Lease Agreement between the Registrant and B9 LS Harrison & Washington LLC, dated December 14, 2021

Contract Categories: Real Estate - Lease Agreements
EX-10.20 3 glue-ex10_20.htm EX-10.20 EX-10.20

Exhibit 10.20

LEASE

by and between

B9 LS HARRISON & WASHINGTON LLC,

a Delaware limited liability company

and

MONTE ROSA THERAPEUTICS, INC.,

a Delaware corporation

 

 

 

 

 

 

 

 

 

 


Table of Contents

1.

Lease of Premises

1

2.

Basic Lease Provisions

2

3.

Term

5

4.

Possession and Commencement Date.

6

5.

Condition of Premises

8

6.

Rentable Area

8

7.

Rent

9

8.

Rent Adjustments

10

9.

Operating Expenses

10

10.

Taxes on Tenant’s Property

15

11.

Security Deposit

16

12.

Use

19

13.

Rules and Regulations, CC&Rs, Parking Facilities and Common Area

22

14.

Project Control by Landlord

23

15.

Quiet Enjoyment

24

16.

Utilities and Services

25

17.

Alterations

29

18.

Repairs and Maintenance

32

19.

Liens

33

20.

Estoppel Certificate

34

21.

Hazardous Materials

34

22.

Odors and Exhaust

37

23.

Insurance

38

24.

Damage or Destruction

42

25.

Eminent Domain

45

26.

Surrender

45

27.

Holding Over

46

28.

Indemnification and Exculpation

47

29.

Assignment or Subletting

48

30.

Subordination and Attornment

52

31.

Defaults and Remedies

53

 

B-i


32.

Bankruptcy

58

33.

Brokers

58

34.

Definition of Landlord

59

35.

Limitation of Landlord’s Liability

59

36.

Joint and Several Obligations

60

37.

Representations

60

38.

Confidentiality

61

39.

Notices

61

40.

Miscellaneous

62

41.

Rooftop Installation Area

65

42.

Option to Extend Term

65

 

 

ii


LEASE

THIS LEASE (this “Lease”) is entered into as of this 14th day of December, 2021 (the “Execution Date”), by and between B9 LS HARRISON & WASHINGTON LLC, a Delaware limited liability company with offices located at 4570 Executive Drive, Suite 400, San Diego, California 92121 (“Landlord”), and MONTE ROSA THERAPEUTICS, INC., a Delaware corporation, with offices located at 645 Summer Street, Suite 102, Boston, Massachusetts 02210 (“Tenant”).

RECITALS

A. WHEREAS, Landlord owns certain real property described on Exhibit A-1 attached hereto (collectively, the “Property”) and the improvements located on the Property at 321 Harrison Avenue, 1000 Washington Street, and 333 Harrison Avenue in Boston, Massachusetts 02118; and

B. WHEREAS, Landlord wishes to lease to Tenant, and Tenant desires to lease from Landlord, certain premises (the “Premises”) on the ninth (9th) and tenth (10th) floors of the building known as 321 Harrison Avenue, Boston, Massachusetts 02118 (the “Building”) located on the Property, pursuant to the terms and conditions of this Lease, as detailed below.

AGREEMENT

NOW, THEREFORE, Landlord and Tenant, in consideration of the mutual promises contained herein and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, and intending to be legally bound, agree as follows:

1. Lease of Premises.

1.1. Effective on the Term Commencement Date (as defined below), Landlord hereby leases to Tenant, and Tenant hereby leases from Landlord, the Premises, as shown on Exhibit A attached hereto, including exclusive shafts, cable runs, and mechanical spaces, for use by Tenant in accordance with the Permitted Use (as defined below) and no other uses. The Property and all landscaping, parking facilities, private drives and other improvements and appurtenances related thereto, including the Building and other buildings and improvements located on the Property, are hereinafter collectively referred to as the “Project.” All portions of the Building that are for the non-exclusive use of the tenants of the Building only, and not the tenants of the Project generally, such as service corridors, stairways, elevators, public restrooms and public lobbies (all to the extent located in the Building), are hereinafter referred to as “Building Common Area.” All portions of the Project that are for the non-exclusive use of tenants of the Project generally, including driveways, sidewalks, parking areas, landscaped areas, and service corridors, stairways, elevators, public restrooms and public lobbies (but excluding Building Common Area), are hereinafter referred to as “Project Common Area.” The Building Common Area and Project Common Area are collectively referred to herein as “Common Area.”

B-1


2. Basic Lease Provisions. For convenience of the parties, certain basic provisions of this Lease are set forth herein. The provisions set forth herein are subject to the remaining terms and conditions of this Lease and are to be interpreted in light of such remaining terms and conditions.

