DATED

Articles of Agreement

This Agreement is made the

2015

Between

The Employer

Quotient Biocampus Limited

(Company No. SC514165)⁽¹⁾

of/whose registered office is at Douglas Building, Pentlands Science Park, Midlothian, EH260PL

And

The Contractor

MW High Tech Projects UK Limited

(Company No. 51 79071)⁽¹⁾

of/whose registered office is at c/o Burges Salmon, 10^th Floor, 6 New Street Square, London, EC4A 3BF

Where the Employer or Contractor is neither a company incorporated under the Companies Acts nor a company registered under the laws of another country, delete the references to Company number and registered office. In the case of a company incorporated outside England and Wales, particulars of its place of Incorporation should be inserted immediately before its Company number. As to execution by foreign companies and matters of jurisdiction, see the Design and Build Contract Guide.

Recitals

Whereas

First

the Employer wishes to have the design and construction of the following work carried out^[2]:

Design, construction and fit out of Phase One Life Sciences Production Facility

at Plot 3, Bio Campus, Bush Lane, Gowkley Moss, Penicuik, Midlothian, EH26. OPZ

(‘the Works’)

and the Employer has supplied to the Contractor documents showing and describing or otherwise stating his requirements (‘the Employer’s Requirements’);

Second

in response to the Employer’s Requirements the Contractor has supplied to the Employer:

·     documents showing and describing the Contractor’s proposals for the design and construction of the Works (the Contractor’s Proposals’); and

·     an analysis of the Contract Sum (‘the Contract Sum Analysis’);

Third

the Employer has examined the Contractor’s Proposals and, subject to the Conditions, is satisfied that they appear to meet the Employer’s Requirements^[3];

Fourth

for the purposes of the Construction Industry Scheme (ClS) under the Finance Act 2004, the status of the Employer is, as at the Base Date, that stated in the Contract Particulars;

Fifth

the division of the Works into Sections is shown in the Employer’s Requirements or in such other documents as are identified in the Contract Particulars^[4];

Sixth

where so stated in the Contract Particulars, this Contract is supplemented by the Framework Agreement identified in those particulars;

Seventh

the Supplemental Provisions identified in the Contract Particulars apply;

State nature and location of intended works.

Where the Employer has accepted a divergence from his requirements in the proposals submitted by the Contractor, the divergence should be removed by amending the Employer’s Requirements before the Contract is executed.

Delete the Fifth Recital if the Works are not divided into Sections.

Articles

Now it is hereby agreed as follows

Article 1: Contractor’s obligations

The Contractor shall complete the design for the Works and carry out and complete the construction of the Works in accordance with the Contract Documents.

Article 2: Contract Sum

The Employer shall pay the Contractor at the time and in the manner specified in the Conditions the sum of the Prime Cost, the Management Fee and any other amounts due to the Contractor from the Employer in accordance with the Conditions

The Contractor has prepared budget estimate for the Works in the VAT-exclusive sum of:

£15,216,504.23 (‘the Contract Sum’)

Article 3: Employer’s Agent

For the purposes of this Contract the Employer’s Agent is

Gordon Robb

of

Quotient Biocampus Limited

or such other person as the Employer shall nominate in his place. Save to the extent that the Employer may otherwise specify by notice to the Contractor, the Employer’s Agent shall have full authority to receive and issue applications, consents, instructions, notices, requests or statements and otherwise to act for the Employer under any of the Conditions.

Article 4: Employer’s Requirements and Contractor’s Proposals

The Employer’s Requirements, the Contractor’s Proposals and the Contract Sum Analysis are those referred to in the Contract Particulars.

Article 5: CDM Co-ordinator

The CDM Co-ordinator for the purposes of the CDM Regulations is the Contractor

(or)^[5]

Ged Gowans

of

Thomson Gray Limited, 5 Thistle Street, Edinburgh, EH2 1DF

Insert the name of the CDM Co-ordinator only where the Contractor is not to fulfil that role, and that of the Principal Contractor only if that is to be a person other than the Contractor. If the project is not notifiable under the CDM Regulations 2007 (i.e. a project which is not likely to involve more than 30 days, or 500 person days, of construction work or which is being carried out for a homeowner as a purely domestic project), delete Articles 5 and 6 in their entirety.

or, if he ceases to be the CDM Co-ordinator, such other person as the Employer shall appoint pursuant to regulation 14(3) of those regulations.

or, if he ceases to be the Principal Contractor, such other contractor as the Employer shall appoint pursuant to regulation 14(3) of the CDM Regulations and/or regulation 4 of the SWMP Regulations.

Article 7: Adjudication

If any dispute or difference arises under this Contract, either Party may refer it to adjudication in accordance with clause 9∙2^[6].

Article 8: Arbitration

Where Article 8 applies^[7], then, subject to Article 7 and the exceptions set out below, any dispute or difference between the Parties of any kind whatsoever arising out of or in connection with this Contract shall be referred to arbitration in accordance with clauses 9∙3 to 9∙8 and the JCT 2011 edition of the Construction Industry Model Arbitration Rules (CIMAR). The exceptions to this Article 8 are:

·     any disputes or differences arising under or in respect of the Construction Industry Scheme or VAT, to the extent that legislation provides another method of resolving such disputes or differences; and

·     any disputes or differences in connection with the enforcement of any decision of an Adjudicator.

Article 9: Legal proceedings^[7]

Subject to Article 7 and (where it applies) to Article 8, the English courts shall have jurisdiction over any dispute or difference between the Parties which arises out of or in connection with this Contract.

Article 10: Schedule of Amendments

The Articles of Agreement, Recitals, Contract Particulars, Conditions and Schedules shall have effect as modified and amended by Amendment 1A and shall be construed accordingly”

As to adjudication in cases where the Employer is a residential occupier within the meaning of section 106 of the Housing Grants, construction and Regeneration Act 1996, see the Design and Build contract Guide.

If it is intended, subject to the right of adjudication and exceptions slated in Article 8. that disputes or differences should be determined by arbitration and not by legal proceedings, the contract Particulars must state that Article 8 and clauses 9∙3 to 9∙8 apply and the words “do not apply” must be deleted, If the Parties wish any dispute or difference to be determined by the courts of another jurisdiction the appropriate amendment should be made to Article 9 (see also clause 1∙10 and Schedule 5 Parts 1 and 2).

Contract Particulars

Note: An asterisk * indicates where selection has been or should have been made.

Part 1: General

Clause etc.

