro Rata Share of any utilities, then Tenant shall pay Landlord for Tenant’s Adjusted Share of such utilities to reflect such excess.  In the event that the Building or Project is less than fully occupied during a calendar year, Tenant acknowledges that Landlord may extrapolate utility usage that varies depending on the occupancy of the Building or Project (as applicable) to equal Landlord’s reasonable estimate of what such utility usage would have been had the Building or Project, as applicable, been ninety-five percent (95%) occupied during such calendar year; provided, however, that Landlord shall not recover more than one hundred percent (100%) of the cost of such utilities. Tenant shall not be liable for the cost of utilities supplied to the Premises attributable to the time period prior to the Term Commencement Date; provided, however, that, if Landlord shall permit Tenant possession of the Premises prior to the Term Commencement Date and Tenant uses the Premises for any purpose other than placement of personal property as set forth in Section 4.3, then Tenant shall be responsible for the cost of utilities supplied to the Premises from such earlier date of possession.

16.2.Landlord shall not be liable for, nor shall any eviction of Tenant result from, the failure to furnish any utility or service, whether or not such failure is caused by accidents; breakage; casualties (to the extent not caused by the party claiming Force Majeure); Severe Weather Conditions (as defined below); physical natural disasters (but excluding weather conditions that are not Severe Weather Conditions); strikes, lockouts or other labor disturbances or labor disputes (other than labor disturbances and labor disputes resulting solely from the acts or omissions of the party claiming Force Majeure); acts of terrorism; riots or civil disturbances; wars or insurrections; shortages of materials (which shortages are not unique to the party claiming Force Majeure); government regulations, moratoria or other governmental actions, inactions or delays; failures to grant consent or delays in granting consent by any Lender whose consent is required under any applicable Loan Document; failures by third parties to deliver gas, oil or another suitable fuel supply, or inability of the party claiming Force Majeure, by exercise of reasonable diligence, to obtain gas, oil or another suitable fuel; or other causes beyond the reasonable control of the party claiming that Force Majeure has occurred (collectively, “Force Majeure”); or, to the extent permitted by Applicable Laws, Landlord’s negligence.  In the event of such failure, Tenant shall not be entitled to termination of this Lease or any abatement or reduction of Rent, nor shall Tenant be relieved from the operation of any covenant or agreement

 

 

23

 


of this Lease.  “Severe Weather Conditions” means weather conditions that are materially worse than those that reasonably would be anticipated for the Property at the applicable time based on historic meteorological records. Notwithstanding anything to the contrary in this Lease, if, for more than five (5) consecutive business days following written notice to Landlord and as a direct result of Landlord’s gross negligence or willful misconduct (and except to the extent that such failure is caused in whole or in part by the action or inaction of a Tenant Party (as defined below)), the provision of HVAC or other utilities to all or a material portion of the Premises that Landlord must provide pursuant to this Lease is interrupted (a “Material Services Failure”), then Tenant’s Base Rent and Operating Expenses (or, to the extent that less than all of the Premises are affected, a proportionate amount (based on the Rentable Area of the Premises that is rendered unusable) of Base Rent and Operating Expenses) shall thereafter be abated until the Premises are again usable by Tenant for the Permitted Use; provided, however, that, if Landlord is diligently pursuing the restoration of such HVAC and other utilities and Landlord provides substitute HVAC and other utilities reasonably suitable for Tenant’s continued use and occupancy of the Premises for the Permitted Use (e.g., supplying potable water or portable air conditioning equipment), then neither Base Rent nor Operating Expenses shall be abated.  During any Material Services Failure, Tenant will cooperate with Landlord to arrange for the provision of any interrupted utility services on an interim basis via temporary measures until final corrective measures can be accomplished, and Tenant will permit Landlord the necessary access to the Premises to remedy such Material Service Failure.  In the event of any interruption of HVAC or other utilities that Landlord must provide pursuant to this Lease, regardless of the cause, Landlord shall diligently pursue the restoration of such HVAC and other utilities.  Notwithstanding anything in this Lease to the contrary, but subject to Article 24 (which shall govern in the event of a casualty), the provisions of this Section shall be Tenant’s sole recourse and remedy in the event of an interruption of HVAC or other utilities to the Premises, including related to Section 16.8.

16.3.Tenant shall pay for, prior to delinquency of payment therefor, any utilities and services that may be furnished to the Premises during or, if Tenant occupies the Premises after the expiration or earlier termination of the Term, after the Term, beyond those utilities provided by Landlord, including telephone, internet service, cable television and other telecommunications, together with any fees, surcharges and taxes thereon.  Upon Landlord’s demand, utilities and services provided to the Premises that are separately metered shall be paid by Tenant directly to the supplier of such utilities or services.

16.4.Tenant shall not, without Landlord’s prior written consent, use any device in the Premises (including data processing machines) that will in any way (a) increase the amount of ventilation, air exchange, gas, steam, electricity or water required or consumed in the Premises based upon Tenant’s Pro Rata Share of the Building or Project (as applicable) beyond the existing capacity of the Building or the Project usually furnished or supplied for the Permitted Use or (b) exceed Tenant’s Pro Rata Share of the Building’s or Project’s (as applicable) capacity to provide such utilities or services.

16.5.If Tenant shall require utilities or services in excess of those usually furnished or supplied for tenants in similar spaces in the Building or the Project by reason of Tenant’s

 

 

24

 


equipment or extended hours of business operations, then Tenant shall first procure Landlord’s consent for the use thereof, which consent Landlord may condition upon the availability of such excess utilities or services, and Tenant shall pay as Additional Rent an amount equal to the cost of providing such excess utilities and services.

16.6.Landlord shall provide water in the Common Area for lavatory and landscaping purposes only, which water shall be from the local municipal or similar source; provided, however, that if Landlord determines that Tenant requires, uses or consumes water provided to the Common Area for any purpose other than ordinary lavatory purposes, Landlord may install a water meter (“Tenant Water Meter”) and thereby measure Tenant’s water consumption for all purposes.  Tenant shall pay Landlord for the costs of any Tenant Water Meter and the installation and maintenance thereof during the Term.  If Landlord installs a Tenant Water Meter, Tenant shall pay for water consumed by Tenant, as shown on such meter, as and when bills are rendered.  If Tenant fails to timely make such payments, Landlord may pay such charges and collect the same from Tenant.  Any such costs or expenses incurred or payments made by Landlord for any of the reasons or purposes stated in this Section shall be deemed to be Additional Rent payable by Tenant and collectible by Landlord as such.

16.7.Landlord reserves the right to stop service of the elevator, plumbing, ventilation, air conditioning and utility systems, when Landlord reasonably deems necessary or desirable, due to accident, emergency or the need to make repairs, alterations or improvements, until such repairs, alterations or improvements shall have been completed, and, except as provided in Section 16.2, Landlord shall further have no responsibility or liability for failure to supply elevator facilities, plumbing, ventilation, air conditioning or utility service when prevented from doing so by Force Majeure or, to the extent permitted by Applicable Laws, Landlord’s negligence.  Without limiting the foregoing, it is expressly understood and agreed that any covenants on Landlord’s part to furnish any service pursuant to any of the terms, covenants, conditions, provisions or agreements of this Lease, or to perform any act or thing for the benefit of Tenant, shall not be deemed breached if Landlord is unable to furnish or perform the same by virtue of Force Majeure or, to the extent permitted by Applicable Laws, Landlord’s negligence.

16.8.For the Premises, Landlord shall (a) maintain and operate the HVAC systems used for the Permitted Use only (“Base HVAC”) and (b) furnish HVAC as reasonably required (except as this Lease otherwise provides or as to any special requirements that arise from Tenant’s particular use of the Premises) for reasonably comfortable occupancy of the Premises twenty-four (24) hours a day, every day during the Term, subject to casualty, eminent domain or as otherwise specified in this Article; provided that Tenant complies with the next sentence.  If Tenant will require Base HVAC outside normal business hours of business days (as reasonably designated by Landlord) in the Premises (“Overtime HVAC”), then Landlord shall be obligated to provide Overtime HVAC only if Tenant requests it by 4 p.m. on the immediately preceding business day.  To the extent that Tenant occupies the Premises for laboratory purposes, Tenant directs Landlord to provide Overtime HVAC at all times outside normal business hours of business days (as reasonably designated by Landlord), pending further written notice from Tenant.   Tenant shall pay Landlord, as Additional Rent, one hundred percent (100%) of Landlord’s actual total cost of delivering steam and chilled water for Overtime HVAC for the

 

 

25

 


Premises, as well as for HVAC provided during Tenant’s business hours.  Notwithstanding anything to the contrary in this Section, Landlord shall have no liability, and Tenant shall have no right or remedy, on account of any interruption or impairment in HVAC services except as provided in Section 16.2.

16.9.For any utilities serving the Premises for which Tenant is billed directly by such utility provider, Tenant agrees to furnish to Landlord (a) any invoices or statements for such utilities within thirty (30) days after Tenant’s receipt thereof, (b) within thirty (30) days after Landlord’s request, any other utility usage information reasonably requested by Landlord, and (c) within thirty (30) days after each calendar year during the Term, authorization to allow Landlord to access Tenant’s usage information necessary for Landlord to complete an ENERGY STAR® Statement of Performance (or similar comprehensive utility usage report (e.g., related to Labs 21), if requested by Landlord) and any other information in Tenant’s possession reasonably requested by Landlord for the immediately preceding year; and Tenant shall comply with any other energy usage or consumption requirements required by Applicable Laws.  Tenant shall retain records of utility usage at the Premises, including invoices and statements from the utility provider, for at least sixty (60) months, or such other period of time as may be requested by Landlord.  Tenant acknowledges that any utility information for the Premises, the Building and the Project may be shared with third parties, including Landlord’s consultants and Governmental Authorities.  In the event that Tenant fails to comply with this Section, Tenant hereby authorizes Landlord to collect utility usage information directly from the applicable utility providers, and Tenant shall pay Landlord a fee of One Thousand Dollars ($1,000) per month to collect such utility usage information.  In addition to the foregoing, Tenant shall comply with all Applicable Laws related to the disclosure and tracking of energy consumption at the Premises.  The provisions of this Section shall survive the expiration or earlier termination of this Lease.

16.10.Tenant, at its sole cost and expense, and subject to the terms and provisions of Article 17 of this Lease, may install a separate acid neutralization tank (the “Acid Neutralization Tank”) in the portion of the Premises located on the first floor of the Building, as shown on Exhibit A.  In connection with the installation of the Acid Neutralization Tank, Tenant may connect to the Building’s common laboratory waste sanitary sewer connection and to the municipal sewer line in the street adjacent to the Building.  Tenant, at its sole cost and expense, shall be responsible for obtaining, and complying with at all times, the MWRA Permit and any other permits and approvals from Governmental Authorities necessary to install, use or operate the Acid Neutralization Tank, and Tenant may not operate the Acid Neutralization Tank without first having provided to Landlord, for Landlord’s approval, copies of all such permits and approvals.  Tenant shall be responsible for all costs, charges and expenses in connection with or arising out of the operation, use, maintenance, repair or refurbishment of the Acid Neutralization Tank, including all clean-up costs relating to the Acid Neutralization Tank. Tenant shall Indemnify the Landlord Indemnitees from and against any and all Claims, including (a) diminution in value of the Project or any portion thereof, (b) damages for the loss or restriction on use of rentable or usable space or of any amenity of the Project, (c) damages arising from any adverse impact on marketing of space in the Project or any portion thereof and (d) sums paid in settlement of Claims that arise during or after the Term as a result of Tenant’s improper use of the Acid Neutralization Tank.  This Indemnification by Tenant includes costs incurred in

 

 

26

 


connection with any investigation of site conditions or any clean-up, remediation, removal or restoration required by any Governmental Authority arising from Tenant’s use of the Acid Neutralization Tank.  

16.11.Subject to each and every term and provision of this Lease (including reasonable closures for repairs or maintenance pursuant to the terms of this Lease), and subject to reasonable closures as the result of casualty, condemnation, emergencies or other circumstances beyond Landlord’s control, Tenant shall have the right to access the Premises twenty-four (24) hours per day, seven (7) days per week.

17.Alterations.

17.1.Tenant shall make no alterations, additions or improvements in or to the Premises or engage in any construction, demolition, reconstruction, renovation or other work (whether major or minor) of any kind in, at or serving the Premises (“Alterations”) without Landlord’s prior written approval, which approval may be subject to the consent of one or more Lenders, if required under any applicable Loan Document, but which approval Landlord shall not otherwise unreasonably withhold; provided, however, that, in the event any proposed Alteration affects (a) any structural portions of the Building, including exterior walls, the roof, the foundation or slab, foundation or slab systems (including barriers and subslab systems) or the core of the Building, (b) the exterior of the Building or (c) any Building systems, including elevator, plumbing, HVAC, electrical, security, life safety and power, then Landlord may withhold its approval in its sole and absolute discretion.  Tenant shall, in making any Alterations, use only those architects, contractors, suppliers and mechanics of which Landlord has given prior written approval, which approval shall be in Landlord’s reasonable discretion.  In seeking Landlord’s approval, Tenant shall provide Landlord, at least thirty (30) days in advance of the proposed construction, with plans, specifications, bid proposals, certified stamped engineering drawings and calculations by Tenant’s engineer of record or architect of record (including connections to the Building’s structural system, modifications to the Building’s envelope, non-structural penetrations in slabs or walls, and modifications or tie-ins to life safety systems), work contracts, requests for laydown areas and such other information concerning the nature and cost of the Alterations as Landlord may reasonably request, provided that Tenant shall not commence any such Alterations that require Landlord’s consent unless and until Tenant has received the written approval of Landlord and any and all Lenders whose consent is required under any applicable Loan Document.  In no event shall Tenant use or Landlord be required to approve any architects, consultants, contractors, subcontractors or material suppliers that Landlord reasonably believes could cause labor disharmony or may not have sufficient experience, in Landlord’s reasonable opinion, to perform work in an occupied Class “A” laboratory research building and in tenant-occupied lab areas. Notwithstanding the foregoing, Tenant may make strictly cosmetic changes to the Premises that do not require any permits or more than three (3) total contractors and subcontractors (“Cosmetic Alterations”) without Landlord’s consent; provided that (y) the cost of any Cosmetic Alterations does not exceed Eighty-Five Thousand Dollars ($85,000.00) in any one instance or Three Hundred Fifty Thousand Dollars ($350,000.00) annually, (z) such Cosmetic Alterations do not (i) require any structural or other substantial modifications to the Premises, (ii) require any changes to or adversely affect the Building systems, (iii) affect the exterior of the

 

 

27

 


Building,  or (iv) trigger any requirement under Applicable Laws that would require Landlord to make any alteration or improvement to the Premises, the Building or the Project. Tenant shall give Landlord at least ten (10) days’ prior written notice of any Cosmetic Alterations.  Notwithstanding anything in this Article 17 to the contrary, the installation of the Acid Neutralization Tank shall not be deemed a Cosmetic Alteration, irrespective of cost.

17.2.Tenant shall not construct or permit to be constructed partitions or other obstructions that might interfere with free access to mechanical installation or service facilities of the Building or with other tenants’ components located within the Building, or interfere with the moving of Landlord’s equipment to or from the enclosures containing such installations or facilities.

17.3.Tenant shall accomplish any work performed on the Premises or the Building in such a manner as to permit any life safety systems to remain fully operable at all times.

17.4.Any work performed on the Premises, the Building or the Project by Tenant or Tenant’s contractors shall be done at such times and in such manner as Landlord may from time to time designate.  Tenant covenants and agrees that all work done by Tenant or Tenant’s contractors shall be performed in full compliance with Applicable Laws.  Within thirty (30) days after completion of any Alterations (other than Cosmetic Alterations, unless requested by Landlord), Tenant shall provide Landlord with complete “as built” drawing print sets and electronic CADD files on disc (or files in such other current format in common use as Landlord reasonably approves or requires) showing any changes in the Premises, as well as a commissioning report prepared by a licensed, qualified commissioning agent hired by Tenant and reasonably approved by Landlord for all new or affected mechanical, electrical and plumbing systems.  Any such “as built” plans shall show the applicable Alterations as an overlay on the Building as-built plans; provided that Landlord provides the Building “as built” plans to Tenant.

17.5.Before commencing any Alterations, Tenant shall (a) give Landlord at least twenty (20) days’ prior written notice of the proposed commencement of such work and the names and addresses of the persons supply labor or materials therefor so that Landlord may enter the Premises to post and keep posted thereon and therein notices or to take any further action that Landlord may reasonably deem proper for the protection of Landlord’s interest in the Project and (b) shall, if required by Landlord, secure, at Tenant’s own cost and expense, a completion and lien indemnity bond satisfactory to Landlord for such work.

17.6.Tenant shall repair any damage to the Premises arising from Tenant’s removal of any property from the Premises.  During any such restoration period, Tenant shall pay Rent to Landlord as provided herein as if such space were otherwise occupied by Tenant.  The provisions of this Section shall survive the expiration or earlier termination of this Lease.

17.7.The Premises plus any Alterations; Signage; Tenant Improvements; attached equipment, decorations, fixtures and trade fixtures; movable laboratory casework and related appliances; and other additions and improvements attached to or built into the Premises made by either of the parties (including all floor and wall coverings; paneling; sinks and related plumbing fixtures; laboratory benches; exterior venting fume hoods; walk-in freezers and refrigerators;

 

 

28

 


ductwork; conduits; electrical panels and circuits; attached machinery and equipment; and built-in furniture and cabinets, in each case, together with all additions and accessories thereto), shall (unless, prior to such construction or installation, or in connection with Landlord’s consent thereto, Landlord elects otherwise in writing) at all times remain the property of Landlord, shall remain in the Premises and shall (unless, prior to construction or installation thereof, Landlord elects otherwise in writing) be surrendered to Landlord upon the expiration or earlier termination of this Lease.  For the avoidance of doubt, the items listed on Exhibit H attached hereto (which Exhibit H may be updated by Tenant from and after the Term Commencement Date, subject to Landlord’s reasonable written consent) constitute Tenant’s property and shall be removed by Tenant upon the expiration or earlier termination of the Lease.  

17.8.Notwithstanding any other provision of this Article to the contrary, in no event shall Tenant remove any improvement from the Premises in which any Lender has a security interest or as to which Landlord contributed payment, including the Tenant Improvements, without Landlord’s prior written consent, which consent Landlord may withhold in its sole and absolute discretion.

17.9.If Tenant shall fail to remove any of its property from the Premises prior to the expiration or earlier termination of this Lease, then Landlord may, at its option, remove the same in any manner that Landlord shall choose and store such effects without liability to Tenant for loss thereof or damage thereto, and Tenant shall pay Landlord, upon demand, any costs and expenses incurred due to such removal and storage or Landlord may, at its sole option and without notice to Tenant, sell such property or any portion thereof at private sale and without legal process for such price as Landlord may obtain and apply the proceeds of such sale against any (a) amounts due by Tenant to Landlord under this Lease and (b) any actual and reasonable expenses incident to the removal, storage and sale of such personal property.

17.10.Except with respect to Cosmetic Alterations, Tenant shall pay to Landlord (upon demand) any out-of-pocket third party costs incurred by Landlord for professional review of any plans or specifications for Alterations that require Landlord’s consent.  Tenant shall reimburse Landlord for any extra expenses incurred by Landlord by reason of faulty work done by Tenant or its contractors, or by reason of delays caused by such work (other than to the extent such delays were caused by Landlord), or by reason of inadequate clean-up.  

17.11.Within sixty (60) days after final completion of any Alterations performed by Tenant with respect to the Premises, Tenant shall submit to Landlord documentation showing the amounts expended by Tenant with respect to such Alterations, together with supporting documentation reasonably acceptable to Landlord.

17.12.Tenant shall take, and shall cause its contractors to take, commercially reasonable steps to protect the Premises during the performance of any Alterations, including covering or temporarily removing any window coverings so as to guard against dust, debris or damage.

17.13.Tenant shall require its contractors and subcontractors performing work on the Premises to name Landlord and its affiliates and Lenders as additional insureds on their respective insurance policies.

 

 

29

 


17.14.Notwithstanding anything to the contrary in this Lease, Landlord and Tenant agree that Landlord shall be permitted to withhold its approval (in its sole and absolute discretion) of any Alteration that converts (office to lab or lab to office, as applicable) the office and lab zones identified on Exhibit A-1 attached hereto.

18.Repairs and Maintenance.

18.1.Landlord shall repair and maintain the structural and exterior portions and Common Area of the Building and the Project, including roofing and covering materials; foundations (excluding any architectural slabs, but including any structural slabs); exterior walls; plumbing; fire sprinkler systems (if any); base Building HVAC systems; the HVAC system located within the Premises up to the first damper or isolation valve that serves the Premises (for purposes of clarity, the portion of the HVAC system that includes such first damper or isolation valve and extends into and through the Premises, including any distribution systems and any supplemental HVAC serving the Premises shall be Tenant’s obligation to maintain and repair pursuant to Section 18.2 hereof); elevators; and base Building electrical systems installed or furnished by Landlord.    

18.2.Except for services of Landlord, if any, required by Section 18.1, Tenant shall at Tenant’s sole cost and expense maintain and keep the Premises (including but not limited to any systems or equipment exclusively serving the Premises, but excluding the base Building HVAC systems up to the first damper or isolation valve that extends into and serves the Premises) and every part thereof in good condition and repair, damage thereto from ordinary wear and tear excepted, and shall, within ten (10) business days after receipt of written notice from Landlord, provide to Landlord any maintenance records that Landlord reasonably requests.  Tenant shall, upon the expiration or sooner termination of the Term, surrender the Premises to Landlord in as good a condition as existed when the Tenant Improvements are finally completed by Landlord, and with respect to Alterations, in substantially the same condition as existed on the date such Alterations are substantially completed by Tenant, ordinary wear and tear excepted.  Landlord shall have no obligation to alter, remodel, improve, repair, decorate or paint the Premises or any part thereof, other than pursuant to the terms and provisions of the Work Letter.

