Lease Agreement, by and between the Company and Are-East Jamie Court, LLC, dated as of May 1, 2011, as amended by that certain First Amendment to Lease, dated as of December 1, 2011, as further amended by that certain Second Amendment to Lease, dated as of July 28, 2014, as further amended by that certain Fourth Amendment to Lease dated as of December 29, 2016

EX-10.16 14 d575899dex1016.htm EX-10.16 EX-10.16

Exhibit 10.16

LEASE AGREEMENT

THIS LEASE AGREEMENT (this “Lease”) is made this 1st day of May, 2011, between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company (“Landlord”), and PRINCIPIA BIOPHARMA INC., a Delaware corporation (“Tenant”).

 

Address:

   400 East Jamie Court, South San Francisco, California

Premises:

   That portion of the third floor of the Project, containing approximately 16,751 rentable square feet, as determined by Landlord, as shown on Exhibit A.
Project:    The real property on which the building (the “Building”) in which the Premises are located, together with all improvements thereon and appurtenances thereto as described on Exhibit B.

 

Base Rent:

   Months 1 – 12:    $[•] per rentable square foot of the Premises per month
  

Months 13 – 24:

   $[•] per rentable square foot of the Premises per month
   Months 25 – 36:    $[•] per rentable square foot of the Premises per month

Rentable Area of Premises: 16,751 sq. ft.

Rentable Area of Building: 88,519 sq. ft.

Building’s Share of Project: 54.20%

Rentable Area of Project: 163,307 sq. ft.

Tenant’s Share of Operating Expenses for the Building: 18.92%

Tenant’s Share of Operating Expenses for the Project: 10.26%

Security Deposit: $[•]

 

 

Target Commencement Date:    October 1, 2011; provided, however, that the Target Commencement Date shall be extended 1 day for each day after May 2, 2011, that this Lease is not executed and delivered by Tenant to Landlord for execution.
Base Term:    Beginning on the Commencement Date and ending 36 months from the first day of the first full month of the Term (as defined in Section 2) hereof.
Permitted Use:    Research and development laboratory, related office and other related uses consistent with the character of the Project and otherwise in compliance with the provisions of Section 7 hereof.

 

Address for Rent Payment:
P.O. Box 975383
Dallas, TX ###-###-####
   Landlord’s Notice Address:
385 E. Colorado Boulevard, Suite 299
Pasadena, CA 91101
Attention: Corporate Secretary
  

 

Tenant’s Notice Address:
400 E. Jamie Court, Third Floor
South San Francisco, California 94080
Attention: Lease Administrator

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 2

 

The following Exhibits and Addenda are attached hereto and incorporated herein by this reference:

 

[X] EXHIBIT A - PREMISES DESCRIPTION

  

[X] EXHIBIT B - DESCRIPTION OF PROJECT

[X] EXHIBIT C - WORK LETTER

  

[X] EXHIBIT D - COMMENCEMENT DATE

[X] EXHIBIT E - RULES AND REGULATIONS    [X] EXHIBIT F - TENANT’S PERSONAL PROPERTY
[X] EXHIBIT G – SPACE PLAN   

1. Lease of Premises. Upon and subject to all of the terms and conditions hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. The portions of the Project which are for the non-exclusive use of tenants of the Project are collectively referred to herein as the “Common Areas.” Landlord reserves the right to modify Common Areas, provided that such modifications do not materially adversely affect Tenant’s use of the Premises for the Permitted Use.

2. Delivery; Acceptance of Premises; Commencement Date. Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlord’s Work Substantially Completed (“Delivery” or “Deliver”). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. If Landlord does not Deliver the Premises within 90 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms “Landlord’s Work,” “Tenants’ Work,” “Tenant Delays” and “Substantially Completed” shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 90 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.

The “Commencement Date” shall be the earliest of: (i) the date Landlord Delivers the Premises to Tenant; (ii) the date Landlord could have Delivered the Premises but for Tenant Delays; and (iii) the date Tenant conducts any business in the Premises or any part thereof. Landlord shall endeavor to deliver to Tenant a construction schedule which provides Tenant at least 90 days advance notice of the date that Landlord expects Landlord’s Work to be Substantially Completed. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date and the expiration date of the Term when such are established in the form of the “Acknowledgement of Commencement Date” attached to this Lease as Exhibit D; provided, however, Tenant’s failure to execute and deliver such acknowledgment shall not affect Landlord’s rights hereunder. The “Term” of this Lease shall be the Base Term, as defined above on the first page of this Lease and the Extension Term which Tenant may elect pursuant to Section 40 hereof.

Except as set forth in the Work Letter and this Lease: (i) Tenant shall accept the Premises in their condition as of the Commencement Date, subject to all applicable Legal Requirements (as defined in Section 7 hereof); (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenant’s taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken.

Subject to the provisions of Section 6 of the Work Letter, Landlord shall permit Tenant access to the Premises commencing on the date that is 30 days prior to the Commencement Date, for Tenant’s installation and set up of its furniture, fixtures and equipment (“FF&E Installation”), provided that such FF&E Installation is coordinated with Landlord, and Tenant complies with the Lease and all other reasonable restrictions and conditions Landlord may impose. All such access shall be during normal business hours. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 3

 

For the period of 30 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to the Building or Building Systems (as defined in Section 13), unless Tenant or any Tenant Party was responsible for the cause of such repair, in which case Tenant shall pay the cost.

Except as otherwise set forth in this Lease, Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenant’s business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenant’s representations, warranties, acknowledgments and agreements contained herein.

3. Rent.

(a) Base Rent. The first month’s Base Rent and the Security Deposit shall be due and payable on delivery of an executed copy of this Lease to Landlord. Tenant shall pay to Landlord in advance, without demand, abatement, deduction or set-off, monthly installments of Base Rent on or before the first day of each calendar month during the Term hereof, in lawful money of the United States of America, at the office of Landlord for payment of Rent set forth above, or to such other person or at such other place as Landlord may from time to time designate in writing. Payments of Base Rent for any fractional calendar month shall be prorated. The obligation of Tenant to pay Base Rent and other sums to Landlord and the obligations of Landlord under this Lease are independent obligations. Tenant shall have no right at any time to abate, reduce, or set-off any Rent (as defined in Section 5) due hereunder except for any abatement as may be expressly provided in this Lease.

Notwithstanding anything to the contrary contained herein, Tenant shall be required to pay Base Rent with respect to only (i) 10,000 rentable square feet of the Premises commencing on the Commencement Date through the expiration of the 12th month of the Base Term, and (ii) 14,000 rentable square feet of the Premises commencing on the first day of the 13th month of the Base Term through the expiration of the 24th month of the Base Term. Tenant shall commence paying Base Rent with respect to the entire Premises on the first day of the 25th month of the Base Term.

(b) Additional Rent. In addition to Base Rent, Tenant agrees to pay to Landlord as additional rent (“Additional Rent”): (i) Tenant’s Share of “Operating Expenses” (as defined in Section 5), and (ii) any and all other amounts Tenant assumes or agrees to pay under the provisions of this Lease, including, without limitation, any and all other sums that may become due by reason of any default of Tenant or failure to comply with the agreements, terms, covenants and conditions of this Lease to be performed by Tenant, after any applicable notice and cure period.

4. Base Rent Adjustments. Base Rent shall be increased during the Base Term as provided for in the schedule set forth on page 1 of this Lease. Base Rent adjustments for any fractional calendar month shall be prorated.

5. Operating Expense Payments. Landlord shall deliver to Tenant a written estimate of Operating Expenses for each calendar year during the Term (the “Annual Estimate”), which may be revised by Landlord from time to time (but not more than twice) during such calendar year. During each month of the Term, on the same date that Base Rent is due, Tenant shall pay Landlord an amount equal to 1/12th of Tenant’s Share of the Annual Estimate. Payments for any fractional calendar month shall be prorated.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 4

 

Notwithstanding anything to the contrary contained herein, Tenant shall be required to pay Operating Expenses with respect to only 10,000 rentable square feet of the Premises commencing on the Commencement Date through the expiration of the 6th month of the Base Term. During such period, Tenant’s Share of Operating Expenses for the Building shall be 11.3%. Tenant shall commence paying Operating Expenses with respect to the entire Premises on the first day of the 7th month of the Base Term.

The term “Operating Expenses” means all costs and expenses of any kind or description whatsoever incurred or accrued each calendar year by Landlord with respect to the Building (including the Building’s Share of all costs and expenses of any kind or description incurred or accrued by Landlord with respect to the Project which are not specific to the Building or any other building located in the Project) (including, without duplication, Taxes (as defined in Section 9), reasonable reserves consistent with good business practice for future repairs and replacements, capital repairs and improvements amortized over the lesser of 10 years and the useful life of such capital items, and the costs of Landlord’s third party property manager or, if there is no third party property manager, administration rent in the amount of [•]% of Base Rent), excluding only:

(a) the original design and/or construction costs of the Project and renovation prior to the date of the Lease and costs of correcting defects in such original construction or renovation;

(b) capital expenditures for expansion of the Project;

(c) interest, principal payments of Mortgage (as defined in Section 27) debts of Landlord, financing costs and amortization of funds borrowed by Landlord, whether secured or unsecured, and all payments of base rent (but not taxes or operating expenses) under any ground lease or other underlying lease of all or any portion of the Project);

(d) depreciation of the Project (except for capital improvements, the cost of which are includable in Operating Expenses and amortized as provided above);

(e) advertising, legal and space planning expenses and leasing commissions and other costs and expenses incurred in procuring and leasing space to tenants for the Project, including any leasing office maintained in the Project, free rent and construction allowances for tenants and signage costs incurred with respect to other tenants of the Project;

(f) legal and other expenses incurred in the negotiation or enforcement of leases;

(g) completing, fixturing, improving, renovating, painting, redecorating or other work, which Landlord pays for or performs for other tenants within their premises, and costs of correcting defects in such work;

(h) costs to be reimbursed by other tenants of the Project or Taxes to be paid directly by Tenant or other tenants of the Project, whether or not actually paid;

(i) salaries, wages, benefits and other compensation paid to officers and employees of Landlord who are not assigned in whole or in part to the operation, management, maintenance or repair of the Project;

(j) general organizational, administrative and overhead costs relating to maintaining Landlord’s existence, either as a corporation, partnership, or other entity, including general corporate, legal and accounting expenses;

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 5

 

(k) costs (including attorneys’ fees and costs of settlement, judgments and payments in lieu thereof) incurred in connection with disputes with tenants, other occupants, or prospective tenants, and costs and expenses, including legal fees, incurred in connection with negotiations or disputes with employees, consultants, management agents, leasing agents, purchasers or mortgagees of the Building;

(l) costs (including attorneys’ fees and costs of settlement, judgments and payments in lieu thereof) incurred by Landlord due to the violation by Landlord, its employees, agents or contractors or any tenant of the terms and conditions of any lease of space in the Project or any Legal Requirement (as defined in Section 7);

(m) penalties, fines or interest incurred as a result of Landlord’s inability or failure to make payment of Taxes and/or to file any tax or informational returns when due, or from Landlord’s failure to make any payment of Taxes required to be made by Landlord hereunder before delinquency;

(n) costs of goods and/or services in, for or to the Project paid to Landlord or to subsidiaries or affiliates of Landlord for goods and/or services in, for or to the Project to the extent the same exceeds the costs of such goods and/or services rendered by unaffiliated third parties on a competitive basis;

(o) costs of Landlord’s charitable or political contributions, or of fine art maintained at the Project;

(p) costs in connection with services (including electricity), items or other benefits of a type which are not standard for the Project and which are not available to Tenant without specific charges therefor, but which are provided to another tenant or occupant of the Project, whether or not such other tenant or occupant is specifically charged therefor by Landlord;

(q) costs incurred in the sale or refinancing of the Project;

(r) net income taxes of Landlord or the owner of any interest in the Project, franchise, capital stock, gift, estate or inheritance taxes or any federal, state or local documentary taxes imposed against the Project or any portion thereof or interest therein;

(s) any costs incurred to remove, study, test, remediate or otherwise related to the presence of Hazardous Materials in or about the Building or the Project, which Hazardous Materials Tenant proves (i) existed prior to the Commencement Date, (ii) originated from any separately demised tenant space within the Project other than the Premises or (iii) were not brought upon, kept, used, stored, handled, treated, generated in, or released or disposed of from, the Project by Tenant or any Tenant Party (as herein defined);

(t) costs of repairs and other work occasioned by fire, windstorm, or other casualty for which Landlord is reimbursed by insurance or for which Landlord would have been reimbursed by insurance if Landlord failed to maintain the insurance which Landlord is required to maintain under this Lease;

(u) any expenses otherwise includable within Operating Expenses to the extent actually reimbursed by persons other than tenants of the Project under leases for space in the Project.

Within 90 days after the end of each calendar year (or such longer period as may be reasonably required), Landlord shall furnish to Tenant a statement (an “Annual Statement”) showing in reasonable detail: (a) the total and Tenant’s Share of actual Operating Expenses for the previous calendar year, and (b) the total of Tenant’s payments in respect of Operating Expenses for such year. If Tenant’s Share of actual Operating Expenses for such year exceeds Tenant’s payments of Operating Expenses for such year, the excess shall be due and payable by Tenant as Rent within 30 days after delivery of such Annual Statement to Tenant. If Tenant’s payments of Operating Expenses for such year exceed Tenant’s Share of actual Operating Expenses for such year Landlord shall pay the excess to Tenant within 30 days after delivery of such Annual Statement, except that after the expiration, or earlier termination of the Term or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 6

 

The Annual Statement shall be final and binding upon Tenant unless Tenant, within 90 days after Tenant’s receipt thereof, shall contest any item therein by giving written notice to Landlord, specifying each item contested and the reason therefor. If, during such 90 day period, Tenant reasonably and in good faith questions or contests the accuracy of Landlord’s statement of Tenant’s Share of Operating Expenses, Landlord will provide Tenant with access to Landlord’s books and records relating to the operation of the Project and such information as Landlord reasonably determines to be responsive to Tenant’s questions (the “Expense Information”). If after Tenant’s review of such Expense Information, Landlord and Tenant cannot agree upon the amount of Tenant’s Share of Operating Expenses, then Tenant shall have the right to have an independent regionally recognized public accounting firm selected by Tenant, working pursuant to a fee arrangement other than a contingent fee (at Tenant’s sole cost and expense) and approved by Landlord (which approval shall not be unreasonably withheld or delayed), audit and/or review the Expense Information for the year in question (the “Independent Review”). The results of any such Independent Review shall be binding on Landlord and Tenant. If the Independent Review shows that the payments actually made by Tenant with respect to Operating Expenses for the calendar year in question exceeded Tenant’s Share of Operating Expenses for such calendar year, Landlord shall at Landlord’s option either (i) credit the excess amount to the next succeeding installments of estimated Operating Expenses or (ii) pay the excess to Tenant within 30 days after delivery of such statement, except that after the expiration or earlier termination of this Lease or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord. If the Independent Review shows that Tenant’s payments with respect to Operating Expenses for such calendar year were less than Tenant’s Share of Operating Expenses for the calendar year, Tenant shall pay the deficiency to Landlord within 30 days after delivery of such statement. If the Independent Review shows that Tenant has overpaid with respect to Operating Expenses by more than [•]% then Landlord shall reimburse Tenant for all costs incurred by Tenant for the Independent Review. Operating Expenses for the calendar years in which Tenant’s obligation to share therein begins and ends shall be prorated. Notwithstanding anything set forth herein to the contrary, if the Building is not at least [•]% occupied on average during any year of the Term, Tenant’s Share of Operating Expenses for such year with respect to Variable Operating Expenses shall be computed as though the Building had been[•]% occupied on average during such year. “Variable Operating Expenses” shall mean those Operating Expenses which vary by occupancy including, without limitation, electricity, trash removal and other Utilities (as defined in Section 11).

Tenant’s Share” shall be the percentage set forth on the first page of this Lease as Tenant’s Share as reasonably adjusted by Landlord for changes in the physical size of the Premises or the Project occurring thereafter. Landlord may equitably increase Tenant’s Share for any item of expense or cost reimbursable by Tenant that relates to a repair, replacement, or service that benefits only the Premises or only a portion of the Project that includes the Premises or that varies with Tenant’s occupancy or use. Base Rent, Tenant’s Share of Operating Expenses and all other amounts payable by Tenant to Landlord hereunder are collectively referred to herein as “Rent.

6. Security Deposit. Tenant shall deposit with Landlord, upon delivery of an executed copy of this Lease to Landlord, a security deposit (the “Security Deposit”) for the performance of all of Tenant’s obligations hereunder in the amount set forth on page 1 of this Lease, which Security Deposit shall be in the form of an unconditional and irrevocable letter of credit (the “Letter of Credit”): (i) in form and substance reasonably satisfactory to Landlord, (ii) naming Landlord as beneficiary, (iii) expressly allowing Landlord upon each occurrence of a Default (as defined in Section 20) to draw upon it at anytime from time to time by delivering to the issuer notice that Landlord is entitled to draw thereunder, (iv) issued by an FDIC-insured financial institution reasonably satisfactory to Landlord, and (v) redeemable by presentation of a sight draft in the state of Landlord’s choice. If Tenant does not provide Landlord with a substitute Letter of Credit complying with all of the requirements hereof at least 10 days before the stated expiration date of any then current Letter of Credit, Landlord shall have the right to draw the full amount of the current Letter of Credit and hold the funds drawn in cash without obligation for interest thereon as the Security Deposit. The Security Deposit shall be held by Landlord as security for the performance of Tenant’s obligations under this Lease. The Security Deposit is not an advance rental deposit or a measure of Landlord’s damages in case of Tenant’s default. Upon each occurrence of a Default (as defined in Section 20), Landlord may use all or any part of the Security Deposit to pay delinquent

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 7

 

payments due under this Lease, future rent damages under California Civil Code Section 1951.2, and the cost of any damage, injury, expense or liability caused by such Default, without prejudice to any other remedy provided herein or provided by law. Landlord’s right to use the Security Deposit under thisSection 6 includes the right to use the Security Deposit to pay future rent damages following the termination of this Lease pursuant to Section 21(c) below. Upon any use of all or any portion of the Security Deposit, Tenant shall pay Landlord on demand the amount that will restore the Security Deposit to the amount set forth on Page 1 of this Lease. Tenant hereby waives the provisions of any law, now or hereafter in force, including, without limitation, California Civil Code Section 1950.7, which provide that Landlord may claim from a security deposit only those sums reasonably necessary to remedy defaults in the payment of Rent, to repair damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums reasonably necessary to compensate Landlord for any other loss or damage, foreseeable or unforeseeable, caused by the act or omission of Tenant or any officer, employee, agent or invitee of Tenant. Upon bankruptcy or other debtor-creditor proceedings against Tenant, the Security Deposit shall be deemed to be applied first to the payment of Rent and other charges due Landlord for periods prior to the filing of such proceedings. Upon any such use of all or any portion of the Security Deposit, Tenant shall, within 5 days after demand from Landlord, restore the Security Deposit to its original amount. If Tenant shall fully perform every provision of this Lease to be performed by Tenant, the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant (or, at Landlord’s option, to the last assignee of Tenant’s interest hereunder) within 90 days after the expiration or earlier termination of this Lease.

If Landlord transfers its interest in the Project or this Lease, Landlord shall either (a) transfer any Security Deposit then held by Landlord to a person or entity assuming Landlord’s obligations under this Section 6, or (b) return to Tenant any Security Deposit then held by Landlord and remaining after the deductions permitted herein. Upon such transfer to and assumption by such transferee or the return of the Security Deposit to Tenant, Landlord shall have no further obligation with respect to the Security Deposit, and Tenant’s right to the return of the Security Deposit shall apply solely against Landlord’s transferee. The Security Deposit is not an advance rental deposit or a measure of Landlord’s damages in case of Tenant’s default. Landlord’s obligation respecting the Security Deposit is that of a debtor, not a trustee, and no interest shall accrue thereon.