Subject

Fourth Recital and clause 4∙5

Construction Industry Scheme (CIS)

*

Employer at the Base Date

is not a ‘contractor’ for the purposes of the CIS

Fifth Recital

Description of Sections (if any) (If not shown or described in the Employer’s Requirements, state the reference numbers and dates or other identifiers of documents in which they are shown.)^[8]

Sixth Recital

Framework Agreement (if applicable) (State date, title and parties.)

Seventh Recital and Part 1 of Schedule 2

Supplemental Provisions – Part 1 (Where neither entry against an item below is deleted, the relevant paragraph does not apply.)

Site

*

Paragraph 1

does not apply

Named Sub-Contractors

*

Paragraph 2

does not apply

Bills of Quantities

*

Paragraph 3

does not apply

Valuation of Changes – Contractor’s estimates

*

Paragraph 4

does not apply

Loss and expense – Contractor’s estimates

*

Paragraph 5

does not apply

If the relevant document or set of documents takes the form of an Annex to this contract, it is sufficient to refer to that Annex.

Seventh Recital and Part 2 of Schedule 2

Supplemental Provisions – Part 2 (Where neither entry against an item below is deleted, the relevant paragraph applies.)

Acceleration Quotation

*

Paragraph 6

does not apply

Collaborative working

*

Paragraph 7

applies

Health and safety

*

Paragraph 8

applies

Cost savings and value improvements

*

Paragraph 9

applies

Sustainable development and environmental considerations

*

Paragraph 10

does not apply

Performance Indicators and monitoring

*

Paragraph 11

does not apply

Notification and negotiation of disputes

*

Paragraph 12

applies

Where paragraph 12 applies, the respective nominees of the Parties are

Employer’s nominee

Gordon Robb

Contractor’s nominee

David Amos

or such replacement as each Party may notify to the other from time to time

Article 4

Employer’s Requirements (State reference numbers and

As listed in Appendix 1

dates or other identifiers of documents in which these are contained.)^[8]

Article 4

Contractor’s Proposals (State reference numbers and dates

As listed in Appendix 2

or other identifiers of documents in which these are contained.)^[8]

Article 4

Contract Sum Analysis

As listed in Appendix 3

(State reference numbers and dates or other identifiers of documents in which this is contained.)^[8]

Article 8

Arbitration (If neither entry is deleted, Article 8 and clauses9∙3 to 9∙8 do not apply. If disputes and differences are to be determined by arbitration and not by legal proceedings, it must be stated that Article 8 and clauses 9∙3 to 9∙8 apply.)^[9]

*

Article 8 and clauses 9∙3 to 9∙8 (Arbitration) apply

1∙1

Base Date

June 2015

1∙1

CDM Planning Period^[10]

shall mean the period of

4

Weeks

*

ending on the Date of Possession

20

1∙1

Date for Completion of the Works

25^th August 2017

(where completion by Sections does not apply)

Sections: Dates for Completion of Sections^[11]

1∙7

Addresses for service of notices by the Parties (If

Employer: __________________

none is stated, the address in each case, subject

Contractor M+W Group A2

to clause 1∙7∙3, shall be that shown at the commencement of the Agreement.)^[12]

Methuen South, Bath Road,

Chippenham, Wiltshire, SNI4

0GT

2∙3

Date of Possession of the site

4^th January 2016

(where possession by Sections does not apply)

Sections: Dates of Possession of Sections^[11]

If the relevant document or set of documents takes the form of an Annex to this contract, it is sufficient to refer to that Annex.

On factors to be taken into account by the Parties in considering whether disputes are to be determined by arbitration or by legal proceedings, see the Design and Build contract Guide, see also footnote [7].

Under the CDM Regulations 2007 every client is expressly required to allocate sufficient time (the CDM Planning Period) prior to the commencement of construction to enable contractors and others to carry out necessary CDM planning and preparation. There may be cases where that planning and preparation needs to be completed earlier than the Date of Possession and adaptation of the entries may be needed where there are sections.

Continue on further sheets if necessary, which should be signed or initialled by or on behalf of each Party and then be annexed to this contract.

As to service of notices etc, outside the United Kingdom, see the Design and Build Contract Guide.

2∙4

Deferment of possession of the site

*

Clause 2∙4

(where possession by Sections does not apply)

applies

Maximum period of deferment (if less than 6 weeks) is

6 weeks

Sections: deferment of possession of Sections

*

Clause 2∙4

does not apply

Maximum period of deferment (if less than 6 weeks) is^[11]

Section _____:

Section _____:

Section _____:

2∙17∙3

Limit of Contractor’s liability for loss of use etc.

£NIL

(if any)

2∙29∙2

Liquidated damages

at the rate of

(where completion by Sections does not apply)

£ NIL

per week

Sections: rate of liquidated damages for each Section^[11]

2∙34

Sections: Section Sums^[11]

2∙35

Rectification Period

Twelve (12) months

(where completion by Sections does not apply)

(If no other period is stated, the period is 6 months.)

from the date of practical completion of the Works

Section: Rectification Periods^[11]

(If no other period is stated, the period is 6 months.)

Continue on further sheets it necessary, which should be signed or initialled by or on behalf of each Party and then be annexed to this contract.

4∙6

Advance payment

*

Clause 4.6

(Not applicable where the Employer is a Local Authority.)

does not apply

If applicable:

the advance payment will be^[13]

£

__________per cent of the Contract Sum

and will be paid to the Contractor on

it will be reimbursed to the Employer in the

following amount(s) and at the following time(s)

4∙6

Advance Payment Bond

*

An advance payment bond

(Not applicable where the Employer is a Local Authority)

is not required

(Where an advance payment is to be made, an advance payment bond is required unless stated that it is not required.)

Insert either a monetary amount or a percentage figure, delete the alternative and complete the other required details.

Delete whichever Alternative is not applicable. Where Interim Payments are to be made by stages (including by quantity of units and sub-units completed) make the appropriate entries or prepare and insert a separate schedule of cumulative stage values.

If the relevant document or set of documents takes the form of an Annex to this Contract, it is sufficient to refer to that Annex.

4.15.4

Listed Items-uniquely identified

(Delete the entry if no bond is required.)

4.15.5

Listed Items-not uniquely identified

(Delete the entry if clause 4.15.5 does not apply.)

4.17

Contractor’s Retention Bond (Not applicable where the Employer is a Local Authority) (Not applicable unless stated to apply and relevant particulars are given below)

*

Clause 4.17

applies

If clause 4.17 applies, the maximum aggregate sum for the purposes of clause 2 of the bond is

to the value of 3% of the Contact Sum.

4.18.1

Retention Percentage (The percentage is 3 per cent unless a different rate is stated; if no retention is required, insert ‘Nil’ or ’O’.)