18.3.Landlord shall not be liable for any failure to make any repairs or to perform any maintenance that is Landlord’s obligation pursuant to this Lease unless such failure shall persist for an unreasonable time after Tenant provides Landlord with written notice of the need of such repairs or maintenance.  Except as otherwise set forth in Section 31.12, Tenant waives its rights under Applicable Laws now or hereafter in effect to make repairs at Landlord’s expense.

18.4.If any excavation shall be made upon land adjacent to or under the Building, or shall be authorized to be made, Tenant shall afford to the person causing or authorized to cause such excavation, license to enter the Premises for the purpose of performing such work as such person shall deem necessary or desirable to preserve and protect the Building from injury or damage and to support the same by proper foundations, without any claim for damages or liability against Landlord and without reducing or otherwise affecting Tenant’s obligations under this Lease.

 

 

30

 


18.5.This Article relates to repairs and maintenance arising in the ordinary course of operation of the Building and the Project.  In the event of a casualty described in Article 24, Article 24 shall apply in lieu of this Article.  In the event of eminent domain, Article 25 shall apply in lieu of this Article.

18.6.Costs incurred by Landlord pursuant to this Article shall constitute Operating Expenses, subject to the limitations on inclusion of certain costs associated with capital expenditures, as set forth in Section 9.1(c).

19.Liens.

19.1.Subject to the immediately succeeding sentence, Tenant shall keep the Premises, the Building and the Project free from any liens arising out of work or services performed, materials furnished to or obligations incurred by Tenant.  Tenant further covenants and agrees that any mechanic’s or materialman’s lien filed against the Premises, the Building or the Project for work or services claimed to have been done for, or materials claimed to have been furnished to, or obligations incurred by Tenant shall be discharged or bonded by Tenant within ten (10) days after the filing thereof, at Tenant’s sole cost and expense.

19.2.Should Tenant fail to discharge or bond against any lien of the nature described in Section 19.1, Landlord may, at Landlord’s election, pay such claim or post a statutory lien bond or otherwise provide security to eliminate the lien as a claim against title, and Tenant shall immediately reimburse Landlord for the actual costs thereof as Additional Rent.  Tenant shall Indemnify the Landlord Indemnitees from and against any Claims arising from any such liens, including any administrative, court or other legal proceedings related to such liens.

19.3.In the event that Tenant leases or finances the acquisition of office equipment, furnishings or other personal property of a removable nature utilized by Tenant in the operation of Tenant’s business, Tenant warrants that any Uniform Commercial Code financing statement shall, upon its face or by exhibit thereto, indicate that such financing statement is applicable only to removable personal property of Tenant located within the Premises.  In no event shall the address of the Premises, the Building or the Project be furnished on a financing statement without qualifying language as to applicability of the lien only to removable personal property located in an identified suite leased by Tenant.  Should any holder of a financing statement record or place of record a financing statement that appears to constitute a lien against any interest of Landlord or against equipment that may be located other than within an identified suite leased by Tenant, Tenant shall, within ten (10) days after filing such financing statement, cause (a) a copy of the lender security agreement or other documents to which the financing statement pertains to be furnished to Landlord to facilitate Landlord’s ability to demonstrate that the lien of such financing statement is not applicable to Landlord’s interest and (b) Tenant’s lender to amend such financing statement and any other documents of record to clarify that any liens imposed thereby are not applicable to any interest of Landlord in the Premises, the Building or the Project. If requested by Tenant or its lender, Landlord will agree to deliver a written statement to such lender providing that this Lease does not grant to Landlord a security interest in Tenant’s personal property.

 

 

31

 


20.Estoppel Certificate.  Tenant shall, within ten (10) business days after receipt of written notice from Landlord, execute, acknowledge and deliver a statement in writing substantially in the form attached to this Lease as Exhibit I, or on any other form reasonably requested by a current or proposed Lender or encumbrancer or proposed purchaser, (a) certifying that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this Lease as so modified is in full force and effect) and the dates to which rental and other charges are paid in advance, if any, (b) acknowledging that there are not, to Tenant’s knowledge, any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (c) setting forth such further information with respect to this Lease or the Premises as may be reasonably requested thereon.  Any such statements may be relied upon by any prospective purchaser or encumbrancer of all or any portion of the Property.  Tenant’s failure to deliver any such statement within the prescribed time shall, at Landlord’s option, constitute a Default (as defined below) under this Lease, and, in any event, shall be binding upon Tenant that the Lease is in full force and effect and without modification except as may be represented by Landlord in any certificate prepared by Landlord and delivered to Tenant for execution.

21.Hazardous Materials.

21.1.Tenant shall not cause or permit any Hazardous Materials (as defined below) to be brought upon, kept or used in or about the Premises, the Building or the Project in violation of Applicable Laws by Tenant or any of its employees, agents, contractors or invitees (collectively with Tenant, each a “Tenant Party”).  If (a) Tenant breaches such obligation, (b) the presence of Hazardous Materials as a result of such a breach results in contamination of the Project, any portion thereof, or any adjacent property, (c) contamination of the Premises otherwise occurs during the Term or any extension or renewal hereof or holding over hereunder (other than if such contamination results from (i) migration of Hazardous Materials from outside the Premises not caused by a Tenant Party or (ii) to the extent such contamination is caused by Landlord’s gross negligence or willful misconduct) or (d) contamination of the Project occurs as a result of Hazardous Materials that are placed on or under or are released into the Project by a Tenant Party, then Tenant shall Indemnify the Landlord Indemnitees from and against any and all Claims of any kind or nature, including (w) diminution in value of the Project or any portion thereof, (x) damages for the loss or restriction on use of rentable or usable space or of any amenity of the Project, (y) damages arising from any adverse impact on marketing of space in the Project or any portion thereof and (z) sums paid in settlement of Claims that arise before, during or after the Term as a result of such breach or contamination.  This Indemnification by Tenant includes costs incurred in connection with any investigation of site conditions or any clean-up, remedial, removal or restoration work required by any Governmental Authority because of Hazardous Materials present in the air, soil or groundwater above, on, under or about the Project.  Without limiting the foregoing, if the presence of any Hazardous Materials in, on, under or about the Project, any portion thereof or any adjacent property caused or permitted by any Tenant Party results in any contamination of the Project, any portion thereof or any adjacent property, then Tenant shall promptly take all actions at its sole cost and expense as are necessary to return the Project, any portion thereof or any adjacent property to its respective condition existing prior to the time of such contamination; provided that Landlord’s written approval of such action shall

 

 

32

 


first be obtained, which approval Landlord shall not unreasonably withhold or delay; and provided, further, that it shall be reasonable for Landlord to withhold its consent if such actions could have a material adverse long-term or short-term effect on the Project, any portion thereof or any adjacent property.  Tenant’s obligations under this Section shall not be affected, reduced or limited by any limitation on the amount or type of damages, compensation or benefits payable by or for Tenant under workers’ compensation acts, disability benefit acts, employee benefit acts or similar legislation.

21.2.Landlord acknowledges that it is not the intent of this Article to prohibit Tenant from operating its business for the Permitted Use.  Tenant may operate its business according to the custom of Tenant’s industry so long as the use or presence of Hazardous Materials is strictly and properly monitored in accordance with Applicable Laws.  As a material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees to deliver to Landlord (a) a list identifying each type of Hazardous Material to be present at the Premises that is subject to regulation under any environmental Applicable Laws in the form of a Tier II form pursuant to Section 312 of the Emergency Planning and Community Right-to-Know Act of 1986 (or any successor statute) or any other form reasonably requested by Landlord, (b) a list of any and all approvals or permits from Governmental Authorities required in connection with the presence of such Hazardous Material at the Premises and (c) correct and complete copies of (i) notices of violations of Applicable Laws related to Hazardous Materials and (ii) plans relating to the installation of any storage tanks to be installed in, on, under or about the Project (provided that installation of storage tanks shall only be permitted after Landlord has given Tenant its written consent to do so, which consent Landlord may withhold in its sole and absolute discretion) and closure plans or any other documents required by any and all Governmental Authorities for any storage tanks installed in, on, under or about the Project for the closure of any such storage tanks (collectively, “Hazardous Materials Documents”).  Tenant shall deliver to Landlord updated Hazardous Materials Documents, within fourteen (14) days after receipt of a written request therefor from Landlord, not more often than once per year, unless (m) there are any changes to the Hazardous Materials Documents or (n) Tenant initiates any Alterations or changes its business, in either case in a way that involves any material increase in the types or amounts of Hazardous Materials, in which case Tenant shall deliver updated Hazardous Materials documents (without Landlord having to request them) before or, if not practicable to do so before, as soon as reasonably practicable after the occurrence of the events in Subsection 21.2(m) or (n).  For each type of Hazardous Material listed, the Hazardous Materials Documents shall include (t) the chemical name, (u) the material state (e.g., solid, liquid, gas or cryogen), (v) the concentration, (w) the storage amount and storage condition (e.g., in cabinets or not in cabinets), (x) the use amount and use condition (e.g., open use or closed use), (y) the location (e.g., room number or other identification) and (z) if known, the chemical abstract service number.  Notwithstanding anything in this Section to the contrary, Tenant shall not be required to provide Landlord with any documents containing information of a proprietary nature, unless such documents contain a reference to Hazardous Materials or activities related to Hazardous Materials.  Landlord may, at Landlord’s expense, cause the Hazardous Materials Documents to be reviewed by a person or firm qualified to analyze Hazardous Materials to confirm compliance with the provisions of this Lease and with Applicable Laws.  In the event that a review of the Hazardous Materials Documents indicates non-compliance with this Lease or

 

 

33

 


Applicable Laws, Tenant shall, at its expense, diligently take steps to bring its storage and use of Hazardous Materials into compliance.  Notwithstanding anything in this Lease to the contrary or Landlord’s review into Tenant’s Hazardous Materials Documents or use or disposal of hazardous materials, however, Landlord shall not have and expressly disclaims any liability related to Tenant’s or other tenants’ use or disposal of Hazardous Materials, it being acknowledged by Tenant that Tenant is best suited to evaluate the safety and efficacy of its Hazardous Materials usage and procedures.

21.3.Tenant represents and warrants to Landlord that is not nor has it been, in connection with the use, disposal or storage of Hazardous Materials, (a) subject to a material enforcement order issued by any Governmental Authority or (b) required to take any remedial action.

21.4.At any time, and from time to time,  prior to the expiration of the Term, Landlord shall have the right to conduct appropriate tests of the Project or any portion thereof to demonstrate that Hazardous Materials are present or that contamination has occurred due to the acts or omissions of a Tenant Party.  Tenant shall pay all reasonable costs of such tests if such tests reveal that Hazardous Materials exist at the Project in violation of this Lease.

21.5.If underground or other storage tanks storing Hazardous Materials installed or utilized by Tenant are located on the Premises, or are hereafter placed on the Premises by Tenant (or by any other party, if such storage tanks are utilized by Tenant), then Tenant shall monitor the storage tanks, maintain appropriate records, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other steps necessary or required under the Applicable Laws.  Tenant shall have no responsibility or liability for underground or other storage tanks installed by anyone other than Tenant unless Tenant utilizes such tanks, in which case Tenant’s responsibility for such tanks shall be as set forth in this Section.

21.6.Tenant shall promptly report to Landlord any actual or suspected presence of mold or water intrusion at the Premises.

21.7.Tenant’s obligations under this Article shall survive the expiration or earlier termination of the Lease.  During any period of time needed by Tenant or Landlord after the termination of this Lease to complete the removal from the Premises of any such Hazardous Materials for which Tenant is responsible under this Lease, Tenant shall be deemed a holdover tenant and subject to the provisions of Article 27.

21.8.As used herein, the term “Hazardous Material” means any toxic, explosive, corrosive, flammable, infectious, radioactive, carcinogenic, mutagenic or otherwise hazardous substance, material or waste that is or becomes regulated by Applicable Laws or any Governmental Authority.

21.9.Notwithstanding anything to the contrary in this Lease, Landlord shall have sole control over the equitable allocation of fire control areas (as defined in the Uniform Building Code as adopted by the city or municipality(ies) in which the Project is located (the “UBC”)) within the Project for the storage of Hazardous Materials.  Notwithstanding anything to the

 

 

34

 


contrary in this Lease, the quantity of Hazardous Materials allowed by this Section is specific to Tenant and shall not run with the Lease in the event of a Transfer (as defined in Article 29).  In the event of a Transfer, if the use of  Hazardous Materials by such new tenant (“New Tenant”) is such that New Tenant utilizes fire control areas in the Project in excess of New Tenant’s Pro Rata Share of the Building or the Project, as applicable, then New Tenant shall, at its sole cost and expense and upon Landlord’s written request, establish and maintain a separate area of the Premises classified by the UBC as an “H” occupancy area for the use and storage of Hazardous Materials, or take such other action as is necessary to ensure that its share of the fire control areas of the Building and the Project is not greater than New Tenant’s Pro Rata Share of the Building or the Project, as applicable.  Notwithstanding anything in this Lease to the contrary, Landlord shall not have and expressly disclaims any liability related to Tenant’s or other tenants’ use or disposal of fire control areas, it being acknowledged by Tenant that Tenant and other tenants are best suited to evaluate the safety and efficacy of its Hazardous Materials usage and procedures.

22.Odors and Exhaust.  Tenant acknowledges that Landlord would not enter into this Lease with Tenant unless Tenant assured Landlord that under no circumstances will any other occupants of the Building or the Project (including persons legally present in any outdoor areas of the Project) be subjected to odors or fumes (whether or not noxious), and that the Building and the Project will not be damaged by any exhaust, in each case from Tenant’s operations.  Landlord and Tenant therefore agree as follows:

22.1.Tenant shall not cause or permit (or conduct any activities that would cause) any release of any odors or fumes of any kind from the Premises.

22.2.If the Building has a ventilation system that, in Landlord’s judgment, is adequate, suitable, and appropriate to vent the Premises in a manner that does not release odors affecting any indoor or outdoor part of the Project, Tenant shall vent the Premises through such system.  If Landlord at any time determines that any existing ventilation system is inadequate, or if no ventilation system exists, Tenant shall, in compliance with Applicable Laws, vent all fumes and odors from the Premises (and remove odors from Tenant’s exhaust stream) as Landlord requires.  The placement and configuration of all ventilation exhaust pipes, louvers and other equipment shall be subject to Landlord’s approval.  Tenant acknowledges Landlord’s legitimate desire to maintain the Project (indoor and outdoor areas) in an odor-free manner, and Landlord may require Tenant, consistent with Landlord’s non-discriminatory requirements for the Building, to abate and remove all odors in a manner that goes beyond the requirements of Applicable Laws.

22.3.Tenant shall, at Tenant’s sole cost and expense, provide odor eliminators and other devices (such as filters, air cleaners, scrubbers and whatever other equipment may in Landlord’s judgment be necessary or appropriate from time to time) to completely remove, eliminate and abate any odors, fumes or other substances in Tenant’s exhaust stream that, in Landlord’s judgment, emanate from Tenant’s Premises.  Any work Tenant performs under this Section shall constitute Alterations.

 

 

35

 


22.4.Tenant’s responsibility to remove, eliminate and abate odors, fumes and exhaust shall continue throughout the Term.  Landlord’s construction of the Tenant Improvements shall not preclude Landlord from requiring additional measures to eliminate odors, fumes and other adverse impacts of Tenant’s exhaust stream (as Landlord may reasonably designate in Landlord’s discretion).  Tenant shall install additional equipment as Landlord reasonably requires from time to time under the preceding sentence.  Such installations shall constitute Alterations. Tenant shall have no obligation or liabilities for odors, fumes or exhaust arising or emanating from portions of the Project that are not the Premises unless arising from the actions or omissions of Tenant or another Tenant Party.

22.5.If Tenant fails to install satisfactory odor control equipment within ten (10) business days after Landlord’s demand made at any time, then Landlord may, without limiting Landlord’s other rights and remedies, require Tenant to cease and suspend any operations in the Premises that, in Landlord’s reasonable determination, cause odors, fumes or exhaust.  For the purpose of the immediately foregoing sentence, Landlord’s determination shall be “reasonable” if Landlord has received a complaint regarding such odors, fumes or exhaust.  For example, if Landlord determines that Tenant’s production of a certain type of product causes odors, fumes or exhaust, and Tenant does not install satisfactory odor control equipment within ten (10) business days after Landlord’s request, then Landlord may require Tenant to stop producing such type of product in the Premises unless and until Tenant has installed odor control equipment satisfactory to Landlord.

23.Insurance.

23.1.Landlord shall maintain insurance for the Building and the Project in amounts equal to full replacement cost (exclusive of the costs of excavation, foundations and footings, engineering costs or such other costs to the extent the same are not incurred in the event of a rebuild and without reference to depreciation taken by Landlord upon its books or tax returns) or such lesser coverage as Landlord may elect, provided that such coverage shall not be less than the amount of such insurance Landlord’s Lender, if any, requires Landlord to maintain, providing protection against any peril generally included within the classification “Fire and Extended Coverage,” together with insurance against sprinkler damage (if applicable), vandalism and malicious mischief.  Landlord, subject to availability thereof, shall further insure, if Landlord deems it appropriate, coverage against flood, environmental hazard, earthquake, loss or failure of building equipment, rental loss during the period of repairs or rebuilding, Workers’ Compensation insurance and fidelity bonds for employees employed to perform services.  Notwithstanding the foregoing, Landlord may, but shall not be deemed required to, provide insurance for any improvements installed by Tenant or that are in addition to the standard improvements customarily furnished by Landlord, without regard to whether or not such are made a part of or are affixed to the Building.

23.2.In addition, Landlord shall carry Commercial General Liability insurance with combined single limits of not less than Five Million Dollars ($5,000,000) per occurrence/general aggregate for bodily injury (including death), or property damage with respect to the Project, written on an occurrence basis.

 

 

36

 


23.3.Tenant shall, at its own cost and expense, procure and maintain during the Term the following insurance for the benefit of Tenant and Landlord (as their interests may appear) with insurers financially acceptable and lawfully authorized to do business in the state where the Premises are located:

(a)Commercial General Liability insurance on a broad-based occurrence coverage form, with coverages including but not limited to bodily injury (including death), property damage (including loss of use resulting therefrom), premises/operations, personal & advertising injury, and contractual liability with limits of liability of not less than $2,000,000 for bodily injury and property damage per occurrence, $2,000,000 general aggregate, which limits may be met by use of excess and/or umbrella liability insurance provided that such coverage is at least as broad as the primary coverages required herein.

(b)Commercial Automobile Liability insurance covering liability arising from the use or operation of any auto, including those owned, hired or otherwise operated or used by or on behalf of the Tenant.  The coverage shall be on a broad-based occurrence form with combined single limits of not less than $1,000,000 per accident for bodily injury and property damage.

(c)Commercial Property insurance covering property damage to the full replacement cost value and business interruption.  Covered property shall include all tenant improvements in the Premises (to the extent not insured by Landlord pursuant to Section 23.1) and Tenant’s Property including personal property, furniture, fixtures, machinery, equipment, stock, inventory and improvements and betterments, which may be owned by Tenant or Landlord and required to be insured hereunder, or which may be leased, rented, borrowed or in the care custody or control of Tenant, or Tenant’s agents, employees or subcontractors.  Such insurance, with respect only to all Tenant Improvements, Alterations or other work performed on the Premises by Tenant (collectively, “Tenant Work”), shall name Landlord and Landlord’s current and future mortgagees as loss payees as their interests may appear.  Such insurance shall be written on an “all risk” of physical loss or damage basis including the perils of fire, extended coverage, electrical injury, mechanical breakdown, windstorm, vandalism, malicious mischief, sprinkler leakage, back-up of sewers or drains, flood, earthquake, terrorism and such other risks Landlord may from time to time designate, for the full replacement cost value of the covered items with an agreed amount endorsement with no co-insurance.  Business interruption coverage shall have limits sufficient to cover Tenant’s lost profits and necessary continuing expenses, including rents due Landlord under the Lease.  The minimum period of indemnity for business interruption coverage shall be twelve (12) months plus twelve (12) months’ extended period of indemnity.

(d)Workers’ Compensation insurance as is required by statute or law, or as may be available on a voluntary basis and Employers’ Liability insurance with limits of not less than the following:  each accident, Five Hundred Thousand Dollars ($500,000); disease ($500,000); disease (each employee), Five Hundred Thousand Dollars ($500,000).

 

 

37

 


(e)Medical malpractice insurance at limits of not less than $1,000,000 each claim during such periods, if any, that Tenant engages in the practice of medicine at the Premises or conducts clinical human trials at the Premises, or counsels or provides medical services to human patients at the Premises.

(f)Pollution Legal Liability insurance is required if Tenant stores, handles, generates or treats Hazardous Materials, as determined solely by Landlord, on or about the Premises.  Such coverage shall include bodily injury, sickness, disease, death or mental anguish or shock sustained by any person; property damage including physical injury to or destruction of tangible property including the resulting loss of use thereof, clean-up costs, and the loss of use of tangible property that has not been physically injured or destroyed; and defense costs, charges and expenses incurred in the investigation, adjustment or defense of claims for such compensatory damages.  Coverage shall apply to both sudden and non-sudden pollution conditions including the discharge, dispersal, release or escape of smoke, vapors, soot, fumes, acids, alkalis, toxic chemicals, liquids or gases, waste materials or other irritants, contaminants or pollutants into or upon land, the atmosphere or any watercourse or body of water.  Claims-made coverage is permitted, provided the policy retroactive date is continuously maintained prior to the commencement date of this agreement, and coverage is continuously maintained during all periods in which Tenant occupies the Premises.  Coverage shall be maintained with limits of not less than $1,000,000 per incident with a $2,000,000 policy aggregate and for a period of two (2) years thereafter.