7. Use. The Premises shall be used solely for the Permitted Use set forth in the basic lease provisions on page 1 of this Lease, and in compliance with all laws, orders, judgments, ordinances, regulations, codes, directives, permits, licenses, covenants and restrictions now or hereafter applicable to the Premises, and to the use and occupancy thereof, including, without limitation, the Americans With Disabilities Act, 42 U.S.C. § 12101, et seq. (together with the regulations promulgated pursuant thereto, “ADA”) (collectively, “Legal Requirements” and each, a “Legal Requirement”). Tenant shall, upon 5 days’ written notice from Landlord, discontinue any use of the Premises which is declared by any Governmental Authority (as defined in Section 9) having jurisdiction to be a violation of a Legal Requirement. Tenant will not use or permit the Premises to be used for any purpose or in any manner that would void Tenant’s or Landlord’s insurance, increase the insurance risk, or cause the disallowance of any sprinkler or other credits. Tenant shall not permit any part of the Premises to be used as a “place of public accommodation”, as defined in the ADA or any similar legal requirement. Tenant shall reimburse Landlord promptly upon demand for any additional premium charged for any such insurance policy by reason of Tenant’s failure to comply with the provisions of this Section or otherwise caused by Tenant’s use and/or occupancy of the Premises. Tenant will use the Premises in a careful, safe and proper manner and will not commit or permit waste, overload the floor or structure of the Premises, subject the Premises to use that would damage the Premises or obstruct or interfere with the rights of Landlord or other tenants or occupants of the Project, including conducting or giving notice of any auction, liquidation, or going out of business sale on the Premises, or using or allowing the Premises to be used for any unlawful purpose. Tenant shall cause any equipment or machinery to be installed in the Premises so as to reasonably prevent sounds or vibrations from the Premises from extending into Common Areas, or other space in the Project. Tenant shall not place any machinery or equipment weighing 500 pounds or more in or upon the Premises or transport or move such items through the Common Areas of the Project or in the Project elevators without the prior written consent of Landlord. Except as may be

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 8

 

provided under the Work Letter, Tenant shall not, without the prior written consent of Landlord, use the Premises in any manner which will require ventilation, air exchange, heating, gas, steam, electricity or water beyond the existing capacity of the Project as proportionately allocated to the Premises based upon Tenant’s Share as usually furnished for the Permitted Use.

Landlord shall, at Landlord’s sole cost and expense, be responsible for the compliance of the Premises with Legal Requirements, including the ADA, as of the Commencement Date. Following the Commencement Date, (i) Landlord shall, as an Operating Expense (to the extent such Legal Requirement is generally applicable to similar buildings in the area in which the Project is located) or at Tenant’s expense (to the extent such Legal Requirement is applicable by reason of Tenant’s, as compared to other tenants of the Project, specific use of the Premises or Tenant’s alterations) make any alterations or modifications to the Common Areas or the exterior of the Building that are required by Legal Requirements. Tenant, at its sole expense, shall make any alterations or modifications to the interior or the exterior of the Premises or the Project that are required by Legal Requirements (including, without limitation, compliance of the Premises with the ADA) related to Tenant’s use or occupancy of the Premises. Notwithstanding any other provision herein to the contrary, Tenant shall be responsible for any and all demands, claims, liabilities, losses, costs, expenses, actions, causes of action, damages or judgments, and all reasonable expenses incurred in investigating or resisting the same (including, without limitation, reasonable attorneys’ fees, charges and disbursements and costs of suit) (collectively,“Claims”) arising out of or in connection with Legal Requirements, and Tenant shall indemnify, defend, hold and save Landlord harmless from and against any and all Claims arising out of or in connection with any failure of the Premises to comply with any Legal Requirement.

8. Holding Over. If, with Landlord’s express written consent, Tenant retains possession of the Premises after the termination of the Term, (i) unless otherwise agreed in such written consent, such possession shall be subject to immediate termination by Landlord at any time, (ii) all of the other terms and provisions of this Lease (including, without limitation, the adjustment of Base Rent pursuant to Section 4 hereof) shall remain in full force and effect (excluding any expansion or renewal option or other similar right or option) during such holdover period, (iii) Tenant shall continue to pay Base Rent in the amount payable upon the date of the expiration or earlier termination of this Lease or such other amount as Landlord may indicate, in Landlord’s sole and absolute discretion, in such written consent, and (iv) all other payments shall continue under the terms of this Lease. If Tenant remains in possession of the Premises after the expiration or earlier termination of the Term without the express written consent of Landlord, (A) Tenant shall become a tenant at sufferance upon the terms of this Lease except that the monthly rental shall be equal to [•]% of Rent in effect during the last 30 days of the Term, and (B) Tenant shall be responsible for all damages suffered by Landlord resulting from or occasioned by Tenant’s holding over, including consequential damages. No holding over by Tenant, whether with or without consent of Landlord, shall operate to extend this Lease except as otherwise expressly provided, and this Section 8 shall not be construed as consent for Tenant to retain possession of the Premises. Acceptance by Landlord of Rent after the expiration of the Term or earlier termination of this Lease shall not result in a renewal or reinstatement of this Lease.

9. Taxes. Landlord shall pay, as part of Operating Expenses, all taxes, levies, fees, assessments and governmental charges of any kind, existing as of the Commencement Date or there after enacted (collectively referred to as “Taxes”), imposed by any federal, state, regional, municipal, local or other governmental authority or agency, including, without limitation, quasi-public agencies (collectively, “Governmental Authority”) during the Term, including, without limitation, all Taxes: (i) imposed on or measured by or based, in whole or in part, on rent payable to (or gross receipts received by) Landlord under this Lease and/or from the rental by Landlord of the Project or any portion thereof, or (ii) based on the square footage, assessed value or other measure or evaluation of any kind of the Premises or the Project, or (iii) assessed or imposed by or on the operation or maintenance of any portion of the Premises or the Project, including parking, or (iv) assessed or imposed by, or at the direction of, or resulting from Legal Requirements, or interpretations thereof, promulgated by any Governmental Authority, or (v) imposed as a license or other fee, charge, tax, or assessment on Landlord’s business or occupation of leasing space in the Project. Landlord may contest by appropriate legal proceedings the amount, validity, or application of any Taxes or liens securing Taxes. Taxes shall not include any net

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 9

 

income taxes imposed on Landlord except to the extent such net income taxes are in substitution for any Taxes payable hereunder. Notwithstanding anything to the contrary contained herein, Taxes shall not include any excess profit taxes, franchise taxes, transfer taxes, capital stock taxes, gift taxes, or estate, inheritance or succession taxes imposed on or payable by Landlord. If any such Tax is levied or assessed directly against Tenant, then Tenant shall be responsible for and shall pay the same at such times and in such manner as the taxing authority shall require. Tenant shall pay, prior to delinquency, any and all Taxes levied or assessed against any personal property or trade fixtures placed by Tenant in the Premises, whether levied or assessed against Landlord or Tenant. If any Taxes on Tenant’s personal property or trade fixtures are levied against Landlord or Landlord’s property, or if the assessed valuation of the Project is increased by a value attributable to improvements in or alterations to the Premises, whether owned by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, higher than the base valuation on which Landlord from time-to-time allocates Taxes to all tenants in the Project, Landlord shall have the right, but not the obligation, to pay such Taxes. Landlord’s reasonable determination of any excess assessed valuation shall be binding and conclusive, absent manifest error. The amount of any such payment by Landlord shall constitute Additional Rent due from Tenant to Landlord immediately upon demand.

10. Parking. Subject to all matters of record, Force Majeure, a Taking (as defined in Section 19 below) and the exercise by Landlord of its rights hereunder, Tenant shall have the right, in common with other tenants of the Project pro rata in accordance with the rentable area of the Premises and the rentable areas of the Project occupied by such other tenants, to park in those areas designated for non-reserved parking, subject in each case to Landlord’s reasonable rules and regulations, at no additional cost to Tenant. As of the date of this Lease, Tenant’s pro rata share of parking equates to 2.8 parking stalls per 1,000 rentable square feet of the Premises. Landlord may allocate parking spaces among Tenant and other tenants in the Project pro rata as described above if Landlord determines that such parking facilities are becoming crowded. Landlord shall not be responsible for enforcing Tenant’s parking rights against any third parties, including other tenants of the Project.

Tenant acknowledge that there is a Preliminary Transportation Demand Management Plan, as may be amended (“TDM”) setting forth certain requirements relating to parking and transportation demand management which are binding on tenants in the Project and agrees to comply with the requirements of the TDM. Tenant acknowledges that Operating Expenses shall include expenses and assessments related to the TDM.

11. Utilities, Services. Landlord shall provide, subject to the terms of this Section 11, water, electricity, heat, ventilation and air-conditioning (“HVAC”), light, power, sewer, and other utilities (including gas and fire sprinklers to the extent the Project is plumbed for such services), refuse and trash collection and janitorial services (collectively, “Utilities”). Landlord shall pay, as Operating Expenses or subject to Tenant’s reimbursement obligation, for all Utilities used on the Premises, all maintenance charges for Utilities, and any storm sewer charges or other similar charges for Utilities imposed by any Governmental Authority or Utility provider, and any taxes, penalties, surcharges or similar charges thereon. Landlord may cause, at Landlord’s expense, any Utilities to be separately metered or charged directly to Tenant by the provider. Tenant shall pay directly to the Utility provider, prior to delinquency, any separately metered Utilities and services which may be furnished to Tenant or the Premises during the Term. Tenant shall pay, as part of Operating Expenses, its share of all charges for jointly metered Utilities based upon consumption, as reasonably determined by Landlord. Tenant shall not be responsible for any late fees or penalties incurred by Landlord provided that Tenant timely made its reimbursement to Landlord pursuant to this Section 11. No interruption or failure of Utilities, from any cause whatsoever other than Landlord’s willful misconduct, shall result in eviction or constructive eviction of Tenant, termination of this Lease or the abatement of Rent. Tenant agrees to limit use of water and sewer with respect to Common Areas to normal restroom use. Tenant shall have access to the Premises and Utilities shall be available to the Premises 24 hours per day, 7 days per week, except in the case of emergencies, as the result of Legal Requirements, the failure of any Utility provider to provide such Utilities, the performance by Landlord or any Utility provider of any installation, maintenance or repairs, or any other temporary interruptions. Notwithstanding anything to the contrary contained herein, Tenant shall not be required to pay Utilities associated with (i) unoccupied leasable space on the first or second floor of the Building other than Tenant’s Share of the first floor lobby, or (ii) any portion of the parking lot serving the Project in excess of Tenant’s Share of the parking lot.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 10

 

Landlord’s sole obligation for either providing emergency generators or providing emergency back-up power to Tenant shall be: (i) to provide emergency generators with not less than the capacity of the emergency generators located in the Building as of the Commencement Date, and (ii) to contract with a third party to maintain the emergency generators as per the manufacturer’s standard maintenance guidelines. Landlord shall have no obligation to provide Tenant with operational emergency generators or back-up power or to supervise, oversee or confirm that the third party maintaining the emergency generators is maintaining the generators as per the manufacturer’s standard guidelines or otherwise. During any period of replacement, repair or maintenance of the emergency generators when the emergency generators are not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative back-up generator or generators or alternative sources of back-up power. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such emergency generators will be operational at all times or that emergency power will be available to the Premises when needed.

12. Alterations and Tenant’s Property. Any alterations, additions, or improvements made to the Premises by or on behalf of Tenant, including additional locks or bolts of any kind or nature upon any doors or windows in the Premises, but excluding installation, removal or realignment of furniture systems (other than removal of furniture systems owned or paid for by Landlord) not involving any modifications to the structure or connections (other then by ordinary plugs or jacks) to Building Systems( as defined in Section 13) (“Alterations”) shall be subject to Landlord’s prior written consent, which may be given or withheld in Landlord’s sole discretion if any such Alteration affects the structure or Building Systems and shall not be otherwise unreasonably withheld. Tenant may construct nonstructural Alterations in the Premises without Landlord’s prior approval if the aggregate cost of all such work in any 12 month period does not exceed $[•] (a “Notice-Only Alteration”), provided Tenant notifies Landlord in writing of such intended Notice-Only Alteration, and such notice shall be accompanied by plans, specifications, work contracts and such other information concerning the nature and cost of the Notice-Only Alteration as may be reasonably requested by Landlord, which notice and accompanying materials shall be delivered to Landlord not less than 15 business days in advance of any proposed construction. If Landlord approves any Alterations, Landlord may impose such conditions on Tenant in connection with the commencement, performance and completion of such Alterations as Landlord may deem appropriate in Landlord’s reasonable discretion. Any request for approval shall be in writing, delivered not less than 15 business days in advance of any proposed construction, and accompanied by plans, specifications, bid proposals, work contracts and such other information concerning the nature and cost of the alterations as may be reasonably requested by Landlord, including the identities and mailing addresses of all persons performing work or supplying materials. Landlord’s right to review plans and specifications and to monitor construction shall be solely for its own benefit, and Landlord shall have no duty to ensure that such plans and specifications or construction comply with applicable Legal Requirements. Tenant shall cause, at its sole cost and expense, all Alterations to comply with insurance requirements and with Legal Requirements and shall implement at its sole cost and expense any alteration or modification required by Legal Requirements as a result of any Alterations. Tenant shall pay to Landlord, as Additional Rent, on demand an amount equal to [•]% of all charges incurred by Tenant or its contractors or agents in connection with any Alteration to cover Landlord’s overhead and expenses for plan review, coordination, scheduling and supervision; provided, however, that no fee shall be charged by Landlord if Landlord’s involvement is limited to the review and approval of Tenant’s plans. Before Tenant begins any Alteration, Landlord may post on and about the Premises notices of non-responsibility pursuant to applicable law. Tenant shall reimburse Landlord for, and indemnify and hold Landlord harmless from, any expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, delays caused by such work, or inadequate cleanup.

Tenant shall furnish security or make other arrangements reasonably satisfactory to Landlord to assure payment for the completion of all Alterations work free and clear of liens, and shall provide (and cause each contractor or subcontractor to provide) certificates of insurance for workers’ compensation and other coverage in amounts and from an insurance company satisfactory to Landlord protecting

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 11

 

Landlord against liability for personal injury or property damage during construction. Upon completion of any Alterations, Tenant shall deliver to Landlord: (i) sworn statements setting forth the names of all contractors and subcontractors who did the work and final lien waivers from all such contractors and subcontractors; and (ii) “as built” plans for any such Alteration, if the nature of such Alteration required such plans.

Except for Removable Installations (as hereinafter defined), all Installations (as hereinafter defined) shall be and shall remain the property of Landlord during the Term and following the expiration or earlier termination of the Term, shall not be removed by Tenant at any time during the Term, and shall remain upon and be surrendered with the Premises as a part thereof. Notwithstanding the foregoing, Landlord shall, at the time its approval of any such Installation is requested, or at the time it receives notice of a Notice Only Alteration, notify Tenant that Landlord requires that Tenant remove such Installation upon the expiration or earlier termination of the Term, in which event Tenant shall remove such Installation in accordance with the immediately succeeding sentence. Upon the expiration or earlier termination of the Term, Tenant shall remove (i) all wires, cables or similar equipment which Tenant has installed in the Premises or in the risers or plenums of the Building, (ii) any Installations for which Landlord has given Tenant notice of removal in accordance with the immediately preceding sentence, and (iii) all of Tenant’s Property (as hereinafter defined), and Tenant shall restore and repair any damage caused by or occasioned as a result of such removal, including, without limitation, capping off all such connections behind the walls of the Premises and repairing any holes. During any restoration period beyond the expiration or earlier termination of the Term, Tenant shall pay Rent to Landlord as provided herein as if said space were otherwise occupied by Tenant.

For purposes of this Lease, (x) “Removable Installations” means any items listed on Exhibit F attached hereto and any items agreed by Landlord in writing to be included on Exhibit F in the future, (y) “Tenant’s Property” means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and (z) “Installations” means all property of any kind paid for by Landlord, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch. Notwithstanding anything to the contrary contained herein, Exhibit F (as may be amended) shall control in the event of a conflict regarding what property may be removed by Tenant from the Premises.

13. Landlord’s Repairs. Landlord, as an Operating Expense (except to the extent expressly excluded from Operating Expenses pursuant to Section 5), shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”)excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the reasonable judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair of which Tenant becomes aware required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 12

 

such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.

14. Tenant’s Repairs. Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all interior portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Should Tenant fail to make any such repair or replacement or fail to maintain the interior of the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlord’s notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises.

15. Mechanic’s Liens. Tenant shall discharge, by bond or otherwise, any mechanic’s lien filed against the Premises or against the Project for work claimed to have been done for, or materials claimed to have been furnished to, Tenant within 10 days after Tenant receives written notice of the filing thereof, at Tenant’s sole cost and shall otherwise keep the Premises and the Project free from any liens arising out of work performed, materials furnished or obligations incurred by Tenant. Should Tenant fail to discharge any lien described herein, Landlord shall have the right, but not the obligation, to pay such claim or post a bond or otherwise provide security to eliminate the lien as a claim against title to the Project and the cost thereof shall be immediately due from Tenant as Additional Rent. If Tenant shall lease or finance the acquisition of office equipment, furnishings, or other personal property of a removable nature utilized by Tenant in the operation of Tenant’s business, Tenant warrants that any Uniform Commercial Code Financing Statement filed as a matter of public record by any lessor or creditor of Tenant will upon its face or by exhibit thereto indicate that such Financing Statement is applicable only to removable personal property of Tenant located within the Premises. In no event shall the address of the Project be furnished on the statement without qualifying language as to applicability of the lien only to removable personal property, located in an identified suite held by Tenant.

16. Indemnification. Tenant hereby indemnifies and agrees to defend, save and hold Landlord harmless from and against any and all Claims for injury or death to persons or damage to property occurring within or about the Premises, arising directly or indirectly out of use or occupancy of the Premises or a breach or default by Tenant in the performance of any of its obligations hereunder, except to the extent caused by the willful misconduct or gross negligence of Landlord. Landlord shall not be liable to Tenant for, and Tenant assumes all risk of damage to, personal property (including, without limitation, loss of records kept within the Premises). Tenant further waives any and all Claims for injury to Tenant’s business or loss of income relating to any such damage or destruction of personal property (including, without limitation, any loss of records). Landlord shall not be liable for any damages arising from any act, omission or neglect of any tenant in the Project or of any other third party.

17. Insurance. Landlord shall maintain all risk property and, if applicable, sprinkler damage insurance covering the full replacement cost of the Project. Landlord shall further procure and maintain commercial general liability insurance with a single loss limit of not less than $[•] for bodily injury and property damage with respect to the Project. Landlord may, but is not obligated to, maintain such other insurance and additional coverages as it may deem necessary, including, but not limited to, flood, environmental hazard and earthquake, loss or failure of building equipment, errors and omissions, rental loss during the period of repair or rebuilding, workers’ compensation insurance and fidelity bonds for employees employed to perform services and insurance for any improvements installed by Tenant or which are in addition to the standard improvements customarily furnished by Landlord without regard to whether or not such are made a part of the Project. All such insurance shall be included as part of the Operating Expenses. The Project may be included in a blanket policy (in which case the cost of such insurance allocable to the Project will be determined by Landlord based upon the insurer’s cost calculations). Tenant shall also reimburse Landlord for any increased premiums or additional insurance which Landlord reasonably deems necessary as a result of Tenant’s use of the Premises.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 13

 

Tenant, at its sole cost and expense, shall maintain during the Term: all risk or special form property insurance with business interruption and extra expense coverage, covering the full replacement cost of all property and improvements installed or placed in the Premises by Tenant at Tenant’s expense; workers’ compensation insurance with no less than the minimum limits required by law; employer’s liability insurance with such limits as required by law; and commercial general liability insurance, with a minimum limit of not less than $[•] per occurrence for bodily injury and property damage with respect to the Premises. The commercial general liability insurance policy shall name Alexandria Real Estate Equities, Inc., and Landlord, its officers, directors, employees, managers, agents, invitees and contractors (collectively, “Landlord Parties”), as additional insureds; insure on an occurrence and not a claims-made basis; be issued by insurance companies which have a rating of not less than policyholder rating of A and financial category rating of at least Class VII in “Best’s Insurance Guide”; include hostile fire and contractual liability coverage; and provide primary coverage to Landlord (any policy issued to Landlord providing duplicate or similar coverage shall be deemed excess over Tenant’s policies). Tenant shall (i) provide Landlord with advance written notice of cancellation of such commercial general liability policy, and (ii) require Tenant’s insurer to endeavor to provide 10 days advance written notice of cancellation of such commercial general liability policy. Certificates of insurance showing the limits of coverage required hereunder and showing Landlord as an additional insured, along with reasonable evidence of the payment of premiums for the applicable period, shall be delivered to Landlord by Tenant upon commencement of the Term and upon each renewal of said insurance. Tenant’s policy may be a “blanket policy” with an aggregate per location endorsement which specifically provides that the amount of insurance shall not be prejudiced by other losses covered by the policy. Tenant shall, at least 5 days prior to the expiration of such policies, furnish Landlord with renewal certificates.

In each instance where insurance is to name Landlord as an additional insured, Tenant shall upon written request of Landlord also designate and furnish certificates so evidencing Landlord as additional insured to: (i) any lender of Landlord holding a security interest in the Project or any portion thereof, (ii) the landlord under any lease wherein Landlord is tenant of the real property on which the Project is located, if the interest of Landlord is or shall become that of a tenant under a ground or other underlying lease rather than that of a fee owner, and/or (iii) any management company retained by Landlord to manage the Project.