NIL-See 4.17 above

Cumulative value of final stage must be equal to the Contract Sum.

The first date should not be more than one month after the Date of Possession. Where it is intended that interim Applications be made on the last day of each month, the entry may be completed/amended to read “the last day of (insert month) and thereafter the last day in each month or the nearest Business Day in that month.” After practical completion, clause 4.8.3 provides for intervals of 2 months (or such other period as the Parties agree) between Interim Applications.

5.5

Daywork

6.4.1.2

Contractor’s insurance: injury to persons or property - insurance cover (for any one occurrence or series of occurrences arising out of one event)

£5,000,000.00

6.5.1

Insurance - liability of Employer

6.7 and Schedule 3

Insurance of the Works - insurance Options^[17][20]

Schedule 3:

*

Insurance Option A applies/

Delete all but one.

The Part to be deleted depends upon which method of formula adjustment (Part 1 - Work Category Method or Part II - Work Group Method) is applicable.

If the relevant document or set of documents takes the form of an Annex to this contract, it is sufficient to refer to that Annex.

Insert an amount where it is stated in the Employer’s Requirements that insurance under clause 6.5.1 is required.  If the indemnity is to be for an aggregate amount and not for any one occurrence the entry should be amended to make this clear.

Obtaining Terrorism Cover, which is necessary in order to comply with the requirements of Insurance Option A, B or C, will involve an additional premium and may in certain situations be difficult to effect. Where a difficulty arises discussion should take place between the Parties and their insurance advisers. See the Design and Build Contract Guide.

6.7 and Schedule 3

Insurance Option A

(paragraphs A.1and A.3), B (paragraph B.1) or C (paragraph C.2)

Percentage to cover professional fees

(If no other percentage is stated, it shall be 15 per cent.)

15 per cent                                        

6.7 and Schedule 3

Annual renewal date of insurance

31^st December 2016                        

Insurance Option A

(paragraph A.3)

(as supplied by the Contractor)

6.12

Professional Indemnity insurance

*

Amount of indemnity required

Level of cover

(If an alternative is not selected the amount shall be the aggregate amount for any one period of insurance. A period of insurance for these purposes shall be one year unless otherwise stated.)

*

is the aggregate amount for any one period of insurance

(If no amount is stated, insurance under clause 6.12 shall not be required.)

and is

£ 5,000,000.000                                

Cover for pollution and contamination claims

(If no amount is stated, such cover shall not be required; unless otherwise stated, the required limit of indemnity is an annual aggregate amount.)

*

is not required

Expiry of required period of Professional Indemnity insurance is

(If no period is selected, the expiry date shall be 6 years from the date of practical completion of the Works.)

*

12 years/

*

6.14

Joint Fire Code

*

The Joint Fire Code

applies^[21]

If the Joint Fire Code applies, state whether the insurer under Schedule 3, Insurance Option A, B or C (paragraph C. 2) has specified that the Works are a ‘Large Project’:

                                          *   Yes^[21]

6.17

Joint Fire Code - amendments/revisions

(The cost shall be borne by the Contractor unless otherwise stated.)

*

The cost, if any, of compliance with amendment(s) or revision(s) to the Joint Fire

Code shall be borne by

the Employer/the Contractor

Where Insurance Option A applies these entries are made on information supplied by the Contractor.

7.2

Assignment/grant by Employer of rights under clause 7.2

(If neither entry is deleted, clause 7.2 applies.)

*

Clause 7.2

applies

Sections: rights under clause 7.2

(If clause 7.2 applies, amend the entry if rights under that clause are to apply to certain Sections only.)

*

Rights under clause 7.2 apply to each Section

8.9.2

Period of suspension

(If none is stated, the period is 2 months.)

2 months                                   

8.11.1.1 to

Period of suspension

2 months                                   

8.11.1.6

(If none is stated, the period is 2 months.)

9.2.1

Adjudication^[22]

The Adjudicator is

Nominating body – where no Adjudicator is named or where the named Adjudicator is unwilling or unable to act (whenever that is established)^[23] (Where an Adjudicator is not named and a nominating body has not been selected, the nominating body shall be one of the bodies listed opposite selected by the Party requiring the reference to adjudication.)

*

The Royal Institution of Chartered Surveyors

9.4.1

Arbitration^[26] – appointor of Arbitrator (and of any replacement)^[27]

(If no appointor is selected, the appointor shall be the President or a Vice-President of the Royal Institute of British Architects.)

President or a Vice-President:

*

The Royal Institution of Chartered Surveyors

The Parties should either name the Adjudicator and select the nominating body or, alternatively, select only the nominating body. The Adjudication Agreement (Adj) and the Adjudication Agreement (Named Adjudicator) (Adj/N) have been prepared by JCT for use when appointing an Adjudicator.

Delete all be one of the nominating bodies asterisked.

constructionadjudicators.com is a trading name of Contractors Legal Grp Ltd.

Association of Independent Construction Adjudicators acts as an agent of and is controlled by the National Specialist Contractor’s Council for the purposes of the nomination of adjudicators.

This only applies where the contract Particulars state (against the reference to Article 8) that Article 8 and clauses 9.3 to 9.8 (Arbitration) apply.

Delete all but one of the bodies asterisked.

Attestation

Note on Execution

This Agreement should be executed by both the Employer and the Contractor either under hand or as a deed. As to factors relevant to that choice, see the Design and Build Contract Guide.

Execution under hand

If this Agreement is to be executed under hand, use the form set out on the following page. Each Party or his authorised representative should sign where indicated in the presence of a witness who should then sign and set out his name and address.

Execution as a Deed

If this Agreement is to be executed as a deed, each Party should use the relevant form marked ‘Execution as a Deed’ in accordance with the notes provided.

Other forms of Attestation

In cases where the forms of attestation set out are not appropriate, e.g. in the case of certain housing associations and partnerships or if a Party wishes an attorney to execute this Agreement on his behalf, the appropriate form(s) may be inserted in the vacant space opposite and/or below.

Notes on Execution as a Deed

1

For the purposes of execution as a deed, two forms are provided for execution, one for the Employer and the other for the Contractor. Each form provides four methods of execution, (A) to (D), for use as appropriate. The full name of the Employer or Contractor (whether an individual, a company or other body) should be inserted where indicated at the commencement of the relevant form. This applies irrespective of the method used.

2

For public and private companies incorporated and registered under the Companies Acts, the three principal methods of execution as a deed are:

(A) through signature by a Director and the Company Secretary or by two Directors;

(B) by affixing the company’s common seal in the presence of a Director and the Company Secretary or of two Directors or other duly authorised officers; or

(C) signature by a single Director in the presence of a witness who attests the signature.