(g)During all construction by Tenant at the Premises, with respect to tenant improvements being constructed (including the Tenant Improvements and any Alterations, insurance required in Exhibit B-1 must be in place.

23.4.The insurance required of Tenant by this Article shall be with companies at all times having a current rating of not less than A- and financial category rating of at least Class VII in “A.M. Best’s Insurance Guide” current edition.  Tenant shall obtain for Landlord from the insurance companies/broker or cause the insurance companies/broker to furnish certificates of insurance evidencing all coverages required herein to Landlord.  Landlord reserves the right to require complete, certified copies of all required insurance policies including any endorsements.  No such policy shall be cancelable or subject to reduction of coverage or other modification or cancellation except after twenty (20) days’ prior written notice to Landlord from Tenant or its insurers (except in the event of non-payment of premium, in which case ten (10) days’ written notice shall be given).  All such policies shall be written as primary policies, not contributing with and not in excess of the coverage that Landlord may carry.  Tenant’s required policies shall contain severability of interests clauses stating that, except with respect to limits of insurance, coverage shall apply separately to each insured or additional insured.  Tenant shall, at least twenty-five (25) days prior to the expiration of such policies, furnish Landlord with renewal certificates of insurance or binders.  Tenant agrees that if Tenant does not take out and maintain such insurance and such failure continues for five (5) business days after written notice to Tenant, Landlord may (but shall not be required to) procure such insurance on Tenant’s behalf and at its cost to be paid by Tenant as Additional Rent.  Commercial General Liability, Commercial Automobile Liability, Umbrella Liability and Pollution Legal Liability insurance as

 

 

38

 


required above shall name Landlord, BioMed Realty, L.P., and BRE Edison Parent L.P., and their respective officers, employees, agents, general partners, members, subsidiaries, affiliates and Lenders (“Landlord Parties”) as additional insureds as respects liability arising from work or operations performed by or on behalf of Tenant, Tenant’s use or occupancy of Premises, and ownership, maintenance or use of vehicles by or on behalf of Tenant.

23.5.In each instance where insurance is to name Landlord Parties as additional insureds, Tenant shall, upon Landlord’s written request, also designate and furnish certificates evidencing such Landlord Parties as additional insureds to (a) any Lender of Landlord holding a security interest in the Building or the Project, (b) the landlord under any lease whereunder Landlord is a tenant of the real property upon which the Building is located if the interest of Landlord is or shall become that of a tenant under a ground lease rather than that of a fee owner and (c) any management company retained by Landlord to manage the Project. No such additional insured coverage shall protect or insure against loss arising from the negligence or wrongful act or omission of an additional insured.

23.6.Subject to Section 23.7 below, Tenant assumes the risk of damage to any fixtures, goods, inventory, merchandise, equipment and leasehold improvements, and Landlord shall not be liable for injury to Tenant’s business or any loss of income therefrom, relative to such damage, all as more particularly set forth within this Lease.  Tenant shall, at Tenant’s sole cost and expense, carry such insurance as Tenant desires for Tenant’s protection with respect to personal property of Tenant or business interruption.

23.7.Each of Landlord and Tenant, for itself and on behalf of such party’s insurers, hereby waive any and all rights of recovery or subrogation against the other and the officers, directors, employees, agents and representatives of the other with respect to any loss, damage, claims, suits or demands, howsoever caused, that are covered, or should have been covered as required under the Lease, by valid and collectible insurance, including any deductibles or self-insurance maintained thereunder.  If necessary, each of Landlord and Tenant agrees to endorse the required insurance policies to permit waivers of subrogation as required hereunder and hold harmless and indemnify the parties entitled to indemnification as provided above for any loss or expense incurred as a result of a failure to obtain such waivers of subrogation from insurers.  Such waivers shall continue so long as Landlord’s and Tenant’s respective insurers so permit.  Any termination of such a waiver shall be by written notice to the other party, containing a description of the circumstances hereinafter set forth in this Section.  Each of Landlord and Tenant, upon obtaining the policies of insurance required or permitted under this Lease, shall give notice to their respective insurance carriers that the foregoing waiver of subrogation is contained in this Lease.  If such policies shall not be obtainable with such waiver or shall be so obtainable only at a premium over that chargeable without such waiver, then the party seeking such policy shall notify the other of such conditions, and the party so notified shall have ten (10) business days thereafter to either (a) procure such insurance with companies reasonably satisfactory to the other party or (b) agree to pay such additional premium (in Tenant’s case, in the proportion that the area of the Premises bears to the insured area).  If the parties do not accomplish either (a) or (b), then this Section shall have no effect during such time as such policies shall not be obtainable or the party in whose favor a waiver of subrogation is desired

 

 

39

 


refuses to pay the additional premium.  If the release of either Landlord or Tenant, as set forth in the first sentence of this Section, shall contravene Applicable Laws, then the liability of the party in question shall be deemed not released but shall be secondary to the liability of the other party’s insurer.

23.8.Landlord may require insurance policy limits required under this Lease to be raised to conform with requirements of Landlord’s Lender or to bring coverage limits to levels then being required of new tenants within the Project.

23.9.Any costs incurred by Landlord pursuant to this Article shall constitute a portion of Operating Expenses.

23.10.The provisions of this Article 23 shall survive the expiration or earlier termination of this Lease.

24.Damage or Destruction

.

24.1.In the event of a partial destruction of (a) the Premises or (b) the Common Area of the Building or the Project ((a) and (b) together, the “Affected Areas”) by fire or other perils covered by extended coverage insurance not exceeding twenty-five percent (25%) of the full insurable value thereof, and provided that (w) the damage thereto is such that the Affected Areas may be repaired, reconstructed or restored within a period of twelve (12 months from the date of the happening of such casualty, (x) Landlord shall receive insurance proceeds from its insurer or Lender sufficient to cover the cost of such repairs, reconstruction and restoration (except for any deductible amount provided by Landlord’s policy, which deductible amount, if paid by Landlord, shall constitute an Operating Expense), (y) the repair, reconstruction or restoration of the Affected Areas is permitted by all applicable Loan Documents or otherwise consented to by any and all Lenders whose consent is required thereunder, and (z) such casualty was not intentionally caused by a Tenant Party, then Landlord shall commence and proceed diligently with the work of repair, reconstruction and restoration of the Affected Areas (including all Tenant Improvements) and this Lease shall continue in full force and effect.

24.2.In the event of any damage to or destruction of the Building or the Project other than as described in Section 24.1, Landlord may elect to repair, reconstruct and restore the Building or the Project, as applicable, in which case this Lease shall continue in full force and effect.  If Landlord elects not to repair, reconstruct and restore the Building or the Project, as applicable, then this Lease shall terminate as of the date of such damage or destruction.  In the event of any damage or destruction (regardless of whether such damage is governed by Section 24.1 or this Section), if (a) in Landlord’s determination as set forth in the Damage Repair Estimate (as defined below), the Affected Areas cannot be repaired, reconstructed or restored within twelve (12) months after the date of the Damage Repair Estimate, (b) subject to Section 24.6, the Affected Areas are not actually repaired, reconstructed and restored within eighteen (18) months after the date of the Damage Repair Estimate, or (c) the damage and destruction occurs within the last twelve (12) months of the then-current Term, then Tenant shall have the right to terminate this Lease, effective as of the date of such damage or destruction, by delivering to Landlord its written notice of termination (a “Termination Notice”) (y) with respect to

 

 

40

 


Subsections 24.2(a) and (c), no later than fifteen (15) days after Landlord delivers to Tenant Landlord’s Damage Repair Estimate and (z) with respect to Subsection 24.2(b), no later than fifteen (15) days after such twelve (12) month period (as the same may be extended pursuant to Section 24.6) expires.  If Tenant provides Landlord with a Termination Notice pursuant to Subsection 24.2(z), Landlord shall have an additional thirty (30) days after receipt of such Termination Notice to complete the repair, reconstruction and restoration.  If Landlord does not complete such repair, reconstruction and restoration within such thirty (30) day period, then Tenant may terminate this Lease by giving Landlord written notice within two (2) business days after the expiration of such thirty (30) day period.  If Landlord does complete such repair, reconstruction and restoration within such thirty (30) day period, then this Lease shall continue in full force and effect.

24.3.As soon as reasonably practicable, but in any event within sixty (60) days following the date of damage or destruction, Landlord shall notify Tenant of Landlord’s good faith estimate of the period of time in which the repairs, reconstruction and restoration will be completed (the “Damage Repair Estimate”), which estimate shall be based upon the opinion of a contractor reasonably selected by Landlord and experienced in comparable repair, reconstruction and restoration of similar buildings.  Additionally, Landlord shall give written notice to Tenant within sixty (60) days following the date of damage or destruction of its election not to repair, reconstruct or restore the Building or the Project, as applicable.  

24.4.Upon any termination of this Lease under any of the provisions of this Article, the parties shall be released thereby without further obligation to the other from the date possession of the Premises is surrendered to Landlord, except with regard to (a) items occurring prior to the damage or destruction and (b) provisions of this Lease that, by their express terms, survive the expiration or earlier termination hereof.

24.5.In the event of repair, reconstruction and restoration as provided in this Article, all Rent to be paid by Tenant under this Lease shall be abated proportionately based on the extent to which Tenant’s use of the Premises is impaired during the period of such repair, reconstruction or restoration, unless Landlord provides Tenant with other space during the period of repair, reconstruction and restoration that, in Tenant’s reasonable opinion, is suitable for the temporary conduct of Tenant’s business; provided, however, that the amount of such abatement shall be reduced by the amount of Rent that is received by Tenant as part of the business interruption or loss of rental income with respect to the Premises from the proceeds of business interruption or loss of rental income insurance.

24.6.Notwithstanding anything to the contrary contained in this Article, (a) Landlord shall not be required to repair, reconstruct or restore any damage or destruction to the extent that  Landlord is prohibited from doing so by any applicable Loan Document or any Lender whose consent is required thereunder withholds its consent, and (b) should Landlord be delayed or prevented from completing the repair, reconstruction or restoration of the damage or destruction to the Premises after the occurrence of such damage or destruction by Force Majeure or delays caused by a Lender or Tenant Party, then the time for Landlord to commence or complete repairs, reconstruction and restoration shall be extended on a day-for-day basis; provided, however, that, at Landlord’s election, Landlord shall be relieved of its obligation to make such repairs, reconstruction and restoration.

 

 

41

 


24.7.If Landlord is obligated to or elects to repair, reconstruct or restore as herein provided, then Landlord shall be obligated to make such repairs, reconstruction or restoration only with regard to (a) those portions of the Premises that were originally provided at Landlord’s expense and (b) the Common Area portion of the Affected Areas.  The repairs, reconstruction or restoration of improvements not originally provided by Landlord or at Landlord’s expense shall be the obligation of Tenant.  In the event Tenant has elected to upgrade certain improvements from Landlord’s building standards (the “Building Standard”), Landlord shall, upon the need for replacement due to an insured loss, provide only the Building Standard, unless Tenant again elects to upgrade such improvements and pay any incremental costs related thereto, except to the extent that excess insurance proceeds, if received, are adequate to provide such upgrades, in addition to providing for basic repairs, reconstruction and restoration of the Premises, the Building and the Project.

24.8.Notwithstanding anything to the contrary contained in this Article, Landlord shall not have any obligation whatsoever to repair, reconstruct or restore the Premises if the damage resulting from any casualty covered under this Article occurs (a) during the thirteenth (13th) through the twenty-fourth (24th) months prior to the expiration of the Term and the Damage Repair Estimate indicates that more than six (6) months will be required for such repair, reconstruction or restoration, (b) during the seventh (7th) through twelfth (12th) months prior to the expiration of the Term and the Damage Repair Estimate indicates that more than thirty (30) days will be required for such repair, reconstruction or restoration, (c) during the last six (6) months of the Term or (d) to the extent that insurance proceeds are not available therefor.

24.9.Landlord’s obligation, should it elect or be obligated to repair, reconstruct or restore, shall be limited to the Affected Areas, and shall be conditioned upon Landlord receiving any permits or authorizations required by Applicable Laws.  Tenant shall, at its expense, replace or fully repair all of Tenant’s personal property and any Alterations installed by Tenant existing at the time of such damage or destruction.  If Affected Areas are to be repaired, reconstructed or restored in accordance with the foregoing, Landlord shall make available to Tenant any portion of insurance proceeds it receives that are allocable to the Alterations constructed by Tenant pursuant to this Lease; provided that Landlord shall not be required to do so while Tenant is in default under this Lease, and subject to the requirements of any Lender of Landlord.

24.10.This Article sets forth the terms and conditions upon which this Lease may terminate in the event of any damage or destruction.  Accordingly, the parties hereby waive the provisions of any Applicable Laws (and any successor statutes) permitting the parties to terminate this Lease as a result of any damage or destruction.

25.Eminent Domain.

25.1.In the event (a) the whole of all Affected Areas or (b) such part thereof as shall substantially interfere with Tenant’s use and occupancy of the Premises for the Permitted Use shall be taken for any public or quasi-public purpose by any lawful power or authority by exercise of the right of appropriation, condemnation or eminent domain, or sold to prevent such taking, Tenant or Landlord may terminate this Lease effective as of the date possession is required to be surrendered to such authority, except with regard to (y) items occurring prior to the taking and (z) provisions of this Lease that, by their express terms, survive the expiration or earlier termination hereof.

 

 

42

 


25.2.In the event of a partial taking of (a) the Building or the Project or (b) drives, walkways or parking areas serving the Building or the Project for any public or quasi-public purpose by any lawful power or authority by exercise of right of appropriation, condemnation, or eminent domain, or sold to prevent such taking, then, without regard to whether any portion of the Premises occupied by Tenant was so taken, Landlord may elect to terminate this Lease (except with regard to (y) items occurring prior to the taking and (z) provisions of this Lease that, by their express terms, survive the expiration or earlier termination hereof) as of such taking if such taking is, in Landlord’s sole opinion, of a material nature such as to make it uneconomical to continue use of the unappropriated portion for purposes of renting office or laboratory space.

25.3.To the extent permitted under all applicable Loan Documents or otherwise consented to by any and all Lenders whose consent is required thereunder, Tenant shall be entitled to any award that is specifically awarded as compensation for (a) the taking of Tenant’s personal property that was installed at Tenant’s expense and (b) the costs of Tenant moving to a new location.  Except as set forth in the previous sentence, any award for such taking shall be the property of Landlord.

25.4.If, upon any taking of the nature described in this Article, this Lease continues in effect, then Landlord shall promptly proceed to restore the Affected Areas to substantially their same condition prior to such partial taking.  To the extent such restoration is infeasible, as determined by Landlord in its sole and absolute discretion, the Rent shall be decreased proportionately to reflect the loss of any portion of the Premises no longer available to Tenant. Notwithstanding anything to the contrary contained in this Article, Landlord shall not be required to restore the Affected Areas to the extent that Landlord is prohibited from doing so by any applicable Loan Document or any Lender whose consent is required thereunder withholds its consent.

25.5.This Article sets forth the terms and conditions upon which this Lease may terminate in the event of any damage or destruction.  Accordingly, the parties hereby waive the provisions of any Applicable Laws (and any successor statutes) permitting the parties to terminate this Lease as a result of any damage or destruction.

26.Surrender.

26.1.At least thirty (30) days prior to Tenant’s surrender of possession of any part of the Premises, Tenant shall provide Landlord with a facility decommissioning and Hazardous Materials closure plan for the Premises (“Exit Survey”) prepared by an independent third party state-certified professional with appropriate expertise, which Exit Survey must be reasonably acceptable to Landlord. The Exit Survey shall comply with the American National Standards Institute’s Laboratory Decommissioning guidelines (ANSI/AIHA Z9.11-2008) or any successor standards published by ANSI or any successor organization (or, if ANSI and its successors no longer exist, a similar entity publishing similar standards).  In addition, at least ten (10) days prior to Tenant’s surrender of possession of any part of the Premises, Tenant shall (a) provide Landlord with written evidence of all appropriate governmental releases obtained by Tenant in accordance with Applicable Laws, including laws pertaining to the surrender of the Premises, (b)

 

 

43

 


place Laboratory Equipment Decontamination Forms on all decommissioned equipment to assure safe occupancy by future users and (c) conduct a site inspection with Landlord. In addition, Tenant agrees to remain responsible after the surrender of the Premises for the remediation of any recognized environmental conditions set forth in the Exit Survey and comply with any recommendations set forth in the Exit Survey.  Tenant’s obligations under this Section shall survive the expiration or earlier termination of the Lease.

26.2.No surrender of possession of any part of the Premises shall release Tenant from any of its obligations hereunder, unless such surrender is accepted in writing by Landlord.

26.3.The voluntary or other surrender of this Lease by Tenant shall not effect a merger with Landlord’s fee title or leasehold interest in the Premises, the Building, the Property or the Project, unless Landlord consents in writing, and shall, at Landlord’s option, operate as an assignment to Landlord of any or all subleases.

26.4.The voluntary or other surrender of any ground or other underlying lease that now exists or may hereafter be executed affecting the Building or the Project, or a mutual cancellation thereof or of Landlord’s interest therein by Landlord and its lessor shall not effect a merger with Landlord’s fee title or leasehold interest in the Premises, the Building or the Property and shall, at the option of the successor to Landlord’s interest in the Building or the Project, as applicable, operate as an assignment of this Lease.

27.Holding Over.

27.1.If, with Landlord’s prior written consent, Tenant holds possession of all or any part of the Premises after the Term, Tenant shall become a tenant from month to month after the expiration or earlier termination of the Term, and in such case Tenant shall continue to pay (a) Base Rent in accordance with Article 7, as adjusted in accordance with Article 8, and (b) any amounts for which Tenant would otherwise be liable under this Lease if the Lease were still in effect, including payments for Tenant’s Adjusted Share of Operating Expenses. Any such month-to-month tenancy shall be subject to every other term, covenant and agreement contained herein.

27.2.Notwithstanding the foregoing, if Tenant remains in possession of the Premises after the expiration or earlier termination of the Term without Landlord’s prior written consent, (a) Tenant shall become a tenant at sufferance subject to the terms and conditions of this Lease, except that the monthly rent shall be equal to one hundred fifty percent (150%) of the Rent in effect during the last thirty (30) days of the Term, and (b) if such holdover persists for more than thirty (30) days after the earlier of (i) the expiration or earlier termination of the Term and (ii) the date Landlord notifies Tenant that Landlord has procured a tenant that is ready, willing and able to sign a lease for the Premises (or a portion thereof), Tenant shall be liable to Landlord for any and all damages suffered by Landlord as a result of such holdover, including any lost rent or consequential, special and indirect damages (in each case, regardless of whether such damages are foreseeable).

27.3.Acceptance by Landlord of Rent after the expiration or earlier termination of the Term shall not result in an extension, renewal or reinstatement of this Lease.

 

 

44

 


27.4.The foregoing provisions of this Article are in addition to and do not affect Landlord’s right of reentry or any other rights of Landlord hereunder or as otherwise provided by Applicable Laws.

27.5.The provisions of this Article shall survive the expiration or earlier termination of this Lease.

28.Indemnification and Exculpation.

28.1.Tenant agrees to Indemnify the Landlord Indemnitees from and against any and all Claims of any kind or nature, real or alleged, arising from (a) injury to or death of any person or damage to any property occurring within or about the Premises, the Building, the Property or the Project, arising directly or indirectly out of (i) the presence at or use or occupancy of the Premises or Project by a Tenant Party, (ii) an act or omission on the part of any Tenant Party, (b) a breach or default by Tenant in the performance of any of its obligations hereunder (including any Claim asserted by any Lender against any Landlord Indemnitees under any Loan Document as a direct result of such breach or default by Tenant) or (c) injury to or death of persons or damage to or loss of any property, real or alleged, arising from the serving of alcoholic beverages at the Premises or Project, including liability under any dram shop law, host liquor law or similar Applicable Law, except to the extent directly caused by Landlord’s negligence or willful misconduct.  Tenant’s obligations under this Section shall not be affected, reduced or limited by any limitation on the amount or type of damages, compensation or benefits payable by or for Tenant under workers’ compensation acts, disability benefit acts, employee benefit acts or similar legislation. Tenant’s obligations under this Section shall survive the expiration or earlier termination of this Lease.  Subject to Sections 23.6, 28.2 and 31.12 and any subrogation provisions contained in the Work Letter, Landlord agrees to Indemnify the Tenant Parties from and against any and all Claims arising from injury to or death of any person or damage to or loss of any physical property occurring within or about the Premises, the Building, the Property or the Project to the extent directly arising out of Landlord’s gross negligence or willful misconduct.

28.2.Notwithstanding anything in this Lease to the contrary, Landlord shall not be liable to Tenant for and Tenant assumes all risk of (a) damage or losses arising from fire, electrical malfunction, gas explosion or water damage of any type (including broken water lines, malfunctioning fire sprinkler systems, roof leaks or stoppages of lines), unless any such loss is due to Landlord’s willful disregard of written notice by Tenant of need for a repair that Landlord is responsible to make for an unreasonable period of time, and (b) damage to personal property or scientific research, including loss of records kept by Tenant within the Premises (in each case, regardless of whether such damages are foreseeable).  Tenant further waives any claim for injury to Tenant’s business or loss of income relating to any such damage or destruction of personal property as described in this Section.  Notwithstanding anything in the foregoing or this Lease to the contrary, except (x) as otherwise provided herein (including Section 27.2), (y) as may be provided by Applicable Laws or (z) in the event of Tenant’s breach of Article 21 or Section 26.1, in no event shall Landlord or Tenant be liable to the other for any consequential, special or indirect damages arising out of this Lease, including lost profits (provided that this Subsection 28.2(z) shall not limit Tenant’s liability for Base Rent or Additional Rent pursuant to this Lease).