The property insurance obtained by Landlord and Tenant shall include a waiver of subrogation by the insurers and all rights based upon an assignment from its insured, against Landlord or Tenant, and their respective officers, directors, employees, managers, agents, invitees and contractors (“Related Parties”), in connection with any loss or damage thereby insured against. Neither party nor its respective Related Parties shall be liable to the other for loss or damage caused by any risk insured against under property insurance required to be maintained hereunder, and each party waives any claims against the other party, and its respective Related Parties, for such loss or damage. The failure of a party to insure its property shall not void this waiver. Landlord and its respective Related Parties shall not be liable for, and Tenant hereby waives all claims against such parties for, business interruption and losses occasioned thereby sustained by Tenant or any person claiming through Tenant resulting from any accident or occurrence in or upon the Premises or the Project from any cause whatsoever. If the foregoing waivers shall contravene any law with respect to exculpatory agreements, the liability of Landlord or Tenant shall be deemed not released but shall be secondary to the other’s insurer.

Landlord may require insurance policy limits to be raised to conform with requirements of Landlord’s lender and/or to bring coverage limits to levels then being generally required of new tenants within the Project; provided, however, that the increased amount of coverage is consistent with coverage amounts then being required by institutional owners of similar projects with tenants occupying similar size premises in the geographical area in which the Project is located.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 14

 

18. Restoration. If, at any time during the Term, the Project or the Premises are damaged or destroyed by a fire or other insured casualty, Landlord shall notify Tenant within 60 days after discovery of such damage as to the amount of time Landlord reasonably estimates it will take to restore the Project or the Premises, as applicable (the “Restoration Period”). If the Restoration Period is estimated to exceed 9 months (the “Maximum Restoration Period”), Landlord may, in such notice, elect to terminate this Lease as of the date that is 75 days after the date of discovery of such damage or destruction. Unless Landlord so elects to terminate this Lease, Landlord shall, subject to receipt of sufficient insurance proceeds (with any deductible to be treated as a current Operating Expense), promptly restore the Premises (excluding the improvements installed by Tenant or by Landlord and paid for by Tenant), subject to delays arising from the collection of insurance proceeds, from Force Majeure events or as needed to obtain any license, clearance or other authorization of any kind required to enter into and restore the Premises issued by any Governmental Authority having jurisdiction over the use, storage, handling, treatment, generation, release, disposal, removal or remediation of Hazardous Materials (as defined in Section 30) in, on or about the Premises (collectively referred to herein as “Hazardous Materials Clearances”); provided, however, that if repair or restoration of the Premises is not substantially complete as of the end of the Maximum Restoration Period or, if longer, the Restoration Period, Landlord may, in its sole and absolute discretion, elect not to proceed with such repair and restoration, or Tenant may by written notice to Landlord delivered within 5 business days of the expiration of the Maximum Restoration Period or, if longer, the Restoration Period, elect to terminate this Lease, in which event Landlord shall be relieved of its obligation to make such repairs or restoration and this Lease shall terminate as of the date that is 75 days after the later of: (i) discovery of such damage or destruction, or (ii) the date all required Hazardous Materials Clearances are obtained, but Landlord shall retain any Rent paid and the right to any Rent payable by Tenant prior to such election by Landlord or Tenant.

Tenant, at its expense, shall promptly perform, subject to delays arising from the collection of insurance proceeds, from Force Majeure (as defined in Section 34) events or to obtain Hazardous Material Clearances, all repairs or restoration not required to be done by Landlord. Notwithstanding the foregoing, either Landlord or Tenant may terminate this Lease, upon written notice to the non-terminating party, if the Premises are damaged during the last 1 year of the Term and Landlord reasonably estimates that it will take more than 2 months to repair such damage; provided, however, that such notice is delivered 15 business days after the date that Landlord provides Tenant with written notice of the estimated Restoration Period. Landlord shall also have the right to terminate this Lease if insurance proceeds are not available for such restoration. Rent shall be abated from the date all required Hazardous Material Clearances are obtained until the Premises are repaired and restored, in the proportion which the area of the Premises, if any, which is not usable by Tenant bears to the total area of the Premises, unless Landlord provides Tenant with other space during the period of repair that is suitable in Tenant’s commercially reasonable judgment for the temporary conduct of Tenant’s business. Such abatement shall be the sole remedy of Tenant, and except as provided in this Section 18, Tenant waives any right to terminate the Lease by reason of damage or casualty loss.

The provisions of this Lease, including this Section 18, constitute an express agreement between Landlord and Tenant with respect to any and all damage to, or destruction of, all or any part of the Premises, or any other portion of the Project, and any statute or regulation which is now or may hereafter be in effect shall have no application to this Lease or any damage or destruction to all or any part of the Premises or any other portion of the Project, the parties hereto expressly agreeing that this Section 18sets forth their entire understanding and agreement with respect to such matters.

19. Condemnation. If the whole or any material part of the Premises or the Project is taken for any public or quasi-public use under governmental law, ordinance, or regulation, or by right of eminent domain, or by private purchase in lieu thereof (a “Taking” or “Taken”), and the Taking would in Landlord’s reasonable judgment, either prevent or materially interfere with Tenant’s use of the Premises or materially interfere with or impair Landlord’s ownership or operation of the Project, then upon written notice by Landlord this Lease shall terminate and Rent shall be apportioned as of said date. If part of the Premises shall be Taken, and this Lease is not terminated as provided above, Landlord shall promptly restore the Premises and the Project as nearly as is commercially reasonable under the circumstances to their

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 15

 

condition prior to such partial Taking and the rentable square footage of the Building, the rentable square footage of the Premises, Tenant’s Share of Operating Expenses and the Rent payable hereunder during the unexpired Term shall be reduced to such extent as may be fair and reasonable under the circumstances. Upon any such Taking, Landlord shall be entitled to receive the entire price or award from any such Taking without any payment to Tenant, and Tenant hereby assigns to Landlord Tenant’s interest, if any, in such award. Tenant shall have the right, to the extent that same shall not diminish Landlord’s award, to make a separate claim against the condemning authority (but not Landlord) for such compensation as may be separately awarded or recoverable by Tenant for moving expenses and damage to Tenant’s trade fixtures, if a separate award for such items is made to Tenant. Tenant hereby waives any and all rights it might otherwise have pursuant to any provision of state law to terminate this Lease upon a partial Taking of the Premises or the Project.

20. Events of Default. Each of the following events shall be a default (“Default”) by Tenant under this Lease:

(a) Payment Defaults. Tenant shall fail to pay any installment of Rent or any other payment hereunder when due; provided, however, that Landlord will give Tenant notice and an opportunity to cure any failure to pay Rent within 3 days of such notice not more than once in any 12 months period and Tenant agrees that such notice shall be in lieu of and not in addition to, or shall be deemed to be, any notice required by law.

(b) Insurance. Any insurance required to be maintained by Tenant pursuant to this Lease shall be canceled or terminated or shall expire or shall be reduced or materially changed, or Landlord shall receive a notice of non renewal of any such insurance and Tenant shall fail to obtain replacement insurance at least 20 days before the expiration of the current coverage.

(c) Abandonment. Tenant shall abandon the Premises for a period in excess of 10 consecutive business days. Tenant shall not be deemed to have abandoned the Premises if (i) Tenant provides Landlord with reasonable advance notice prior to vacating and, at the time of vacating the Premises, Tenant completes Tenant’s obligations with respect to the Surrender Plan in compliance with Section 28, (ii) Tenant has made reasonable arrangements with Landlord for the security of the Premises for the balance of the Term, and (Hi) Tenant continues during the balance of the Term to satisfy all of its obligations under the Lease as they come due.

(d) Improper Transfer. Tenant shall assign, sublease or otherwise transfer or attempt to transfer all or any portion of Tenant’s interest in this Lease or the Premises except as expressly permitted herein, or Tenant’s interest in this Lease shall be attached, executed upon, or otherwise judicially seized and such action is not released within 90 days of the action.

(e) Liens. Tenant shall fail to discharge or otherwise obtain the release of any lien placed upon the Premises in violation of this Lease within 10 days after any such lien is filed against the Premises.

(f) Insolvency Events. Tenant or any guarantor or surety of Tenant’s obligations hereunder shall: (A) make a general assignment for the benefit of creditors; (B) commence any case, proceeding or other action seeking to have an order for relief entered on its behalf as a debtor or to adjudicate it a bankrupt or insolvent, or seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of it or its debts or seeking appointment of a receiver, trustee, custodian or other similar official for it or for all or of any substantial part of its property (collectively a “Proceeding for Relief”); (C) become the subject of any Proceeding for Relief which is not dismissed within 90 days of its filing or entry; or (D) die or suffer a legal disability (if Tenant, guarantor, or surety is an individual) or be dissolved or otherwise fail to maintain its legal existence (if Tenant, guarantor or surety is a corporation, partnership or other entity).

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 16

 

(g) Estoppel Certificate or Subordination Agreement. Tenant fails to execute any document required from Tenant under Sections 23 or 27 within 5 days after a second notice requesting such document.

(h) Other Defaults. Tenant shall fail to comply with any provision of this Lease other than those specifically referred to in this Section 20, and, except as otherwise expressly provided herein, such failure shall continue for a period of 30 days after written notice thereof from Landlord to Tenant; provided that if the nature of Tenant’s default pursuant to this Section 20(h) is such that it cannot be cured by the payment of money and reasonably requires more than 30 days to cure, then Tenant shall not be deemed to be in default if Tenant commences such cure within said 30 day period and thereafter diligently prosecutes the same to completion; provided, however, that such cure shall be completed no later than 45 days from the date of Landlord’s notice.

Any notice given under Section 20(h) hereof shall: (i) specify the alleged default, (ii) demand that Tenant cure such default, (iii) be in lieu of, and not in addition to, or shall be deemed to be, any notice required under any provision of applicable law, and (iv) not be deemed a forfeiture or a termination of this Lease unless Landlord elects otherwise in such notice; provided that if the nature of Tenant’s default pursuant to Section 20(h) is such that it cannot be cured by the payment of money and reasonably requires more than 30 days to cure, then Tenant shall not be deemed to be in default if Tenant commences such cure within said 30 day period and thereafter diligently prosecutes the same to completion; provided, however, that such cure shall be completed no later than 60 days from the date of Landlord’s notice.

21. Landlord’s Remedies.

(a) Payment By Landlord; Interest. Upon a Default by Tenant hereunder, Landlord may, without waiving or releasing any obligation of Tenant hereunder, make such payment or perform such act. All sums so paid or incurred by Landlord, together with interest thereon, from the date such sums were paid or incurred, at the annual rate equal to [•]% per annum or the highest rate permitted by law (the “Default Rate”), whichever is less, shall be payable to Landlord on demand as Additional Rent. Nothing herein shall be construed to create or impose a duty on Landlord to mitigate any damages resulting from Tenant’s Default hereunder.

(b) Late Payment Rent. Late payment by Tenant to Landlord of Rent and other sums due will cause Landlord to incur costs not contemplated by this Lease, the exact amount of which will be extremely difficult and impracticable to ascertain. Such costs include, but are not limited to, processing and accounting charges and late charges which may be imposed on Landlord under any Mortgage covering the Premises. Therefore, if any installment of Rent due from Tenant is not received by Landlord within 5 days after the date such payment is due, Tenant shall pay to Landlord an additional sum equal to [•]% of the overdue Rent as a late charge. Notwithstanding the foregoing, before assessing a late charge the first time in any calendar year, Landlord shall provide Tenant written notice of the delinquency and will waive the right if Tenant pays such delinquency within 5 days thereafter. The parties agree that this late charge represents a fair and reasonable estimate of the costs Landlord will incur by reason of late payment by Tenant. In addition to the late charge, Rent not paid when due shall bear interest at the Default Rate from the 5th day after the date due until paid.

(c) Remedies. Upon the occurrence of a Default, Landlord, at its option, without further notice or demand to Tenant, shall have in addition to all other rights and remedies provided in this Lease, at law or in equity, the option to pursue any one or more of the following remedies, each and all of which shall be cumulative and nonexclusive, without any notice or demand whatsoever.

(i) Terminate this Lease, or at Landlord’s option, Tenant’s right to possession only, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy which it may have for possession or arrearages in rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim or damages therefor;

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 17

 

(ii) Upon any termination of this Lease, whether pursuant to the foregoing Section 21(c)(i) or otherwise, Landlord may recover from Tenant the following:

(A) The worth at the time of award of any unpaid rent which has been earned at the time of such termination; plus

(B) The worth at the time of award of the amount by which the unpaid rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(C) The worth at the time of award of the amount by which the unpaid rent for the balance of the Term after the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus

(D) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenant’s failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including, but not limited to, brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion thereof for anew tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant; and

(E) At Landlord’s election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by applicable law.

The term “rent” as used in this Section 21 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii)(A) and (B), above, the “worth at the time of award” shall be computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus [•]%.

(iii) Landlord may continue this Lease in effect after Tenant’s Default and recover rent as it becomes due (Landlord and Tenant hereby agreeing that Tenant has the right to sublet or assign hereunder, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease following a Default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due.

(iv) Whether or not Landlord elects to terminate this Lease following a Default by Tenant, Landlord shall have the right to terminate any and all subleases, licenses, concessions or other consensual arrangements for possession entered into by Tenant and affecting the Premises or may, in Landlord’s sole discretion, succeed to Tenant’s interest in such subleases, licenses, concessions or arrangements. Upon Landlord’s election to succeed to Tenant’s interest in any such subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of such election, have no further right to or interest in the rent or other consideration receivable thereunder.

(v) Independent of the exercise of any other remedy of Landlord hereunder or under applicable law, Landlord may conduct an environmental test of the Premises as generally described in Section 30(d) hereof, at Tenant’s expense.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 18

 

(d) Effect of Exercise. Exercise by Landlord of any remedies hereunder or otherwise available shall not be deemed to be an acceptance of surrender of the Premises and/or a termination of this Lease by Landlord, it being understood that such surrender and/or termination can be effected only by the express written agreement of Landlord and Tenant. Any law, usage, or custom to the contrary notwithstanding, Landlord shall have the right at all times to enforce the provisions of this Lease in strict accordance with the terms hereof; and the failure of Landlord at any time to enforce its rights under this Lease strictly in accordance with same shall not be construed as having created a custom in any way or manner contrary to the specific terms, provisions, and covenants of this Lease or as having modified the same and shall not be deemed a waiver of Landlord’s right to enforce one or more of its rights in connection with any subsequent default. A receipt by Landlord of Rent or other payment with knowledge of the breach of any covenant hereof shall not be deemed a waiver of such breach, and no waiver by Landlord of any provision of this Lease shall be deemed to have been made unless expressed in writing and signed by Landlord. To the greatest extent permitted by law, Tenant waives the service of notice of Landlord’s intention to re-enter, re-take or otherwise obtain possession of the Premises as provided in any statute, or to institute legal proceedings to that end, and also waives all right of redemption in case Tenant shall be dispossessed by a judgment or by warrant of any court or judge. Any reletting of the Premises or any portion thereof shall be on such terms and conditions as Landlord in its sole discretion may determine. Landlord shall not be liable for, nor shall Tenant’s obligations hereunder be diminished because of, Landlord’s failure to relet the Premises or collect rent due in respect of such reletting or otherwise to mitigate any damages arising by reason of Tenant’s Default.

22. Assignment and Subletting.

(a) General Prohibition. Without Landlord’s prior written consent subject to and on the conditions described in this Section 22, Tenant shall not, directly or indirectly, voluntarily or by operation of law, assign this Lease or sublease the Premises or any part thereof or mortgage, pledge, or hypothecate its leasehold interest or grant any concession or license within the Premises, and any attempt to do any of the foregoing shall be void and of no effect. If Tenant is a corporation, partnership or limited liability company, the shares or other ownership interests thereof which are not actively traded upon a stock exchange or in the over-the-counter market, a transfer or series of transfers whereby 50% or more of the issued and outstanding shares or other ownership interests of such corporation are, or voting control is, transferred (but excepting transfers upon deaths of individual owners) from a person or persons or entity or entities which were owners thereof at time of execution of this Lease to persons or entities who were not owners of shares or other ownership interests of the corporation, partnership or limited liability company at time of execution of this Lease, shall be deemed an assignment of this Lease requiring the consent of Landlord as provided in this Section 22. Notwithstanding the foregoing, Tenant shall have the right to obtain financing from institutional investors (including venture capital funding and corporate partners) which regularly invest in private biotechnology companies or undergo a public offering which results in a change in control of Tenant without such change of control constituting an assignment under this Section 22 requiring Landlord consent, provided that (i) Tenant notifies Landlord in writing of the financing at least 5 business days prior to the closing of the financing, and (ii) provided that in no event shall such financing result in a change in use of the Premises from the use contemplated by Tenant at the commencement of the Term.

(b) Permitted Transfers. If Tenant desires to assign, sublease, hypothecate or otherwise transfer this Lease or sublet the Premises, other than pursuant to a Permitted Assignment (as defined below), then at least 15 business days, but not more than 45 business days, before the date Tenant desires the assignment or sublease to be effective (the “Assignment Date”), Tenant shall give Landlord a notice (the “Assignment Notice”) containing such information about the proposed assignee or sublessee, including the proposed use of the Premises and any Hazardous Materials proposed to be used, stored handled, treated, generated in or released or disposed of from the Premises, the Assignment Date, any relationship between Tenant and the proposed assignee or sublessee, and all material terms and conditions of the proposed assignment or sublease, including a copy of any proposed assignment or sublease in its final form, and such other information as Landlord may deem reasonably necessary or appropriate to its consideration whether to grant its consent. Landlord may, by giving written notice to Tenant within 15 business days after receipt of the Assignment Notice: (i) grant such consent,

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 19

 

(ii) refuse such consent, in its reasonable discretion; or (iii) if the sublease or assignment affects all or substantially all of the Premises for the remainder of the Term, terminate this Lease with respect to the space described in the Assignment Notice as of the Assignment Date (an “Assignment Termination”). Among other reasons, it shall be reasonable for Landlord to withhold its consent in any of these instances: (1) the proposed assignee or subtenant is a governmental agency; (2) in Landlord’s reasonable judgment, the use of the Premises by the proposed assignee or subtenant would entail any alterations that would lessen the value of the leasehold improvements in the Premises, or would require increased services by Landlord; (3) in Landlord’s good faith reasonable judgment, the proposed assignee or subtenant is engaged in areas of scientific research or other business concerns that are controversial such that they may (i) attract or cause negative publicity for or about the Building or the Project, (ii) negatively affect the reputation of the Building, the Project or Landlord, (iii) attract protestors to the Building or the Project, or (iv) lessen the attractiveness of the Building or the Project to any tenants or prospective tenants, purchasers or lenders; (4) the proposed assignee or subtenant lacks the creditworthiness to support the financial obligations it will incur under the proposed assignment or sublease; (5) in Landlord’s reasonable judgment, the character, reputation, or business of the proposed assignee or subtenant is inconsistent with the desired tenant-mix or the quality of other tenancies in the Project or is inconsistent with the type and quality of the nature of the Building; (6) Landlord has received from any prior landlord to the proposed assignee or subtenant a negative report concerning such prior landlord’s experience with the proposed assignee or subtenant; (7) Landlord has experienced previous defaults by or is in litigation with the proposed assignee or subtenant; (8) the use of the Premises by the proposed assignee or subtenant will violate any applicable Legal Requirement; (9) the proposed assignee or subtenant, or any entity that, directly or indirectly, controls, is controlled by, or is under common control with the proposed assignee or subtenant, is then an occupant of the Project; (10) the proposed assignee or subtenant is an entity with whom Landlord has executed a letter of intent to lease space in the Project; or (11) the assignment or sublease is prohibited by Landlord’s lender. If Landlord delivers notice of its election to exercise an Assignment Termination, Tenant shall have the right to withdraw such Assignment Notice by written notice to Landlord of such election within 5 business days after Landlord’s notice electing to exercise the Assignment Termination. If Tenant withdraws such Assignment Notice, this Lease shall continue in full force and effect. If Tenant does not withdraw such Assignment Notice, this Lease, and the term and estate herein granted, shall terminate as of the Assignment Date with respect to the space described in such Assignment Notice. No failure of Landlord to exercise any such option to terminate this Lease, or to deliver a timely notice in response to the Assignment Notice, shall be deemed to be Landlord’s consent to the proposed assignment, sublease or other transfer. Tenant shall pay to Landlord a fee equal to [•] Dollars ($[•]) in connection with its consideration of any Assignment Notice and/or its preparation or review of any consent documents. Notwithstanding the foregoing, Landlord’s consent to an assignment of this Lease or a subletting of any portion of the Premises to any entity controlling, controlled by or under common control with Tenant (a “Control Permitted Assignment”) shall not be required, provided that Landlord shall have the right to approve the form of any such sublease or assignment. In addition, Tenant shall have the right to assign this Lease, upon 30 days prior written notice to Landlord (unless Tenant is prohibited from providing such notice by confidentiality or Legal Requirements in which case Tenant shall notify Landlord promptly thereafter) but without obtaining Landlord’s prior written consent, to a corporation or other entity which is a successor-in-interest to Tenant, by way of merger, consolidation or corporate reorganization, or by the purchase of allor substantially all of the assets or the ownership interests of Tenant provided that (i) such merger or consolidation, or such acquisition or assumption, as the case may be, is for a good business purpose and not principally for the purpose of transferring the Lease, and (ii) the net worth (as determined in accordance with generally accepted accounting principles (“GAAP”)) of the assignee is not less than the greater of the net worth (as determined in accordance with GAAP) of Tenant as of (A) the Commencement Date, or (B) as of the date of Tenant’s most current quarterly or annual financial statements, and (iii) such assignee shall agree in writing to assume all of the terms, covenants and conditions of this Lease arising after the effective date of the assignment (a “Corporate Permitted Assignment”). Control Permitted Assignments and Corporate Permitted Assignments are hereinafter referred to as “Permitted Assignments.