Methods (A) and (C) are available to public and private companies whether or not they have a common seal. (Method (C) was introduced by section 44(2)(b) of the Companies Act 2006.) Methods (A) and (C) are not available under companies legislation to local authorities or to certain other bodies corporate, e.g. bodies incorporated by letters patent or private Act of Parliament that are not registered under companies legislation and such bodies may only use method (B).

3

Where method (A) is being used, delete the inappropriate words and insert in the spaces indicated the names of the two Directors, or of the Director and the Company Secretary, who are to sign.

4

If method (B) (affixing the common seal) is adopted in cases where either or both the authorised officers attesting its affixation are not themselves a Director or the Company Secretary, their respective office(s) should be substituted for the reference(s) to Director and/or to Company Secretary/Director. (In the case of execution by bodies that are not companies, the reference to “Company” under the second signature should be deleted where appropriate.)

5

Method (C) (execution by a single Director) has been introduced primarily, but not exclusively, for ‘single officer’ companies. The Director should sign where indicated in the presence of a witness who should then sign and set out his name and address.

6

Where the Employer or Contractor is an individual, he should use method (D) and sign where indicated in the presence of a witness who should then sign and set out his name and address.

acting by a Director and the Company Secretary/two Directors of the company^2,3

by affixing hereto the common seal of the company/other body corporate ^{2, 4}

in the presence of

by attested signature of a single Director of the company ^2,5

by attested signature of the individual ⁶

acting by a Director and the Company Secretary/two Directors of the company ^2,3

All payments made to or in connection with all persons engaged full or part time upon the Works, including incentive payments, holiday stamps, bonus, general expenses, subsistence and travelling expenses, payments made in accordance with the current Staff Handbook, Employers’ contribution to National Insurance and Government and Company Pension Scheme and any payroll tax, levy, contribution or payments which may be imposed and which shall be payable in respect of such persons.

The cost of materials and goods actually used in connection with the Works.

Payments due to Sub-contractors in accordance with the terms and conditions of their Sub-contract.

The cost of statutory fees and other specialist service fees.

Travelling and hotel accommodation and other expenses of all staff (salaried or otherwise) other than Executive Directors.

(a) The cost of insurance of plant and tools against fire.

(b) The cost of insurances and Bonds including SLL own defects liability insurance allowance.

(c) The stated amount for each and every claim resulting from the insurance clauses.

The cost of cartage, transport to and from Site, erection, site maintenance and dismantling of all plant, tools, fencing, scaffolding, huts, sheds, mess rooms, etcetera, together with the running costs, i.e. electricity, gas, petrol, oil, etcetera, of all mechanical plant.

The hire charge of mechanical and non mechanical plant at invoiced cost.

Site office expenses, including telephone charges and postage.

The cost of any tax, levy, contribution or payment or of any variation in tax legislation which may be imposed and which shall be payable in respect of the Works.

The cost of Design and Consultants costs incurred on the project.

The Management, organisational, accounting and specialist services of Head Office Staff.

All charges for rent, rates, taxes, telephones, stationary, heating, lighting, cleaning and all other overhead expenditure relating to Head Office.

All expenses incurred by Executive Directors, including the cost of travelling and hotel accommodation.

Profit.

The Contractor shall design and carry out and complete the Works in accordance with, and the rights and duties of the Employer and the Contractor shall be regulated by, these Articles of Agreement together with the contract particulars forming part of this Agreement (the “Contract Particulars”) and the Schedule annexed hereto (the “Schedule”) including, without limitation, the Contract Documents as defined in the Conditions (as hereinafter defined) as such Conditions are amended by the Schedule of Amendments (“the Schedule of Amendments”) and listed in the Schedule Part 8 of the Conditions all of which Contract Documents are hereby incorporated in and form part of this Agreement. If there is any conflict or inconsistency between the Schedule of Amendments on the one hand, and the terms of any other items referred to in this Article 1 on the other hand, the terms of the Schedule of Amendments shall prevail and have effect in priority to the items referred to in this Article 1.

Notwithstanding the date or dates of execution of this Contract, the employment of the Contractor under this Contract shall be deemed to have commenced with effect from the date on which the Contractor began to perform his duties and comply with his obligations under this Contract.”

Prior to the CDM Date, the CDM Co-ordinator for the purposes of the CDM Regulations is Thomson Gray Limited, incorporated under the Companies Acts (Registered Number SC270835) and whose Registered Office is at Prospect House, 5 Thistle Street, Edinburgh, EH2 IDF or, if they cease to be the CDM Co-ordinator, such other person as the Employer shall appoint pursuant to those Regulations.

On and from the CDM Date, the Principal Designer for the purposes of the CDM Regulations shall be Thomson Gray Limited, incorporated under the Companies Acts (Registered Number SC270835) and whose Registered Office is at Prospect House, 5 Thistle Street, Edinburgh, EH2 1DF or such other person as the Employer shall

appoint pursuant to those Regulations or, if they cease to be the Principal Designer, such other person as the Employer shall appoint pursuant to those Regulations.”  

Delete all entries in respect of “Method of Payment” and “Alternative A: Stage payments” and delete the words “Alternative B:” from before the words “Periodic Payments”.

Amend the following definitions to read:

Delete the text of sub-clause 1.4 and substitute the following instead:-

The Clause headings in this Contract are for convenience only and do not affect its interpretation.

Words importing the singular meaning shall, where the context so admits, include the plural meaning and vice-versa; words denoting the masculine gender shall include the feminine and neuter genders; words denoting natural persons shall include corporations and firms; and all such words shall be construed interchangeably in that manner.

Where the context so admits, references in this Contract to a Clause are to a Clause of this Contract; and references to a Schedule is to the Schedule to this Contract.

References in this Contract to any statute or statutory instrument shall include and refer to any statutory amendment or re-enactment thereof from time to time for the time being, including any legislation which re-enacts it, with or without modification.

The words “include”, “including” and similar expressions shall be construed without limitation.

If any term or provision of this Contract or the application thereof to any person or circumstance shall to any extent be invalid or unenforceable, the remainder of this Contract or the application of such term of provision to persons or circumstances other than those as to which it is invalid or unenforceable shall not be affected thereby and each term of provision of this Contract shall be valid and enforceable to the fullest extent permitted by law.

Where any clause or sub-clause is deleted ánd not replaced by other text, there shall be deemed to be added to such clause or sub-clause the words “number not used” and there shall be no consequential renumbering, unless stated to the contrary.

The words of this Contract shall bear their natural meaning. The parties have had the opportunity to take legal advice on this Contract and no terms shall be construed contra proferentem.”