 

 

45

 


28.3.Landlord shall not be liable for any damages arising from any act, omission or neglect of any other tenant in the Building or the Project, or of any other third party.

28.4.Tenant acknowledges that security devices and services, if any, while intended to deter crime, may not in given instances prevent theft or other criminal acts.  Landlord shall not be liable for injuries or losses arising from criminal acts of third parties, and Tenant assumes the risk that any security device or service may malfunction or otherwise be circumvented by a criminal.  If Tenant desires protection against such criminal acts, then Tenant shall, at Tenant’s sole cost and expense, obtain appropriate insurance coverage.  Tenant’s security programs and equipment for the Premises shall be coordinated with Landlord and subject to Landlord’s reasonable approval.

28.5.The provisions of this Article shall survive the expiration or earlier termination of this Lease.

29.Assignment or Subletting.

29.1.Except as hereinafter expressly permitted, none of the following (each, a “Transfer”), either voluntarily or by operation of Applicable Laws, shall be directly or indirectly performed without Landlord’s prior written consent, which consent shall not be unreasonably withheld, conditioned or delayed:  (a) Tenant selling, hypothecating, assigning, pledging, encumbering or otherwise transferring this Lease or subletting the Premises or (b) a controlling interest in Tenant being sold, assigned or otherwise transferred (other than as a result of shares in Tenant being sold on a public stock exchange).  For purposes of the preceding sentence, “control” means (a) owning (directly or indirectly) more than fifty percent (50%) of the stock or other equity interests of another person or (b) possessing, directly or indirectly, the power to direct or cause the direction of the management and policies of such person.  Tenant shall have the right to Transfer, without Landlord’s prior written consent, Tenant’s interest in this Lease or the Premises or any part thereof to (i) any person that as of the date of determination and at all times thereafter directly, or indirectly through one or more intermediaries, controls, is controlled by or is under common control with Tenant (“Tenant’s Affiliate”) or (ii) any person or any entity with which Tenant is merged or to which all or substantially all of Tenant’s assets or all or substantially all of the ownership interests in Tenant are sold; provided that (in each instance under the foregoing clauses (i) and (ii)) Tenant shall notify Landlord in writing at least ten (10) business days prior to the effectiveness of such Transfer (an “Exempt Transfer” and otherwise comply with the requirements of this Lease regarding such Transfer; and provided, further, that the person that will be the tenant under this Lease after the Exempt Transfer has a net worth (as of both the day immediately prior to and the day immediately after the Exempt Transfer) that is equal to or greater than the net worth (as of both the Execution Date and the date of the Exempt Transfer) of the transferring Tenant.  For purposes of the immediately preceding sentence, “control” requires both (a) owning (directly or indirectly) more than fifty percent (50%) of the stock or other equity interests of another person and (b) possessing, directly or indirectly, the power to direct or cause the direction of the management and policies of such person.  In no event shall Tenant perform a Transfer (other than an Exempt Transfer) (a) to or with an entity that is a tenant at the Project or at property owned by Landlord or an affiliate of Landlord in

 

 

46

 


Cambridge, Massachusetts unless, upon Tenant’s written request, Landlord confirms in writing to Tenant that Landlord or such affiliate does not have available space at the Project or such other property of Landlord’s affiliate or (b) if the proposed transferee is in then-active discussions or negotiations with Landlord or an affiliate of Landlord as reasonably determined by Landlord after receipt of a  written request from Tenant for such determination.  Notwithstanding anything in this Lease to the contrary, if (a)  any proposed transferee, assignee or sublessee of Tenant has been required by any prior landlord, Lender or Governmental Authority to take material remedial action in connection with Hazardous Materials contaminating a property if the contamination resulted from such party’s action or omission or use of the property in question or (b) any proposed transferee, assignee or sublessee is subject to a material enforcement order issued by any Governmental Authority in connection with the use, disposal or storage of Hazardous Materials, then it shall not be unreasonable for Landlord to withhold its consent to any proposed transfer, assignment or subletting (with respect to any such matter involving a proposed transferee, assignee or sublessee).  

29.2.In the event Tenant desires to effect a Transfer, then, at least thirty (30) but not more than ninety (90) days prior  to the date when Tenant desires the Transfer to be effective (the “Transfer Date”), Tenant shall provide written notice to Landlord (the “Transfer Notice”) containing information (including references) concerning the character of the proposed transferee, assignee or sublessee; the Transfer Date; the most recent unconsolidated financial statements of Tenant and of the proposed transferee, assignee or sublessee satisfying the requirements of Section 40.2 (“Required Financials”); any ownership or commercial relationship between Tenant and the proposed transferee, assignee or sublessee; copies of Hazardous Materials Documents for the proposed transferee, assignee or sublessee; and the consideration and all other material terms and conditions of the proposed Transfer, all in such detail as Landlord shall reasonably require.  Without limiting any other factors that Landlord may consider in determining whether to withhold, condition or delay its consent to any Transfer in accordance with Section 29.1 of this Lease, Tenant hereby acknowledges and agrees that (a) if Tenant does not deliver to Landlord the most recent consolidated financial statements of Tenant (or if Tenant is not the ultimate parent company, the unconsolidated financial statements of Tenant) and the most recent unconsolidated financial statements of such proposed transferee, then it shall be reasonable for Landlord to withhold its consent to any Transfer to such proposed transferee, (b) if Landlord reasonably determines that the proposed Transfer will diminish the value of Landlord’s interest under this Lease, it shall be reasonable for Landlord to withhold its consent to any such Transfer and (c) if Landlord reasonably determines that such proposed Transferee’s financial condition is not satisfactory, it shall be reasonable for Landlord to condition its consent to any such Transfer upon the proposed transferee’s ultimate parent company providing a guaranty to Landlord of such transferee’s obligations under this Lease, in a form acceptable to Landlord, which guaranty shall be executed and delivered to Landlord by the applicable guarantor prior to the Transfer Date, or upon Tenant or the proposed transferee providing other credit enhancements acceptable to Landlord (including without limitation an increased Security Deposit).  For purposes of the immediately foregoing clause (c), such transferee’s financial condition will be deemed not satisfactory if Landlord determines that such transferee is not capable of satisfying all of the obligations of the Tenant under this Lease.

 

 

47

 


29.3.Landlord, in determining whether consent should be given to a proposed Transfer, may give consideration to (a) the financial strength of Tenant and of such transferee, assignee or sublessee (notwithstanding Tenant remaining liable for Tenant’s performance), (b) any change in use that such transferee, assignee or sublessee proposes to make in the use of the Premises and (c) Landlord’s desire to exercise its rights under Section 29.7 to cancel this Lease.  In no event shall Landlord be deemed to be unreasonable for declining to consent to a Transfer if any applicable Loan Document prohibits such assignment or any Lender whose consent is required thereunder withholds its consent, or if the Transfer is to a transferee, assignee or sublessee of poor reputation, lacking financial qualifications or seeking a change in the Permitted Use, or jeopardizing directly or indirectly the status of Landlord or any of Landlord’s affiliates as a Real Estate Investment Trust under the Internal Revenue Code of 1986 (as the same may be amended from time to time, the “Revenue Code”).  Notwithstanding anything contained in this Lease to the contrary, (w) no Transfer shall be consummated on any basis such that the rental or other amounts to be paid by the occupant, assignee, manager or other transferee thereunder would be based, in whole or in part, on the income or profits derived by the business activities of such occupant, assignee, manager or other transferee; (x) Tenant shall not furnish or render any services to an occupant, assignee, manager or other transferee with respect to whom transfer consideration is required to be paid, or manage or operate the Premises or any capital additions so transferred, with respect to which transfer consideration is being paid; (y) Tenant shall not consummate a Transfer with any person in which Landlord owns an interest, directly or indirectly (by applying constructive ownership rules set forth in Section 856(d)(5) of the Revenue Code); and (z) Tenant shall not consummate a Transfer with any person or in any manner that could cause any portion of the amounts received by Landlord pursuant to this Lease or any sublease, license or other arrangement for the right to use, occupy or possess any portion of the Premises to fail to qualify as “rents from real property” within the meaning of Section 856(d) of the Revenue Code, or any similar or successor provision thereto or which could cause any other income of Landlord to fail to qualify as income described in Section 856(c)(2) of the Revenue Code.

29.4.The following are conditions precedent to a Transfer or to Landlord considering a request by Tenant to a Transfer:

(a)Tenant shall remain fully liable under this Lease.  Tenant agrees that it shall not be (and shall not be deemed to be) a guarantor or surety of this Lease, however, and waives its right to claim that is it is a guarantor or surety or to raise in any legal proceeding any guarantor or surety defenses permitted by this Lease or by Applicable Laws;

(b)[Intentionally omitted];

(c)In the case of an Exempt Transfer, Tenant shall provide Landlord with evidence reasonably satisfactory to Landlord that the Transfer qualifies as an Exempt Transfer;

(d)Tenant shall provide Landlord with evidence reasonably satisfactory to Landlord that the value of Landlord’s interest under this Lease shall not be diminished or reduced by the proposed Transfer.  Such evidence shall include evidence respecting the relevant business experience and financial responsibility and status of the proposed transferee, assignee or sublessee;

 

 

48

 


(e)Tenant shall reimburse Landlord for Landlord’s actual costs and expenses, including reasonable attorneys’ fees, charges and disbursements incurred in connection with the review, processing and documentation of such request;

(f)Except with respect to an Exempt Transfer, if Tenant’s transfer of rights or sharing of the Premises provides for the receipt by, on behalf of or on account of Tenant of any consideration of any kind whatsoever (including a premium rental for a sublease or lump sum payment for an assignment, but excluding Tenant’s reasonable costs in marketing and subleasing the Premises) in excess of the rental and other charges due to Landlord under this Lease, Tenant shall pay fifty percent (50%) of all of such excess to Landlord, after making deductions for any reasonable marketing expenses, tenant improvement funds expended by Tenant, alterations, cash concessions, brokerage commissions, attorneys’ fees and free rent actually paid by Tenant.  If such consideration consists of cash paid to Tenant, payment to Landlord shall be made upon receipt by Tenant of such cash payment;

(g)The proposed transferee, assignee or sublessee shall agree that, in the event Landlord gives such proposed transferee, assignee or sublessee notice that Tenant is in default under this Lease, such proposed transferee, assignee or sublessee shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments shall be received by Landlord without any liability being incurred by Landlord, except to credit such payment against those due by Tenant under this Lease, and any such proposed transferee, assignee or sublessee shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided, however, that in no event shall Landlord or its Lenders, successors or assigns be obligated to accept such attornment;

(h)Landlord’s consent to any such Transfer shall be effected on Landlord’s forms, which shall be commercially reasonable;

(i)Tenant shall not then be in default of any monetary obligation or any material non-monetary obligation hereunder in any respect;

(j)Tenant shall not then be in default of any nonmaterial, nonmonetary obligation beyond any applicable notice and cure period;

(k)Such proposed transferee, assignee or sublessee’s use of the Premises shall be the same as the Permitted Use;

(l)Landlord shall not be bound by any provision of any agreement pertaining to the Transfer, except for Landlord’s written consent to the same;

(m)Tenant shall pay all transfer and other taxes (including interest and penalties) assessed or payable for any Transfer;

(n)Landlord’s consent (or waiver of its rights) for any Transfer shall not waive Landlord’s right to consent or refuse consent to any later Transfer;

 

 

49

 


(o)Tenant shall deliver to Landlord one executed copy of any and all written instruments evidencing or relating to the Transfer; and

(p)Tenant shall deliver to Landlord a list of Hazardous Materials (as defined below), certified by the proposed transferee, assignee or sublessee to be true and correct, that the proposed transferee, assignee or sublessee intends to use or store in the Premises.  Additionally, Tenant shall deliver to Landlord, on or before the date any proposed transferee, assignee or sublessee takes occupancy of the Premises, all of the items relating to Hazardous Materials of such proposed transferee, assignee or sublessee as described in Section 21.2.

29.5.Any Transfer that is not in compliance with the provisions of this Article or with respect to which Tenant does not fulfill its obligations pursuant to this Article shall be void and shall, at the option of Landlord, terminate this Lease.

29.6.Notwithstanding any Transfer, Tenant shall remain fully and primarily liable for the payment of all Rent and other sums due or to become due hereunder, and for the full performance of all other terms, conditions and covenants to be kept and performed by Tenant.  The acceptance of Rent or any other sum due hereunder, or the acceptance of performance of any other term, covenant or condition thereof, from any person or entity other than Tenant shall not be deemed a waiver of any of the provisions of this Lease or a consent to any Transfer.

29.7.If Tenant delivers to Landlord a Transfer Notice indicating a desire to transfer all or substantially all of the Premises and/or for all or substantially all of the remainder of the Term to a proposed transferee, assignee or sublessee other than pursuant to an Exempt Transfer, then Landlord shall have the option, exercisable by giving notice to Tenant at any time within ten (10) business days after Landlord’s receipt of such Transfer Notice, to terminate this Lease as of the date specified in the Transfer Notice as the Transfer Date, except for those provisions that, by their express terms, survive the expiration or earlier termination hereof.  If Landlord exercises such option, then Tenant shall have the right to withdraw such Transfer Notice by delivering to Landlord written notice of such election within five (5) business days after Landlord’s delivery of notice electing to exercise Landlord’s option to terminate this Lease.  In the event Tenant withdraws the Transfer Notice as provided in this Section, this Lease shall continue in full force and effect.  No failure of Landlord to exercise its option to terminate this Lease shall be deemed to be Landlord’s consent to a proposed Transfer.

29.8.If Tenant sublets the Premises or any portion thereof, Tenant hereby immediately and irrevocably assigns to Landlord, as security for Tenant’s obligations under this Lease, all rent from any such subletting, and appoints Landlord as assignee and attorney-in-fact for Tenant, and Landlord (or a receiver for Tenant appointed on Landlord’s application) may collect such rent and apply it toward Tenant’s obligations under this Lease; provided that, until the occurrence of a Default (as defined below) by Tenant, Tenant shall have the right to collect such rent.

29.9.In the event that Tenant enters into a sublease for the entire Premises in accordance with this Article that expires within two (2) days of the Term Expiration Date, the term expiration date of such sublease shall, notwithstanding anything in this Lease, the sublease or any consent to the sublease to the contrary, be deemed to be the date that is two (2) days prior to the Term Expiration Date.

 

 

50

 


30.Subordination and Attornment.

30.1.This Lease shall be subject and subordinate to the lien of any mortgage, deed of trust, or lease in which Landlord is tenant now or hereafter in force against the Building or the Project and to all advances made or hereafter to be made upon the security thereof without the necessity of the execution and delivery of any further instruments on the part of Tenant to effectuate such subordination.

30.2.Notwithstanding the foregoing, Tenant shall execute and deliver upon demand such further instrument or instruments evidencing such subordination of this Lease to the lien of any such mortgage or mortgages or deeds of trust or lease in which Landlord is tenant as may be required by Landlord.  If any Lender so elects, however, this Lease shall be deemed prior in lien to any such lease, mortgage, or deed of trust upon or including the Premises regardless of date and Tenant shall execute a statement in writing to such effect at Landlord’s request.  If Tenant fails to execute any document required from Tenant under this Section within ten (10) business days after written request therefor, it shall be a default hereunder, subject to applicable notice and cure periods.  For the avoidance of doubt, “Lenders” shall also include historic tax credit investors and new market tax credit investors.

30.3.Upon written request of Landlord and opportunity for Tenant to review, Tenant agrees to execute any Lease amendments not materially altering the terms of this Lease or increasing Tenant’s monetary obligations or materially increasing Tenant’s other material non-monetary obligations hereunder, if required by a Lender incident to the financing of the real property of which the Premises constitute a part.

30.4.In the event any proceedings are brought for foreclosure, or in the event of the exercise of the power of sale under any mortgage or deed of trust made by Landlord covering the Premises, Tenant shall at the election of the purchaser at such foreclosure or sale attorn to the purchaser upon any such foreclosure or sale and recognize such purchaser as Landlord under this Lease.

30.5Landlord agrees to use commercially reasonable efforts to request from its current Lender of the Property that such Lender enter into its standard subordination, non-disturbance and attornment agreement (the “SNDA”) with Tenant.  If Lender so agrees to enter into the  SNDA, Tenant shall pay the reasonable charges or fees which may be required by such Lender in order to obtain such agreement.  

31.Defaults and Remedies.

31.1.Late payment by Tenant to Landlord of Rent and other sums due shall cause Landlord to incur costs not contemplated by this Lease, the exact amount of which shall be extremely difficult and impracticable to ascertain.  Such costs include processing and accounting charges and late charges that may be imposed on Landlord by the terms of any mortgage or trust deed covering the Premises.  Therefore, if any installment of Rent due from Tenant is not received by Landlord within three (3) business days after the date such payment is due, Tenant shall pay to Landlord (a) an additional sum of five percent (5%) of the overdue Rent as a late

 

 

51

 


charge plus (b) interest at an annual rate (the “Default Rate”) equal to the lesser of (a) twelve percent (12%) and (b) the highest rate permitted by Applicable Laws.  The parties agree that this late charge represents a fair and reasonable estimate of the costs that Landlord shall incur by reason of late payment by Tenant and shall be payable as Additional Rent to Landlord due with the next installment of Rent or within five (5) business days after Landlord’s demand, whichever is earlier.  Landlord’s acceptance of any Additional Rent (including a late charge or any other amount hereunder) shall not be deemed an extension of the date that Rent is due or prevent Landlord from pursuing any other rights or remedies under this Lease, at law or in equity.

31.2.No payment by Tenant or receipt by Landlord of a lesser amount than the Rent payment herein stipulated shall be deemed to be other than on account of the Rent, nor shall any endorsement or statement on any check or any letter accompanying any check or payment as Rent be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance of such Rent or pursue any other remedy provided in this Lease or in equity or at law.  If a dispute shall arise as to any amount or sum of money to be paid by Tenant to Landlord hereunder, Tenant shall have the right to make payment “under protest,” such payment shall not be regarded as a voluntary payment, and there shall survive the right on the part of Tenant to institute suit for recovery of the payment paid under protest.

31.3.If Tenant fails to pay any sum of money required to be paid by it hereunder or perform any other act on its part to be performed hereunder, in each case within the applicable cure period (if any) described in Section 31.4, then Landlord may (but shall not be obligated to), without waiving or releasing Tenant from any obligations of Tenant, make such payment or perform such act; provided that such failure by Tenant unreasonably interfered with the use of the Building or the Project by any other tenant or with the efficient operation of the Building or the Project, or resulted or could have resulted in a violation of Applicable Laws or the cancellation of an insurance policy maintained by Landlord.  Notwithstanding the foregoing, in the event of an emergency, Landlord shall have the right to enter the Premises and act in accordance with its rights as provided elsewhere in this Lease.  In addition to the late charge described in Section 31.1, Tenant shall pay to Landlord as Additional Rent all sums so paid or incurred by Landlord, together with interest at the Default Rate, computed from the date such sums were paid or incurred.

31.4.The occurrence of any one or more of the following events shall constitute a “Default” hereunder by Tenant:

(a)If Tenant (i) abandons the Premises; or (ii)(A) Landlord receives notice of Tenant’s vacation of or Tenant’s intention to vacate the Premises prior to the scheduled expiration or earlier termination of this Lease, other than in accordance with a right expressly granted to Tenant under this Lease, and such vacation (or intention to vacate) is related to financial hardship or Tenant’s inability to pay its debts as they become due, a dissolution of Tenant, or the liquidation or winding up of Tenant’s business operations; or (B) Tenant vacates the Premises prior to the scheduled expiration or earlier termination of this Lease, other than in accordance with a right expressly granted to Tenant under this Lease, within the one-hundred

 

 

52

 


twenty (120) day period following the filing of any involuntary petition against Tenant or the attachment of Tenant’s interest in this Lease (notwithstanding anything to the contrary in Sections 31.4(g) and 31.4(i));

(b)Tenant fails to make any payment of Rent, as and when due, or to satisfy its obligations under Article 19, where such failure shall continue for a period of three (3) business days after written notice thereof from Landlord to Tenant;

(c)Tenant fails to observe or perform any obligation or covenant contained herein (other than described in Sections 31.4(a) and 31.4(b)) to be performed by Tenant, where such failure continues for a period of thirty (30) days after written notice thereof from Landlord to Tenant; provided that, if the nature of Tenant’s default is such that it reasonably requires more than thirty (30) days to cure, Tenant shall not be deemed to be in Default if Tenant commences such cure within such thirty (30) day period and thereafter diligently prosecutes the same to completion; and provided, further, that such cure is completed no later than ninety (90) days after Tenant’s receipt of written notice from Landlord;

(d)Tenant makes an assignment for the benefit of creditors;

(e)A receiver, trustee or custodian is appointed to or does take title, possession or control of all or substantially all of Tenant’s assets;

(f)Tenant files a voluntary petition under the United States Bankruptcy Code or any successor statute (as the same may be amended from time to time, the “Bankruptcy Code”) or an order for relief is entered against Tenant pursuant to a voluntary or involuntary proceeding commenced under any chapter of the Bankruptcy Code;

(g)Any involuntary petition is filed against Tenant under any chapter of the Bankruptcy Code and is not dismissed within one hundred twenty (120) days;

(h)Tenant fails to deliver an estoppel certificate in accordance with Article 20; or

(i)Tenant’s interest in this Lease is attached, executed upon or otherwise judicially seized and such action is not released within one hundred twenty (120) days of the action.

Notices given under this Section shall specify the alleged default and shall demand that Tenant perform the provisions of this Lease or pay the Rent that is in arrears, as the case may be, within the applicable period of time, or quit the Premises.  No such notice shall be deemed a forfeiture or a termination of this Lease unless Landlord elects otherwise in such notice.  