2.1. This Lease shall take effect upon the Execution Date and, except as specifically otherwise provided within this Lease, each of the provisions hereof shall be binding upon and inure to the benefit of Landlord and Tenant from the date of execution and delivery hereof by all parties hereto.

2.2. In the definitions below, Rentable Area (as defined below) is expressed in square feet. Rentable Area and “Tenant’s Pro Rata Shares” are all subject to adjustment as provided in this Lease.

Definition or Provision

Means the Following (As of the Execution Date)

Approximate Rentable Area of Premises*

63,327 square feet

Approximate Rentable Area of Building

247,670 square feet

Approximate Rentable Area of Project

493,375 square feet

Tenant’s Pro Rata Share of Building*

25.57%

Tenant’s Pro Rata Share of Project*

12.84%

* Note: Subject to adjustment based upon the Rentable Area of the Premises, Building and Project as of the Term Commencement Date, but not by more than once during the initial Term of this Lease.

2.3. Monthly and annual installments of Base Rent for the Premises (“Base Rent”) as of the Rent Commencement Date (as defined below), subject to adjustment under this Lease, will be as follows:

Dates

Square Feet of Rentable Area*

Base Rent per Square Foot of Rentable Area

Monthly Base Rent*

Annual Base Rent*

Rent Commencement Date-date immediately prior to 1st anniversary of Rent Commencement Date

63,327

 $ 95.00

 $501,338.75

$6,016,065.00

 

2


1st anniversary of Rent Commencement Date - date immediately prior to 2nd anniversary of Rent Commencement Date

63,327

 $ 97.85

 $516,378.91

$6,196,546.95

2nd anniversary of Rent Commencement Date - date immediately prior to 3rd anniversary of Rent Commencement Date

63,327

 $100.79

 $531,870.28

 $6,382,443.36

3rd anniversary of Rent Commencement Date - date immediately prior to 4th anniversary of Rent Commencement Date

63,327

 $103.81

 $547,826.39

 $6,573,916.66

4th anniversary of Rent Commencement Date - date immediately prior to 5th anniversary of Rent Commencement Date

63,327

 $106.92

 $564,261.18

 $6,771,134.16

5th anniversary of Rent Commencement Date - date immediately prior to 6th anniversary of Rent Commencement Date

63,327

 $110.13

 $581,189.02

 $6,974,268.18

6th anniversary of Rent Commencement Date - date immediately prior to 7th anniversary of Rent Commencement Date

63,327

 $113.43

 $598,624.69

 $7,183,496.23

7th anniversary of Rent Commencement Date - date immediately prior to 8th anniversary of Rent Commencement Date

63,327

 $116.84

 $616,583.43

 $7,399,001.12

 

3


8th anniversary of Rent Commencement Date - date immediately prior to 9th anniversary of Rent Commencement Date

63,327

 $120.34

 $635,080.93

 $7,620,971.15

9th anniversary of Rent Commencement Date - date immediately prior to 10th anniversary of Rent Commencement Date

63,327

 $123.95

 $654,133.36

 $7,849,600.28

* Note: Subject to adjustment based upon the Rentable Area of the Premises as of the Term Commencement Date, but not by more than once during the initial Term of this Lease.

2.4. Estimated Term Commencement Date: April 1, 2022

2.5. Estimated Term Expiration Date: December 31, 2032

2.6. Security Deposit: $4,010,710.00, subject to increase or decrease in accordance with the terms hereof

2.7. Permitted Use: Office, laboratory, research and development, and limited vivarium use in conformity with all federal, state, municipal and local laws, codes, ordinances, rules and regulations of Governmental Authorities (as defined below), committees, associations, or other regulatory committees, agencies or governing bodies having jurisdiction over the Premises, the Building, the Property, the Project, Landlord or Tenant, including both statutory and common law and hazardous waste rules and regulations (“Applicable Laws”)

2.8. Address for Rent Payment:

B9 LS HARRISON & WASHINGTON LLC Attention Entity 110300

P.O. Box 511387

Los Angeles, California 90051-7942

2.9. Address for Notices to Landlord:

B9 LS HARRISON & WASHINGTON LLC

4570 Executive Drive, Suite 400

San Diego, California 92121

Attn: Legal Department

Email: ***@***

2.10. Address for Notices to Tenant:

Prior to the Rent Commencement Date:

4


 

MONTE ROSA THERAPEUTICS, INC.

645 Summer Street, Suite 102, Boston,

Massachusetts 02210 Attn: Legal Department

Email: ***@***

 

From and after the Rent Commencement Date:

 

MONTE ROSA THERAPEUTICS, INC.

321 Harrison Avenue

Boston, Massachusetts 02118

Attn: Legal Department

Email: ***@***

 

2.11. Address for Invoices to Tenant:

MONTE ROSA THERAPEUTICS, INC.