Delete the text of sub-clause 1 .6 and substitute the following instead:-

Delete the text of sub-clause 1 .7 and substitute the following instead:

All notices, certificates, valuations, orders or other written communications required to be served or sent under the terms of this Contract (“Notices”) shall require to be in writing. The addresses or numbers for service are those stated in the parties designations in this Contract, or such other address for service as may be notified in writing for time to time.

Unless otherwise specifically provided, all Notices shall require to be served or sent by hand delivery or by first class recorded delivery post or by fax or by email.

All Notices shall be sufficiently served if served by or on the parties’ solicitors, being:

for the Employer: DWF LLP, Dalmore House, 310 St Vincent Street, Glasgow G2 5QR; and

for the Contractor: Clarke Willmott LLP, 1 Georges Square, Bath Street, Bristol BSI 6BA.

All Notices sent in accordance with this Clause shall be deemed to have been validly served in accordance with this Contract:-

at the time of delivery (hand delivered);

on the second working day after posting (if posted); and

upon the fax transmission having been effected (if faxed) or completion of transmission of the email message (if emailed). For record purposes, however, any faxed or emailed Notice

shall also be sent forthwith by first class recorded delivery post or hand delivery in each case, unless proved to the contrary.” 

In the second line after “manner” insert “following Good Industry Practice,”

In the second line after “Contract Documents” insert “, Necessary Consents,”

At the end of clause 2.1.1, insert, “The Contractor shall in carrying out the design for the Works exercise the skill and care to be expected of an appropriately qualified and competent design and build contractor experienced in carrying out works of the nature, scale and complexity to the Works.”

In the first line after “The contractor shall” insert “immediately”.

Insert a new Clause 2.1.5 as follows:

Subject to the provisions of clause 3.7, the Contractor shall not undertake the Works or any part of the Works other than in compliance with the Employer’s Requirements and the Contractor’s Proposals without the prior written consent of the Employer.

If the Contractor undertakes the Works or any part thereof other than in compliance with Clause 2.1.5.1 it shall not be entitled to payment for such works done or in any entitlement to an extension of time or additional monies relating to those works.”  

Insert new clause 2.1.6 as follows:-

The Contractor shall carry out and complete the Works in conformity with the Employer’s obligations under any Third Party Agreement which the Employer shall have brought to the attention of the Contractor including any Third Party Agreement which the Employer shall bring to the attention of the Contractor from time to time and without infringing any right, reservation, covenant, restriction, stipulation or other encumbrance that is binding upon or affects the Site; and

Provided that the Employer has brought such Third Party Agreement to his attention, the Contractor undertakes to the Employer that he has performed and shall continue to perform his obligations under Contract in such a manner and at such times that no negligent act, omissions or default on the part of the Contractor or any of his professional consultants or their respective employees, agents or sub-contractors shall cause or contribute to any breach by the Employer of any of its obligations under any Third Party Agreement.”

Insert new clause 2.1.7 as follows:

Details of any Statutory Consents, consents or approvals already obtained by the Employer are given in the Employer’s Requirements. The Contractor shall be responsible for obtaining all other Necessary Consents and to fulfil the following obligations including but not limited to discharging the planning conditions, obtaining any subsequent amendments to the planning permission and applying for the building control certificate/building warrants.”

The Contractor hereby confirms that prior to the commencement of construction on Site he has reviewed the Pre-Construction Information (as defined in the CDM Regulations) and is satisfied that it is both appropriate for the Contractor’s proposed method of construction and sufficiently developed to enable construction work to proceed on Site in accordance with the requirements of the CDM Regulations. The Contractor shall, before construction work on Site is due to commence, develop the Construction Phase Plan so as to ensure that construction work can proceed on Site in accordance with the requirements of the CDM Regulations without there being any delay or disruption to the commencement and subsequent execution of the Works or a Section.

The Contractor shall use its best endeavours to keep the Site at all times safe and secure and shall ensure that only personnel authorised by the Contractor in connection with the due and proper execution of the Works or any part thereof or by the Employer gain access to or occupy the Site or any part thereof.

Whenever the Contractor completes any discrete part of the Works or a Section or upon Practical Completion of the Works or a Section he shall remove from the relevant area or part of the Site all surplus materials, all plant, equipment and other items belonging to the Contractor and leave the area in a neat and tidy condition.”

Notwithstanding clause 2.3 and without prejudice to any other obligation of the Contractor, the Contractor shall not start the “Construction Phase” (as defined in Regulation 2 of the CDM Regulations) in breach of Regulation 13 and 22 of the CDM Regulations.

Upon termination of the Contractor’s employment under this Contract, whether in accordance with clauses 8.4, 8.5, 8.6, 8.9, 8.10 or 8.11 or otherwise or upon termination of this Contract and whether or not any purported termination by the Employer is disputed by the Contractor, the Contractor shall immediately bring an end to the Works in an orderly manner and make safe the Site and the Works and shall forthwith deliver possession of them to the Employer within 14 days of termination. The Employer shall allow the Contractor a reasonable opportunity to return to the Site to collect its plant and equipment (subject to the provisions of clause 8.7).”

Renumber the existing Clause 2.8 as 2.8.1 and add the following new clauses:-

The Contractor shall, not less than 10 working days before the Date of Possession, provide to the Employer’s Agent two copies of the Programme for the design and construction of the Works. Such programme should contain the following information:-

The Contractor shall revise the Programme as appropriate from time to time if and within 5 working days after it becomes apparent that the progress of the Works is being delayed by any circumstances, or that a change of programme is necessary to avoid or minimise delay, the Contractor shall supply the Employer’s Agent with two copies of a suitably revised programme.

Each month the Contractor shall report to the Employer in writing comparing the progress of the Works with the Programme current at that time, and promptly advise the Employer of any delay or disruption to the Works and agree measures with the Employer in respect of mitigation of any such delay or disruption of the Works.”

Renumber the existing clause 2.9 as 2.9.1 and add the following new clauses:-

The Employer shall be responsible for making whatever arrangements are necessary for obtaining ingress to or egress from the Site or to execute any work off-site in order for the Contractor to carry out and complete the Works in accordance with this Contract and the Contractor shall comply with all such arrangements.

The Employer shall be responsible for settling appropriate arrangements for such access with the local highway or other appropriate authority and/or owners or occupiers, as appropriate, and the Contractor shall comply with all such arrangements.”