(c) Additional Conditions. As a condition to any such assignment or subletting, whether or not Landlord’s consent is required, Landlord may require:

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 20

 

(i) that any assignee or subtenant agree, in writing at the time of such assignment or subletting, that if Landlord gives such party notice that Tenant is in default under this Lease, such party shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments will be received by Landlord without any liability except to credit such payment against those due under the Lease, and any such third party shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided, however, in no event shall Landlord or its successors or assigns be obligated to accept such attornment; and

(ii) A list of Hazardous Materials, certified by the proposed assignee or sublessee to be true and correct, which the proposed assignee or sublessee intends to use, store, handle, treat, generate in or release or dispose of from the Premises, together with copies of all documents relating to such use, storage, handling, treatment, generation, release or disposal of Hazardous Materials by the proposed assignee or subtenant in the Premises or on the Project, prior to the proposed assignment or subletting, including, without limitation: permits; approvals; reports and correspondence; storage and management plans; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given its written consent to do so, which consent may be withheld in Landlord’s sole and absolute discretion); and all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks. Neither Tenant nor any such proposed assignee or subtenant is required, however, to provide Landlord with anyportion(s) of the such documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities. The provisions of this clause (ii) shall not apply if the proposed use of the proposed assignee or sublicense is purely an office use at the time of the proposed assignment or sublease.

(d) No Release of Tenant, Sharing of Excess Rents. Notwithstanding any assignment or subletting, Tenant and any guarantor or surety of Tenant’s obligations under this Lease shall at all times remain fully and primarily responsible and liable for the payment of Rent and for compliance with all of Tenant’s other obligations under this Lease. If the Rent due and payable by a sublessee or assignee (or a combination of the rental payable under such sublease or assignment plus any bonus or other consideration therefor or incident thereto in any form) exceeds the sum of rental payable under this Lease, (excluding however, any Rent payable under this Section) and actual and reasonable brokerage fees and costs related to and required pursuant to any such sublease (“Excess Rent”), then Tenant shall be bound and obligated to pay Landlord as Additional Rent hereunder [•]% of such Excess Rent within 10 days following receipt thereof by Tenant. If Tenant shall sublet the Premises or any part thereof, Tenant hereby immediately and irrevocably assigns to Landlord, as security for Tenant’s obligations under this Lease, all rent from any such subletting, and Landlord as assignee and as attorney-in-fact for Tenant, or a receiver for Tenant appointed on Landlord’s application, may collect such rent and apply it toward Tenant’s obligations under this Lease; except that, until the occurrence of a Default, Tenant shall have the right to collect such rent.

(e) No Waiver. The consent by Landlord to an assignment or subletting shall not relieve Tenant or any assignees of this Lease or any sublessees of the Premises from obtaining the consent of Landlord to any further assignment or subletting nor shall it release Tenant or any assignee or sublessee of Tenant from full and primary liability under the Lease. The acceptance of Rent hereunder, or the acceptance of performance of any other term, covenant, or condition thereof, from any other person or entity shall not be deemed to be a waiver of any of the provisions of this Lease or a consent to any subletting, assignment or other transfer of the Premises.

(f) Prior Conduct of Proposed Transferee. Notwithstanding any other provision of this Section 22, if (i) the proposed assignee or sublessee of Tenant has been required by any prior landlord, lender or Governmental Authority to take remedial action in connection with Hazardous Materials contaminating a property, where the contamination resulted from such party’s action or use of the property in question, (ii) the proposed assignee or sublessee is subject to an enforcement order issued by any Governmental Authority in connection with the use, storage, handling, treatment, generation, release

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 21

 

or disposal of Hazardous Materials (including, without limitation, any order related to the failure to make a required reporting to any Governmental Authority), or (iii) because of the existence of a pre-existing environmental condition in the vicinity of or underlying the Project, the risk that Landlord would be targeted as a responsible party in connection with the remediation of such pre-existing environmental condition would be materially increased or exacerbated by the proposed use of Hazardous Materials by such proposed assignee or sublessee, Landlord shall have the absolute right to refuse to consent to any assignment or subletting to any such party.

23. Estoppel Certificate. Tenant shall, within 10 business days of written notice from Landlord, execute, acknowledge and deliver a statement in writing in any form reasonably requested by a proposed lender or purchaser, (i) certifying that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this Lease as so modified is in full force and effect) and the dates to which the rental and other charges are paid in advance, if any, (ii) acknowledging that, to Tenant’s knowledge, there are not any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (iii) setting forth such further information with respect to the status of this Lease or the Premises as may be requested thereon. Any such statement may be relied upon by any prospective purchaser or encumbrancer of all or any portion of the real property of which the Premises are a part. Tenant’s failure to deliver such statement within such time shall, at the option of Landlord, constitute a Default under this Lease, and, in any event, shall be conclusive upon Tenant that the Lease is in full force and effect and without modification except as maybe represented by Landlord in any certificate prepared by Landlord and delivered to Tenant for execution.

24. Quiet Enjoyment. So long as Tenant is not in Default under this Lease, Tenant shall, subject to the terms of this Lease, at all times during the Term, have peaceful and quiet enjoyment of the Premises against any person claiming by, through or under Landlord.

25. Prorations. All prorations required or permitted to be made hereunder shall be made on the basis of a 360 day year and 30 day months.

26. Rules and Regulations. Tenant shall, at all times during the Term and any extension thereof, comply with all reasonable rules and regulations at any time or from time to time established by Landlord covering use of the Premises and the Project. The current rules and regulations are attached hereto as Exhibit E. If there is any conflict between said rules and regulations and other provisions of this Lease, the terms and provisions of this Lease shall control. Landlord shall not have any liability or obligation for the breach of any rules or regulations by other tenants in the Project and shall not enforce such rules and regulations in a discriminatory manner.

27. Subordination. This Lease and Tenant’s interest and rights hereunder are hereby made and shall be subject and subordinate at all times to the lien of any Mortgage now existing or hereafter created on or against the Project or the Premises, and all amendments, restatements, renewals, modifications, consolidations, refinancing, assignments and extensions thereof, without the necessity of any further instrument or act on the part of Tenant; provided, however that so long as there is no Default hereunder, Tenant’s right to possession of the Premises shall not be disturbed by the Holder of any such Mortgage. Tenant agrees, at the election of the Holder of any such Mortgage, to attorn to any such Holder. Tenant agrees, within 10 business days of written notice from Landlord, to execute, acknowledge and deliver such instruments, confirming such subordination, and such instruments of attornment as shall be requested by any such Holder, provided any such instruments contain appropriate non-disturbance provisions assuring Tenant’s quiet enjoyment of the Premises as set forth in Section 24 hereof. Notwithstanding the foregoing, any such Holder may at any time subordinate its Mortgage to this Lease, without Tenant’s consent, by notice in writing to Tenant, and thereupon this Lease shall be deemed prior to such Mortgage without regard to their respective dates of execution, delivery or recording and in that event such Holder shall have the same rights with respect to this Lease as though this Lease had been executed prior to the execution, delivery and recording of such Mortgage and had been assigned to such Holder. The term “Mortgage” whenever used in this Lease shall be deemed to include deeds of trust, security assignments and any other encumbrances, and any reference to the “Holder” of a Mortgage shall be deemed to include the beneficiary under a deed of trust.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 22

 

28. Surrender. Upon the expiration of the Term or earlier termination of Tenant’s right of possession, Tenant shall surrender the Premises to Landlord in the same condition as received, reasonable wear and tear excepted, subject to any Alterations or Installations permitted by Landlord to remain in the Premises, free of Hazardous Materials brought upon, kept, used, stored, handled, treated, generated in, or released or disposed of from, the Premises by any person other than a Landlord Party (collectively, “Tenant HazMat Operations”) and released of all Hazardous Materials Clearances, broom clean, ordinary wear and tear and casualty loss and condemnation covered by Sections 18 and 19 excepted. At least 3 months prior to the surrender of the Premises, Tenant shall deliver to Landlord a narrative description of the actions proposed (or required by any Governmental Authority) to be taken by Tenant in order to surrender the Premises (including any Installations permitted by Landlord to remain in the Premises) at the expiration or earlier termination of the Term, free from any residual impact from the Tenant HazMat Operations and otherwise released for unrestricted use and occupancy (the “Surrender Plan”). Such Surrender Plan shall be accompanied by a current listing of (i) all Hazardous Materials licenses and permits held by or on behalf of any Tenant Party with respect to the Premises, and (ii) all Hazardous Materials used, stored, handled, treated, generated, released or disposed of from the Premises, and shall be subject to the review and approval of Landlord’s environmental consultant. In connection with the review and approval of the Surrender Plan, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such additional non-proprietary information concerning Tenant HazMat Operations as Landlord shall reasonably request. On or before such surrender, Tenant shall deliver to Landlord evidence that the approved Surrender Plan shall have been satisfactorily completed and Landlord shall have the right, subject to reimbursement at Tenant’s expense as set forth below, to cause Landlord’s environmental consultant to inspect the Premises and perform such additional procedures as may be deemed reasonably necessary to confirm that the Premises are, as of the effective date of such surrender or early termination of the Lease, free from any residual impact from Tenant HazMat Operations. Tenant shall reimburse Landlord, as Additional Rent, for the actual out-of pocket expense incurred by Landlord for Landlord’s environmental consultant to review and approve the Surrender Plan and to visit the Premises and verify satisfactory completion of the same, which cost shall not exceed $[•]. Landlord shall have the unrestricted right to deliver such Surrender Plan and any report by Landlord’s environmental consultant with respect to the surrender of the Premises to third parties; provided, however, that Landlord instructs such parties to treat the same as confidential.

If Tenant shall fail to prepare or submit a Surrender Plan approved by Landlord, or if Tenant shall fail to complete the approved Surrender Plan, or if such Surrender Plan, whether or not approved by Landlord, shall fail to adequately address any residual effect of Tenant HazMat Operations in, on or about the Premises, Landlord shall have the right to take such actions as Landlord may deem reasonable or appropriate to assure that the Premises and the Project are surrendered free from any residual impact from Tenant HazMat Operations, the cost of which actions shall be reimbursed by Tenant as Additional Rent, without regard to the limitation set forth in the first paragraph of this Section 28.

Tenant shall immediately return to Landlord all keys and/or access cards to parking, the Project, restrooms or all or any portion of the Premises furnished to or otherwise procured by Tenant. If any such access card or key is lost, Tenant shall pay to Landlord, at Landlord’s election, either the reasonable cost of replacing such lost access card or key or the reasonable cost of reprogramming the access security system in which such access card was used or changing the lock or locks opened by such lost key. Any Tenant’s Property, Alterations and property not so removed by Tenant as permitted or required herein shall be deemed abandoned and may be stored, removed, and disposed of by Landlord at Tenant’s expense, and Tenant waives all claims against Landlord for any damages resulting from Landlord’s retention and/or disposition of such property. All obligations of Tenant hereunder not fully performed as of the termination of the Term, including the obligations of Tenant under Section 30 hereof, shall survive the expiration or earlier termination of the Term, including, without limitation, indemnity obligations, payment obligations with respect to Rent and obligations concerning the condition and repair of the Premises.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 23

 

29. Waiver of Jury Trial. TO THE EXTENT PERMITTED BY LAW, TENANT AND LANDLORD WAIVE ANY RIGHT TO TRIAL BY JURY OR TO HAVE A JURY PARTICIPATE IN RESOLVING ANY DISPUTE, WHETHER SOUNDING IN CONTRACT, TORT, OR OTHERWISE, BETWEEN LANDLORD AND TENANT ARISING OUT OF THIS LEASE OR ANY OTHER INSTRUMENT, DOCUMENT, OR AGREEMENT EXECUTED OR DELIVERED IN CONNECTION HEREWITH OR THE TRANSACTIONS RELATED HERETO.

30. Environmental Requirements.

(a) Prohibition/Compliance/Indemnity. Tenant shall not cause or permit any Hazardous Materials (as hereinafter defined) to be brought upon, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises or the Project in violation of applicable Environmental Requirements (as hereinafter defined) by Tenant or any Tenant Party. If Tenant breaches the obligation stated in the preceding sentence, or if the presence of Hazardous Materials in the Premises during the Term or any holding over results in contamination of the Premises, the Project or any adjacent property or if contamination of the Premises, the Project or any adjacent property by Hazardous Materials brought into, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises by anyone other than Landlord and Landlord’s employees, agents and contractors otherwise occurs during the Term or any holding over, Tenant hereby indemnifies and shall defend and hold Landlord, its officers, directors, employees, agents and contractors harmless from any and all actions (including, without limitation, remedial or enforcement actions of any kind, administrative or judicial proceedings, and orders or judgments arising out of or resulting therefrom), costs, claims, damages (including, without limitation, punitive damages and damages based upon diminution in value of the Premises or the Project, or the loss of, or restriction on, use of the Premises or any portion of the Project), expenses (including, without limitation, attorneys’, consultants’ and experts’ fees, court costs and amounts paid in settlement of any claims or actions), fines, forfeitures or other civil, administrative or criminal penalties, injunctive or other relief (whether or not based upon personal injury, property damage, or contamination of, or adverse effects upon, the environment, water tables or natural resources), liabilities or losses (collectively, “Environmental Claims”) which arise during or after the Term as a result of such contamination. This indemnification of Landlord by Tenant includes, without limitation, costs incurred in connection with any investigation of site conditions or any cleanup, treatment, remedial, removal, or restoration work required by any federal, state or local Governmental Authority because of Hazardous Materials present in the air, soil or ground water above, on, or under the Premises. Without limiting the foregoing, if the presence of any Hazardous Materials on the Premises, the Building, the Project or any adjacent property caused or permitted by Tenant or any Tenant Party results in any contamination of the Premises, the Building, the Project or any adjacent property, Tenant shall promptly take all actions at its sole expense and in accordance with applicable Environmental Requirements as are necessary to return the Premises, the Building, the Project or any adjacent property to the condition existing prior to the time of such contamination, provided that Landlord’s approval of such action shall first be obtained, which approval shall not unreasonably be withheld so long as such actions would not potentially have any material adverse long-term or short-term effect on the Premises, the Building or the Project. Notwithstanding anything to the contrary contained in this Section 30, Tenant shall not be responsible for, and the indemnification and hold harmless obligation set forth in this paragraph shall not apply to (i) contamination in the Premises which Tenant can prove to Landlord’s reasonable satisfaction existed in the Premises immediately prior to the Commencement Date, or (ii) the presence of any Hazardous Materials in the Premises which Tenant can prove to Landlord’s reasonable satisfaction migrated from outside of the Premises into the Premises, or (iii) contamination caused by Landlord or any Landlord’s employees, agents and contractors unless in each case, the presence of such Hazardous Materials (x) is the result of a breach by Tenant of any of its obligations under this Lease, or (y) was caused, contributed to or exacerbated by Tenant or any Tenant Party.

(b) Business. Landlord acknowledges that it is not the intent of this Section 30 to prohibit Tenant from using the Premises for the Permitted Use. Tenant may operate its business according to prudent industry practices so long as the use or presence of Hazardous Materials is strictly and properly monitored according to all then applicable Environmental Requirements. As a material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees to

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 24

 

deliver to Landlord prior to the Commencement Date a list identifying each type of Hazardous Materials to be brought upon, kept, used, stored, handled, treated, generated on, or released or disposed of from, the Premises and setting forth any and all governmental approvals or permits required in connection with the presence, use, storage, handling, treatment, generation, release or disposal of such Hazardous Materials on or from the Premises (“Hazardous Materials List”). Tenant shall deliver to Landlord an updated Hazardous Materials List at least once a year and shall also deliver an updated list before any new Hazardous Material is brought onto, kept, used, stored, handled, treated, generated on, or released or disposed of from, the Premises. Tenant shall deliver to Landlord true and correct copies of the following documents (the “Haz Mat Documents”) relating to the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials prior to the Commencement Date, or if unavailable at that time, concurrent with the receipt from or submission to a Governmental Authority: permits; approvals; reports and correspondence; storage and management plans, notice of violations of any Legal Requirements; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given Tenant its written consent to do so, which consent may be withheld in Landlord’s sole and absolute discretion); all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks; and a Surrender Plan (to the extent surrender in accordance with Section 28 cannot be accomplished in 3 months). Tenant is not required, however, to provide Landlord with any portion(s) of the Haz Mat Documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities. It is not the intent of this Section to provide Landlord with information which could be detrimental to Tenant’s business should such information become possessed by Tenant’s competitors.

(c) Tenant Representation and Warranty. Tenant hereby represents and warrants to Landlord that (i) neither Tenant nor, to the best of Tenant’s knowledge, any of its legal predecessors has been required by any prior landlord, lender or Governmental Authority at any time to take remedial action in connection with Hazardous Materials contaminating a property which contamination was permitted by Tenant of such predecessor or resulted from Tenant’s or such predecessor’s action or use of the property in question, and (ii) Tenant is not subject to any enforcement order issued by any Governmental Authority in connection with the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials (including, without limitation, any order related to the failure to make a required reporting to any Governmental Authority). If Landlord determines that this representation and warranty was not true as of the date of this lease, Landlord shall have the right to terminate this Lease in Landlord’s sole and absolute discretion.

(d) Testing. Landlord shall have the right to conduct annual tests of the Premises to determine whether any contamination of the Premises or the Project has occurred as a result of Tenant’s use. Tenant shall be required to pay the cost of such annual test of the Premises if there is a violation of this Section 30 or if contamination for which Tenant is responsible under this Section 30 is identified; provided, however, that if Tenant conducts its own tests of the Premises using third party contractors and test procedures acceptable to Landlord which tests are certified to Landlord, Landlord shall accept such tests in lieu of the annual tests to be paid for by Tenant. In addition, at any time, and from time to time, prior to the expiration or earlier termination of the Term, Landlord shall have the right to conduct appropriate tests of the Premises and the Project to determine if contamination has occurred as a result of Tenant’s use of the Premises. In connection with such testing, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such non-proprietary information concerning the use of Hazardous Materials in or about the Premises by Tenant or any Tenant Party. If contamination has occurred for which Tenant is liable under this Section 30 Tenant shall pay all costs to conduct such tests. If no such contamination is found, Landlord shall pay the costs of such tests (which shall not constitute an Operating Expense). Landlord shall provide Tenant with a copy of all third party, non-confidential reports and tests of the Premises made by or on behalf of Landlord during the Term without representation or warranty and subject to a confidentiality agreement. Tenant shall, at its sole cost and expense, promptly and satisfactorily remediate any environmental conditions identified by such testing for which Tenant is responsible under this Section 30 in accordance with all Environmental Requirements. Landlord’s receipt of or satisfaction with any environmental assessment in no way waives any rights which Landlord may have against Tenant.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 25

 

(e) Control Areas. Tenant shall be allowed to utilize up to its pro rata share of hazardous Materials inventory within any control area or zone (located within the Premises), as designated by the applicable building code, for chemical use or storage. As used in the preceding sentence, Tenant’s pro rata share of any control areas or zones located within the Premises shall be determined based on the rentable square footage that Tenant leases within the applicable control area or zone. For purposes of example only, if a control area or zone contains 10,000 rentable square feet and 2,000 rentable square feet of a tenant’s premises are located within such control area or zone (while such premises as a whole contains 5,000 rentable square feet), the applicable tenant’s pro rata share of such control area would be 20%.

(f) Underground Tanks. If underground or other storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements, as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks.

(g) Tenant’s Obligations. Tenant’s obligations under this Section 30 shall survive the expiration or earlier termination of the Lease. During any period of time after the expiration or earlier termination of this Lease required by Tenant or Landlord to complete the removal from the Premises of any Hazardous Materials for which Tenant is responsible under this Lease (including, without limitation, the release and termination of any licenses or permits restricting the use of the Premises and the completion of the approved Surrender Plan), Tenant shall continue to pay the full Rent in accordance with this Lease for any portion of the Premises that cannot be relet by Landlord due to Tenant’s failure to complete such removal of Hazardous Materials, which Rent shall be prorated daily.