 

 

53

 


31.5.In the event of a Default by Tenant, and at any time thereafter, with or without notice or demand and without limiting Landlord in the exercise of any right or remedy that Landlord may have, Landlord has the right to do any or all of the following:

(a)Halt any Tenant Improvements or Alterations and order Tenant’s contractors, subcontractors, consultants, designers and material suppliers to stop work;

(b)Terminate Tenant’s right to possession of the Premises by written notice to Tenant or by any lawful means, in which case Tenant shall immediately surrender possession of the Premises to Landlord.  In such event, Landlord shall have the immediate right to re-enter and remove all persons and property, and such property may be removed and stored in a public warehouse or elsewhere at the cost and for the account of Tenant, all without service of notice or resort to legal process and without being deemed guilty of trespass or becoming liable for any loss or damage that may be occasioned thereby; and

(c)Terminate this Lease, in which event Tenant shall immediately surrender possession of the Premises to Landlord.  In such event, Landlord shall have the immediate right to re-enter and remove all persons and property, and such property may be removed and stored in a public warehouse or elsewhere at the cost and for the account of Tenant, all without service of notice or resort to legal process and without being deemed guilty of trespass or becoming liable for any loss or damage that may be occasioned thereby.  In the event that Landlord shall elect to so terminate this Lease, then Landlord shall be entitled to recover from Tenant all damages incurred by Landlord by reason of Tenant’s default, including the sum of:

(i)The worth at the time of award of any unpaid Rent that had accrued at the time of such termination; plus

(ii)The costs of restoring the Premises to the condition required under the terms of this Lease; plus

(iii)An amount (the “Election Amount”) equal to either (A) the positive difference (if any, and measured at the time of such termination) between (1) the then-present value of the total Rent and other benefits that would have accrued to Landlord under this Lease for the remainder of the Term if Tenant had fully complied with the Lease minus (2) the then-present cash rental value of the Premises as determined by Landlord for what would be the then-unexpired Term if the Lease remained in effect, computed using the discount rate of the Federal Reserve Bank of San Francisco at the time of the award plus one (1) percentage point (the “Discount Rate”) or (B) twelve (12) months (or such lesser number of months as may then be remaining in the Term) of Base Rent and Additional Rent at the rate last payable by Tenant pursuant to this Lease, in either case as Landlord specifies in such election.  Landlord and Tenant agree that the Election Amount represents a reasonable forecast of the minimum damages expected to occur in the event of a breach, taking into account the uncertainty, time and cost of determining elements relevant to actual damages, such as fair market rent, time and costs that may be required to re-lease the Premises, and other factors; and that the Election Amount is not a penalty.

 

 

54

 


As used in Section 31.5(c)(i), “worth at the time of award” shall be computed by allowing interest at the Default Rate.

31.6.In addition to any other remedies available to Landlord at law or in equity and under this Lease, Landlord may continue this Lease in effect after Tenant’s Default or abandonment and recover Rent as it becomes due.  In addition, Landlord shall not be liable in any way whatsoever for its failure or refusal to relet the Premises.  For purposes of this Section, the following acts by Landlord will not constitute the termination of Tenant’s right to possession of the Premises:

(a)Acts of maintenance or preservation or efforts to relet the Premises, including alterations, remodeling, redecorating, repairs, replacements or painting as Landlord shall consider advisable for the purpose of reletting the Premises or any part thereof; or

(b)The appointment of a receiver upon the initiative of Landlord to protect Landlord’s interest under this Lease or in the Premises.

Notwithstanding the foregoing, in the event of a Default by Tenant, Landlord may elect at any time to terminate this Lease and to recover damages to which Landlord is entitled.

31.7.If Landlord does not elect to terminate this Lease as provided in Section 31.5, then Landlord may, from time to time, recover all Rent as it becomes due under this Lease.  At any time thereafter, Landlord may elect to terminate this Lease and to recover damages to which Landlord is entitled.

31.8.In the event Landlord elects to terminate this Lease and relet the Premises, Landlord may execute any new lease in its own name.  Tenant hereunder shall have no right or authority whatsoever to collect any Rent from such tenant.  The proceeds of any such reletting shall be applied as follows:

(a)First, to the payment of any indebtedness other than Rent due hereunder from Tenant to Landlord, including storage charges or brokerage commissions owing from Tenant to Landlord as the result of such reletting;

(b)Second, to the payment of the costs and expenses of reletting the Premises, including (i) alterations and repairs that Landlord deems reasonably necessary and advisable and (ii) reasonable attorneys’ fees, charges and disbursements incurred by Landlord in connection with the retaking of the Premises and such reletting;

(c)Third, to the payment of Rent and other charges due and unpaid hereunder; and

(d)Fourth, to the payment of future Rent and other damages payable by Tenant under this Lease.

 

 

55

 


31.9.All of Landlord’s rights, options and remedies hereunder shall be construed and held to be nonexclusive and cumulative.  Landlord shall have the right to pursue any one or all of such remedies, or any other remedy or relief that may be provided by Applicable Laws, whether or not stated in this Lease.  No waiver of any default of Tenant hereunder shall be implied from any acceptance by Landlord of any Rent or other payments due hereunder or any omission by Landlord to take any action on account of such default if such default persists or is repeated, and no express waiver shall affect defaults other than as specified in such waiver.  Notwithstanding any provision of this Lease to the contrary, in no event shall Landlord be required to mitigate its damages with respect to any default by Tenant, except as required by Applicable Laws.  Any such obligation imposed by Applicable Laws upon Landlord to relet the Premises after any termination of this Lease shall be subject to the reasonable requirements of Landlord to (a) lease to high quality tenants on such terms as Landlord may from time to time deem appropriate in its discretion and (b) develop the Project in a harmonious manner with a mix of uses, tenants, floor areas, terms of tenancies, etc., as determined by Landlord.  Landlord shall not be obligated to relet the Premises to (y) any Tenant’s Affiliate or (z) any party (i) unacceptable to a Lender, (ii) that requires Landlord to make improvements to or re-demise the Premises, (iii) that desires to change the Permitted Use, (iv) that desires to lease the Premises for more or less than the remaining Term or (v) to whom Landlord or an affiliate of Landlord may desire to lease other available space in the Project or at another property owned by Landlord or an affiliate of Landlord.

31.10.Landlord’s termination of (a) this Lease or (b) Tenant’s right to possession of the Premises shall not relieve Tenant of any liability to Landlord that has previously accrued or that shall arise based upon events that occurred prior to the later to occur of (y) the date of Lease termination and (z) the date Tenant surrenders possession of the Premises.

31.11.To the extent permitted by Applicable Laws, Tenant waives any and all rights of redemption granted by or under any present or future Applicable Laws if Tenant is evicted or dispossessed for any cause, or if Landlord obtains possession of the Premises due to Tenant’s default hereunder or otherwise.

31.12.Landlord shall not be in default or liable for damages under this Lease unless Landlord fails to perform obligations required of Landlord within a reasonable time, but in no event shall such failure continue for more than thirty (30) days after written notice from Tenant specifying the nature of Landlord’s failure; provided, however, that if the nature of Landlord’s obligation is such that more than thirty (30) days are required for its performance, then Landlord shall not be in default if Landlord commences performance within such thirty (30) day period and thereafter diligently prosecutes the same to completion.  If Landlord fails to commence to cure any default by Landlord within the period provided above in this paragraph and if, as a result the default, Tenant is incapable despite commercially reasonable efforts to continue operations within the Premises, Tenant may give Landlord an additional written notice confirming that the default has not been cured and that Tenant intends to cure such default, and, if Landlord fails to cure such default within thirty (30) days after such notice, Tenant may take such steps within the confines of its Premises as are reasonably appropriate to cure the default and seek to recover from Landlord the reasonable cost of such cure. Tenant shall have no right to perform any

 

 

56

 


obligation of Landlord in lieu of Landlord to the extent the same involves or may impact any base building system, any structural element of the Building, or any area of the Building outside of the Premises, including, without limitation, the Common Area or the premises of any other tenant or occupant of the Building (collectively, the “Excluded Systems/Areas”).  Landlord’s liability to keep, maintain, and repair shall always be limited to the cost of making such repair or accomplishing such maintenance or repair and Landlord shall not be liable for any consequential or any indirect damages.  In no event shall Tenant have the right to terminate this Lease or offset from Rent as a result of Landlord's default.   Notwithstanding the above provisions of this Section 31.12 to the contrary, in emergency situations such that the prior written notice to Landlord provided for above is not practical, Tenant may, upon such shorter period of written notice or contemporaneous written and oral notice as is appropriate under the circumstances, and excluding in all instances any work or access to Excluded Systems/Areas, take such steps as are reasonably appropriate to cure the default, in which event Tenant’s rights with respect to recovering the cost of such cure shall be as provided above.

31.13.In the event of any default by Landlord, Tenant shall give notice by registered or certified mail to any (a) beneficiary of a deed of trust or (b) mortgagee under a mortgage covering the Premises, the Building or the Project and to any landlord of any lease of land upon or within which the Premises, the Building or the Project is located, and shall offer such beneficiary, mortgagee or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Building or the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided that Landlord shall furnish to Tenant in writing, upon written request by Tenant, the names and addresses of all such persons who are to receive such notices.

32.Bankruptcy.   In the event a debtor, trustee or debtor in possession under the Bankruptcy Code, or another person with similar rights, duties and powers under any other Applicable Laws, proposes to cure any default under this Lease or to assume or assign this Lease and is obliged to provide adequate assurance to Landlord that (a) a default shall be cured, (b) Landlord shall be compensated for its damages arising from any breach of this Lease and (c) future performance of Tenant’s obligations under this Lease shall occur, then such adequate assurances shall include any or all of the following, as designated by Landlord in its sole and absolute discretion:

32.1.Those acts specified in the Bankruptcy Code or other Applicable Laws as included within the meaning of “adequate assurance,” even if this Lease does not concern a shopping center or other facility described in such Applicable Laws;

32.2.A prompt cash payment to compensate Landlord for any monetary defaults or actual damages arising directly from a breach of this Lease;

32.3.A cash deposit in an amount at least equal to the then-current amount of the Security Deposit; or

32.4.The assumption or assignment of all of Tenant’s interest and obligations under this Lease.

 

 

57

 


33.Brokers.

33.1.Landlord and Tenant each represents and warrants to the other that it has had no dealings with any real estate broker or agent in connection with the negotiation of this Lease other than Jones Lang LaSalle (“Broker”), and that it knows of no other real estate broker or agent that is or might be entitled to a commission in connection with this Lease.  Landlord shall compensate Broker in relation to this Lease pursuant to a separate agreement between Landlord and Broker.

33.2.Tenant represents and warrants that no broker or agent has made any representation or warranty relied upon by Tenant in Tenant’s decision to enter into this Lease, other than as contained in this Lease.

33.3.Tenant acknowledges and agrees that the employment of brokers by Landlord is for the purpose of solicitation of offers of leases from prospective tenants and that no authority is granted to any broker to furnish any representation (written or oral) or warranty from Landlord unless expressly contained within this Lease.  Landlord is executing this Lease in reliance upon Tenant’s representations, warranties and agreements contained within Sections 33.1 and 33.2.

33.4.Landlord and Tenant each agree to Indemnify, respectively, the Tenant Indemnitees and Landlord Indemnitees harmless from any and all cost or liability for compensation claimed by any broker or agent, other than Broker, employed or engaged by Landlord and Tenant or claiming to have been employed or engaged by Landlord or Tenant.

34.Definition of Landlord.  With regard to obligations imposed upon Landlord pursuant to this Lease, the term “Landlord,” as used in this Lease, shall refer only to Landlord or Landlord’s then-current successor-in-interest.  In the event of any transfer, assignment or conveyance of Landlord’s interest in this Lease or in Landlord’s fee title to or leasehold interest in the Property, as applicable, Landlord herein named (and in case of any subsequent transfers or conveyances, the subsequent Landlord) shall be automatically freed and relieved, from and after the date of such transfer, assignment or conveyance, from all liability for the performance of any covenants or obligations contained in this Lease thereafter to be performed by Landlord and, without further agreement, the transferee, assignee or conveyee of Landlord’s in this Lease or in Landlord’s fee title to or leasehold interest in the Property, as applicable, shall be deemed to have assumed and agreed to observe and perform any and all covenants and obligations of Landlord hereunder during the tenure of its interest in the Lease or the Property.  Landlord or any subsequent Landlord may transfer its interest in the Premises or this Lease without Tenant’s consent.

35.Limitation of Landlord’s Liability.

35.1.If Landlord is in default under this Lease and, as a consequence, Tenant recovers a monetary judgment against Landlord, the judgment shall be satisfied only out of (a) the proceeds of sale received on execution of the judgment and levy against the right, title and interest of Landlord in the Building and the Project, (b) rent or other income from such real property receivable by Landlord or (c) the consideration received by Landlord from the sale, financing, refinancing or other disposition of all or any part of Landlord’s right, title or interest in the Building or the Project.

 

 

58

 


35.2.Neither Landlord nor any of its affiliates, nor any of their respective partners, shareholders, directors, officers, employees, members or agents shall be personally liable for Landlord’s obligations or any deficiency under this Lease, and service of process shall not be made against any shareholder, director, officer, employee or agent of Landlord or any of Landlord’s affiliates.  No partner, shareholder, director, officer, employee, member or agent of Landlord or any of its affiliates shall be sued or named as a party in any suit or action, and service of process shall not be made against any partner or member of Landlord except as may be necessary to secure jurisdiction of the partnership, joint venture or limited liability company, as applicable.  No partner, shareholder, director, officer, employee, member or agent of Landlord or any of its affiliates shall be required to answer or otherwise plead to any service of process, and no judgment shall be taken or writ of execution levied against any partner, shareholder, director, officer, employee, member or agent of Landlord or any of its affiliates.

35.3.Tenant’s directors, officers or employees shall not be personally liable for Tenant’s obligations or any deficiency under this Lease.  No director, officer or employee of Tenant shall be sued or named as a party in any suit or action, and service of process shall not be made against any director, officer or employee. No director, officer or employee of Tenant shall be required to answer or otherwise plead to any service of process, and no judgment shall be taken or writ of execution levied against any director, officer or employee.

35.4.Each of the covenants and agreements of this Article shall be applicable to any covenant or agreement either expressly contained in this Lease or imposed by Applicable Laws and shall survive the expiration or earlier termination of this Lease.

36.Joint and Several Obligations.  If more than one person or entity executes this Lease as Tenant, then:

36.1.Each of them is jointly and severally liable for the keeping, observing and performing of all of the terms, covenants, conditions, provisions and agreements of this Lease to be kept, observed or performed by Tenant, and such terms, covenants, conditions, provisions and agreements shall be binding with the same force and effect upon each and all of the persons executing this Agreement as Tenant; and

36.2.The term “Tenant,” as used in this Lease, shall mean and include each of them, jointly and severally.  The act of, notice from, notice to, refund to, or signature of any one or more of them with respect to the tenancy under this Lease, including any renewal, extension, expiration, termination or modification of this Lease, shall be binding upon each and all of the persons executing this Lease as Tenant with the same force and effect as if each and all of them had so acted, so given or received such notice or refund, or so signed.

37.Representations.  Tenant warrants and represents that (a) Tenant is duly incorporated or otherwise established or formed and validly existing under the laws of its state of incorporation, establishment or formation, (b) Tenant has and is duly qualified to do business in the state in which the Property is located, (c) Tenant has full corporate, partnership, trust, association or other appropriate power and authority to enter into this Lease and to perform all Tenant’s obligations hereunder, (d) each person (and all of the persons if more than one signs) signing this

 

 

59

 


Lease on behalf of Tenant is duly and validly authorized to do so and (e) neither (i) the execution, delivery or performance of this Lease nor (ii) the consummation of the transactions contemplated hereby will violate or conflict with any provision of documents or instruments under which Tenant is constituted or to which Tenant is a party.  In addition, Tenant represents that Tenant, and to Tenant’s current, actual knowledge, its members, shareholders or other equity owners (without duty of inquiry) is not an entity with whom U.S. persons or entities are restricted from doing business under regulations of the Office of Foreign Asset Control (“OFAC”) of the Department of the Treasury (including those named on OFAC’s Specially Designated and Blocked Persons List) or under any statute, executive order (including the September 24, 2001, Executive Order Blocking Property and Prohibiting Transactions with Persons Who Commit, Threaten to Commit, or Support Terrorism) or other similar governmental action. Landlord represents that, to its current, actual knowledge (without duty of inquiry), it is not an entity with whom U.S. persons or entities are restricted from doing business under regulations of OFAC of the Department of the Treasury (including those named on OFAC's Specially Designated and Blocked Persons List) or under any statute, executive order (including the September 24, 2001, Executive Order Blocking Property and Prohibiting Transactions with Persons Who Commit, Threaten to Commit, or Support Terrorism) or other similar governmental action.

38.Confidentiality.  Tenant shall keep the terms and conditions of this Lease and any information provided to Tenant or its employees, agents or contractors pursuant to Article 9 confidential and shall not (a) disclose to any third party any terms or conditions of this Lease or any other Lease-related document (including subleases, assignments, work letters, construction contracts, letters of credit, subordination agreements, non-disturbance agreements, brokerage agreements or estoppels) or (b) provide to any third party an original or copy of this Lease (or any Lease-related document).  Landlord shall not release to any third party any non-public financial information or non-public information about Tenant’s ownership structure that Tenant gives Landlord.  Notwithstanding the foregoing, confidential information under this Section may be released by Landlord or Tenant under the following circumstances:  (x) if required by Applicable Laws or in any judicial proceeding; provided that the releasing party has given the other party reasonable notice of such requirement, if feasible, (y) to a party’s attorneys, accountants, brokers, lenders, potential lenders, investors, potential investors and other bona fide consultants or advisers (with respect to this Lease only); provided such third parties agree to be bound by this Section or (z) to bona fide prospective assignees or subtenants of this Lease; provided they agree in writing to be bound by this Section.

39.Notices.  Except as otherwise stated in this Lease, any notice, consent, demand, invoice, statement or other communication required or permitted to be given hereunder shall be in writing and shall be given by (a) personal delivery or (b) overnight delivery with a reputable international overnight delivery service, such as FedEx.  Any such notice, consent, demand, invoice, statement or other communication shall be deemed delivered (y) upon receipt, if given in accordance with Subsection 39(a); or (z) one (1) business day after deposit with a reputable international overnight delivery service, if given if given in accordance with Subsection 39(b).  Except as otherwise stated in this Lease, any notice, consent, demand, invoice, statement or other communication required or permitted to be given pursuant to this Lease shall be addressed to Tenant at the Premises, or to Landlord or Tenant at the addresses shown in Sections 2.9 and 2.10 or 2.11, respectively.  Either party may, by notice to the other given pursuant to this Section,

 

 

60

 


specify additional or different addresses for notice purposes.  Notices may be given by an agent on behalf of Landlord or Tenant, and with respect to any agent of Tenant, Tenant shall first notify Landlord in writing that such agent is the authorized agent of Tenant.

40.Miscellaneous.

40.1.Landlord reserves the right to change the name of the Building or the Project in its sole discretion.

40.2.To induce Landlord to enter into this Lease, Tenant agrees that it shall promptly furnish to Landlord, from time to time, upon Landlord’s written request, the most recent year-end consolidated financial statements reflecting Tenant’s current financial condition audited by a nationally recognized accounting firm (except if the named Tenant under this Lease is not the ultimate parent company, such financial statements shall be unconsolidated financial statements of Tenant).  Tenant shall, within ninety (90) days after the end of Tenant’s financial year, furnish Landlord with a certified copy of Tenant’s year-end consolidated financial statements for the previous year certified by Tenant’s chief financial officer; provided, however, if the named Tenant under this Lease is not the ultimate parent company, then such required financial statements shall be unconsolidated financial statements of Tenant.  Additionally, Tenant shall, within one hundred eighty (180) days after the end of Tenant’s financial year, furnish Landlord with Tenant’s year-end consolidated financial statements audited by a nationally recognized accounting firm; provided, however, if the named Tenant under this Lease is not the ultimate parent company, then such required financial statements shall be unconsolidated financial statements of Tenant.  Tenant represents and warrants that all financial statements, records and information furnished by Tenant to Landlord in connection with this Lease are true, correct and complete in all respects.  If audited financials are not otherwise prepared, unaudited financials complying with generally accepted accounting principles and certified by the chief financial officer of Tenant as true, correct and complete in all respects shall suffice for purposes of this Section.  The provisions of this Section shall not apply at any time while Tenant is a corporation whose shares are traded on any nationally recognized stock exchange.

40.3.Submission of this instrument for examination or signature by Tenant does not constitute a reservation of or option for a lease, and shall not be effective as a lease or otherwise until execution by and delivery to both Landlord and Tenant.

40.4.The terms of this Lease are intended by the parties as a final, complete and exclusive expression of their agreement with respect to the terms that are included herein, and may not be contradicted or supplemented by evidence of any other prior or contemporaneous agreement.

40.5.Upon the request of either Landlord or Tenant, the parties shall execute a document in recordable form containing only such information as is necessary to constitute a Notice of Lease under Massachusetts law.  All costs of preparing and recording such notice shall be borne by the requesting party.  Within ten (10) days after receipt of written request from Landlord after the expiration or earlier termination of this Lease, Tenant shall execute a termination of any Notice of Lease recorded with respect hereto.  Neither party shall record this Lease.

 

 

61

 


40.6.Where applicable in this Lease, the singular includes the plural and the masculine or neuter includes the masculine, feminine and neuter.  The words “include,” “includes,” “included” and “including” mean “‘include,’ etc., without limitation.” The word “shall” is mandatory and the word “may” is permissive.  The section headings of this Lease are not a part of this Lease and shall have no effect upon the construction or interpretation of any part of this Lease.  Landlord and Tenant have each participated in the drafting and negotiation of this Lease, and the language in all parts of this Lease shall be in all cases construed as a whole according to its fair meaning and not strictly for or against either Landlord or Tenant.