321 Harrison Avenue

Boston, Massachusetts 20118

Attn: Accounts Payable

Email: ***@***

 

2.12. The following Exhibits are attached hereto and incorporated herein by reference:

Exhibit A Premises

Exhibit A-1 Legal Description of the Property

Exhibit A-2 Lab and Office Zones

Exhibit B Work Letter

Exhibit B-1 Tenant Work Insurance Schedule

Exhibit B-2 Landlord’s Work

Exhibit C-1 Acknowledgement of Term Commencement Date

Exhibit C-2 Acknowledgement of Rent Commencment Date and Term Expiration Date

Exhibit D Intentionally Omitted

Exhibit E Form of Letter of Credit

Exhibit F Rules and Regulations

Exhibit G Transportation Access Plan Agreement

Exhibit H Tenant’s Personal Property

Exhibit I Form of Estoppel Certificate

Exhibit J Definition of Obsolete Equipment

 

 

3. Term. The term of the leasehold granted by this Lease (as the same may be extended pursuant to Article 42 hereof, and as the same may be earlier terminated in accordance with this Lease, the “Term”) shall commence on the Term Commencement Date (as defined in Article 4) and end on the date (the “Term Expiration Date”) that is one hundred twenty-eight (128) months after the

5


Term Commencement Date, subject to extension or earlier termination of this Lease as provided herein.

4. Possession and Commencement Date.

4.1. The “Term Commencement Date” shall be the date Landlord tenders possession of the Premises to Tenant with Landlord’s Work at a stage at which commencement of the Tenant Improvements by Tenant’s contractor may occur. Landlord shall use commercially reasonable efforts to tender possession of the Premises to Tenant on the Estimated Term Commencement Date, however, Tenant agrees that in the event Landlord does not deliver the Premeises in the Delivery Condition on the Estimated Term Commencement Date for any reason, then (a) this Lease shall not be void or voidable and (b) Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, provided, however, that the Rent Commencement Date shall not be deemed to have occurred until the Landlord’s Work described in Exhibit B-2 has been Substantially Completed. Notwithstanding the foregoing, if the actual Term Commencment Date has not occurred on or before the date which is ninety (90) days afer the Estimated Term Commencement Date (as extended by Tenant Delays or Force Majeure), then Tenant shall receive an abatement of Rent in an amount equal to one (1) day’s Rent for each day that Landlord is delayed in delivering the Premises beyond such ninety (90) day period. Tenant shall execute and deliver to Landlord written acknowledgment of the actual Term Commencement Date and the Term Expiration Date within ten (10) days after the Term Commencement Date, in the form attached as Exhibit C-1 hereto, and Tenant shall execute and deliver to Landlord written acknowledgment of the actual Rent Commencement Date and Term Expiration Date within ten (10) days after the Rent Commencement Date, in the form attached as Exhibit C-2 hereto. Failure to execute and deliver such acknowledgments, however, shall not affect the Term Commencement Date, the Rent Commencement Date, the Term Expiration Date or Landlord’s or Tenant’s liability hereunder. Failure by Tenant to obtain any governmental licensing or similar governmental approval of the Premises required for the Permitted Use by Tenant shall not serve to extend the Term Commencement Date. The term “Substantially Complete” or “Substantial Completion” means (i) with respect to the Tenant Improvements, that the Tenant Improvements are substantially complete in accordance with the Approved Plans (as defined in the Work Letter), except for punch list items, and the Premises may be legally occupied pursuant to a temporary certificate of occupancy, final signed building permit or its substantial equivalent, and (ii) with respect to Landlord’s Work, that Landlord’s Work is substantially complete, except for punch list items. If possession is delayed by any action or omission of Tenant or a Tenant Party (“Tenant Delay”), then the Term Commencement Date shall be the date that the Term Commencement Date would have occurred but for such Tenant Delay.

 

4.2. Tenant shall cause the certain tenant improvement work (the “Tenant Improvements”) to be constructed in the Premises pursuant to the Work Letter attached hereto as Exhibit B (the “Work Letter”) at a cost to Landlord not to exceed (a) Twelve Million Nine Hundred Eighty-Two Thousand Thirty-Five and 00/100 Dollars ($12,982,035.00) (based upon Two Hundred Dollars ($205.00) per square foot of Rentable Area (as defined below)) (the “Base TI Allowance”) plus (b) if properly requested by Tenant pursuant to this Article, Six Hundred Thirty-Three Thousand Two Hundred Seventy and 00/100 Dollars ($633,270.00) (based upon Ten Dollars ($10.00) per square foot of Rentable Area) (the “Additional TI Allowance”), for a total of Thirteen Million Six Hundred Fifteen Thousand Three Hundred Five and 00/100 Dollars