(h) Definitions. As used herein, the term “Environmental Requirements” means all applicable present and future statutes, regulations, ordinances, rules, codes, judgments, orders or other similar enactments of any Governmental Authority regulating or relating to health, safety, or environmental conditions on, under, or about the Premises or the Project, or the environment, including without limitation, the following: the Comprehensive Environmental Response, Compensation and Liability Act; the Resource Conservation and Recovery Act; and all state and local counterparts thereto, and any regulations or policies promulgated or issued thereunder. As used herein, the term “Hazardous Materials” means and includes any substance, material, waste, pollutant, or contaminant listed or defined as hazardous or toxic, or regulated by reason of its impact or potential impact on humans, animals and/or the environment under any Environmental Requirements, asbestos and petroleum, including crude oil or any fraction thereof, natural gas liquids, liquefied natural gas, or synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas). As defined in Environmental Requirements, Tenant is and shall be deemed to be the “operator” of Tenant’s “facility” and the “owner” of all Hazardous Materials brought on the Premises by Tenant or any Tenant Party, and the wastes, by-products, or residues generated, resulting, or produced therefrom.

31. Tenant’s Remedies/Limitation of Liability. Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 26

 

necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlord’s obligations hereunder.

All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term “Landlord” in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, and the assumption of the successor owner of all the liabilities and obligations of such owner thereafter accruing, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owner’s ownership.

32. Inspection and Access. Landlord and its agents, representatives, and contractors may enter the Premises at any reasonable time to inspect the Premises and to make such repairs as may be required or permitted pursuant to this Lease and for any other business purpose. Landlord and Landlord’s representatives may enter the Premises during business hours on not less than 48 hours advance written notice (except in the case of emergencies in which case no such notice shall be required and such entry may be at any time) for the purpose of effecting any such repairs, inspecting the Premises, showing the Premises to prospective purchasers and, during the last year of the Term, to prospective tenants or for any other business purpose. Landlord may erect a suitable sign on the Premises stating the Premises are available to let or that the Project is available for sale. Landlord may grant easements, make public dedications, designate Common Areas and create restrictions on or about the Premises, provided that no such easement, dedication, designation or restriction materially, adversely affects Tenant’s use or occupancy of the Premises for the Permitted Use. At Landlord’s request, Tenant shall execute such instruments as may be necessary for such easements, dedications or restrictions, provided that such items do not impose any financial or other material burden on Tenant. Tenant shall at all times, except in the case of emergencies, have the right to escort Landlord or its agents, representatives, contractors or guests while the same are in the Premises, provided such escort does not materially and adversely affect Landlord’s access rights hereunder.

33. Security. Tenant acknowledges and agrees that security devices and services, if any, while intended to deter crime may not in given instances prevent theft or other criminal acts and that Landlord is not providing any security services with respect to the Premises. Tenant agrees that Landlord shall not be liable to Tenant for, and Tenant waives any claim against Landlord with respect to, any loss by theft or any other damage suffered or incurred by Tenant in connection with any unauthorized entry into the Premises or any other breach of security with respect to the Premises. Tenant shall be solely responsible for the personal safety of Tenant’s officers, employees, agents, contractors, guests and invitees while any such person is in, on or about the Premises and/or the Project. Tenant shall at Tenant’s cost obtain insurance coverage to the extent Tenant desires protection against such criminal acts.

34. Force Majeure. Landlord shall not be responsible or liable for delays in the performance of its obligations hereunder when caused by, related to, or arising out of acts of God, sinkholes or subsidence, strikes, lockouts, or other labor disputes, embargoes, quarantines, unusual weather, national, regional, or local disasters, calamities, or catastrophes, inability to obtain labor or materials (or reasonable substitutes therefor) at reasonable costs or failure of, or inability to obtain, utilities necessary for performance, governmental restrictions, orders, limitations, regulations, or controls, national emergencies, delay in issuance or revocation of permits, enemy or hostile governmental action, terrorism, insurrection, riots, civil disturbance or commotion, fire or other casualty, and other causes or events beyond the reasonable control of Landlord (“Force Majeure”).

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 27

 

35. Brokers. Landlord and Tenant each represents and warrants that it has not dealt with any broker, agent or other person (collectively, “Broker”) in connection with this transaction and that no Broker brought about this transaction, other than CresaPartners, Jones Lang LaSalle and CTBT Commercial. Landlord and Tenant each hereby agree to indemnify and hold the other harmless from and against any claims by any Broker, other than the broker, if any named in this Section 35, claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard to this leasing transaction. Landlord shall pay any commissions due to CresaPartners, Jones Lang LaSalle and CTBT Commercial arising out of the execution of this Lease in accordance with the terms of separate written agreements between Landlord and such Brokers.

36. Limitation on Landlord’s Liability. NOTWITHSTANDING ANYTHING SET FORTH HEREIN OR IN ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT TO THE CONTRARY: (A) LANDLORD SHALL NOT BE LIABLE TO TENANT OR ANY OTHER PERSON FOR (AND TENANT AND EACH SUCH OTHER PERSON ASSUME ALL RISK OF) LOSS, DAMAGE OR INJURY, WHETHER ACTUAL OR CONSEQUENTIAL TO: TENANT’S PERSONAL PROPERTY OF EVERY KIND AND DESCRIPTION, INCLUDING, WITHOUT LIMITATION TRADE FIXTURES, EQUIPMENT, INVENTORY, SCIENTIFIC RESEARCH, SCIENTIFIC EXPERIMENTS, LABORATORY ANIMALS, PRODUCT, SPECIMENS, SAMPLES, AND/OR SCIENTIFIC, BUSINESS, ACCOUNTING AND OTHER RECORDS OF EVERY KIND AND DESCRIPTION KEPT AT THE PREMISES AND ANY AND ALL INCOME DERIVED OR DERIVABLE THEREFROM; (B) THERE SHALL BE NO PERSONAL RECOURSE TO LANDLORD FOR ANY ACT OR OCCURRENCE IN, ON OR ABOUT THE PREMISES OR ARISING IN ANY WAY UNDER THIS LEASE OR ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT WITH RESPECT TO THE SUBJECT MATTER HEREOF AND ANY LIABILITY OF LANDLORD HEREUNDER SHALL BE STRICTLY LIMITED SOLELY TO LANDLORD’S INTEREST IN THE PROJECT OR ANY PROCEEDS FROM SALE OR CONDEMNATION THEREOF AND ANY INSURANCE PROCEEDS PAYABLE IN RESPECT OF LANDLORD’S INTEREST IN THE PROJECT OR IN CONNECTION WITH ANY SUCH LOSS; AND (C) IN NO EVENT SHALL ANY PERSONAL LIABILITY BE ASSERTED AGAINST LANDLORD IN CONNECTION WITH THIS LEASE NOR SHALL ANY RECOURSE BE HAD TO ANY OTHER PROPERTY OR ASSETS OF LANDLORD OR ANY OF LANDLORD’S OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS. UNDER NO CIRCUMSTANCES SHALL LANDLORD OR ANY OF LANDLORD’S OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS BE LIABLE FOR INJURY TO TENANT’S BUSINESS OR FOR ANY LOSS OF INCOME OR PROFIT THEREFROM.

37. Severability. If any clause or provision of this Lease is illegal, invalid or unenforceable under present or future laws, then and in that event, it is the intention of the parties hereto that the remainder of this Lease shall not be affected thereby. It is also the intention of the parties to this Lease that in lieu of each clause or provision of this Lease that is illegal, invalid or unenforceable, there be added, as a part of this Lease, a clause or provision as similar in effect to such illegal, invalid or unenforceable clause or provision as shall be legal, valid and enforceable.

38. Signs; Exterior Appearance. Tenant shall not, without the prior written consent of Landlord, which may be granted or withheld in Landlord’s reasonable discretion: (i) attach any awnings, exterior lights, decorations, balloons, flags, pennants, banners, painting or other projection to any outside wall of the Project, (ii) use any curtains, blinds, shades or screens other than Landlord’s standard window coverings, (iii) coat or otherwise sunscreen the interior or exterior of any windows, (iv) place any bottles, parcels, or other articles on the window sills, (v) place any equipment, furniture or other items of personal property on any exterior balcony, or (vi) paint, affix or exhibit on any part of the Premises or the Project any signs, notices, window or door lettering, placards, decorations, or advertising media of any type which can be viewed from the exterior of the Premises. Interior signs on doors and the directory tablet shall be inscribed, painted or affixed for Tenant by Landlord at the sole cost and expense of Tenant, and shall be of a size, color and type acceptable to Landlord. Nothing may be placed on the exterior of corridor walls or corridor doors other than Landlord’s standard lettering. The directory tablet shall be provided exclusively for the display of the name and location of tenants.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 28

 

39. Right to Expand.

(a) Right of First Refusal. At any time after the date of this Lease through the date that is 18 months after the Commencement Date (“Expansion Right Expiration Date”) that Landlord intends to accept a written proposal (the “Pending Deal”) to lease the Expansion Space (as hereinafter defined) to a third party, Landlord shall deliver to Tenant written notice (the “Pending Deal Notice”) of the existence of such Pending Deal, which Pending Deal Notice shall include the material business terms of such Pending Deal which Landlord intends to accept (“Pending Deal Terms”). For purposes of this Section 39(a), “Expansion Space” shall mean that certain approximately 8,399 rentable square feet on the third floor of the Building leased as of the date of this Lease to Sequenta, Inc., and/or that certain approximately 5,063 rentable square feet of the third floor of the Building leased as of the date of this Lease to Patheon Pharmaceuticals Inc., but only if either or both Sequenta, Inc. or Patheon Pharmaceuticals Inc. terminates its lease for its respective premises prior to the Expansion Right Expiration Date. Tenant shall be entitled to exercise its right under this Section 39(a) only with respect to the entire Expansion Space described in such Pending Deal Notice. Within 7 days after Tenant’s receipt of the Pending Deal Notice, Tenant shall deliver to Landlord written notice (the “Space Acceptance Notice”) if Tenant elects to lease the Expansion Space. Tenant’s right to receive the Pending Deal Notice and election to lease or not lease the Expansion Space pursuant to this Section 39(a) is hereinafter referred to as the “Right of First Refusal.” If Tenant elects to lease the Expansion Space described in the Pending Deal Notice by delivering the Space Acceptance Notice within the required 7 day period, Tenant shall be deemed to agree to lease the Expansion Space on the same general terms and conditions as this Lease except that the terms of this Lease shall be modified to reflect the Pending Deal Terms for the rental of the Expansion Space. The term of the Lease with respect to the Expansion Space shall be the term set forth in the Pending Deal Terms, and Tenant agrees that if the term of the Lease with respect to the Expansion Space is scheduled to expire after the expiration of the Base Term of the Lease with respect to the original Premises, the Base Term of the Lease with respect to the original Premises shall be extended so as to be co-terminous with the Base Term of the Lease with respect to the Expansion Space. Notwithstanding anything to the contrary contained herein, in no event shall the Work Letter apply to the Expansion Space. If Tenant fails to deliver a Space Acceptance Notice to Landlord within the required 7 day period, Tenant shall be deemed to have waived its rights under this Section39(a) with respect to the Expansion Space identified in the Pending Deal Notice and the provisions of this Section 39(a) shall no longer apply to the Expansion Space identified in the Pending Deal Notice.

(b) Amended Lease. If: (i) Tenant fails to timely deliver a Space Acceptance Notice, or (ii) after the expiration of a period of 10 days after Landlord’s delivery to Tenant of a lease amendment or lease agreement for Tenant’s lease of the Expansion Space on substantially the same terms and conditions of this Lease other than business terms and other than as modified by the Pending Deal Notice, no lease amendment or lease agreement for the Expansion Space acceptable to both parties each in their sole and absolute discretion, has been executed, Tenant shall be deemed to have waived its right to lease such Expansion Space.

(c) Exceptions. Notwithstanding the above, the Right of First Refusal shall, at Landlord’s option, not be in effect and may not be exercised by Tenant:

(i) during any period of time that Tenant is in Default under any provision of the Lease; or

(ii) if Tenant has been in Default under any provision of the Lease 3 or more times, whether or not the Defaults are cured, during the 12 month period prior to the date on which Tenant seeks to exercise the Right of First Refusal.

(d) Termination. The Right of First Refusal shall, at Landlord’s option, terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Right of First Refusal, if, after such exercise, but prior to the commencement date of the lease of such Expansion Space (i) Tenant fails to timely cure any default by Tenant under the Lease; or (ii) Tenant has Defaulted 3 or more times during the period from the date of the exercise of the Right of First Refusal to the date of the commencement of the lease of the Expansion Space whether or not such Defaults are cured.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 29

 

(e) Subordinate. Tenant’s rights in connection with the Expansion Right are and shall be subject to and subordinate to any expansion or extension rights granted in the Project to Sequenta, Inc. and Patheon Pharmaceuticals Inc.

(f) Rights Personal. The Right of First Refusal is personal to Tenant and is not assignable without Landlord’s consent, which may be granted or withheld in Landlord’s sole discretion separate and apart from any consent by Landlord to an assignment of Tenant’s interest in the Lease, except that they may be assigned in connection with any Permitted Assignment of this Lease.

(g) No Extensions. The period of time within which the Right of First Refusal may be exercised shall not be extended or enlarged by reason of Tenant’s inability to exercise the Right of First Refusal.

40. Right to Extend Term. Tenant shall have the right to extend the Term of the Lease upon the following terms and conditions:

(a) Extension Rights. Tenant shall have 1 right (an “Extension Right”) to extend the term of this Lease for 2 years (an “Extension Term”) on the same terms and conditions as this Lease (other than with respect to Base Rent and the Work Letter) by giving Landlord written notice of its election to exercise such Extension Right at least 9 months prior, and no earlier than 12 months prior, to the expiration of the Base Term of the Lease.

Upon the commencement of the Extension Term, Base Rent shall be payable at the Market Rate (as defined below). Base Rent shall thereafter be adjusted on each annual anniversary of the commencement of such Extension Term by a percentage as determined by Landlord and agreed to by Tenant at the time the Market Rate is determined. As used herein, “Market Rate” shall mean the then market rental rate as determined by Landlord and agreed to by Tenant.

If, on or before the date which is 180 days prior to the expiration of the Base Term of this Lease, Tenant has not agreed with Landlord’s determination of the Market Rate and the rent escalations during the Extension Term after negotiating in good faith, Tenant shall be deemed to have elected arbitration as described in Section 40(b). Tenant acknowledges and agrees that, if Tenant has elected to exercise the Extension Right by delivering notice to Landlord as required in this Section 40(a). Tenant shall have no right thereafter to rescind or elect not to extend the term of the Lease for the Extension Term.

(b) Arbitration.

(i) Within 10 days of Tenant’s notice to Landlord of its election (or deemed election) to arbitrate Market Rate and escalations, each party shall deliver to the other a proposal containing the Market Rate and escalations that the submitting party believes to be correct (“Extension Proposal”). If either party fails to timely submit an Extension Proposal, the other party’s submitted proposal shall determine the Base Rent and escalations for the Extension Term. If both parties submit Extension Proposals, then Landlord and Tenant shall meet within 7 days after delivery of the last Extension Proposal and make a good faith attempt to mutually appoint a single Arbitrator (and defined below) to determine the Market Rate and escalations. If Landlord and Tenant are unable to agree upon a single Arbitrator, then each shall, by written notice delivered to the other within 10 days after the meeting, select an Arbitrator. If either party fails to timely give notice of its selection for an Arbitrator, the other party’s submitted proposal shall determine the Base Rent for the Extension Term. The 2 Arbitrators so appointed shall, within 5 business days after their appointment, appoint a third Arbitrator. If the 2 Arbitrators so selected cannot agree on the selection of the third Arbitrator within the time above specified, then either party, on behalf of both parties, may request such appointment of such third Arbitrator by application to any state court of general jurisdiction in the jurisdiction in which the Premises are located, upon 10 days prior written notice to the other party of such intent.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 30

 

(ii) The decision of the Arbitrator(s) shall be made within 30 days after the appointment of a single Arbitrator or the third Arbitrator, as applicable. The decision of the single Arbitrator shall be final and binding upon the parties. The average of the two closest Arbitrators in a three Arbitrator panel shall be final and binding upon the parties. Each party shall pay the fees and expenses of the Arbitrator appointed by or on behalf of such party and the fees and expenses of the third Arbitrator shall be borne equally by both parties. If the Market Rate and escalations are not determined by the first day of the Extension Term, then Tenant shall pay Landlord Base Rent in an amount equal to the Base Rent in effect immediately prior to the Extension Term and increased by the Rent Adjustment Percentage until such determination is made. After the determination of the Market Rate and escalations, the parties shall make any necessary adjustments to such payments made by Tenant. Landlord and Tenant shall then execute an amendment recognizing the Market Rate and escalations for the Extension Term.

(iii) An “Arbitrator” shall be any person appointed by or on behalf of either party or appointed pursuant to the provisions hereof and: (i) shall be (A) a member of the American Institute of Real Estate Appraisers with not less than 10 years of experience in the appraisal of improved office and high tech or life science industrial real estate in the greater South San Francisco area, or (B) a licensed commercial real estate broker with not less than 15 years experience representing landlords and/or tenants in the leasing of high tech or life sciences space in the greater South San Francisco area, (ii) devoting substantially all of their time to professional appraisal or brokerage work, as applicable, at the time of appointment and (Hi) be in all respects impartial and disinterested.

(c) Rights Personal. The Extension Right is personal to Tenant and is not assignable without Landlord’s consent, which may be granted or withheld in Landlord’s sole discretion separate and apart from any consent by Landlord to an assignment of Tenant’s interest in the Lease, except that they may be assigned in connection with any Permitted Assignment of this Lease.

(d) Exceptions. Notwithstanding anything set forth above to the contrary, the Extension Right shall, at Landlord’s option, not be in effect and Tenant may not exercise the Extension Right:

(i) during any period of time that Tenant is in Default under any provision of this Lease; or

(ii) if Tenant has been in Default under any provision of this Lease 3 or more times, whether or not the Defaults are cured, during the 12 month period immediately prior to the date that Tenant intends to exercise the Extension Right, whether or not the Defaults are cured.

(e) No Extensions. The period of time within which the Extension Right may be exercised shall not be extended or enlarged by reason of Tenant’s inability to exercise the Extension Right.

(f) Termination. The Extension Right shall, at Landlord’s option, terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Extension Right, if, after such exercise, but prior to the commencement date of the Extension Term, (i) Tenant fails to timely cure any default by Tenant under this Lease; or (ii) Tenant has Defaulted 3 or more times during the period from the date of the exercise of the Extension Right to the date of the commencement of the Extension Term, whether or not such Defaults are cured.

41. Intentionally Deleted.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 31

 

42. Miscellaneous.

(a) Notices. All notices or other communications between the parties shall be in writing and shall be deemed duly given upon delivery or refusal to accept delivery by the addressee thereof if delivered in person, or upon actual receipt if delivered by reputable overnight guaranty courier, addressed and sent to the parties at their addresses set forth above. Landlord and Tenant may from time to time by written notice to the other designate another address for receipt of future notices.

(b) Joint and Several Liability. If and when included within the term “Tenant,” as used in this instrument, there is more than one person or entity, each shall be jointly and severally liable for the obligations of Tenant.

(c) Financial Information. Tenant shall furnish Landlord with true and complete copies of (i) Tenant’s most recent unaudited or, if available, audited annual financial statements within 90 days of the end of each of Tenant’s fiscal years during the Term, (H) Tenant’s most recent unaudited quarterly financial statements within 45 days of the end of each of Tenant’s first three fiscal quarters of each of Tenant’s fiscal years during the Term, (iii) at Landlord’s request from time to time, updated business plans, including cash flow projections and/or pro forma balance sheets and income statements, all of which shall be treated by Landlord as confidential information belonging to Tenant, (iv) corporate brochures and/or profiles prepared by Tenant for prospective investors, and (v) any other financial information or summaries that Tenant typically provides to its lenders or shareholders. Notwithstanding the foregoing, in no event shall Tenant be required to provide any financial information to Landlord which Tenant does not otherwise prepare (or cause to be prepared) for its own purposes.

(d) Recordation. Neither this Lease nor a memorandum of lease shall be filed by or on behalf of Tenant in any public record. Landlord may prepare and file, and upon request by Landlord Tenant will execute, a memorandum of lease.

(e) Interpretation. The normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Lease or any exhibits or amendments hereto. Words of any gender used in this Lease shall be held and construed to include any other gender, and words in the singular number shall be held to include the plural, unless the context otherwise requires. The captions inserted in this Lease are for convenience only and in no way define, limit or otherwise describe the scope or intent of this Lease, or any provision hereof, or in any way affect the interpretation of this Lease.

(f) Not Binding Until Executed. The submission by Landlord to Tenant of this Lease shall have no binding force or effect, shall not constitute an option for the leasing of the Premises, nor confer any right or impose any obligations upon either party until execution of this Lease by both parties.