40.7.Except as otherwise expressly set forth in this Lease, each party shall pay its own costs and expenses incurred in connection with this Lease and such party’s performance under this Lease; provided that, if either party commences an action, proceeding, demand, claim, action, cause of action or suit against the other party arising out of or in connection with this Lease, then the substantially prevailing party shall be reimbursed by the other party for all reasonable costs and expenses, including reasonable attorneys’ fees and expenses, incurred by the substantially prevailing party in such action, proceeding, demand, claim, action, cause of action or suit, and in any appeal in connection therewith (regardless of whether the applicable action, proceeding, demand, claim, action, cause of action, suit or appeal is voluntarily withdrawn or dismissed).  

40.8.Time is of the essence with respect to the performance of every provision of this Lease.

40.9.Each provision of this Lease performable by Tenant shall be deemed both a covenant and a condition.

40.10.Notwithstanding anything to the contrary contained in this Lease, Tenant’s obligations under this Lease are independent and shall not be conditioned upon performance by Landlord.

40.11.Whenever consent or approval of either party is required, that party shall not unreasonably withhold, condition or delay such consent or approval, except as may be expressly set forth to the contrary.

40.12.Any provision of this Lease that shall prove to be invalid, void or illegal shall in no way affect, impair or invalidate any other provision hereof, and all other provisions of this Lease shall remain in full force and effect and shall be interpreted as if the invalid, void or illegal provision did not exist.

40.13.Each of the covenants, conditions and agreements herein contained shall inure to the benefit of and shall apply to and be binding upon the parties hereto and their respective heirs; legatees; devisees; executors; administrators; and permitted successors and assigns.  This Lease is for the sole benefit of the parties and their respective heirs, legatees, devisees, executors, administrators and permitted successors and assigns, and nothing in this Lease shall give or be construed to give any other person or entity any legal or equitable rights.  Nothing in this Section shall in any way alter the provisions of this Lease restricting assignment or subletting.

 

 

62

 


40.14.This Lease shall be governed by, construed and enforced in accordance with the laws of the state in which the Premises are located, without regard to such state’s conflict of law principles.

40.15.Each party hereto guarantees, warrants and represents that the individual or individuals signing this Lease have the power, authority and legal capacity to sign this Lease on behalf of and to bind all entities, corporations, partnerships, limited liability companies, joint venturers or other organizations and entities on whose behalf such individual or individuals have signed.

40.16.This Lease may be executed in one or more counterparts, each of which, when taken together, shall constitute one and the same document. The parties acknowledge and agree that this Lease may be executed via .pdf format (including computer-scanned or other electronic reproduction of the actual signatures) and that delivery of a signature by electronic or physical means shall be effective to the same extent as delivery of an original signature.  Notwithstanding the foregoing, originally signed documents shall be provided upon either party’s request.

40.17.No provision of this Lease may be modified, amended or supplemented except by an agreement in writing signed by Landlord and Tenant.

40.18.No waiver of any term, covenant or condition of this Lease shall be binding upon Landlord unless executed in writing by Landlord.  The waiver by Landlord of any breach or default of any term, covenant or condition contained in this Lease shall not be deemed to be a waiver of any preceding or subsequent breach or default of such term, covenant or condition or any other term, covenant or condition of this Lease.

40.19.To the extent permitted by Applicable Laws, the parties waive trial by jury in any action, proceeding or counterclaim brought by the other party hereto related to matters arising out of or in any way connected with this Lease; the relationship between Landlord and Tenant; Tenant’s use or occupancy of the Premises; or any claim of injury or damage related to this Lease or the Premises.

41.Rooftop Installation Area.

41.1.Tenant may use the portion of the Building identified as a “Rooftop Installation Area” on Exhibit A attached hereto (the “Rooftop Installation Area”) solely to operate, maintain, repair and replace rooftop antennae, mechanical equipment, communications antennas, a generator, and other equipment installed by Tenant in the Rooftop Installation Area in accordance with this Article (“Tenant’s Rooftop Equipment”).  Tenant’s Rooftop Equipment shall be only for Tenant’s use of the Premises for the Permitted Use.

41.2.Tenant shall install Tenant’s Rooftop Equipment at its sole cost and expense, at such times and in such manner as Landlord may reasonably designate, and in accordance with this Article and the applicable provisions of this Lease regarding Alterations.  Tenant’s Rooftop Equipment and the installation thereof shall be subject to Landlord’s prior written approval, which approval shall not be unreasonably withheld, delayed or conditioned.  Among other

 

 

63

 


reasons, Landlord may withhold approval if the installation or operation of Tenant’s Rooftop Equipment could reasonably be expected to damage the structural integrity of the Building or to transmit vibrations or noise or cause other adverse effects beyond the Premises to an extent not customary in first class laboratory buildings, unless Tenant implements measures that are acceptable to Landlord in its reasonable discretion to avoid any such damage or transmission.

41.3.Tenant shall comply with any roof or roof-related warranties.  Tenant shall obtain a letter from Landlord’s roofing contractor within thirty (30) days after completion of any Tenant work on the rooftop stating that such work did not affect any such warranties.  Tenant, at its sole cost and expense, shall inspect the Rooftop Installation Area at least annually, and correct any loose bolts, fittings or other appurtenances and repair any damage to the roof arising from the installation or operation of Tenant’s Rooftop Equipment.  Tenant shall not permit the installation, maintenance or operation of Tenant’s Rooftop Equipment to violate any Applicable Laws or constitute a nuisance.  Tenant shall pay Landlord within thirty (30) days after demand (a) all applicable taxes, charges, fees or impositions imposed on Landlord by Governmental Authorities as the result of Tenant’s use of the Rooftop Installation Areas in excess of those for which Landlord would otherwise be responsible for the use or installation of Tenant’s Rooftop Equipment and (b) the amount of any increase in Landlord’s insurance premiums as a result of the installation of Tenant’s Rooftop Equipment.  Upon Tenant’s written request to Landlord, Landlord shall use commercially reasonable efforts to cause other tenants to remedy any interference in the operation of Tenant’s Rooftop Equipment arising from any such tenants’ equipment installed after the applicable piece of Tenant’s Rooftop Equipment; provided, however, that Landlord shall not be required to request that such tenants waive their rights under their respective leases.

41.4.If Tenant’s Equipment (a) causes physical damage to the structural integrity of the Building, (b) interferes with any telecommunications, mechanical or other systems located at or near or servicing the Building or the Project that were installed prior to the installation of Tenant’s Rooftop Equipment, (c) interferes with any other service provided to other tenants in the Building or the Project by rooftop or penthouse installations that were installed prior to the installation of Tenant’s Rooftop Equipment or (d) interferes with any other tenant’s business, in each case in excess of that permissible under Federal Communications Commission regulations, then Tenant shall cooperate with Landlord to determine the source of the damage or interference and promptly repair such damage and eliminate such interference, in each case at Tenant’s sole cost and expense, within ten (10) business days after receipt of notice of such damage or interference (which notice may be oral; provided that Landlord also delivers to Tenant written notice of such damage or interference within twenty-four (24) hours after providing oral notice).  Notwithstanding such foregoing 10-business day cure period, if Tenant’s Rooftop Equipment is causing damage to the Building or the Project or another tenant’s equipment, then Tenant, upon receipt of notice from Landlord, shall immediately cease using Tenant’s Rooftop Equipment and shall immediately commence to repair any such damage in consultation with, and after approval from, Landlord. After any such damage has been repaired and Tenant’s Rooftop Equipment modified to prevent further damage, Tenant may re-commence use of Tenant’s Rooftop Equipment.

 

 

64

 


41.5.Landlord reserves the right to cause Tenant to relocate Tenant’s Rooftop Equipment to comparably functional space on the roof or in the penthouse of the Building by giving Tenant prior written notice thereof.  Landlord agrees to pay the reasonable costs thereof.  Tenant shall arrange for the relocation of Tenant’s Rooftop Equipment within sixty (60) days after receipt of Landlord’s notification of such relocation.  In the event Tenant fails to arrange for relocation within such sixty (60)-day period, Landlord shall have the right to arrange for the relocation of Tenant’s Rooftop Equipment in a manner that does not unnecessarily interrupt or interfere with Tenant’s use of the Premises for the Permitted Use.

42. Option to Extend Term.  Tenant shall have one (1) option (the “Option”) to extend the Term by five (5) years as to the entire Premises upon the following terms and conditions.  Any extension of the Term pursuant to the Option shall be on all the same terms and conditions as this Lease, except as follows:

42.1.Base Rent at the commencement of the Option term shall equal the then-current fair market value for comparable office and laboratory space in the East Cambridge submarket of comparable age, quality, level of finish and proximity to amenities and public transit, and containing the systems and improvements present in the Premises as of the date that Tenant gives Landlord written notice of Tenant’s election to exercise the Option, including the then-current fair market value annual escalations of Base Rent (“FMV”).  Tenant may, no more than thirteen (13) months prior to the date the Term is then scheduled to expire, request Landlord’s estimate of the FMV for the Option term.  Landlord shall, within fifteen (15) days after receipt of such request, give Tenant a written proposal of such FMV.  If Tenant gives written notice to exercise the Option, such notice shall specify whether Tenant accepts Landlord’s proposed estimate of FMV.  If Tenant does not accept the FMV, then the parties shall endeavor to agree upon the FMV, taking into account all relevant factors, including (v) the size of the Premises, (w) the length of the Option term, (x) rent in comparable buildings in the relevant submarket, including concessions offered to new tenants, such as free rent, tenant improvement allowances and moving allowances, (y) Tenant’s creditworthiness and (z) the quality and location of the Building and the Project.  In the event that the parties are unable to agree upon the FMV within thirty (30) days after Tenant notifies Landlord that Tenant is exercising the Option, then either party may request that the same be determined as follows:  a senior officer of a nationally recognized leasing brokerage firm with local knowledge of the East Cambridge laboratory/research and development leasing submarket (the “Baseball Arbitrator”) shall be selected and paid for jointly by Landlord and Tenant.  If Landlord and Tenant are unable to agree upon the Baseball Arbitrator, then the same shall be designated by the local chapter of the Judicial Arbitration and Mediation Services or any successor organization thereto (the “JAMS”). The Baseball Arbitrator selected by the parties or designated by JAMS shall (y) have at least ten (10) years’ experience in the leasing of laboratory/research and development space in the East Cambridge submarket and (z) not have been employed or retained by either Landlord or Tenant or any affiliate of either for a period of at least ten (10) years prior to appointment pursuant hereto.  Each of Landlord and Tenant shall submit to the Baseball Arbitrator and to the other party its determination of the FMV.  The Baseball Arbitrator shall grant to Landlord and Tenant a hearing and the right to submit evidence.  The Baseball Arbitrator shall determine which of the two (2) FMV determinations more closely represents the actual FMV.  The arbitrator may not select any other FMV for the Premises other than one submitted by Landlord or Tenant.  The FMV selected by the Baseball Arbitrator shall be binding upon Landlord and Tenant and shall serve as the basis

 

 

65

 


for determination of Base Rent payable for the Option term.  If, as of the commencement date of the Option term, the amount of Base Rent payable during the Option term shall not have been determined, then, pending such determination, Tenant shall pay Base Rent equal to the Base Rent payable with respect to the last year of the then-current Term.  After the final determination of Base Rent payable for the Option term, the parties shall promptly execute a written amendment to this Lease specifying the amount of Base Rent to be paid during the Option term.  Any failure of the parties to execute such amendment shall not affect the validity of the FMV determined pursuant to this Section.

42.2.The Option is not assignable separate and apart from this Lease.

42.3.The Option is conditional upon Tenant giving Landlord written notice of its election to exercise the Option at least twelve (12) months prior to the end of the expiration of the then-current Term.  Time shall be of the essence as to Tenant’s exercise of the Option.  Tenant assumes full responsibility for maintaining a record of the deadlines to exercise the Option.  Tenant acknowledges that it would be inequitable to require Landlord to accept any exercise of the Option after the date provided for in this Section.

42.4.Notwithstanding anything contained in this Article to the contrary, Tenant shall not have the right to exercise the Option:

(a)During the time commencing from the date Landlord delivers to Tenant a written notice that Tenant is in default under any provisions of this Lease and continuing until Tenant has cured the specified default;

(b)At any time after any Default as described in Article 31 of the Lease (provided, however, that, for purposes of this Section 42.4(b), Landlord shall not be required to provide Tenant with notice of such Default other than any notice from Landlord that may be required under Article 31 of this Lease) and continuing until Tenant cures any such Default, if such Default is susceptible to being cured;

(c)At the time Tenant exercises its Option and as of the last day of the initial Term, Tenant has not (i) subleased any Rentable Area of the Premises, and (ii) assigned this Lease, except in connection with an Exempt Transfer;

(d)In the event that Tenant has defaulted in the performance of its obligation to pay Base Rent, Operating Expenses or the Property Management Fee two (2) or more times during the twelve (12)-month period immediately prior to the date that Tenant intends to exercise the Option, whether or not Tenant has cured such defaults; or

(e)In the event that Tenant has been in Default of any material non-monetary obligations under this Lease or its obligation to pay Additional Rent (excluding Operating Expenses and the Property Management Fee) two (2) or more times during the twelve (12)-month period immediately prior to the date that Tenant intends to exercise the Option, whether or not Tenant has cured such defaults.

 

 

66

 


42.5.The period of time within which Tenant may exercise the Option shall not be extended or enlarged by reason of Tenant’s inability to exercise such Option because of the provisions of Section 42.4.

42.6.All of Tenant’s rights under the provisions of the Option shall terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Option if, after such exercise, but prior to the commencement date of the new term, (a) Tenant fails to pay to Landlord a monetary obligation of Tenant for a period of twenty (20) days after written notice from Landlord to Tenant, (b) Tenant fails to commence to cure a default (other than a monetary default) within thirty (30) days after the date Landlord gives notice to Tenant of such default or (c) Tenant has been in Default under this Lease two (2) or more times and a service or late charge under Section 31.1 has become payable for any such Default, whether or not Tenant has cured such Defaults.

43.Early Termination  Provided that Tenant has executed a lease with Landlord or an affiliate of Landlord for premises totaling more than 60,000 square feet of Rentable Area in another building owned by an affiliate of Landlord, with an initial term of ten (10) years or more (the “Expansion Lease”), as of the date the Termination Option Notice (as hereafter defined) is delivered and the Termination Date (as hereafter defined) occurs, then Tenant shall have the one-time option to terminate this Lease with respect to the entire Premises (the “Termination Option”) by providing Landlord with written notice thereof (the “Termination Option Notice”) on or about the date that is ten (10) days after the execution date of the Expansion Lease.  Tenant shall set forth in the Termination Option Notice the date that this Lease shall terminate (the “Termination Date”).  If Tenant fails to timely deliver to Landlord the Termination Option Notice, then the Termination Option shall automatically terminate and be of no further force or effect.  If Tenant timely delivers to Landlord the Termination Option Notice, then Tenant shall surrender the Premises to Landlord on or before the Termination Date in accordance with all of the terms and conditions of the Lease.  If Tenant does not so surrender the Premises in accordance with all of the terms and conditions of the Lease on or before the Termination Date, then Tenant, pursuant to Article 27 of this Lease, shall become a tenant at sufferance until the actual date that Tenant surrenders the Premises to Landlord in accordance with the terms and conditions of this Lease.  If Tenant timely delivers to Landlord the Termination Option Notice, then this Lease shall terminate on the Termination Date and shall thereafter be of no further force or effect, except for those provisions that, by their express terms, survive the expiration or earlier termination thereof.  Notwithstanding anything in this Section to the contrary, Tenant shall not be permitted to exercise the Termination Option during any period of time during which Tenant is in default of its obligations under the Lease.  Any attempted exercise of the Termination Option during a period of time in which Tenant is in default shall be void and of no force or effect.  The Termination Option is personal to Synlogic, Inc., and may not be exercised by any assignee, sublessee or transferee of this Lease, unless Landlord expressly agrees that the Termination Option may be transferred to any such assignee, sublessee or transferee, which agreement Landlord may grant or withhold in its sole discretion.

 

 

67

 


44.Ground Lease.  Ground Lessor and Landlord shall execute and deliver to Tenant a recognition agreement providing that Ground Lessor will recognize this Lease and not disturb Tenant's possession of the Premises and recognize this Lease and all of Tenant’s rights hereunder, in the form of the Non-Disturbance and Attornment Agreement attached hereto as Exhibit J.  

[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]

 

 

68

 


 

IN WITNESS WHEREOF, the parties hereto have executed this Lease as a sealed Massachusetts instrument as of the date first above written.

LANDLORD:

BMR-ROGERS STREET LLC,
a Delaware limited liability company

 

By:

 

Name:

 

Title:

 

 

TENANT:

SYNLOGIC, INC.,
a Delaware corporation

 

By:

 

Name:

 

Title:

 

 

 

 

 

 

 

 


 

EXHIBIT A

PREMISES

 

 

A-1

 


 

EXHIBIT A-1

PROPERTY

 

 

 

A-1-1

 


 

EXHIBIT B

WORK LETTER

This Work Letter (this “Work Letter”) is made and entered into as of the [____] day of [_______], 2017, by and between BMR-ROGERS STREET LLC, a Delaware limited liability company(“Landlord”), and SYNLOGIC, INC., a Delaware corporation (“Tenant”), and is attached to and made a part of that certain Lease dated as of [_______], 2017 (as the same may be amended, amended and restated, supplemented or otherwise modified from time to time, the “Lease”), by and between Landlord and Tenant for the Premises located at 301 Binney Street in Cambridge, Massachusetts.  All capitalized terms used but not otherwise defined herein shall have the meanings given them in the Lease.

1.General Requirements.

1.1.Authorized Representatives.

(a)Landlord designates, as Landlord’s authorized representative (“Landlord’s Authorized Representative”), (i) Salvatore Zinno as the person authorized to initial plans, drawings, approvals and to sign change orders pursuant to this Work Letter and (ii) an officer of Landlord as the person authorized to sign any amendments to this Work Letter or the Lease.  Tenant shall not be obligated to respond to or act upon any such item until such item has been initialed or signed (as applicable) by the appropriate Landlord’s Authorized Representative.  Landlord may change either Landlord’s Authorized Representative upon one (1) business day’s prior written notice to Tenant.

(b)Tenant designates [_______] (“Tenant’s Authorized Representative”) as the person authorized to initial and sign all plans, drawings, change orders and approvals pursuant to this Work Letter.  Landlord shall not be obligated to respond to or act upon any such item until such item has been initialed or signed (as applicable) by Tenant’s Authorized Representative.  Tenant may change Tenant’s Authorized Representative upon one (1) business day’s prior written notice to Landlord.

1.2.Schedule.  The schedule for design and development of the Tenant Improvements, including the time periods for preparation and review of construction documents, approvals and performance, shall be in accordance with the scheduled attached hereto as Schedule 1 (the “Schedule”).  The Schedule shall be subject to adjustment as mutually agreed upon in writing by the parties, or as otherwise provided in this Work Letter.  

1.3.Landlord’s Architects, Contractors and Consultants.  The architect, engineering consultants, design team, general contractor and subcontractors responsible for the construction of the Tenant Improvements shall be selected by Landlord.  Landlord hereby selects R.E. Dinneen as the architect and The Richmond Group as the general contractor.

2.Tenant Improvements.  All Tenant Improvements shall be performed by Landlord’s contractor, at Tenant’s sole cost and expense (subject to Landlord’s obligations with respect to any portion of the TI Allowance used by Landlord in completing the Tenant Improvements) and

 

 

B-1

 


 

in substantial accordance with the Approved Plans (as defined below), the Lease and this Work Letter.  To the extent that the total projected cost of the Tenant Improvements (as projected by Landlord) exceeds the TI Allowance (such excess, the “Excess TI Costs”), Tenant shall advance to Landlord any Excess TI Costs within ten (10) days after receipt of an invoice therefor, but in any case before Landlord commences the Tenant Improvements.  If Landlord is delayed in commencing the Tenant Improvements due to Tenant’s failure to timely pay the Excess TI Costs to Landlord, Landlord shall be entitled to a day-for-day extension to achieve Substantial Completion of the Tenant Improvements for the period of such delay.  If the actual Excess TI Costs are less than the Excess TI Costs paid by Tenant to Landlord, Landlord shall credit Tenant with the overage paid by Tenant against Tenant’s Rent obligations, beginning after Landlord has completed the final accounting for the Tenant Improvements. If the cost of the Tenant Improvements (as projected by Landlord) increases over Landlord’s initial projection, then Landlord may notify Tenant and Tenant shall deposit any additional Excess TI Costs with Landlord in the same way that Tenant deposited the initial Excess TI Costs.  If Tenant fails to pay, or is late in paying, any sum due to Landlord under this Work Letter, then Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including the right to interest and the right to assess a late charge), and for purposes of any litigation instituted with regard to such amounts the same shall be considered Rent.  All material and equipment furnished by Landlord or its contractors as the Tenant Improvements shall be new or “like new,” and the Tenant Improvements shall be performed in a first-class, workmanlike manner.

2.1.Schematic Design Plans.  Landlord and Tenant hereby approve the plans and specifications for the Tenant Improvements (the “Schematic Design Plans”) and the Basis of Design, each attached to this Work Letter as Schedule 2.