Where there is a discrepancy within the Contractor’s Proposals or within the Employer’s Requirements (including any non-compliance with the Statutory Requirements) or a divergence between the Employer’s Requirements and the Contractor’s Proposals, the Contractor shall notify the Employer in writing of its proposed amendment to remove the discrepancy or divergence and (subject always to compliance with the Statutory Requirements) the Employer shall decide between the discrepant or divergent items or otherwise may accept the Contractor’s proposed amendments and the Contractor shall be obliged to comply with the decision or acceptance by the Employer.”

Delete the text of sub-clauses 2.17.1 and substitute the following instead:-

The Contractor accepts responsibility for the design of the whole of the Works, including (without limitation) any design contained in the Employer’s Requirements, the Contractor’s Proposals and design developed after the preparation of the Employer’s Requirements.”

Insert a new clause as follows:

Insert a new clause as follows:

death or personal injury caused by the Contractor’s negligence; or

fraud or fraudulent misrepresentation

The Contractor warrants and undertakes to the Employer that, in designing the Works, the Contractor has exercised and will continue to exercise the Design Duty of Care. The Contractor further warrants and undertakes that the Works shall be designed using Good Industry Practice.

Without prejudice to the generality of sub-clauses 2.17.1 and 2.17.4, the Contractor warrants and undertakes to the Employer that the Contractor has exercised and will continue to exercise the Design Duty of Care to ensure that the Works, when completed, will comply with any performance specification or requirement included or referred to in the Employer’s Requirements and/or the Contractor’s Proposals or to be reasonably inferred therefrom.”

The Contractor shall execute all works and things required necessary in order:-

to comply with the Environmental Protection Legislation;

to enable a fire certificate to be granted in respect of the Project (or any relevant part or parts thereof); and

to satisfy any pre-requisites for the adoption of relevant part or parts of the Works or a Section by the local authority or other relevant statutory authority (including, without limitation, drainage, water, gas, electricity and telecommunications authorities).

The Contractor shall procure:

that no mechanical or electrical services serving any part of the Site other than the Premises shall pass through the Premises;

that any plant and equipment and/or smoking areas located on the exterior of the Premises or the remainder of the Contractor is positioned or suitably screened so that it cannot be seen or heard from the interior of the Premises; and  

the carrying out of all mains services connections.

The Contractor shall perform and discharge and/or procure the performance and discharge of all the functions, duties and obligations imposed upon a Principal Contractor and Designers relative to the Works pursuant to the CDM Regulations.

The Contractor shall not specify for use or use and shall not permit or approve for use in connection with the construction of the Works any goods, materials, processes or substances which at the date of incorporation are not in accordance with British or European Standards and Codes of Practice (and where in the case of British or European Standards or Codes of Practice there is a range of equivalent standard substances which are not in accordance with such other equivalent standards) or substances which are not recommended or are identified as being deleterious, unsatisfactory or of unsuitable quality having regard to the provisions of the latest edition of the publication entitled “Good Practice in the Selection of Construction Materials” published by the British Council for Offices current as at the date of specification of the relevant goods etc or substances, materials, products, techniques or methods known in the construction industry, as at the date of incorporation in any part of the Works, to be deleterious including substances, materials, products, techniques or methods which have been publicised in the British Research Establishment Digest as amended from time to time as being deleterious to health and safety or to the durability of property in the circumstances in which they are used.

The Contractor has had the opportunity of inspecting the physical conditions (including the sub-surface conditions) and other conditions of or affecting the Site and shall be deemed to have fully acquainted himself with the same and to have obtained all information available which may influence or affect the execution of the Works. The Contractor shall have no liability for any unforeseen ground conditions which would not have been reasonably foreseen by a competent and experienced design and build contractor working on works similar to the scope and size of the Works under this Contract. Such unforeseeable ground conditions include contamination, sub-soil and sub-surface hazardous conditions, materials or obstructions or adverse physical conditions. Any instructions which the Employer may issue consequent on any such unforeseen ground conditions shall give rise to a Change in the Works, an entitlement to an adjustment of the Completion Date under clauses 2.23 to 2.25 and reimbursement of loss and/or expense under clause 4.20. Any costs incurred as a result of such unforeseen ground conditions shall be included within the Prime Cost.

The obligations and liabilities of the Contractor in terms of or arising out of this Contract shall not be released, diminished or in any other way affected by:-

any enquiry or inspection into any relevant matter which may be made or carried out by or on behalf of the Employer or the Employer’s Agent;

the Employer or the Employer’s Agent including the value of any design, work, materials or goods in any certificate or statement or any interim or final payment or any certificate, written statement or notice pursuant to this Contract;

any approval, admission, consent, comment, sanction, acknowledgement, confirmation or advice made or given by or on behalf of the Employer or the Employer’s Agent, or in any case in the absence thereof; or

the attendance at meetings by the Employer or the Employer’s Agent.

For the purposes of the Working Time Regulations 1998 (“the WTRs”) the Contractor expressly agrees and warrants that neither the Contractor nor any of his sub-contractors or any workers employed by the Contractor and/or his sub-contractors are workers employed by the Employer. The Contractor further agrees and warrants that he shall ensure compliance with the WTRs in relation to his own workers and shall ensure that any sub-contractors comply with the WTRs in respect of their workers. Further, the Contractor shall indemnify and keep indemnified the Employer in respect of any claim which may be brought against the Employer in any court, employment tribunal or other forum relating to any breach of the WTRs committed by the Contractor or his sub-contractors or arising from any failure on the part of the Contractor or his sub-contractors to implement or comply with the WTRs.”

Delete existing Clause 2.22 and substitute the following instead:-

“The Contractor shall include appropriate provisions in every sub-contract, contract of sale and/or supply agreement entered into or to be entered into by the Contractor relative to the Works to ensure that the property in all materials and goods incorporated or to be incorporated in the Works passes to the Employer at the time that the value of such materials and goods is included in an interim payment paid to the Contractor under this Contract.”

Delete the word “and” at the end of this sub-clause.

Delete “.” and substitute “; and” instead at the end of this sub-clause and add the following new sub-clause:-

the Contractor has complied at all times with his obligations under clauses 2.8.2 and 2.8.3”

Notwithstanding the provisions of sub-clause 2.25 the Contractor shall not be entitled to any extension of time where and to the extent that the Relevant Event in question results from any negligence, omission, breach of statutory duty, default or breach of contract on the part of the Contractor, his servants or agents or any sub-contractor or supplier or their respective servants or agents other than where such negligence is a Specified Peril;”

Add the following in clause 2.26 after the words “clauses 2.24 and 2.25”:-

Add the following after “instructions”:-

Insert the following at the end of clause 2.26.7:-

Delete the remainder of the clause from the word “which” in line 1 and replace with “provided that the Contractor has used all reasonable endeavours to avoid or reduce any such delay.”