(g) Limitations on Interest. It is expressly the intent of Landlord and Tenant at all times to comply with applicable law governing the maximum rate or amount of any interest payable on or in connection with this Lease. If applicable law is ever judicially interpreted so as to render usurious any interest called for under this Lease, or contracted for, charged, taken, reserved, or received with respect to this Lease, then it is Landlord’s and Tenant’s express intent that all excess amounts theretofore collected by Landlord be credited on the applicable obligation (or, if the obligation has been or would thereby be paid in full, refunded to Tenant), and the provisions of this Lease immediately shall be deemed reformed and the amounts thereafter collectible hereunder reduced, without the necessity of the execution of any new document, so as to comply with the applicable law, but so as to permit the recovery of the fullest amount otherwise called for hereunder.

(h) Choice of Law. Construction and interpretation of this Lease shall be governed by the internal laws of the state in which the Premises are located, excluding any principles of conflicts of laws.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 32

 

(i) Time. Time is of the essence as to the performance of Landlord’s and Tenant’s obligations under this Lease.

(j) OFAC. Tenant, and all beneficial owners of Tenant, are currently (a) in compliance with and shall at all times during the Term of this Lease remain in compliance with the regulations of the Office of Foreign Assets Control (“OFAC”) of the U.S. Department of Treasury and any statute, executive order, or regulation relating thereto (collectively, the “OFAC Rules”), (b) not listed on, and shall not during the term of this Lease be listed on, the Specially Designated Nationals and Blocked Persons List maintained by OFAC and/or on any other similar list maintained by OFAC or other governmental authority pursuant to any authorizing statute, executive order, or regulation, and (c) not a person or entity with whom a U.S. person is prohibited from conducting business under the OFAC Rules.

(k) Incorporation by Reference. All exhibits and addenda attached hereto are hereby incorporated into this Lease and made a part hereof. If there is any conflict between such exhibits or addenda and the terms of this Lease, such exhibits or addenda shall control.

(I) Entire Agreement. This Lease, including the exhibits attached hereto, constitutes the entire agreement between Landlord and Tenant pertaining to the subject matter hereof and supersedes all prior and contemporaneous agreements, understandings, letters of intent, negotiations and discussions, whether oral or written, of the parties, and there are no warranties, representations or other agreements, express or implied, made to either party by the other party in connection with the subject matter hereof except as specifically set forth herein.

(m) No Accord and Satisfaction. No payment by Tenant or receipt by Landlord of a lesser amount than the monthly installment of Base Rent or any Additional Rent will be other than on account of the earliest stipulated Base Rent and Additional Rent, nor will any endorsement or statement on any check or letter accompanying a check for payment of any Base Rent or Additional Rent be an accord and satisfaction. Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance of such Rent or to pursue any other remedy provided in this Lease.

(n) Hazardous Activities. Notwithstanding any other provision of this Lease, Landlord, for itself and its employees, agents and contractors, reserves the right to refuse to perform any repairs or services in any portion of the Premises which, pursuant to Tenant’s routine safety guidelines, practices or custom or prudent industry practices, require any form of protective clothing or equipment other than safety glasses. In any such case, Tenant shall contract with parties who are acceptable to Landlord, in Landlord’s reasonable discretion, for all such repairs and services, and Landlord shall, to the extent required, equitably adjust Tenant’s Share of Operating Expenses in respect of such repairs or services to reflect that Landlord is not providing such repairs or services to Tenant.

[ Signatures on next page ]

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 33

 

IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease as of the day and year first above written.

 

TENANT:
PRINCIPIA BIOPHARMA INC.,
a Delaware corporation
  /s/ Eliot Charles
By:  

Eliot Charles

Its:   Interim COO
LANDLORD:
ARE-EAST JAMIE COURT, LLC,
a Delaware limited liability company
By:   ALEXANDRIA REAL ESTATE EQUITIES, L.P., a Delaware limited partnership, managing member
  By:   ARE-QRS CORP.,
   

a Maryland corporation,

general partner

    By:  

/s/ Eric S. Johnson

    Its:  

 

      Eric S. Johnson
      Vice President
      Real Estate Legal Affairs

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Net Multi-Tenant Laboratory    400 E. Jamie Court/Principia - Page 1

 

EXHIBIT A TO LEASE

DESCRIPTION OF PREMISES

 

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


   400 E. Jamie Court/Principia - Page 1

 

EXHIBIT B TO LEASE

DESCRIPTION OF PROJECT

All that certain real property in the City of South San Francisco, County of San Mateo, State of California, more particularly described as follows:

LEGAL DESCRIPTION

PARCEL 2, AS DESIGNATED ON THE MAP ENTITLED “PARCEL MAP, BEING A RESUBDIVISION OF PARCEL 5, AS SAID PARCEL IS DELINEATED AND SO DESIGNATED UPON THAT CERTAIN PARCEL MAP RECORDED IN BOOK 47 OF PARCEL MAPS AT PAGES 4 & 5, SAN MATEO CO. RECORDS, SOUTH SAN FRANCISCO, SAN MATEO CO., CALIFORNIA”, WHICH MAP WAS FILED IN THE OFFICE OF THE RECORDER OF THE COUNTY OF SAN MATEO, STATE OF CALIFORNIA, ON OCTOBER 23, 1981, IN BOOK 51 OF MAPS AT PAGES 96 AND 97.

EXCEPTING THEREFROM, WATER RIGHTS AS LIE BENEATH THE SURFACE OF THE EARTH, WITH NO RIGHT OF SURFACE ENTRY, AS CONTAINED IN THAT QUITCLAIM DEED FROM ARTHUR S. HASKINS, JR., TO CALIFORNIA WATER SERVICE COMPANY, A CALIFORNIA CORPORATION, DATED OCTOBER 2, 1981, AND RECORDED OCTOBER 30, 1981, UNDER INSTRUMENT NO. 2299-AT, RECORDS OF SAN MATE() COUNTY.

 

ASSESSOR’S PARCEL NO. 015-102-120    JOINT PLANT NO. 015-010-102-25A

METES AND BOUNDS DESCRIPTION

PARCEL 2, AS DESIGNATED ON THE MAP ENTITLED “PARCEL MAP, BEING A RESUBDIVISION OF PARCEL 5, AS SAID PARCEL IS DELINEATED AND SO DESIGNATED UPON THAT CERTAIN PARCEL MAP RECORDED IN BOOK 47 OF PARCEL MAPS AT PAGES 4 & 5, SAN MATEO CO. RECORDS, SOUTH SAN FRANCISCO, SAN MATEO CO., CALIFORNIA”, WHICH MAP WAS FILED IN THE OFFICE OF THE RECORDER OF THE COUNTY OF SAN MATEO, STATE OF CALIFORNIA, ON OCTOBER 23, 1981, IN BOOK 51 OF MAPS AT PAGES 96 AND 97.

BEGINNING AT THE SOUTHWEST CORNER OF PARCEL 2, THENCE ALONG THE WESTERLY LINE OF SAID PARCEL 2, NORTH, 115.08 FEET; THENCE WEST, 20.78 FEET; THENCE NORTH, 201.65 FEET; THENCE EASTERLY ALONGTHE ARC OF A NON-TANGENT CURVE TO THE RIGHT, THE RADIUS POINT OF WHICH BEARS SOUTH 43°50’30” EAST, 30.00 FEET THROUGH A CENTRAL ANGLE OF 47°00’48”, AN ARC DISTANCE OF 24.62 FEET; THENCE SOUTH 86°49’42” EAST, 874.36 FEET; THENCE SOUTH 275.50 FEET; THENCE SOUTH 89°55’25” WEST, 874.68 FEET; TO THE POINT OF BEGINNING, CONTAINING 6.13 ACRES, MORE OR LESS.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Work Letter - Tenant Build    400 E. Jamie Court/Principia - Page 1

 

EXHIBIT C TO LEASE

WORK LETTER

THIS WORK LETTER dated     May 1    , 2011 (this “Work Letter”) is made and entered into by and between ARE-EAST JAMIE COURT LLC, a Delaware limited liability company (“Landlord”), and PRINCIPIA BIOPHARMA INC., a Delaware corporation (“Tenant”), and is attached to and made a part of the Lease Agreement dated     May 1    , 2011 (the “Lease”), by and between Landlord and Tenant. Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.

1. General Requirements.

(a) Tenant’s Authorized Representative. Tenant designates Eliot Charles and Hans van Houte (either such individual acting alone, “Tenant’s Representative”) as the only persons authorized to act for Tenant pursuant to this Work Letter. Landlord shall not be obligated to respond to or act upon any request, approval, inquiry or other communication (“Communication”) from or on behalf of Tenant in connection with this Work Letter unless such Communication is in writing (including e-mail) from Tenant’s Representative. Tenant may change either Tenant’s Representative at any time upon not less than 5 business days advance written notice to Landlord. Neither Tenant nor Tenant’s Representative shall be authorized to direct Landlord’s contractors in the performance of Landlord’s Work (as hereinafter defined).

(b) Landlord’s Authorized Representative. Landlord designates Rob Kain and Todd Miller (either such individual acting alone, “Landlord’s Representative”) as the only persons authorized to act for Landlord pursuant to this Work Letter. Tenant shall not be obligated to respond to or act upon any request, approval, inquiry or other Communication from or on behalf of Landlord in connection with this Work Letter unless such Communication is in writing (including e-mail) from Landlord’s Representative. Landlord may change either Landlord’s Representative at any time upon not less than 5 business days advance written notice to Tenant. Landlord’s Representative shall be the sole persons authorized to direct Landlord’s contractors in the performance of Landlord’s Work.

(c) Architects, Consultants and Contractors. Landlord and Tenant hereby acknowledge and agree that: (i) the general contractor and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenant’s approval, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Dowler Gruman Associates shall be the architect (the “TI Architect”) for the Tenant Improvements.

2. Tenant Improvements.

(a) Tenant Improvements Defined. As used herein, “Tenant Improvements” shall mean all improvements to the Project of a fixed and permanent nature as shown on the TI Construction Drawings, as defined in Section 2(c) below. Other than Landlord’s Work (as defined in Section 3(a)below, Landlord shall not have any obligation whatsoever with respect to the finishing of the Premises for Tenant’s use and occupancy.

(b) Tenant’s Space Plans. Landlord and Tenant acknowledge and agree that the plan attached to the Lease as Exhibit G (the “Space Plan”) has been approved by both Landlord and Tenant. Landlord and Tenant further acknowledge and agree that any changes to the Space Plan constitute a Change Request the cost of which changes shall be paid for by Tenant. Tenant shall be solely responsible for all costs incurred by Landlord to alter the Building (or Landlord’s plans for the Building) as a result of Tenant’s requested changes.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Work Letter - Tenant Build    400 E. Jamie Court/Principia - Page 2

 

(c) Working Drawings. Landlord shall cause the TI Architect to prepare and deliver to Tenant for review and comment construction plans, specifications and drawings for the Tenant Improvements (“TI Construction Drawings”), which TI Construction Drawings shall be prepared substantially in accordance with the Space Plan. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenant’s requirements for the Tenant Improvements. Tenant shall deliver its written comments on the TI Construction Drawings to Landlord not later than 10 business days after Tenant’s receipt of the same; provided, however, that Tenant may not disapprove any matter that is consistent with the Space Plan which disapproval causes a delay in the Substantial Completion of Landlord’s Work or an increase in TI Costs without submitting a Change Request. Landlord and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Tenant how Landlord proposes to respond to such comments, but Tenant’s review rights pursuant to the foregoing sentence shall not delay the design or construction schedule for the Tenant Improvements. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the Space Plan, Tenant shall approve the TI Construction Drawings submitted by Landlord, unless Tenant submits a Change Request. Once approved by Tenant, subject to the provisions of Section 4below, Landlord shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(b) below).

(d) Approval and Completion. It is hereby acknowledged by Landlord and Tenant that the TI Construction Drawings must be completed and approved no later than May 19, 2011, in order for the Landlord’s Work to be Substantially Complete by the Target Commencement Date (as defined in the Lease). Upon any dispute regarding the design of the Tenant Improvements, which is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlord’s and Tenant’s positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision (arising from such dispute) by Tenant shall be payable by Tenant, and (iii) Tenant’s decision will not affect the base Building, structural components of the Building or any Building systems. Any changes to the TI Construction Drawings following Landlord’s and Tenant’s approval of same requested by Tenant shall be processed as provided in Section 4 hereof.

3. Performance of Landlord’s Work.

(a) Definition of Landlord’s Work. As used herein, “Landlord’s Work” shall mean the work of constructing (or causing to be constructed) the Tenant Improvements.

(b) Commencement and Permitting. Landlord shall commence construction of the Tenant Improvements upon obtaining a building permit (the “TI Permit”) authorizing the construction of the Tenant Improvements consistent with the TI Construction Drawings approved by Tenant. The cost of obtaining the TI Permit shall be payable by Landlord. Tenant shall (at no additional cost to Tenant) cooperate with Landlord’s efforts to obtain the TI Permit. If any Governmental Authority having jurisdiction over the construction of Landlord’s Work or any portion thereof shall impose terms or conditions upon the construction thereof that: (i) are inconsistent with Landlord’s obligations hereunder, (ii) increase the cost of constructing Landlord’s Work, or (iii) will materially delay the construction of Landlord’s Work, Landlord and Tenant shall reasonably and in good faith seek means by which to mitigate or eliminate any such adverse terms and conditions.

(c) Completion of Landlord’s Work. Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, in accordance with the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises (“Substantial Completion” or “SubstantiallyComplete”). Upon Substantial Completion of Landlord’s Work, Landlord shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comply with any request by Tenant for modifications to Landlord’s Work; (iii) to comport with good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments for field deviations or conditions encountered during the construction of Landlord’s Work.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Work Letter - Tenant Build    400 E. Jamie Court/Principia - Page 3

 

(d) Selection of Materials. Where more than one type of material or structure is indicated on the TI Construction Drawings approved by Landlord and Tenant, the option will be within Landlord’s reasonable discretion if the matter concerns the Tenant Improvements (provided that Landlord shall use reasonable efforts to see Tenant’s comments on such choice), and within Landlord sole and absolute discretion if the matter concerns the structural components of the Building or any Building System. The quality for such materials and structure reflected in the TI Construction Drawings indicates the minimum quality for such materials and structure approved by the parties with respect to the Tenant Improvements. If Landlord, in its sole discretion, desires to increase the quality of such materials and/or structure, Landlord shall be responsible for the additional costs incurred in connection with such increase in quality. As to all building materials and equipment that Landlord is obligated to supply under this Work Letter, Landlord shall select the manufacturer thereof in its reasonable discretion.

(e) Delivery of the Premises. When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e) Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor.

(f) Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely by Tenant. Landlord shall promptly undertake and endeavor to complete, or endeavor to cause to be completed, all punch list items within 30 days of Substantial Completion.

(g) Commencement Date Delay. Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):

(i) Tenant’s Representative was not available within 1 business day to give or receive any Communication or to take any other action required to be taken by Tenant hereunder;

(ii) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;

(iii) Construction of any Change Requests;

(iv) Tenant’s request for materials, finishes or installations requiring unusually long lead times, provided that promptly after Landlord learns of such long lead time items, Landlord informs Tenant that the requested items will require unusually long lead times;

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Work Letter - Tenant Build    400 E. Jamie Court/Principia - Page 4

 

(v) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;

(vi) Tenant’s delay in providing information critical to the normal progression of the Project. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;

(vii) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(b) below); or

(viii) Any other act at the Premises by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than one (1) day after Landlord’s notice thereof to Tenant.

If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been completed but for such Tenant Delay and such certified date shall be the date of Delivery.

4. Changes. Any changes requested by Tenant to the Tenant Improvements after the delivery and approval by Landlord of the Space Plan shall be requested and instituted in accordance with the provisions of this Section 4 and shall be subject to the written approval of Landlord and the TI Architect, such approval not to be unreasonably withheld, conditioned or delayed.

(a) Tenant’s Request For Changes. If Tenant shall request changes to the Tenant Improvements (“Changes”), Tenant shall request such Changes by notifying Landlord in writing in substantially the same form as the AIA standard change order form (a “Change Request”), which Change Request shall detail the nature and extent of any such Change. Such Change Request must be signed by Tenant’s Representative. Landlord shall, before proceeding with any Change, use commercially reasonable efforts to respond to Tenant as soon as is reasonably possible with an estimate of: (i) the time it will take, and (ii) the architectural and engineering fees and costs that will be incurred, to analyze such Change Request (which costs shall be paid by Tenant to the extent actually incurred, whether or not such change is implemented). Landlord shall thereafter submit to Tenant in writing, within 5 business days of receipt of the Change Request (or such longer period of time as is reasonably required depending on the extent of the Change Request), an analysis of the additional cost or savings involved, including, without limitation, architectural and engineering costs and the period of time, if any, that the Change will extend the date on which Landlord’s Work will be Substantially Complete. Any such delay in the completion of Landlord’s Work caused by a Change, including any suspension of Landlord’s Work while any such Change is being evaluated and/or designed, shall be Tenant Delay.

(b) Implementation of Changes. If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for completion of Landlord’s Work, if any, resulting from a Change, and (ii) deposits with Landlord any Excess TI Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by Tenant of any estimate of the delay caused by such proposed Change, the TI Architect’s determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant.

5. Costs.

(a) TI Costs. Landlord shall be responsible for the payment of design, permits and construction costs in connection with the construction of the Tenant Improvements, including, without limitation, the cost of preparing the TI Construction Drawings and the Space Plans and Landlord’s out-of-pocket expenses (collectively, “TI Costs”). Notwithstanding anything to the contrary contained herein (except as otherwise set forth in this paragraph), in no event shall Landlord be required to pay for any furniture, personal property or other non-Building system materials or equipment, including, but not limited

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Work Letter - Tenant Build    400 E. Jamie Court/Principia - Page 5

 

to, Tenant’s voice or data cabling, phones, server racks, and video conferencing equipment, and Tenant shall be responsible for the cost of such items; provided, however, that Landlord shall provide to Tenant a furniture allowance of up to $[•] (“Furniture Allowance”) for office furniture only for the Premises selected by Tenant and reasonably acceptable to Landlord.

(b) Excess TI Costs. Landlord shall cause the Tenant Improvements to be constructed pursuant to this Work Letter on a turn-key basis such that on the Commencement Date the same shall be delivered to Tenant Substantially Completed; provided, however, that Tenant acknowledges and agrees that Landlord shall have no responsibility for (i) any increase in the TI Costs arising from Tenant’s changes to the Space Plans or TI Construction Drawings, Tenant Delays, or the cost of Changes, or (ii) the cost of office furniture in excess of the Furniture Allowance (collectively, “Excess TI Costs”). Upon Landlord’s request from time to time, Tenant shall deposit with Landlord, as a condition precedent to Landlord’s obligation to complete the Tenant Improvements, 100% of the Excess TI Costs. If Tenant fails to deposit the Excess TI Costs with Landlord, Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including, but not limited to, the right to interest at the Default Rate and the right to assess a late charge). For purposes of any litigation instituted with regard to such amounts, those amounts will be deemed Rent under the Lease. Funds deposited by Tenant shall be disbursed to pay Excess TI Costs.

6. Tenant Access.

(a) Tenant’s Access Rights. Landlord hereby agrees to permit Tenant access, at Tenant’s sole risk and expense, to the Building (i) 30 days prior to the Commencement Date to perform any work (“Tenant’s Work”) required by Tenant other than Landlord’s Work, provided that such Tenant’s Work is coordinated with the TI Architect and the general contractor, and complies with the Lease and all other reasonable restrictions and conditions Landlord may impose, and (ii) prior to the completion of Landlord’s Work, to inspect and observe work in process; all such access shall be during normal business hours or at such other times as are reasonably designated by Landlord. Notwithstanding the foregoing, Tenant shall have no right to enter onto the Premises or the Project unless and until Tenant shall deliver to Landlord evidence reasonably satisfactory to Landlord demonstrating that any insurance reasonably required by Landlord in connection with such pre-commencement access (including, but not limited to, any insurance that Landlord may require pursuant to the Lease) is in full force and effect. Any entry by Tenant shall comply with all established safety practices of Landlord’s contractor and Landlord until completion of Landlord’s Work and acceptance thereof by Tenant.

(b) No Interference. Neither Tenant nor any Tenant Party (as defined in the Lease) shall interfere with the performance of Landlord’s Work, nor with any inspections or issuance of final approvals by applicable Governmental Authorities, and upon any such interference, Landlord shall have the right to exclude Tenant and any Tenant Party from the Premises and the Project until Substantial Completion of Landlord’s Work.

(c) No Acceptance of Premises. The fact that Tenant may, with Landlord’s consent, enter into the Project prior to the date Landlord’s Work is Substantially Complete for the purpose of performing Tenant’s Work shall not be deemed an acceptance by Tenant of possession of the Premises, but in such event Tenant shall defend with counsel reasonably acceptable by Landlord, indemnify and hold Landlord harmless from and against any loss of or damage to Tenant’s property, completed work, fixtures, equipment, materials or merchandise, and from liability for death of, or injury to, any person, caused by the act or omission of Tenant or any Tenant Party.

7. Miscellaneous.

(a) Consents. Whenever consent or approval of either party is required under this Work Letter, that party shall not unreasonably withhold, condition or delay such consent or approval, unless expressly set forth herein to the contrary.