2.2.Construction Plans.  Landlord shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Schematic Design Plans and the Basis of Design and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below).  As soon as such final plans and specifications (“Construction Plans”) are completed, Landlord shall deliver the same to Tenant for Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed.  Such Construction Plans shall be approved or disapproved by Tenant within five (5) business days after delivery to Tenant.  Tenant’s failure to respond within such five (5) business day period shall be deemed approval by Tenant.  If the Construction Plans are disapproved by Tenant, then Tenant shall notify Landlord in writing of its reasonable objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans.  Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Landlord shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval.  The Construction Plans so approved, and all change orders specifically permitted by this Work Letter, are referred to herein as the “Approved Plans.” In the event that the Construction Plans are not approved by Tenant within the initial five (5) business day period specified in this Section 2.2, then, notwithstanding anything in the Lease or this Work Letter to the contrary, it shall be deemed a delay by Tenant, and in accordance with Section 4.2 of the Lease, the Term Commencement Date shall be the date that the Term Commencement Date would have occurred but for such delay.

 

 

B-2

 


 

2.3.Changes to the Tenant Improvements.  Any changes to the Approved Plans (each, a “Change”) shall be requested and instituted in accordance with the provisions of this Article 2 and shall be subject to the written approval of the non-requesting party in accordance with this Work Letter.

(a)Change Request.  Either Landlord or Tenant may request Changes after Tenant approves the Approved Plans by notifying the other party thereof in writing in substantially the same form as the AIA standard change order form (a “Change Request”), which Change Request shall detail the nature and extent of any requested Changes, including (a) the Change, (b) the party required to perform the Change and (c) any modification of the Approved Plans and the Schedule, as applicable, necessitated by the Change.  If the nature of a Change requires revisions to the Approved Plans, then the requesting party shall be solely responsible for the cost and expense of such revisions and any increases in the cost of the Tenant Improvements as a result of such Change.  Change Requests shall be signed by the requesting party’s Authorized Representative.

(b)Approval of Changes.  All Change Requests shall be subject to the other party’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed.  The non-requesting party shall have five (5) business days after receipt of a Change Request to notify the requesting party in writing of the non-requesting party’s decision either to approve or object to the Change Request.  The non-requesting party’s failure to respond within such five (5) business day period shall be deemed approval by the non-requesting party.

3.Requests for Consent.  Except as otherwise provided in this Work Letter, Tenant shall respond to all requests for consents, approvals or directions made by Landlord pursuant to this Work Letter within five (5) business days following Tenant’s receipt of such request.  Tenant’s failure to respond within such five (5) business day period shall be deemed approval by Tenant.

4. TI Allowance.

4.1.Application of TI Allowance.  Landlord shall contribute, in the following order, the TI Allowance and any Excess TI Costs advanced by Tenant to Landlord toward the costs and expenses incurred in connection with the performance of the Tenant Improvements, in accordance with Article 4 of the Lease.  If the entire TI Allowance is not applied toward or reserved for the costs of the Tenant Improvements, then Tenant shall not be entitled to a credit of such unused portion of the TI Allowance.  If the entire Excess TI Costs advanced by Tenant to Landlord are not applied toward the costs of the Tenant Improvements, then Landlord shall promptly return such excess to Tenant following completion of the Tenant Improvements.  Tenant may apply the TI Allowance for the payment of construction and other costs in accordance with the terms and provisions of the Lease.

4.2.Approval of Budget for the Tenant Improvements.  The parties agree that the budget for the Tenant Improvements attached hereto as Schedule 3 is a preliminary budget (the “Preliminary Budget”).  Landlord anticipates obtaining from its general contractor updated budgets in connection with the Construction Plans, which shall be subject to the review and approval of Landlord and Tenant.  Notwithstanding anything to the contrary set forth elsewhere

 

 

B-3

 


 

in this Work Letter or the Lease, Landlord shall not have any obligation to expend any portion of the TI Allowance until Landlord and Tenant shall have approved in writing a final budget for the Tenant Improvements (the “Approved Budget”).  Prior to Landlord’s approval of the Approved Budget, Tenant shall pay all of the costs and expenses incurred in connection with the Tenant Improvements as they become due.  Tenant shall promptly reimburse Landlord for actual costs or expenses relating to the Tenant Improvements that exceed the amount of the TI Allowance.

5.Miscellaneous.

5.1.Incorporation of Lease Provisions.  Sections 40.6 through 40.19 of the Lease are incorporated into this Work Letter by reference, and shall apply to this Work Letter in the same way that they apply to the Lease.

5.2.General.  Except as otherwise set forth in the Lease or this Work Letter, this Work Letter shall not apply to improvements performed in any additional premises added to the Premises at any time or from time to time, whether by any options under the Lease or otherwise; or to any portion of the Premises or any additions to the Premises in the event of a renewal or extension of the original Term, whether by any options under the Lease or otherwise, unless the Lease or any amendment or supplement to the Lease expressly provides that such additional premises are to be delivered to Tenant in the same condition as the initial Premises.

[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]


 

 

B-4

 


 

IN WITNESS WHEREOF, Landlord and Tenant have executed this Work Letter as a sealed Massachusetts instrument to be effective on the date first above written.

LANDLORD:

BMR-ROGERS STREET LLC,
a Delaware limited liability company

By:

 

Name:

 

Title:

 

 

TENANT:

SYNLOGIC, INC.,

a Delaware corporation

 

By:

 

Name:

 

Title:

 

 

 

 

 

 

B-5

 


 

EXHIBIT B-1

TENANT WORK INSURANCE SCHEDULE

Tenant shall be responsible for requiring all of Tenant contractors doing construction or renovation work to purchase and maintain such insurance as shall protect it from the claims set forth below which may arise out of or result from any Tenant Work whether such Tenant Work is completed by Tenant or by any Tenant contractors or by any person directly or indirectly employed by Tenant or any Tenant contractors, or by any person for whose acts Tenant or any Tenant contractors may be liable:

1.Claims under workers’ compensation, disability benefit and other similar employee benefit acts which are applicable to the Tenant Work to be performed.

2.Claims for damages because of bodily injury, occupational sickness or disease, or death of employees under any applicable employer’s liability law.

3.Claims for damages because of bodily injury, or death of any person other than Tenant’s or any Tenant contractors’ employees.

4.Claims for damages insured by usual personal injury liability coverage which are sustained (a) by any person as a result of an offense directly or indirectly related to the employment of such person by Tenant or any Tenant contractors or (b) by any other person.

5.Claims for damages, other than to the Tenant Work itself, because of injury to or destruction of tangible property, including loss of use therefrom.

6.Claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle.

Tenant contractors’ Commercial General Liability Insurance shall include premises/operations (including explosion, collapse and underground coverage if such Tenant Work involves any underground work), elevators, independent contractors, products and completed operations, and blanket contractual liability on all written contracts, all including broad form property damage coverage.

Tenant contractors’ Commercial General, Automobile, Employers and Umbrella Liability Insurance shall be written for not less than limits of liability as follows:

 

a.    Commercial General Liability:

        Bodily Injury and Property Damage

 

Commercially reasonable amounts, but in any event no less than $1,000,000 per occurrence and $2,000,000 general  aggregate, with $2,000,000 products and  completed operations aggregate.

 

 

 

B-1-1

 


b.    Commercial Automobile Liability:

        Bodily Injury and Property Damage

$1,000,000 per accident

c.    Employer’s Liability:

 

       Each Accident

       Disease – Policy Limit

       Disease – Each Employee

$500,000

$500,000

$500,000

d.Umbrella Liability:

Bodily Injury and Property Damage

Commercially reasonable amounts (excess of coverages a, b and c above), but in any event no less than $5,000,000 per occurrence / aggregate.

All subcontractors for Tenant contractors shall carry the same coverages and limits as specified above, unless different limits are reasonably approved by Landlord.  The foregoing policies shall contain a provision that coverages afforded under the policies shall not be canceled or not renewed until at least thirty (30) days’ prior written notice has been given to the Landlord.  Certificates of insurance including required endorsements showing such coverages to be in force shall be filed with Landlord prior to the commencement of any Tenant Work and prior to each renewal.  Coverage for completed operations must be maintained for the lesser of ten (10) years and the applicable statue of repose following completion of the Tenant Work, and certificates evidencing this coverage must be provided to Landlord.  The minimum A.M. Best’s rating of each insurer shall be A- VII.  Landlord and its mortgagees shall be named as an additional insureds under Tenant contractors’ Commercial General Liability, Commercial Automobile Liability and Umbrella Liability Insurance policies as respects liability arising from work or operations performed, or ownership, maintenance or use of any autos, by or on behalf of such contractors.  Each contractor and its insurers shall provide waivers of subrogation with respect to any claims covered or that should have been covered by valid and collectible workers’ compensation or employer’s liability insurance, including any deductibles or self-insurance maintained thereunder.

If any contractor’s work involves the handling or removal of asbestos (as determined by Landlord in its sole and absolute discretion), such contractor shall also carry Pollution Legal Liability insurance.  Such coverage shall include bodily injury, sickness, disease, death or mental anguish or shock sustained by any person; property damage, including physical injury to or destruction of tangible property (including the resulting loss of use thereof), clean-up costs and the loss of use of tangible property that has not been physically injured or destroyed; and defense costs, charges and expenses incurred in the investigation, adjustment or defense of claims for such damages.  Coverage shall apply to both sudden and non-sudden pollution conditions including the discharge, dispersal, release or escape of smoke, vapors, soot, fumes, acids, alkalis, toxic chemicals, liquids or gases, waste materials or other irritants, contaminants or pollutants into or upon land, the atmosphere or any watercourse or body of water.  Claims-made coverage is permitted, provided the policy retroactive date is continuously maintained prior to the Term Commencement Date, and coverage is continuously maintained during all periods in which Tenant occupies the Premises.  Coverage shall be maintained with limits of not less than $1,000,000 per incident with a $2,000,000 policy aggregate.


 

 

B-1-2

 


SCHEDULE 1 TO WORK LETTER

 

SCHEDULE

 

(see attached)

 


 

 

B-1-3

 


SCHEDULE 2 TO WORK LETTER

SCHEMATIC DESIGN PLANS AND BASIS OF DESIGN

 

(see attached)

 


 

 

B-1-4

 


SCHEDULE 3 TO WORK LETTER

PRELIMINARY BUDGET

 

(see attached)

 

 

 

 

 

B-1-5

 


 

EXHIBIT C

ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE

AND TERM EXPIRATION DATE

This acknowledgement of TERM commencement date and TERM EXPIRATION DATE is entered into as of [_______], 20[__], with reference to that certain Lease (the “Lease”) dated as of [_______], 2017, by SYNLOGIC, INC., a Delaware corporation (“Tenant”), in favor of BMR-ROGERS STREET LLC, a Delaware limited liability company  (“Landlord”).  All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease.

Tenant hereby confirms the following:

1.Tenant accepted possession of the Premises for use in accordance with the Permitted Use on [_______], 20[__].  Tenant first occupied the Premises for the Permitted Use on [_______], 20[__].

2.The Premises are in good order, condition and repair.

3.The Tenant Improvements are Substantially Complete.

4.All conditions of the Lease to be performed by Landlord as a condition to the full effectiveness of the Lease have been satisfied, and Landlord has fulfilled all of its duties in the nature of inducements offered to Tenant to lease the Premises, except as follows:  ____________

5.In accordance with the provisions of Article 4 of the Lease, the Term Commencement Date is [_______], 20[__], and, unless the Lease is terminated prior to the Term Expiration Date pursuant to its terms, the Term Expiration Date shall be [_______], 20[__].

6.The Lease is in full force and effect, and the same represents the entire agreement between Landlord and Tenant concerning the Premises.

7.Tenant has no existing defenses against the enforcement of the Lease by Landlord, and there exist no offsets or credits against Rent owed or to be owed by Tenant.

 

 

C-1

 


8.The obligation to pay Rent is presently in effect and all Rent obligations on the part of Tenant under the Lease commenced to accrue on [_______], 20[__], with Base Rent payable on the dates and amounts set forth in the chart below, subject to annual adjustment under Article 8 of the Lease:

Dates

Approximate Square Feet of Rentable Area*

Base Rent per Square Foot of Rentable Area

Monthly Base Rent*

Annual Base Rent*

Rent Commencement Date- The day immediately prior to the first (1st) annual anniversary of the Rent Commencement Date

41,346

$76.00 annually

$261,858.00

$3,142,296.00

9.The undersigned Tenant has not made any prior assignment, transfer, hypothecation or pledge of the Lease or of the rents thereunder or sublease of the Premises or any portion thereof.

[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]

 

 

C-2

 


 

IN WITNESS WHEREOF, Tenant has executed this Acknowledgment of Term Commencement Date and Term Expiration Date as of the date first written above.

TENANT:

SYNLOGIC, INC.,

a Delaware corporation

 

By:

 

Name:

 

Title:

 

 

 

 

 

 

C-3

 


 

EXHIBIT D

Intentionally omitted

 

 

 

D-1

 


 

EXHIBIT E

[FORM OF LETTER OF CREDIT

[On letterhead or L/C letterhead of Issuer]

LETTER OF CREDIT

Date: _______, 20__

BMR-ROGERS STREET LLC (the “Beneficiary”)

_________________________

_________________________

Attention: ________________

L/C. No.: _________________

Loan No. : ________________

Ladies and Gentlemen:

We establish in favor of Beneficiary our irrevocable and unconditional Letter of Credit numbered as identified above (the “L/C”) for an aggregate amount of $1,064,000.00, expiring at __:00 p.m. on _______ or, if such day is not a Banking Day, then the next succeeding Banking Day (such date, as extended from time to time, the “Expiry Date”). “Banking Day” means a weekday except a weekday when commercial banks in _____________ are authorized or required to close.

We authorize Beneficiary to draw on us (the “Issuer”) for the account of _______ (the “Account Party”), under the terms and conditions of this L/C.

Funds under this L/C are available by presenting the following documentation (the “Drawing Documentation”): (a) the original L/C and (b) a sight draft substantially in the form of Attachment 1, with blanks filled in and bracketed items provided as appropriate. No other evidence of authority, certificate, or documentation is required.

Drawing Documentation must be presented at Issuer’s office at ____________ on or before the Expiry Date by personal presentation, courier or messenger service, or fax. Presentation by fax shall be effective upon electronic confirmation of transmission as evidenced by a printed report from the sender’s fax machine. After any fax presentation, but not as a condition to its effectiveness, Beneficiary shall with reasonable promptness deliver the original Drawing Documentation by any other means.  Issuer will on request issue a receipt for Drawing Documentation.

 

 

E-1

 


We agree, irrevocably, and irrespective of any claim by any other person, to honor drafts drawn under and in conformity with this L/C, within the maximum amount of this L/C, presented to us on or before the Expiry Date, provided we also receive (on or before the Expiry Date) any other Drawing Documentation this L/C requires.

We shall pay this L/C only from our own funds by check or wire transfer, in compliance with the Drawing Documentation.

If Beneficiary presents proper Drawing Documentation to us on or before the Expiry Date, then we shall pay under this L/C at or before the following time (the “Payment Deadline”): (a) if presentment is made at or before noon of any Banking Day, then the close of such Banking Day; and (b) otherwise, the close of the next Banking Day.  We waive any right to delay payment beyond the Payment Deadline. If we determine that Drawing Documentation is not proper, then we shall so advise Beneficiary in writing, specifying all grounds for our determination, within one Banking Day after the Payment Deadline.

Partial drawings are permitted. This L/C shall, except to the extent reduced thereby, survive any partial drawings.

We shall have no duty or right to inquire into the validity of or basis for any draw under this L/C or any Drawing Documentation.  We waive any defense based on fraud or any claim of fraud.

The Expiry Date shall automatically be extended by one year (but never beyond _____ (the “Outside Date”)) unless, on or before the date 90 days before any Expiry Date, we have given Beneficiary notice that the Expiry Date shall not be so extended (a “Nonrenewal Notice”). We shall promptly upon request confirm any extension of the Expiry Date under the preceding sentence by issuing an amendment to this L/C, but such an amendment is not required for the extension to be effective. We need not give any notice of the Outside Date.

Beneficiary may from time to time without charge transfer this L/C, in whole but not in part, to any transferee (the “Transferee”).  Issuer shall look solely to Account Party for payment of any fee for any transfer of this L/C.  Such payment is not a condition to any such transfer. Beneficiary or Transferee shall consummate such transfer by delivering to Issuer the original of this L/C and a Transfer Notice substantially in the form of Attachment 2, purportedly signed by Beneficiary, and designating Transferee.  Issuer shall promptly reissue or amend this L/C in favor of Transferee as Beneficiary.  Upon any transfer, all references to Beneficiary shall automatically refer to Transferee, who may then exercise all rights of Beneficiary.  Issuer expressly consents to any transfers made from time to time in compliance with this paragraph.

Any notice to Beneficiary shall be in writing and delivered by hand with receipt acknowledged or by overnight delivery service such as FedEx (with proof of delivery) at the above address, or such other address as Beneficiary may specify by written notice to Issuer. A copy of any such notice shall also be delivered, as a condition to the effectiveness of such notice, to: ___________ (or such replacement as Beneficiary designates from time to time by written notice).

 

 

E-2

 


No amendment that adversely affects Beneficiary shall be effective without Beneficiary’s written consent.

This L/C is subject to and incorporates by reference: (a) the International Standby Practices 98 (“ISP 98”); and (b) to the extent not inconsistent with ISP 98, Article 5 of the Uniform Commercial Code of the State of New York.

Very truly yours,

[Issuer Signature]

 

 

 

E-3

 


 

ATTACHMENT 1 TO EXHIBIT E

FORM OF SIGHT DRAFT

[Beneficiary Letterhead]

TO:

[Name and Address of Issuer]

SIGHT DRAFT

AT SIGHT, pay to the Order of ______________, the sum of ______________ United States Dollars ($______________). Drawn under [Issuer] Letter of Credit No. ______________ dated ______________.

[Issuer is hereby directed to pay the proceeds of this Sight Draft solely to the following account: _________________________.]

[Name and signature block, with signature or purported signature of Beneficiary]

Date: ________________

 

 

 

E-1-1

 


 

ATTACHMENT 2 TO EXHIBIT E

FORM OF TRANSFER NOTICE

[Beneficiary Letterhead]

TO:

[Name and Address of Issuer] (the “Issuer”)

TRANSFER NOTICE

By signing below, the undersigned, Beneficiary (the “Beneficiary”) under Issuer’s Letter of Credit No. ______________ dated ______________ (the “L/C”), transfers the L/C to the following transferee (the “Transferee”):

[Transferee Name and Address]

The original L/C is enclosed. Beneficiary directs Issuer to reissue or amend the L/C in favor of Transferee as Beneficiary. Beneficiary represents and warrants that Beneficiary has not transferred, assigned, or encumbered the L/C or any interest in the L/C, which transfer, assignment, or encumbrance remains in effect.

[Name and signature block, with signature or purported signature of Beneficiary]

Date: ________________]

 

 

 

E-2-1

 


 

EXHIBIT F

RULES AND REGULATIONS

NOTHING IN THESE RULES AND REGULATIONS (“RULES AND REGULATIONS”) SHALL SUPPLANT ANY PROVISION OF THE LEASE.  IN THE EVENT OF A CONFLICT OR INCONSISTENCY BETWEEN THESE RULES AND REGULATIONS AND THE LEASE, THE LEASE SHALL PREVAIL.

 

1.

No Tenant Party shall encumber or obstruct the common entrances, lobbies, elevators, sidewalks and stairways of the Building(s) or the Project or use them for any purposes other than ingress or egress to and from the Building(s) or the Project.

 

2.

Except as specifically provided in the Lease, no sign, placard, picture, advertisement, name or notice shall be installed or displayed on any part of the outside of the Premises or the Building without Landlord’s prior written consent.  Landlord shall have the right to remove, at Tenant’s sole cost and expense and without notice, any sign installed or displayed in violation of this rule.

 

3.

If Landlord objects in writing to any curtains, blinds, shades, screens, hanging plants or other similar objects attached to or used in connection with any window or door of the Premises or placed on any windowsill, and (a) such window, door or windowsill is visible from the exterior of the Premises and (b) such curtain, blind, shade, screen, hanging plant or other object is not included in plans approved by Landlord, then Tenant shall promptly remove such curtains, blinds, shades, screens, hanging plants or other similar objects at its sole cost and expense.

 

4.

Deliveries shall be made no earlier than 7 a.m. and no later than 6 p.m., and shall comply with the City of Cambridge Truck Traffic and Noise Ordinance.  No deliveries shall be made that impede or interfere with other tenants in or the operation of the Project.  Movement of furniture, office equipment or any other large or bulky material(s) through the Common Area shall be restricted to such hours as Landlord may designate and shall be subject to reasonable restrictions that Landlord may impose.  Tenant will ensure all overhead loading dock doors are secured after receipt of any delivery.  Tenant must accept all deliveries.  Building personnel, security or Landlord's third party contractors will not accept any deliveries on behalf of Tenant.

 

5.

Tenant shall not place a load upon any floor of the Premises that exceeds the load per square foot that (a) such floor was designed to carry or (b) is allowed by Applicable Laws.  Fixtures and equipment that cause noises or vibrations that may be transmitted to the structure of the Building to such a degree as to be objectionable to other tenants shall be placed and maintained by Tenant, at Tenant’s sole cost and expense, on vibration eliminators or other devices sufficient to eliminate such noises and vibrations to levels reasonably acceptable to Landlord and the affected tenants of the Project.

 

 

F-1

 


 

6.

Tenant shall not use any method of HVAC other than that shown in the Tenant Improvement plans approved in writing by Landlord.

 

7.

Tenant shall not install any radio, television or other antennae; cell or other communications equipment; or other devices on the roof or exterior walls of the Premises except in accordance with the Lease.  Tenant shall not interfere with radio, television or other digital or electronic communications at the Project or elsewhere.

 

8.

Canvassing, peddling, soliciting and distributing handbills or any other written material within, on or around the Project (other than within the Premises) are prohibited.  Tenant shall cooperate with Landlord to prevent such activities by any Tenant Party.