Delete “force majeure” and replace with “any other occurrence or circumstances amounting to Force Majeure”.

The Contractor shall give the Employer and the Employer’s Agent not less than 21 days’ notice (or such other period as may be agreed by the Employer acting reasonably) of the date upon which the Contractor considers that Practical Completion of the Works or a Section has been reached, he shall forthwith notify the Employer and the Employer’s Agent thereof and shall provide them with details of any works required to be executed which he considers do not prevent the Works from being practically complete. The Contractor shall also provide his proposals and programme for execution of such Works, which will be approved by the Employer prior to issue of the Statement of Practical Completion.

As a pre-requisite to the issue of the Practical Completion Statement the Contractor shall provide to the Employer’s Agent 2 no. copies of the following:-

the building control completion certificates and discharge of planning conditions except and to the extent that where the discharge of planning conditions requires the Employer to discharge a planning condition(s) in which case the Contractor shall use best endeavours to provide appropriate assistance and co-ordination to facilitate the Employer’s satisfaction of those planning condition(s);

all necessary Statutory Undertakers’ completion certificates;

all test and commissioning certificates for Mechanical, Electrical and Plumbing Installation other than certificates that are subject to post Practical Completion testing and commissioning; and

draft “as built” drawings, draft installation, operating and maintenance manuals and draft Health & Safety file.

Not used.

Upon the issue of the Practical Completion Statement the Contractor shall provide to the Employer’s Agent (and shall use best endeavours to do so within 2 months of the date of the issue of the Practical Completion Statement) 3 copies (2 in paper and 1 in electronic format) of the following:-

“as built” drawings including the run and installation of all drains, pipes, cables and other services which are comprised in the Works and which run in, upon, under or over the Site or off-site and all connections to previously existing services and utilities together with all guarantees (including manufacturer warranties and/or product guarantees) and installation, operating and maintenance manuals complete with commissioning data and other appropriate records and related certificates where available and all structural calculations in respect of the Works as completed and of the design;

amendments to Building Control certificate (if applicable);

where applicable evidence of satisfactory completion of testing of gutters, roofs and rainwater outlets; and

Health & Safety file (in so far as applicable under the CDM Regulations).”

Delete the wording in the last paragraph and substitute the following new sub-clause:

The Contractor shall (at no cost to the Employer): 

make good any Emergency Defects (as defined below) as a matter of urgency within 24 hours of receiving the Employer’s instruction. “Emergency Defects” are those defects, shrinkages or other faults which the Employer reasonably considers directly affect the operation of the installation or have health and safety implications. For example (but without limitation):

gas leaks;

dangerous electrical faults;

complete lighting failure;

serious water leaks;

blocked drains;

dangerous structures;

breakdown of heating/AC system;

breakdown of lift installation;

failure of fire alarm system;

failure of security system;

failure of ventilation system;

failure of voice and data cabling; and

failure of hot and cold water services;

make good any Serious Defects (as defined below) within 7 days of receiving the Employer’s instruction. “Serious Defects” are such serious defects, shrinkages (particularly including shrinkage joints in areas of clinical operation) or other faults which the Employer reasonably considers if left unattended would lead to a situation whereby service would be affected; and

shall make good all other Routine Defects (as defined below) notified to the Contractor within 4 weeks of receipt of the Employer’s instructions. “Routine Defects” are all defects, shrinkages and other faults which are not Emergency Defects or Serious Defects.

If the Contractor fails to comply with the Employer’s instruction within the periods specified in Clause 2.35.3, the Employer may serve written notice on the Contractor requiring compliance and if the Contractor does not comply with such notice within twenty four hours for Emergency Defects and forty-eight hours for Serious Defects or Routine Defects then the Employer may employ and pay other persons to execute any work whatsoever which may be necessary to give effect to such instruction and all reasonable costs properly incurred in connection with such employment may be deducted by the Employer from the Contract Sum.

Clause 2.35.3 shall apply mutatis mutandis to any defect shrinkage or other fault and to any items of incomplete work remaining at Practical Completion of the Works or a Section, provided that it is notified to the Contractor not later than 14 days after end of the Rectification Period.”

Delete clause 2.37 and substitute the following:-

Delete clause 2.38 and substitute the following:

The copyright in all designs, drawings, models, plans, specifications, design details, photographs, brochures, reports, notes of meetings, C.A.D. materials and any other materials prepared by the Contractor in connection with the Works (whether in existence or to be made) and all amendments or additions thereto and any works, designs or inventions of the Contractor incorporated or referred to therein (for the purpose of this clause 2.38 hereinafter known as “the Documents”) shall remain vested in the Contractor but the Contractor hereby grants to the Employer an irrevocable royalty free non-exclusive licence to copy, use and reproduce the Documents for any purpose in relation to the Works including (but without limitation) the construction, completion, reconstruction, modification, extension, repair, reinstatement, refurbishment, redevelopment, maintenance, use, letting, promotion and advertisement of the Works provided that the Contractor shall not be liable for the use of the Documents for any purpose for which the Documents were not originally prepared. The said licence shall carry with it the right to grant sub-licences and shall be transferable to third parties without the prior consent of the Contractor.

The Contractor shall not be liable for the use of the sub-licences by third parties for any purpose for which the Documents were not originally prepared. The Contractor warrants that the use of the Documents for the purposes of the Development wlll not infringe the rights of any third person.”

The Contractor warrants to the Employer and undertakes to procure that his Sub Contractors and Suppliers shall waive any rights the Contractor, the Sub-Contractors and/or Suppliers may have pursuant to Section 80 of the copyright, Designs and Patents Act 1988.

The copyright licence shall subsist notwithstanding that the Contractor has completed the Works in accordance with this Contract or that either the Employer or the Contractor has terminated this Contract.”

Save as may be required by legislation or order of a court of competent jurisdiction, the Contractor shall not disclose the existence of, nor any details of this Contract (including the documents referred to therein) to any employee, agent or third party except on a need to know basis, save with the prior written consent of the Employer.

The Contractor shall regard as confidential, any information provided by or on behalf of the Employer in relation to this Contract (including the documents referred to therein), and shall ensure that its agents and advisers comply with the terms of clause 2.39.1.

The obligations in clauses 2.39.1 and 2.39.2 do not apply to information already in the public domain or to any disclosure required by law.”

Delete existing clause and substitute the following instead:-

Delete existing text and insert the following:-

Delete the words “need not comply to the extent that he makes reasonable objection to it in writing to the Employer” and substitute the following therefor:-

Delete the words “pursuant to his obligations under regulation 20 (if he is the CDM Co-ordinator) or regulation 22 of the CDM Regulations” and substitute the following therefor:-

Insert the following words immediately prior to the full stop at the end of clause 3.12:

Undertakings to comply

After the words “notifiable” in the opening paragraph insert “or is one to which CDM 2015 applies”.