(b) Modification. No modification, waiver or amendment of this Work Letter or of any of its conditions or provisions shall be binding upon Landlord or Tenant unless in writing signed by Landlord and Tenant.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


   400 E. Jamie Court/Principia - Page 1

 

EXHIBIT D TO LEASE

ACKNOWLEDGMENT OF COMMENCEMENT DATE

This ACKNOWLEDGMENT OF COMMENCEMENT DATE is made this 1st day of     October    , 2011 , between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company (“Landlord”), and PRINCIPIA BIOPHARMA INC., a Delaware corporation (“Tenant”), and is attached to and made a part of the Lease dated                 May 1                , 2011 (the “Lease”), by and between Landlord and Tenant. Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.

Landlord and Tenant hereby acknowledge and agree, for all purposes of the Lease, that the Commencement Date of the Base Term of the Lease is     October 1st    ,     2011     and the termination date of the Base Term of the Lease shall be midnight on     September 30    , 2014 . In case of a conflict between the terms of the Lease and the terms of this Acknowledgment of Commencement Date, this Acknowledgment of Commencement Date shall control for all purposes.

IN WITNESS WHEREOF, Landlord and Tenant have executed this ACKNOWLEDGMENT OF COMMENCEMENT DATE to be effective on the date first above written.

 

TENANT:
PRINCIPIA BIOPHARMA INC.,
a Delaware corporation
 

/s/ Eliot Charles

By:   Eliot Charles
Its:   Interim COO
LANDLORD:
ARE-EAST JAMIE COURT, LLC,
a Delaware limited liability company
By:   ALEXANDRIA REAL ESTATE EQUITIES, L.P., a Delaware limited partnership,
  managing member
  By:  

ARE-QRS CORP.,

    a Maryland corporation,
    general partner
    By:  

/s/ Eric S. Johnson

    Its:   Eric S. Johnson
      Vice President
      Real Estate Legal Affairs

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Rules and Regulations

   400 E. Jamie Court/Principia - Page 1

 

EXHIBIT E TO LEASE

Rules and Regulations

1. The sidewalk, entries, and driveways of the Project shall not be obstructed by Tenant, or any Tenant Party, or used by them for any purpose other than ingress and egress to and from the Premises.

2. Tenant shall not place any objects, including antennas, outdoor furniture, etc., in the parking areas, landscaped areas or other areas outside of its Premises, or on the roof of the Project.

3. Except for animals assisting the disabled, no animals shall be allowed in the offices, halls, or corridors in the Project.

4. Tenant shall not disturb the occupants of the Project or adjoining buildings by the use of any radio or musical instrument or by the making of loud or improper noises.

5. If Tenant desires telegraphic, telephonic or other electric connections in the Premises, Landlord or its agent will direct the electrician as to where and how the wires may be introduced; and, without such direction, no boring or cutting of wires will be permitted. Any such installation or connection shall be made at Tenant’s expense.

6. Tenant shall not install or operate any steam or gas engine or boiler, or other mechanical apparatus in the Premises, except as specifically approved in the Lease. The use of oil, gas or inflammable liquids for heating, lighting or any other purpose is expressly prohibited. Explosives or other articles deemed extra hazardous shall not be brought into the Project. This paragraph shall not apply to those materials expressly permitted under the Lease.

7. Parking any type of recreational vehicles is specifically prohibited on or about the Project. Except for the overnight parking of operative vehicles, no vehicle of any type shall be stored in the parking areas at any time. In the event that a vehicle is disabled, it shall be removed within 48 hours. There shall be no “For Sale” or other advertising signs on or about any parked vehicle. All vehicles shall be parked in the designated parking areas in conformity with all signs and other markings. All parking will be open parking, and no reserved parking, numbering or lettering of individual spaces will be permitted except as specified by Landlord.

8. Tenant shall maintain the Premises free from rodents, insects and other pests.

9. Landlord reserves the right to exclude or expel from the Project any person who, in the judgment of Landlord, is intoxicated or under the influence of liquor or drugs or who shall in any manner do any act in violation of the Rules and Regulations of the Project.

10. Tenant shall not cause any unnecessary labor by reason of Tenant’s carelessness or indifference in the preservation of good order and cleanliness. Landlord shall not be responsible to Tenant for any loss of property on the Premises, however occurring, or for any damage done to the effects of Tenant by the janitors or any other employee or person.

11. Tenant shall give Landlord prompt notice of any defects of which Tenant becomes aware in the water, lawn sprinkler, sewage, gas pipes, electrical lights and fixtures, heating apparatus, or any other service equipment affecting the Premises.

12. Tenant shall not permit storage outside the Premises, including without limitation, outside storage of trucks and other vehicles, or dumping of waste or refuse or permit any harmful materials to be placed in any drainage system or sanitary system in or about the Premises.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Rules and Regulations

   400 E. Jamie Court/Principia - Page 2

 

13. All moveable trash receptacles provided by the trash disposal firm for the Premises must be kept in the trash enclosure areas, if any, provided for that purpose.

14. No auction, public or private, will be permitted on the Premises or the Project.

15. No awnings shall be placed over the windows in the Premises except with the prior written consent of Landlord.

16. The Premises shall not be used for lodging, sleeping or cooking or for any immoral or illegal purposes or for any purpose other than that specified in the Lease; provided, however that cooking shall be permitted in a kitchen or employee break room. No gaming devices shall be operated in the Premises.

17. Tenant shall ascertain from Landlord the maximum amount of electrical current which can safely be used in the Premises, taking into account the capacity of the electrical wiring in the Project and the Premises and the needs of other tenants, and shall not use more than such safe capacity. Landlord’s consent to the installation of electric equipment shall not relieve Tenant from the obligation not to use more electricity than such safe capacity.

18. Tenant assumes full responsibility for protecting the Premises from theft, robbery and pilferage.

19. Tenant shall not install or operate on the Premises any machinery or mechanical devices of a nature not directly related to Tenant’s Permitted Use of the Premises and shall keep all such machinery free of vibration, noise and air waves which may be transmitted beyond the Premises.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


   400 E. Jamie Court/Principia - Page 1

 

EXHIBIT F TO LEASE

TENANT’S PERSONAL PROPERTY

None.

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


   400 E. Jamie Court/Principia - Page 1

 

EXHIBIT G TO LEASE

SPACE PLAN

 

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


   400 E. Jamie Court/Principia - Page 2

 

400 East Jamie Court — 3rd floor

Principia Construction Scope of Work

Misc. Metal

 

   

Cylinder Rack

Doors and Hardware

 

   

Frames, Doors and Hardware

 

   

Glass and Glazing

Ceiling

 

   

Acoustical Ceiling Grid and Tile

 

   

Drywall Ceiling

Flooring

 

   

Carpet

 

   

VCT

 

   

Sheet Vinyl at Tissue Culture

 

   

Epoxy at Vivarium

Hazmat Room Construction

 

   

Rated Wall

 

   

Epoxy Flooring & Painting

 

   

Chemical Storage Cabinets

Misc. Specialties

 

   

Glass Marker Board in Conference Room

Lab Casework

 

   

Lab Benches — Epoxy Resin Work Surfaces with Drop-in Sinks

 

   

Reagent Shelving

 

   

Wall Shelving

 

   

Fume Hoods

 

   

1 block of 4-8’ fume hoods (4 total) will be new fume hoods at 42” overall depth.

 

   

2 blocks of 4-8’ fume hoods (8 total) will be re-used hoods at 35” overall depth (21  12

 

   

clear, sash to baffle dimension, with monkey bars set in 2/3rds of the hood).

 

   

Remaining fume hoods will be re-used hoods.

 

   

Lab Hot and Cold Water Mixing Faucets

 

   

Deck Mounted Eyewashes

 

   

Turrets

 

   

Cup Sinks-All

Plumbing

 

   

Building Plumbing and Process Piping

 

   

Emergency Shower/Eyewash Stations

 

   

Special Systems

 

   

Vacuum System

 

   

RO/DI System — One faucet per laboratory

 

   

CDA System

 

   

Point of Use — Unistrut and Strapping for CO2 per ARE Standard.

 

   

Argon (1) manifold and piping.

 

   

Nitrogen piping.

 

   

VAC and High VAC connections.

Fire Protection

 

   

Fire Sprinkler System

Mechanical

 

   

HVAC

 

   

Controls

 

   

Magnahelic Gauges Monitoring (no interlocking door devices)

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


   400 E. Jamie Court/Principia - Page 3

 

   

Test and Balance

 

   

Commissioning

 

   

HEPA for vivarium

 

   

Snorkels for Chemistry Lab and Mass Spec

 

   

Oxygen Sensor

 

   

Magnahelic Gauge at Tissue Culture

Electrical

 

   

Power

 

   

Lighting

 

   

Telephone and Data

 

   

Fire Alarm

 

   

Car Readers

By Tenant

 

Audio and Visual Provisions       $[●]

 

   

Dark Window Shades

 

   

Upgrade Motorized Projector Screen

 

   

Electrical/Cable Conduit Provisions

 

   

Ceiling Mount for Overhead Projector

      Total Cost            $[●]

 

      Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


FIRST AMENDMENT TO LEASE

THIS FIRST AMENDMENT TO LEASE (this “First Amendment”) is made as of December 1 , 2011, by and between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company(“Landlord”), and PRINCIPIA BIOPHARMA INC., a Delaware corporation (“Tenant”).

RECITALS

A. Landlord and Tenant are parties to that certain Lease Agreement dated as of May 1,2011 (the “Lease”). Pursuant to the Lease, Tenant leases certain premises consisting of approximately 16,751 rentable square feet (“Premises”) in a building located at 400 East Jamie Court, South San Francisco, California (“Building”). The Premises are more particularly described in the Lease.Capitalized terms used herein without definition shall have the meanings defined for such terms in the Lease.

B. Landlord and Tenant desire, subject to the terms and conditions set forth below, toamend the Premises, the Rentable Area of the Premises, the Rentable Area of the Building, Building’s Share of Project, Rentable Area of Project, Tenant’s Share of Operating Expenses for the Building and Tenant’s Share of Operating Expenses for the Project, as set forth in the Lease, to account for changes in the overall square footage of the Premises, Building and Project resulting from the conversion of certain portions of the Common Areas to tenant usable space and the correction of certain BOMA calculationswith respect to the Premises, Building and Project.

NOW, THEREFORE, in consideration of the foregoing Recitals, which are incorporated herein by this reference, the mutual promises and conditions contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Landlord and Tenant hereby agree as follows:

 

1.

Premises and Rentable Area of Premises. Commencing on January 1, 2012, the defined terms “Premises” and “Rentable Area of Premises” on page 1 of the Lease are deleted in their entirety and replaced with the following:

Premises: That portion of the third floor of the Project, containing approximately 16,255 rentable square feet, as determined by Landlord, as shown on Exhibit A.

Rentable Area of Premises: 16,255 sq. ft.”

 

2.

Rentable Area of Building and Project. Commencing on January 1, 2012, the defined terms “Rentable Area of Building” and “Rentable Area of Project” on page 1 of the Lease aredeleted in their entirety and replaced with the following:

Rentable Area of Building: 88,284 sq. ft.

Rentable Area of Project: 163,072 sq. ft.”

 

3.

Building’s Share of Project. Commencing on January 1, 2012, the defined term “BuildingShare of Project” on page 1 of the Lease is deleted and replaced in its entirety with the following:

Building’s Share of Project: 54.14%”

 

   1       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


4.

Tenant’s Share of Operating Expenses. Commencing on January 1, 2012, the defined terms “Tenant’s Share of Operating Expenses for the Building” and “Tenant’s Share of OperatingExpenses for the Project” on page 1 of the Lease are deleted in their entirety and replaced with the following:

Tenant’s Share of Operating Expenses for the Building: 18.41%

Tenant’s Share of Operating Expenses for the Project: 9.97%”

 

5.

Miscellaneous.

a. This First Amendment is the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous oral and writtenagreements and discussions. This First Amendment may be amended only by an agreement in writing, signed by the parties hereto.

b. Landlord and Tenant each represents and warrants that it has not dealt with anybroker, agent or other person (collectively, “Broker”) in connection with the transactionreflected in this First Amendment and that no Broker brought about this transaction. Landlordand Tenant each hereby agree to indemnify and hold the other harmless from and against any claims by any Broker, other than the broker, if any, named in this First Amendment, claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard to this leasing transaction.

c. This First Amendment is binding upon and shall inure to the benefit of the partieshereto, their respective agents, employees, representatives, officers, directors, divisions, subsidiaries, affiliates, assigns, heirs, successors in interest and shareholders.

d. This First Amendment may be executed in any number of counterparts, each of whichshall be deemed an original, but all of which when taken together shall constitute one and thesame instrument. The signature page of any counterpart may be detached therefrom without impairing the legal effect of the signature(s) thereon provided such signature page is attachedto any other counterpart identical thereto except having additional signature pages executed by other parties to this First Amendment attached thereto.

e. Except as amended and/or modified by this First Amendment, the Lease is herebyratified and confirmed and all other terms of the Lease shall remain in full force and effect,unaltered and unchanged by this First Amendment. In the event of any conflict between the provisions of this First Amendment and the provisions of the Lease, the provisions of this First Amendment shall prevail. Whether or not specifically amended by this First Amendment, all ofthe terms and provisions of the Lease are hereby amended to the extent necessary to giveeffect to the purpose and intent of this First Amendment.

[Signatures are on the next page.]

 

   2       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


IN WITNESS WHEREOF, the parties hereto have executed this First Amendment as of the day and year first above written.

 

LANDLORD:  

ARE-EAST JAMIE COURT, LLC,

a Delaware limited liability company

  By:  

ALEXANDRIA REAL ESTATE EQUITIES, L.P.,

a Delaware limited partnership,

managing member

    By:  

ARE-QRS CORP.,

a Maryland corporation,

general partner

     

By:         /s/ Eric S. Johnson                                                   

Its:         Eric S. Johnson                                                         

             Vice President

Real Estate Legal Affairs

TENANT:  

PRINCIPIA BIOPHARMA INC.,

a Delaware corporation

    /s/ Eliot Charles
  By:  

Eliot Charles

  Its:   Interim COO

 

         Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


SECOND AMENDMENT TO LEASE

THIS SECOND AMENDMENT TO LEASE (this “Second Amendment”) is made as of July 28 , 2014, by and between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company(“Landlord”), and PRINCIPIA BIOPHARMA INC., a Delaware corporation (“Tenant”).

RECITALS

A. Landlord and Tenant are parties to that certain Lease Agreement dated as of May 1,2011, as amended by that certain First Amendment to Lease dated as of December 1, 2011 (asamended, the “Lease”). Pursuant to the Lease, Tenant leases certain premises consisting ofapproximately 16,255 rentable square feet (“Original Premises”) in a building located at 400 East Jamie Court, South San Francisco, California (“Building”). The Original Premises are more particularlydescribed in the Lease. Capitalized terms used herein without definition shall have the meanings defined for such terms in the Lease.

B. The Base Term of the Lease is currently scheduled to expire on September 30, 2014 (“Expiration Date”).

C. As of the date of this Second Amendment, Tenant occupies space in the Building in addition to the Existing Premises, consisting of approximately 5,003 rentable square feet, which Tenant currently subleases from Patheon Pharmaceuticals, Inc., a Delaware corporation (“Patheon”), pursuant to that certain Sublease between Tenant and Patheon dated August 20, 2013 (“Patheon Sublease”).

D. Landlord and Tenant desire to, among other things, amend the Lease to (i) provide for Tenant to lease that certain approximately 5,003 rentable square feet of space currently subject to the Patheon Sublease, as shown on Exhibit A attached hereto (“Expansion Premises”) following the expiration of the Patheon Sublease, and (ii) extend the Term of the Lease through January 31, 2017.

NOW, THEREFORE, in consideration of the foregoing Recitals, which are incorporated herein by this reference, the mutual promises and conditions contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Landlord and Tenanthereby agree as follows:

 

1.

Expansion Premises. In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenantleases from Landlord, the Expansion Premises.

 

2.

Delivery; Acceptable of the Expansion Premises. The “Expansion Premises Commencement Date” shall occur on September 1, 2014. The “Expansion Premises Rent Commencement Date” shall occur on January 1, 2015.

Tenant acknowledges that Landlord shall require access to portions of the Premises after the Expansion Premises Commencement Date in order to complete certain Landlord’s Work (defined below). Landlord and its contractors and agents shall have the right to enter the Premises afterthe Expansion Premises Commencement Date in order to complete such Landlord’s Work and Tenant shall cooperate with Landlord in connection with the same. Tenant acknowledges that Landlord’s completion of Landlord’s Work may adversely affect Tenant’s use and occupancy ofthe Premises. Landlord shall use reasonable efforts to minimize interruption to Tenant’s business during the performance of Landlord’s Work. Landlord shall cause Landlord’s Work to becompleted pursuant to a schedule reasonably acceptable to Landlord and Tenant. Tenant waives all claims against Landlord in connection with Landlord’s Work, including, without limitation,claims for rent abatement. For the purposes of this paragraph, “Landlord’s Work” shall meanthe installation of 3 card readers in the Premises, at Landlord’s cost and expense, using Building standard materials (i.e., equipment, materials and finishes of the same quality as those currentlyin the Original Premises) and in a manner reasonably acceptable to Landlord and Tenant, and in locations within the Premises identified by Tenant and reasonably acceptable to Landlord.

 

   1       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Notwithstanding anything to the contrary contained in the Lease, Tenant shall not be required to remove or restore at the expiration or earlier termination of the Term, Landlord’s Work or any improvements existing in the Expansion Premises as of the date of this Second Amendment, nor shall Tenant have the right to remove such Landlord’s Work or existing improvements at any time during the Term.

For the period of 30 consecutive days after the Expansion Premises Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to the Building Systems serving the Expansion Premises, unless Tenant or any Tenant Party was responsible for the cause of such repair, in which case Tenant shall pay the cost.

Except as otherwise expressly set forth in this Second Amendment: (i) Landlord shall have no obligation for any defects in the Expansion Premises; and (ii) the occupancy by Tenant of the Expansion Premises pursuant to the terms of the Patheon Sublease shall be conclusive evidence that Tenant accepts the Expansion Premises as of the Expansion Premises CommencementDate.

Tenant agrees and acknowledges that, except as otherwise expressly set forth in this Second Amendment, neither Landlord nor any agent of Landlord has made any representation orwarranty with respect to the condition of all or any portion of the Expansion Premises and/or the suitability of the Expansion Premises for the conduct of Tenant’s business, and Tenant waivesany implied warranty that the Expansion Premises are suitable for the Permitted Use.

 

3.

Definition of Premises and Rentable Area of Premises. Commencing on the Expansion Premises Commencement Date, the defined terms “Premises” and “Rentable Area ofPremises” on Page 1 of the Lease shall be deleted in their entirety and replaced with thefollowing:

Premises: That portion the Project containing approximately 21,258 rentable squarefeet, consisting of (i) approximately 16,255 rentable square feet (the “Original Premises”), and(ii) approximately 5,003 rentable square feet (“Expansion Premises”), all as determined by Landlord, as shown on Exhibit A.”

Rentable Area of Premises: Approximately 21,258 sq. ft.”

As of the Expansion Premises Commencement Date, Exhibit A to the Lease shall be amended to include the Expansion Premises as shown on Exhibit A attached to this Second Amendment.

 

4.

Base Rent.

a. Original Premises. Tenant shall continue paying Base Rent with respect to theOriginal Premises as provided for in the Lease through September 30, 2014. Commencing on October 1, 2014, Tenant shall commence paying Base Rent for the Original Premises in theamount of $[•] per rentable square foot of the Original Premises per month through January 31, 2017.

Notwithstanding anything to the contrary contained in this Second Amendment, so long as no Default (beyond any applicable notice and cure periods) has occurred under the Lease, Tenant shall not be required to pay Base Rent with respect to the Original Premises for the period commencing October 1, 2014, through December 31, 2014. Tenant shall resume paying Base Rent (in the amount provided for in the immediately preceding paragraph) with respect to the Original Premises on January 1, 2015.

 

   2       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


b. Expansion Premises. Commencing on the Expansion Premises Rent Commencement Date, Tenant shall pay Base Rent with respect to the Expansion Premises in the amount of $[•] per rentable square foot of the Expansion Premises per month through January 31, 2017.

 

5.

Definition of Tenant’s Share of Operating Expenses. Commencing on the Expansion Premises Commencement Date, the defined terms “Tenant’s Share of Operating Expenses for the Building” and “Tenant’s Share of Operating Expenses for the Project” on page 1 of the Lease are deleted in their entirety and replaced with the following:

Tenant’s Share of Operating Expenses for the Building: 24.08%”

Tenant’s Share of Operating Expenses for the Project: 13.04%”

 

6.

Base Term. Commencing on the Expansion Premises Commencement Date, the defined term “Base Term” on page 1 of the Lease is deleted in its entirety and replaced with the following:

Base Term: Commencing (i) with respect to the Original Premises on October 1, 2011, and (ii) commencing with respect to the Expansion Premises on the Expansion Premises Commencement Date, and ending with respect to the entire Premises on January 31, 2017.”