 

9.

The loading dock shall be used for all deliveries.  All persons parking at the loading dock must adhere to a thirty (30) minute limit when making deliveries.  Vehicles left unattended beyond the time limit are subject to towing at the vehicle owner’s expense.  Landlord shall not be responsible for damage to vehicles, businesses or personnel incurred due to parking or loading dock operations.

 

10.

Except as otherwise permitted under the Lease, Tenant shall not mark, paint, drill into or in any way deface any part of the Building or Premises.  No boring, driving of nails or screws, cutting or stringing of wires shall be permitted except with Landlord’s prior written consent, which Landlord shall not unreasonably withhold, or as Landlord may direct.

 

11.

Tenant shall only discharge industrial sewage if Tenant, at its sole cost and expense, obtains all necessary permits and licenses therefor, including (without limitation) permits from State and local authorities having jurisdiction thereover.

 

12.

Tenant shall store all of its trash, garbage and Hazardous Materials in receptacles within its Premises or in receptacles designated by Landlord outside of the Premises.  Tenant shall not place in any such receptacle any material that cannot be disposed of in the ordinary and customary manner of trash, garbage and Hazardous Materials disposal.  Any Hazardous Materials transported through the Common Area shall be held in secondary containment devices.  Tenant shall be responsible, at its sole cost and expense, for Tenant’s removal of its Hazardous Materials.  Tenant is encouraged to participate in the waste removal and recycling program in place at the Project.  

 

13.

The Premises shall not be used for lodging or for any improper purpose.  No cooking shall be done or permitted in the Premises; provided, however, that Tenant may use (a) equipment approved in accordance with the requirements of insurance policies that Landlord or Tenant is required to purchase and maintain pursuant to the Lease for brewing coffee, tea, hot chocolate and similar beverages, (b) microwave ovens for employees’ use and (c) equipment shown on Tenant Improvement plans approved by Landlord; provided, further, that any such equipment and microwave ovens are used in accordance with Applicable Laws.

 

 

F-2

 


 

14.

Tenant shall not, without Landlord’s prior written consent, use the name of the Project, if any, in connection with or in promoting or advertising Tenant’s business except as Tenant’s address.

 

15.

Tenant shall comply with all safety, fire protection and evacuation procedures and regulations established by Landlord or any Governmental Authority.

 

16.

Tenant assumes any and all responsibility for protecting the Premises from theft, robbery and pilferage, which responsibility includes keeping doors locked and other means of entry to the Premises closed.

 

17.

Tenant shall not modify any locks to the Premises without Landlord’s prior written consent, which consent Landlord shall not unreasonably withhold, condition or delay.  Tenant shall furnish Landlord with copies of keys, pass cards or similar devices for locks to the Premises.

 

18.

Tenant shall cooperate and participate in all reasonable security programs affecting the Premises.

 

19.

Tenant shall not permit any animals in the Project, other than for guide animals or for use in laboratory experiments.

 

20.

Bicycles shall not be taken into the Building (including the elevators and stairways of the Building) except into areas designated by Landlord.

 

21.

The water and wash closets and other plumbing fixtures shall not be used for any purposes other than those for which they were constructed, and no sweepings, rubbish, rags or other substances shall be deposited therein.

 

22.

Discharge of industrial sewage shall only be permitted if Tenant, at its sole expense, first obtains all necessary permits and licenses therefor from all applicable Governmental Authorities.

 

23.

Smoking is prohibited at the Project, except in designated outdoor areas, if any.

 

24.

The Project’s hours of operation are currently 24 hours a day, seven days a week.

 

25.

Tenant shall comply with all orders, requirements and conditions now or hereafter imposed by Applicable Laws or Landlord (“Waste Regulations”) regarding the collection, sorting, separation and recycling of waste products, garbage, refuse and trash generated by Tenant (collectively, “Waste Products”), including (without limitation) the separation of Waste Products into receptacles reasonably approved by Landlord and the removal of such receptacles in accordance with any collection schedules prescribed by Waste Regulations.

 

26.

Tenant, at Tenant’s sole cost and expense, shall cause the Premises to be exterminated on a monthly basis to Landlord’s reasonable satisfaction and shall cause all portions of the Premises used for the storage, preparation, service or consumption of food or beverages to be cleaned daily in a manner reasonably satisfactory to Landlord, and to be treated against infestation by insects, rodents and other vermin and pests whenever there is

 

 

F-3

 


 

evidence of any infestation.  Tenant shall not permit any person to enter the Premises or the Project for the purpose of providing such extermination services, unless such persons have been approved by Landlord.  If requested by Landlord, Tenant shall, at Tenant’s sole cost and expense, store any refuse generated in the Premises by the consumption of food or beverages in a cold box or similar facility.

 

27.

If Tenant desires to use any portion of the Common Area for a Tenant-related event, Tenant must notify Landlord in writing at least thirty (30) days prior to such event on the form attached as Attachment 1 to this Exhibit, which use shall be subject to Landlord’s prior written consent, not to be unreasonably withheld, conditioned or delayed.  Notwithstanding anything in this Lease or the completed and executed Attachment to the contrary, Tenant shall be solely responsible for setting up and taking down any equipment or other materials required for the event, and shall promptly pick up any litter and report any property damage to Landlord related to the event.  Any use of the Common Area pursuant to this Section shall be subject to the provisions of Article 28 of the Lease.

Landlord may waive any one or more of these Rules and Regulations for the benefit of Tenant or any other tenant, but no such waiver by Landlord shall be construed as a waiver of such Rules and Regulations in favor of Tenant or any other tenant, nor prevent Landlord from thereafter enforcing any such Rules and Regulations against any or all of the tenants of the Project, including Tenant.  These Rules and Regulations are in addition to, and shall not be construed to in any way modify or amend, in whole or in part, the terms covenants, agreements and conditions of the Lease.  Landlord reserves the right to make such other and additional reasonable and uniform rules and regulations as, in its judgment, may from time to time be needed for safety and security, the care and cleanliness of the Project, or the preservation of good order therein; provided, however, that Landlord shall provide reasonable written notice to Tenant of such rules and regulations prior to them taking effect; and provided, further, that no such additional rule or regulation shall adversely affect Tenant’s use or enjoyment of the Project as permitted under the Lease for the Permitted Use.  Tenant agrees to abide by these Rules and Regulations and any such additional rules and regulations issued or adopted by Landlord.  Tenant shall be responsible for the observance of these Rules and Regulations by all Tenant Parties.

 

 

F-4

 


 

ATTACHMENT 1 TO EXHIBIT F

REQUEST FOR USE OF COMMON AREA

REQUEST FOR USE OF COMMON AREA

 

Date of Request:

 

 

 

 

 

Landlord/Owner:

 

 

 

 

 

Tenant/Requestor:

 

 

 

 

 

Property Location:

 

 

 

 

 

Event Description:

 

 

 

 

 

Proposed Plan for Security & Cleaning:

 

 

 

 

 

Date of Event:

 

 

 

 

 

Hours of Event: (to include set-up and take down):

 

 

 

 

 

Location at Property (see attached map):

 

 

 

 

 

Number of Attendees:

 

 

 

Open to the Public?[___] YES[___] NO

Food and/or Beverages?[___] YES[___] NO

If YES:

 

Will food be prepared on site?     [___] YES [___] NO

 

Please describe:

 

Will alcohol be served?[___] YES[___] NO

 

Please describe:

 

Will attendees be charged for alcohol?  [___] YES[___] NO

 

Is alcohol license or permit required? [___] YES[___] NO

 

Does caterer have alcohol license or permit: [___] YES[___] NO[___] N/A    

Other Amenities (tent, booths, band, food trucks, bounce house, etc.):

 

 

F-1-1

 


 

Other Event Details or Special Circumstances:

 

The undersigned certifies that the foregoing is true, accurate and complete and he/she is duly authorized to sign and submit this request on behalf of the Tenant/Requestor named above.

[INSERT NAME OF TENANT/REQUESTOR]

 

By:

 

Name:

 

Title:

 

Date:

 

 

 

 

 

 

 

 

 

 

 

 

F-1-2

 


 

EXHIBIT G

PTDM

 

(see attached)

 

 

G-1-1

 


 

EXHIBIT H

TENANT’S PROPERTY

 

 

To be provided by Tenant prior to the Term Commencement Date.

 

 

H-1

 


EXHIBIT I

FORM OF ESTOPPEL CERTIFICATE

To:

BMR-Rogers Street LLC

17190 Bernardo Center Drive

San Diego, California  92128

Attention: Legal Department

BioMed Realty, L.P.

17190 Bernardo Center Drive

San Diego, California  92128

Re:

Suite [___] (the “Premises”) at 301 Binney Street, Cambridge, Massachusetts (the “Property”)

The undersigned tenant (“Tenant”) hereby certifies to you as follows:

1.Tenant is a tenant at the Property under a lease (the “Lease”) for the Premises dated as of [_______], 20[__].  The Lease has not been cancelled, modified, assigned, extended or amended [except as follows:  [_______]], and there are no other agreements, written or oral, affecting or relating to Tenant’s lease of the Premises or any other space at the Property.  The lease term expires on [_______], 20[__].

2.Tenant took possession of the Premises, currently consisting of [_______] square feet, on [_______], 20[__], and commenced to pay rent on [_______], 20[__].  Tenant has full possession of the Premises, has not assigned the Lease or sublet any part of the Premises, and does not hold the Premises under an assignment or sublease[, except as follows:  [_______]].

3.All base rent, rent escalations and additional rent under the Lease have been paid through [_______], 20[__].  There is no prepaid rent[, except $[_______]][, and the amount of security deposit is $[_______] [in cash][OR][in the form of a letter of credit]].  Tenant currently has no right to any future rent abatement under the Lease.

4.Base rent is currently payable in the amount of $[_______] per month.

5.Tenant is currently paying estimated payments of additional rent of $[_______] per month on account of real estate taxes, insurance, management fees and Common Area maintenance expenses.

6.All work to be performed for Tenant under the Lease has been performed as required under the Lease and has been accepted by Tenant[, except [_______]], and all allowances to be paid to Tenant, including allowances for tenant improvements, moving expenses or other items, have been paid.

 

 

2

 


7.The Lease is in full force and effect, free from default and free from any event that could become a default under the Lease, and Tenant has no claims against the landlord or offsets or defenses against rent, and there are no disputes with the landlord. Tenant has received no notice of prior sale, transfer, assignment, hypothecation or pledge of the Lease or of the rents payable thereunder[, except [_______]].

8.[Tenant has the following expansion rights or options for leasing additional space at the Property:  [_______].][OR][Tenant has no rights or options to purchase the Property.]

9.To Tenant’s knowledge, no hazardous wastes have been generated, treated, stored or disposed of by or on behalf of Tenant in, on or around the Premises or the Project in violation of any environmental laws.

10.The undersigned has executed this Estoppel Certificate with the knowledge and understanding that [INSERT NAME OF LANDLORD, PURCHASER OR LENDER, AS APPROPRIATE] or its assignee is [acquiring the Property/making a loan secured by the Property] in reliance on this certificate and that the undersigned shall be bound by this certificate.  The statements contained herein may be relied upon by [INSERT NAME OF PURCHASER OR LENDER, AS APPROPRIATE], [LANDLORD], BioMed Realty, L.P., BRE-Edison Parent L.P., and any [other] mortgagee of the Property and their respective successors and assigns.

Any capitalized terms not defined herein shall have the respective meanings given in the Lease.

Dated this [____] day of [_______], 20[__].

[_______],

a [_______]

 

By:

 

Name:

 

Title:

 

 

 

 

 

 


 

 

3

 


EXHIBIT J

FORM OF GROUND LEASE NONDISTURBANCE AND ATTORNMENT AGREEMENT

 

NONDISTURBANCE AND ATTORNMENT AGREEMENT

 

 

THIS AGREEMENT (“Agreement”), made this 31st day of March, 2015 between BMR-ROGERS STREET LLC, a Delaware limited liability company with offices at 17190 Bernardo Center Drive, San Diego, California (“Tenant”), SYNLOGIC, INC., a Delaware corporation with offices at 200 Sidney Street, Cambridge, Massachusetts (“Subtenant”) and MBA-ROGERS STREET, LLC, successor in interest to MBA-Cambridge, LLC and O&T Realty, LLC (“Ground Landlord”).

 

Background

 

A. Tenant has entered into a certain ground lease dated March 30, 1999, as amended by that certain letter dated July 29, 1999 and that certain Agreement Regarding Arbitration and Lease Amendments dated December 15, 1999, and as such ground lease has been assigned pursuant to that certain Assignment and Assumption of Ground Lease dated as of April 4, 2007 (collectively, and as the same may have been further amended, supplemented or otherwise modified, the “Ground Lease”), with the Ground Lease covering, in part, the building known and numbered as 301 Binney Street, Cambridge, Massachusetts (the “Building”) which Building is located on Ground Landlord’s property described in Exhibit A attached hereto (the “Property”).  A notice of said Ground Lease is recorded with the Middlesex (South) Registry of Deeds in Book 31460, Page 4.

 

B. Subtenant and Tenant have entered into a lease, a copy of which is attached as Exhibit B (the “Sublease”) (provided that a copy of the Sublease shall not be attached to any counterpart of this Agreement to be recorded at the Registry of Deeds) for certain premises located on the fourth floor of the Building (the “Premises”).  

 

C. Ground Landlord has been requested by Tenant and Subtenant to enter into a nondisturbance agreement with Subtenant.

 

 

 

4

 


AGREEMENT

 

NOW, THEREFORE in consideration of the promises and the mutual covenants hereinafter contained, the parties hereto mutually covenant and agree as follows:

 

1.Ground Landlord consents to the execution and delivery of the Sublease. The provisions of this Agreement set forth in Sections 2, 3 and 4, below, shall take effect upon the Execution Date (as defined in the Sublease).

 

 

2. Effective as of the Execution Date, if the Ground Lease shall terminate before the expiration of the then-current term, unless such termination results from condemnation or fire or other catastrophe, the Sublease, if then in existence, shall continue with the same force and effect as if Ground Landlord as lessor and Subtenant as lessee had entered into a lease for a term equal to the then unexpired term of the Sublease, as of the termination of the Ground Lease, containing the same terms, covenants and conditions as those contained in the Sublease (except as hereinafter provided), including the rights of renewal therein.

 

3. (a)    Intentionally Omitted.

 

(b)Effective as of the Execution Date, any option which shall be or become vested in Subtenant to cancel the Sublease, because of default of Tenant, shall be ineffective unless Subtenant shall give Ground Landlord notice thereof, and Ground Landlord shall fail to cure such default within the time and in the manner Tenant would have been authorized to do had Tenant simultaneously received such notice.  The provisions of this Subsection shall apply to any default occurring before or after the Sublease goes into effect.

 

4.Effective as of the Execution Date, from and after such termination of the Ground Lease and if Subtenant's right of possession shall be preserved as aforesaid and Subtenant is not in default under the terms of the Sublease (beyond applicable notice and grace periods):

 

(a)  Subtenant will attorn as tenant to Ground Landlord, and Ground Landlord will accept such attornment.

 

(b) Ground Landlord will have the same remedies by entry, action or otherwise for the nonperformance of any agreement contained in the Sublease for the recovery of rent, for the doing of any waste or for any cause of forfeiture, as Tenant had or would have had if the Ground Lease had not been terminated.

 

 

(c) From and after the time of such attornment, Subtenant shall have the same remedies against Ground Landlord for the breach of an agreement contained in the Sublease that Subtenant might have had against Tenant if the Ground Lease had not been

 

 

5

 


terminated, except that Ground Landlord shall not be (i) liable for any act or omission of Tenant, except to the extent such act or omission continues after term initiation of the Ground Lease, (ii) subject to any offsets or defenses which Subtenant might have against Tenant, except to the extent such offsets or defenses relate to matters continuing after termination of the Ground Lease, (iii) bound by any rent or additional rent paid more than one month in advance of its due date which Subtenant might have paid in advance to  Tenant, (iv) bound by any material amendment of the Sublease not consented to by Ground Landlord that results in a reduction in the amount of rent payable thereunder, or (v) liable for any security or tenant deposits held by or on behalf of any prior tenant (including Tenant) except to the extent actually received by Ground Landlord.

 

 

(d) Ground Landlord and Subtenant will enter into an agreement supplemental hereto containing the same terms and conditions as those contained in the Sublease but with such changes as may be necessary by reason of the substitution of Ground Landlord in the place and stead of Tenant as lessor.

 

5. The rights under this Agreement shall inure to the benefit of only Subtenant and those permitted assignees of Subtenant under the Sublease.

 

6. The term “Ground Landlord” as used in this Agreement means only the owner for the time being of the Premises, so that in the event of any sale of the Premises the predecessor owner shall be and hereby is entirely freed and relieved of all covenants and obligations of Ground Landlord hereunder provided that its successor assumes the same.  The provisions of this Agreement, however, shall bind any subsequent owner of the Premises.  The liability of Ground Landlord to Subtenant under this Agreement shall be limited to Ground Landlord’s interest in the Property and insurance, condemnation, and any sale proceeds therefrom.

 

7. If any defaults shall occur under the Ground Lease, then, subject to the further conditions hereof, Subtenant may, but shall be under no obligation to, make payments to cure the same, and in such event Ground Landlord shall accept any sums so tendered if tendered prior to the expiration of any grace period, but Ground Landlord shall not be obligated to accept any payment which would have the effect of waiving any claim for damages which Ground Landlord may at any time have against Tenant or its successors in interest unless the payment by Subtenant shall be of the entire amount of such claim for damages whether or not then accrued.

 

 

 

6

 


8. Neither Subtenant nor its successors or assigns shall enter into any agreement which shall modify the rental terms of the Sublease without Ground Landlord’s prior written consent not to be unreasonably withheld or delayed.  Any agreement made in contravention to the provisions of this Section shall be of no force or effect as to Ground Landlord.

 

9. Nothing in this Agreement contained shall be deemed or construed to modify any of the provisions of the Ground Lease as between Ground Landlord and Tenant or to waive any rights which Ground Landlord may now or hereafter have against Tenant by reason of the Ground Lease or anything connected therewith.

 

10.If any lease or tenancy shall come into existence between Ground Landlord and Subtenant pursuant to the provisions of Section 2 or Section 4, the provisions of Section 6 shall apply to any liability imposed upon Ground Landlord by reason of such lease or tenancy.

 

11.This Agreement may not be modified orally or in any other manner than by an agreement in writing signed by all parties hereto or their respective successors in interest.

 

12.The covenants and agreements herein contained shall apply to, inure to the benefit of and be binding upon the parties hereto and upon their respective successors in interest and legal representatives except as otherwise hereinbefore provided.

 

 

13.This Agreement may be executed in counterpart and, when all counterpart documents are executed, the counterparts shall constitute a single binding instrument.

 

 


 

 

7

 


Executed under seal as of the date first written above.

 

GROUND LANDLORD:        MBA-ROGERS STREET, LLC

 

By:

 

 

Name:

 

 

Title:

 

 

 

[signatures continue on following page]


 

 

8

 


 

 

TENANT:      BMR-ROGERS STREET LLC

 

 

By:

 

 

Name:

 

 

Title:

 

 

 

[signatures continue on following page]


 

 

9

 


SUBTENANT:      SYNLOGIC, INC.

 

 

By:

 

 

Name:

 

 

Title:

 

 

 

 

 


 

 

10

 


EXHIBIT A

 

PROPERTY

 

Parcel One:

 

A certain parcel of land situated in Cambridge, in Middlesex County and Common­

wealth of Massachusetts, bounded and described as follows:

 

 

 

NORTHWESTERLY:

on Binney Street two hundred (200) feet, thence turning at right angles and running;

 

 

 

NORTHEASTERLY:

along land shown on the plan hereinafter mentioned as belonging to Associates Transport, Inc., two hundred (200) feet to a point on the private way shown as Rogers Street on the plan hereinafter mentioned; thence turning at right angles and running;

 

 

 

SOUTHEASTERLY:

on Rogers Street two hundred (200) feet to a point on Sixth Street; thence turning at right angles and running;

 

 

 

SOUTHWESTERLY:

on Sixth Street two hundred (200) feet to the point of beginning.

 

 

Containing 40,000 square feet and being the parcel of land shown on the plan entitled "Plan of Land in Cambridge, Mass." dated August 8, 1945. William S. Crocker, C. E., said plan being duly recorded with Middlesex South Registry District Deeds, Book 6893, Page 509; and also being the parcel of land shown on a plan of land entitled “Plan of Land in Cambridge, Mass. Property of Industrial Stainless Steel Inc.” dated October 21, 1960, Schofield Brothers, Reg. Land Surveyors, said plan being duly recorded with Middlesex South Registry of Deeds as Plan Number 1664 of 1960 at Book 9706, Page End.

 

Parcel Two:

 

A certain parcel of land with the buildings thereon situated in said Cambridge, bounded and described as follows:

 

 

NORTHERLY:

by Rogers Street, three-hundred thirty-five and 27/100 (335.27) feet;

 

 

EASTERLY:

by land now or formerly of Harry J. Dowd, two hundred and no/100 (200) feet;

 

 

 

 

 


 

SOUTHERLY:

by Binney Street;

 

 

WESTERLY:

by Fulkerson Street.

 

Parcels One and Two together comprise all of Lots A, B, C and D as shown on a plan of Land entitled “Plan Showing Sub-division of land in Cambridge, Massachusetts,” dated July 29, 1940, Wm. H. McGinness C. E., said plan being duly recorded with the Middlesex South Registry of Deeds as Plan Number 1052 of 1940, at Book 6445, Page 394.

 

 

 

 

 

 

 


 

EXHIBIT B

 

SUBLEASE

 

See attached.

 

{A0424541.10 }

B-1