After “CDM Co-ordinator” insert “or Principal Designer”.

After “CDM Co-ordinator” insert “or Principal Designer”.

After “CDM Co-ordinator” insert “or Principal Designer”.

After “CDM Co-ordinator” insert “or Principal Designer”.

he has performed and fulfilled and will continue to perform and fulfil the duties imposed on him by the CDM Regulations, both in his capacity as a “contractor” (as defined in the CDM Regulations) and as the Principal Contractor; and

he has performed and fulfilled and will continue to perform and fulfil the duties imposed by the CDM Regulations on a “designer” (as defined in the CDM Regulations); and

he is competent to perform all duties imposed on him by the CDM Regulations;

he has advised and supported and will continue to advise and provide support to the Employer to assist the Employer in performing the duties imposed by the CDM Regulations on a “client” (as defined by the CDM Regulations);”

After “CDM Co-ordinator” (each time it appears) insert “or Principal Designer”.

The Employer shall pay the Contractor in accordance with the provisions of this section 4:

not used.”

not used.

Delete “The Contract Sum is exclusive of VAT and in” an substitute with “In”.”

Delete from “and whichever of the Alternatives...” to the end of the clause.

Delete the words “an amount equal to the Gross Valuation under clause 4.13 where Alternative A applies, or clause 4.14 where alternative B applies, in either case…” and substitute with:

Delete the words: “Where Alternative B applies, for” and replace with “For”.

Delete the first four lines of the clause from “The Final Statement shall set out” until “already paid by the Employer to the Contractor,” and substitute with:

not used.”

not used.”

Delete “in the terms set out in Part 3 of Schedule 6” in the third line and substitute with:

not used.”

not used.”

After “clause 3.13” insert “or as a result of an identified deficiency in the Contractor’s Proposals”.

Delete the words “the alteration of” and replace with “in the event that the Employer instructs the Contractor to make an alteration in”.

Add the following after the word “Works” on line 3 of the clause:-

Delete the existing clause 6.2 and substitute the following instead:-

Liability of Contractor — Trespass, Nuisance etc.

The Contractor shall insofar as reasonably practicable prevent any trespass, nuisance (including without limitation, any such nuisance caused by noxious fumes, noisy working operations or the deposit of any material or debris on the public highway) or other interference with the rights and activities of any adjoining or neighbouring landowner, tenant or occupier or any visitor to property owned or occupied by such third parties or any utility company or statutory undertaker arising out of the carrying out of the Works or of any obligation pursuant to Clause 2.35 and which has been caused or contributed to any act or omission of the Contractor, his servants or agents, or any other person, his servants or agents, for whom the Contractor is responsible for the purposes of Clause 6.3.

For the avoidance of doubt, the Employer may issue to the Contractor such instructions as he considers necessary if any injunction is granted or court order is made in consequence of any such trespass, nuisance or interference, but (save as aforesaid) no such instruction shall be construed as a Change in the Employer’s Requirements.”

Delete the existing wording and insert, “Without prejudice to his obligation to indemnify the Employer under clauses 6.1 and 6.2, the Contractor shall take out and maintain a Policy in the sum of Five Million Pounds (£5, 000,000) Sterling for each and every claim in respect of claims arising out of his liability referred to in clauses 6.1 and 6.2 which:”

Delete the word “and” where it appears at the end of the clause 6.11.2;

Delete “.” and substitute “; and” at the end of clause 6.11.3; and

the insurance referred to in this clause 6.11 shall be with a well established insurance office or underwriter of repute operating in the EU Market. As and when the Contractor is reasonably required to do so by the Employer or the Employer’s Agent, the Contractor shall produce documentary evidence that the insurances required are being properly maintained;

the Contractor shall carry out its obligations under this Contract and shall ensure that its servants or agents shall carry out their respective obligations in such manner that all requirements, terms, conditions, stipulations and provisos of the said insurance are at all time fully complied with; and

this Clause 6.11 shall continue to apply following the termination or repudiation of this Contract for any reason.”

Delete the existing clause and substitute the following instead:-

The Contractor will not be entitled to contend that any person to whom this Contract is assigned in accordance with clause 7.1 or 7.2.1 is precluded from recovering under this Contract any loss incurred by such assignee resulting from any breach of this Contract (whenever happening) by reason that such person is an assignee and not a named party hereunder.”

The Contractor shall use its reasonable endeavours to procure (insofar as is reasonably practicable) that all benefit, right and title to the guarantees and warranties obtainable from manufacturers and suppliers of the key product plant and materials in respect of the roofing, cladding and lift installation, are issued directly to the Employer.”

Contractor’s Collateral Warranties

the Owner;

each Tenant;

each Purchaser; and 

each Purchaser’s Funder;

Sub-Contractor’s Collateral Warranties

the Owner;

the Employer;

each Purchaser;

each Tenant; and

each Purchaser’s Funder;

Sub-Contracts

Other Consultants

Suppliers Guarantees

Insert “(including falling to proceed regularly and diligently with the completion of the Works)” after “Contract” in line 2 of sub-clause 8.4.1.2.

Add the following in line 1 after “(but not before)”:-

Delete the existing clause and replace with “[Number not used]” 

Ethical Conduct of the Parties

Delete the words in the heading: “a Joint Names Policy” and substitute with “an Insurance Policy”

Delete each reference to: “Joint Names Policy” within the clause and substitute with: “Insurance Policy”.

Delete the words:

Delete the words in the second line: “Joint Names Policy” and substitute with: “Insurance Policy”.

Delete the words at the end of the first line: “Joint Names Policy” and substitute with: “Insurance Policy”.

Delete the clause in its entirety.

Delete the clause in its entirety.

Delete the words in the third line: “Joint Names Policy” and substitute with: “Insurance Policy”.

at Edinburgh

on December 3, 2015

by:

/s/ D.J.P.E. Cowan

 (Signature)

D.J.P.E. COWAN

 (Full name in CAPITALS)

Director

/s/ Nele Wordsworth Bhebhe

 (Signature)

NELE WORDSWORTH BHEBHE

 (Full name in CAPITALS)

Witness

C/O No 2 LOCHRIN SQUARE

 (Full address - witness only)

at                                                  

on                           

by:

 (Signature)

 (Full name in CAPITALS)

 (Signature)

 (Full name in CAPITALS)

Director/Witness

 (Full address - witness only)