 

7.

Right to Expand. Section 39 of the Lease is hereby deleted in its entirety and replaced with the following:

“39. Right to Expand.

(a) Right of First Refusal. At any time during the period commencing on the date that the Second Amendment is mutually executed and delivered by the parties, through February 28, 2016 (“Expansion Right Expiration Date”) that Landlord intends to accept a written proposal (the “Pending Deal”) to lease the Expansion Space (as hereinafter defined) to a third party, Landlord shall deliver to Tenant written notice (the “Pending Deal Notice”) of the existence of such Pending Deal, which Pending Deal Notice shall include the material business terms of such Pending Deal which Landlord intends to accept (“Pending Deal Terms”). For purposes of this Section 39(a), “Expansion Space” shall mean that certain approximately 8,797 rentable square feet on the third floor of the Building currently leased to Sequenta, Inc., as shown on Exhibit B attached to the Second Amendment, but only if the rights of Sequenta, Inc. with respect to such space have expired or been otherwise extinguished. Tenant shall be entitled to exercise its right under this Section 39(a) only with respect to the entire Expansion Space described in such Pending Deal Notice. Within 7 business days after Tenant’s receipt of the Pending Deal Notice, Tenant shall deliver to Landlord written notice (the “Space Acceptance Notice”) if Tenant elects to lease the Expansion Space. Tenant’s right to receive the Pending Deal Notice and election to lease or not lease the Expansion Space pursuant to this Section 39(a) is hereinafter referred to as the “Right of First Refusal.” If Tenant elects to lease the Expansion Space described in the Pending Deal Notice by delivering the Space Acceptance Notice within the required 7 business day period, Tenant shall be deemed to agree to lease the Expansion Space on the same general terms and conditions as this Lease except that the terms of this Lease shall be modified to reflect the Pending Deal Terms for the rental of the Expansion Space. The term of the Lease with respect to the Expansion Space shall be the term set forth in the Pending Deal Terms, and the term of the Lease with respect to the Expansion Premises may not be co-terminous with the Term of the Lease with respect to the original Premises; provided, however, that if the term of the

 

   3       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Lease with respect to the Expansion Space is scheduled to expire after the expiration of the current Term of the Lease with respect to the original Premises, Tenant may elect in its Space Acceptance Notice to extend the current Term of the Lease with respect to the original Premises to be co-terminous with the Base Term of the Lease with respect to the Expansion Space. Notwithstanding anything to the contrary contained herein, in no event shall the Work Letter attached to the Lease apply to the Expansion Space. If Tenant fails to deliver a Space Acceptance Notice to Landlord within the required 7 business day period, Tenant shall be deemed to have waived its rights under this Section 39(a) with respect to the Expansion Space identified in the Pending Deal Notice, and Landlord shall have the right to lease such Expansion Space to the third party subject to the Pending Deal (or an affiliate of such third party) (“Pending Deal Party”). Tenant’s Right of First Refusal with respect to the Expansion Space identified in the Pending Deal Notice shall be restored if Landlord fails to enter into an agreement to lease such Expansion Space to the Pending Deal Party within 3 months after Landlord’s delivery of the Pending Deal Notice to Tenant; provided, however, that in no event shall Tenant’s Right of First Refusal extend beyond the Expansion Right Expiration Date.

(b) Amended Lease. If: (i) Tenant fails to timely deliver a Space Acceptance Notice, or (ii) after the expiration of a period of 10 business days after Landlord’s delivery to Tenant of a lease amendment or lease agreement for Tenant’s lease of the Expansion Space on substantially the same terms and conditions of this Lease other than business terms and other than as modified by the Pending Deal Notice, no lease amendment or lease agreement for the Expansion Space acceptable to both parties each in their sole and absolute discretion, has been executed, Tenant shall be deemed to have forever waived its right to lease such Expansion Space.

(c) Exceptions. Notwithstanding the above, the Right of First Refusal shall, at Landlord’s option, not be in effect and may not be exercised by Tenant:

(i) during any period of time that Tenant is in Default under any provision of the Lease; or

(ii) if Tenant has been in Default under any provision of the Lease 3 or more times, whether or not the Defaults are cured, during the 12 month period prior to the date on which Tenant seeks to exercise the Right of First Refusal.

(d) Termination. The Right of First Refusal shall, at Landlord’s option, terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Right of First Refusal, if, after such exercise, but prior to the commencement date of the lease of such Expansion Space (i) Tenant fails to timely cure any default by Tenant under the Lease; or (ii)Tenant has Defaulted 3 or more times during the period from the date of the exercise of the Right of First Refusal to the date of the commencement of the lease of the Expansion Space whether or not such Defaults are cured.

(e) Subordinate. Tenant’s rights in connection with the Expansion Right are and shall be subject to and subordinate to any expansion or extension rights granted in the Project to Sequenta, Inc.

(f) Rights Personal. The Right of First Refusal is personal to Tenant and is not assignable without Landlord’s consent, which may be granted or withheld in Landlord’s sole discretion separate and apart from any consent by Landlord to an assignment of Tenant’s interest in the Lease, except that they may be assigned in connection with any Permitted Assignment of this Lease.

 

   4       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


(g) No Extensions. The period of time within which the Right of First Refusal may be exercised shall not be extended or enlarged by reason of Tenant’s inability to exercise the Right of First Refusal.”

 

8.

Right to Extend Term. Section 40 of the Lease is hereby deleted in its entirety and replaced with the following:

“40. Right to Extend Term. Tenant shall have the right to extend the Term of the Lease upon the following terms and conditions:

(a) Extension Rights. Tenant shall have 1 right (an “Extension Right”) to extend the term of this Lease for 2 years (an “Extension Term”) on the same terms and conditions as this Lease (other than with respect to Base Rent and the Work Letter) by giving Landlord written notice of its election to exercise such Extension Right at least 6 months prior, and no earlier than9 months prior, to the expiration of the Base Term of the Lease.

Base Rent shall be adjusted on the commencement date of such Extension Term and on each annual anniversary of the commencement of such Extension Term by multiplying the Base Rent payable immediately before such adjustment by 3% and adding the resulting amount to the Base Rent payable immediately before such adjustment.

(b) Rights Personal. The Extension Right is personal to Tenant and is not assignable without Landlord’s consent, which may be granted or withheld in Landlord’s sole discretion separate and apart from any consent by Landlord to an assignment of Tenant’s interest in the Lease, except that they may be assigned in connection with any Permitted Assignment of this Lease.

(c) Exceptions. Notwithstanding anything set forth above to the contrary, the Extension Right shall, at Landlord’s option, not be in effect and Tenant may not exercise the Extension Right:

(i) during any period of time that Tenant is in Default under any provision of this Lease; or

(ii) if Tenant has been in Default under any provision of this Lease 3 or more times, whether or not the Defaults are cured, during the 12 month period immediately prior to the date that Tenant intends to exercise the Extension Right, whether or not the Defaults are cured.

(d) No Extensions. The period of time within which the Extension Right may be exercised shall not be extended or enlarged by reason of Tenant’s inability to exercise the Extension Right.

(e) Termination. The Extension Right shall, at Landlord’s option, terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Extension Right, if, after such exercise, but prior to the commencement date of the Extension Term, (i) Tenant fails to timely cure any default by Tenant under this Lease; or (ii) Tenant has Defaulted 3 or more times during the period from the date of the exercise of the Extension Right to the date of the commencement of the Extension Term, whether or not such Defaults are cured.”

 

9.

Disclosure. For purposes of Section 1938 of the California Civil Code, as of the date of this Second Amendment, Tenant acknowledges having been advised by Landlord that the Project has not been inspected by a certified access specialist.

 

   5       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


10.

Miscellaneous.

a. This Second Amendment is the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous oral and written agreements and discussions. This Second Amendment may be amended only by an agreement in writing, signed by the parties hereto.

b. Landlord and Tenant each represents and warrants that it has not dealt with any broker, agent or other person (collectively, “Broker”) in connection with the transaction reflected in this Second Amendment and that no Broker brought about this transaction, other than CBRE. Landlord and Tenant each hereby agree to indemnify and hold the other harmless from and against any claims by any Broker, other than CBRE, claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard to this leasing transaction. Landlord shall be responsible for all fees of CBRE arising out of the execution of this Second Amendment in accordance with the terms of separate written agreement between Landlord and CBRE.

c. This Second Amendment is binding upon and shall inure to the benefit of the parties hereto, and their respective successors and assigns.

d. This Second Amendment may be executed in any number of counterparts, each of which shall be deemed an original, but all of which when taken together shall constitute one and the same instrument. The signature page of any counterpart may be detached there from without impairing the legal effect of the signature(s) thereon provided such signature page is attached to any other counterpart identical thereto except having additional signature pages executed by other parties to this Second Amendment attached thereto.

e. Except as amended and/or modified by this Second Amendment, the Lease is hereby ratified and confirmed and all other terms of the Lease shall remain in full force and effect, unaltered and unchanged by this Second Amendment. In the event of any conflict between the provisions of this Second Amendment and the provisions of the Lease, the provisions of this Second Amendment shall prevail. Whether or not specifically amended by this Second Amendment, all of the terms and provisions of the Lease are hereby amended to the extent necessary to give effect to the purpose and intent of this Second Amendment.

[Signatures are on the next page.]

 

   6       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


IN WITNESS WHEREOF, the parties hereto have executed this Second Amendment as of the day and year first above written.

 

TENANT:

 

PRINCIPIA BIOPHARMA INC.,

a Delaware corporation

  /s/ Eliot Charles
By:  

Eliot Charles

Its:   Interim CEO

LANDLORD:

 

ARE-EAST JAMIE COURT, LLC,

a Delaware limited liability company

By:

 

ALEXANDRIA REAL ESTATE EQUITIES, L.P., a Delaware limited partnership,

managing member

  By:  

ARE-QRS CORP.,

a Maryland corporation,

general partner

    By:  

/s/ Eric S. Johnson

    Its:   Eric S. Johnson
      Vice President
      Real Estate Legal Affairs

 

   7       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


EXHIBIT A

Expansion Premises

 

 

         Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


EXHIBIT B

Expansion Space

 

 

   B-1       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


FOURTH AMENDMENT TO LEASE

THIS FOURTH AMENDMENT TO LEASE (this “Fourth Amendment”) is made as of December 29, 2016, by and between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company (“Landlord”), and PRINCIPIA BIOPHARMA INC., a Delaware corporation (“Tenant”).

RECITALS

A. Landlord and Tenant are now parties to that certain Lease Agreement dated as of February 17, 2011, as amended by that certain Amended and Restated First Amendment to Lease Agreement dated as of January 12, 2012, as further amended by that certain Second Amendment to Lease Agreement dated as of February 25, 2013, and as further amended by that certain Third Amendment to Lease Agreement dated as of November 14, 2014 (the “Third Amendment”) (as amended, the “Lease”). Pursuant to the Lease, Tenant leases certain premises consisting of approximately 12,574 rentable square feet (“Premises”) in a building located at 400 East Jamie Court, South San Francisco, California. The Premises are more particularly described in the Lease. Capitalized terms used herein without definition shall have the meanings defined for such terms in the Lease.

B. The Term of the Lease is scheduled to expire on August 31, 2018.

C. Landlord and Tenant desire, subject to the terms and conditions set forth below, to amend the Lease to, among other things, (i) reflect the surrender of a portion of the Premises consisting of approximately 3,777 rentable square feet, as shown on Exhibit A attached hereto (the “Surrender Premises”) as of January 14, 2017 (the “Surrender Date”), and (ii) extend the Term of the Lease with respect to the remaining Premises through January 31, 2019.

NOW, THEREFORE, in consideration of the foregoing Recitals, which are incorporated herein by this reference, the mutual promises and conditions contained herein, and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, Landlord and Tenant hereby agree as follows:

 

1.

Surrender of Surrender Premises. The Lease with respect to the Surrender Premises shall terminate as provided for in the Lease on the Surrender Date. Tenant shall voluntarily surrender the Surrender Premises on such date in accordance with all surrender requirements contained in the Lease and in the condition in which Tenant is required to surrender the Premises as of the expiration of the Lease; provided, however, that SutroVax, Inc., a Delaware corporation (“SutroVax”), the subtenant that currently occupies the Surrender Premises pursuant to that certain Sublease Agreement between Tenant and SutroVax dated July 10, 2015 (the “Sublease”), shall be entitled to remain in the Surrender Premises so long as SutroVax agrees in writing to attorn to Landlord under the Sublease. From and after the Surrender Date, Tenant shall have no further rights of any kind with respect to the Surrender Premises nor shall Tenant have any obligations arising out of or resulting from the use or occupancy of, or any event occurring at the Surrender Premises after the Surrender Date. Without limiting the generality of the foregoing, Tenant shall reasonably cooperate with SutroVax before the Surrender Date to provide a Surrender Plan to Landlord as required under the Lease with respect to the Surrender Premises, but Tenant shall have no further obligation with respect to the preparation or delivery of the Surrender Plan for the Surrender Premises after the Surrender Date. Notwithstanding the foregoing, those provisions of the Lease which, by their terms, survive the termination of the Lease shall survive the surrender of the Surrender Premises and termination of the Lease with respect to the Surrender Premises as provided for herein. Nothing herein shall excuse Tenant from its obligations under the Lease with respect to the Surrender Premises prior to the Surrender Date.

 

   1       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


The failure by SutroVax to surrender the Surrender Premises on or before the Surrender Date shall not constitute a holdover by Tenant in the Surrender Premises nor shall it constitute a Default by Tenant under the Lease.

 

2.

Definition of Premises and Rentable Area of Premises. Commencing on January 15, 2017, the defined terms “Premises” and “Rentable Area of Premises” on Page 1 of the Lease shall be deleted in their entirety and replaced with the following:

Premises: That portion of the Building containing approximately 8,797 rentable square feet, consisting of the (i) “Original Premises” containing approximately 8,399 rentable square feet, and (ii) “Second Expansion Premises” containing approximately 398 rentable square feet, all as determined by Landlord, as shown on Exhibit A.”

Rentable Area of Premises: 8,797 sq. ft.”

As of January 15, 2017, Exhibit A to the Lease shall be amended to exclude the Surrender Premises.

 

3.

Base Term. The expiration date of the Term of the Lease with respect to the remaining Premises (not including the Surrender Premises) is hereby extended through January 31, 2019.

 

4.

Base Rent. Tenant shall continue to pay Base Rent for the entire Premises (including the Surrender Premises) as provided under the Lease through the Surrender Date. Commencing on January 15, 2017, Tenant shall no longer be required to pay Base Rent with respect to the Surrender Premises. Tenant shall continue to pay Base Rent for the remaining Premises as provided in Section 2 of the Third Amendment (and as adjusted pursuant to Section 2 of the Third Amendment) through August 31, 2018. Commencing on September 1, 2018, Tenant shall continue paying Base Rent for the remaining Premises at the same per square foot rate per month paid for the month of August 2018, through January 31, 2019.

 

5.

Definition of Tenant’s Share of Operating Expenses. Commencing on January 15, 2017, the defined terms “Tenant’s Share of Operating Expenses for the Building” and “Tenant’s Share of Operating Expenses for the Project” on page 1 of the Lease are deleted in their entirety and replaced with the following:

Tenant’s Share of Operating Expenses for the Building: 9.96%”

Tenant’s Share of Operating Expenses for the Project: 5.39%”

Notwithstanding anything to the contrary contained in the Lease, there shall be no reconciliation of Tenant’s Share of Operating Expenses payable with respect to the Surrender Premises for the 2016 calendar year.

 

6.

Termination Payment. Landlord shall, within 10 business days following the Surrender Date, deliver to Tenant funds in the amount of $[•] as consideration for Tenant’s agreement to enter into this Fourth Amendment and surrendering the Surrender Premises on or before the Surrender Date.

 

7.

Condition Precedent. Notwithstanding anything to the contrary contained in this Fourth Amendment, Tenant and Landlord acknowledge and agree that the effectiveness of this Fourth Amendment shall be subject to the following condition precedent (“Conditions Precedent”) having been satisfied: (i) Landlord shall have entered into a lease agreement with a third party (“New Tenant”) pursuant to which New Tenant agrees to lease the Surrender Premises, which lease agreement shall be on terms and conditions acceptable to Landlord, in Landlord’s

 

   2       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


  reasonable discretion, and (ii) SutroVax shall have attorned to Landlord under the Sublease effective as of January 15, 2017. In the event that the Condition Precedents are not satisfied, Landlord shall have the right to terminate this Fourth Amendment upon delivery of written notice to Tenant, in which case this Fourth Amendment shall be null and void and of no further force or effect. Landlord shall have no liability whatsoever to Tenant relating to or arising from Landlord’s inability or failure to cause the Conditions Precedent to be satisfied.

 

8.

Disclosure. For purposes of Section 1938 of the California Civil Code, as of the date of this Fourth Amendment, Tenant acknowledges having been advised by Landlord that the Project has not been inspected by a certified access specialist.

 

9.

OFAC. Tenant and all beneficial owners of Tenant are currently (a) in compliance with and shall at all times during the Term of the Lease remain in compliance with the regulations of the Office of Foreign Assets Control (“OFAC”) of the U.S. Department of Treasury and any statute, executive order, or regulation relating thereto (collectively, the “OFAC Rules”), (b) not listed on, and shall not during the term of the Lease be listed on, the Specially Designated Nationals and Blocked Persons List, Foreign Sanctions Evaders List or the Sectoral Sanctions Identifications List, which are all maintained by OFAC and/or on any other similar list maintained by OFAC or other governmental authority pursuant to any authorizing statute, executive order, or regulation, and (c) not a person or entity with whom a U.S. person is prohibited from conducting business under the OFAC Rules.

 

10.

Legal Fees. Landlord agrees to reimburse Tenant for the actual reasonable legal fees incurred by Tenant in connection with this Fourth Amendment and related documents being negotiated concurrently herewith with respect to the termination of the SutroVax Sublease, up to $[•], within 30 days following Tenant’s delivery to Landlord of evidence reasonably satisfactory to Landlord of such costs incurred by Tenant.

 

11.

Miscellaneous.

a. This Fourth Amendment is the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior and contemporaneous oral and written agreements and discussions. This Fourth Amendment may be amended only by an agreement in writing, signed by the parties hereto.

b. Landlord and Tenant each represents and warrants that it has not dealt with anybroker, agent or other person (collectively, “Broker”) in connection with the transaction reflected in this Fourth Amendment and that no Broker brought about this transaction. Landlord andTenant each hereby agree to indemnify and hold the other harmless from and against any claims by any Broker claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard to this leasing transaction.

c. This Fourth Amendment is binding upon and shall inure to the benefit of the parties hereto, and their respective successors and assigns.

d. This Fourth Amendment may be executed in any number of counterparts, each of which shall be deemed an original, but all of which when taken together shall constitute one and the same instrument. The signature page of any counterpart may be detached therefrom without impairing the legal effect of the signature(s) thereon provided such signature page is attached to any other counterpart identical thereto except having additional signature pages executed by other parties to this Fourth Amendment attached thereto.

 

   3       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


e. Except as amended and/or modified by this Fourth Amendment, the Lease is hereby ratified and confirmed and all other terms of the Lease shall remain in full force and effect, unaltered and unchanged by this Fourth Amendment. In the event of any conflict between the provisions of this Fourth Amendment and the provisions of the Lease, the provisions of thisFourth Amendment shall prevail. Whether or not specifically amended by this Fourth Amendment, all of the terms and provisions of the Lease are hereby amended to the extent necessary to give effect to the purpose and intent of this Fourth Amendment.

[Signatures are on the next page.]

 

   4       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


IN WITNESS WHEREOF, the parties hereto have executed this Fourth Amendment as of the day and year first above written.

 

LANDLORD:   ARE-EAST JAMIE COURT, LLC,
  a Delaware limited liability company
  By:   ALEXANDRIA REAL ESTATE EQUITIES, L.P.,
    a Delaware limited partnership,
    managing member
    By:   ARE-QRS CORP.,
      a Maryland corporation,
      general partner
      By: /s/ Eric S. Johnson                                                             
      Its: Senior Vice President, RE Legal Affairs                          
TENANT:   PRINCIPIA BIOPHARMA INC.,
  a Delaware corporation
  By:  

/s/ Christopher Y. Chai

  Its:   CFO

 

   5       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.


Exhibit A

Surrender Premises

 

   6       Copyright © 2005, Alexandria Real Estate Equities, Inc. ALL RIGHT RESERVED. Confidential and Proprietary – Do Not Copy or Distribute. Alexandria and the Alexandria Logo are registered trademarks of Alexandria Real Estate Equities, Inc.

 

[*] = Certain confidential information contained in this document, marked by brackets, is filed with the Securities and Exchange Commission pursuant to Rule 406 of the Securities Act of 1933, as amended.