6


($13,615,305.00) (based upon Two Hundred Fifteen and 00/100 Dollars ($215.00) per square foot of Rentable Area). The Base TI Allowance, together with Additional TI Allowance (if properly requested by Tenant pursuant to this Article), shall be referred to herein as the “TI Allowance.” The TI Allowance may be applied to the costs of (m) construction, (n) project review by Landlord (which fee shall equal two percent (2%) of the cost of the Tenant Improvements, including the Base TI Allowance and, if used by Tenant, the Additional TI Allowance), (o) commissioning of mechanical, electrical and plumbing systems by a licensed, qualified commissioning agent hired by Tenant, and review of such party’s commissioning report by a licensed, qualified commissioning agent hired by Landlord, (p) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant, (q) building permits and other taxes, fees, charges and levies by Governmental Authorities (as defined below) for permits or for inspections of the Tenant Improvements, and (r) costs and expenses for labor, material, equipment and fixtures including all telecommunications wiring and cabling, and movable laboratory casework. In no event shall the TI Allowance be used for (v) the cost of work that is not authorized by the Approved Plans (as defined in the Work Letter) or otherwise approved in writing by Landlord, (w) payments to Tenant or any affiliates of Tenant, (x) the purchase of any furniture, personal property or other non-building system equipment, (y) costs arising from any default by Tenant of its obligations under this Lease or (z) costs that are recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors).

4.3. Tenant shall have until the date which is eighteen (18) months following the Term Commencement Date (the “TI Deadline”), to submit Fund Requests (as defined in the Work Letter) to Landlord for disbursement of the unused portion of the TI Allowance, after which date Landlord’s obligation to fund any such costs for which Tenant has not submitted a Fund Request to Landlord shall expire. Initial Base Rent shall be increased to include the amount of the Additional TI Allowance disbursed by Landlord in accordance with this Lease amortized over the initial Term at a rate of eight percent (8%) annually for each Dollar of the Additional TI Allowance disbursed by Landlord in accordance with this Lease. The amount by which Base Rent shall be increased shall be determined (and Base Rent shall be increased accordingly) as of the Term Commencement Date and, if such determination does not reflect use by Tenant of all of the Additional TI Allowance, shall be determined again as of the TI Deadline, with Tenant paying (on the next succeeding day that Base Rent is due under this Lease (the “TI True-Up Date”)) any underpayment of the further adjusted Base Rent for the period beginning on the Term Commencement Date and ending on the TI True-Up Date. The initial Base Rent, as adjusted to reflect the disbursement of the Additional TI Allowance in accordance with this Section, shall be subject to further annual adjustments as set forth in Section 8.1.

4.4. To the extent that the total projected cost of the Tenant Improvements (as projected by Landlord) exceeds the TI Allowance (such excess, the “Excess TI Costs”), Tenant shall pay the costs of the Tenant Improvements on a pari passu basis with Landlord as such costs are paid, in the proportion of Excess TI Costs payable by Tenant to the Base TI Allowance and, if used by Tenant, the Additional TI Allowance payable by Landlord. If the cost of the Tenant Improvements (as projected by Landlord) increases over Landlord’s initial projection, then Landlord may notify Tenant and Tenant shall deposit any additional Excess TI Costs with Landlord in the same way that Tenant deposited the initial Excess TI Costs. In no event shall any unused TI Allowance entitle Tenant to a credit against Rent payable under this Lease. Tenant shall deliver to Landlord (a) a certificate of occupancy (or its substantial equivalent) for the Premises suitable for the

7


Permitted Use and (b) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect and the general contractor.

4.5. Prior to entering upon the Premises, Tenant shall furnish to Landlord evidence satisfactory to Landlord that insurance coverages required of Tenant under the provisions of Article 23 are in effect, and such entry shall be subject to all the terms and conditions of this Lease other than the payment of Base Rent.

4.6. Landlord and Tenant shall mutually agree upon the selection of the architect, engineer, general contractor and major subcontractors for the Tenant Improvements, and Landlord and Tenant shall each participate in the review of the competitive bid process. Landlord hereby approves PIDC Construction as Tenant’s general contractor, and Landlord preapproves Symmes Maini and McKee Associates and Jacobs as architects (Tenant to notify Landlord of which architect is selected). Landlord may refuse to approve any architects, consultants, engineers, contractors, subcontractors or material suppliers that Landlord reasonably believes could cause labor disharmony or may not have sufficient experience, in Landlord’s reasonable opinion, to perform work in an occupied Class “A” laboratory research building and in lab areas.

4.7. Notwithstanding anything to the contrary in this Lease, Landlord and Tenant agreed that all Tenant Improvements shall (a) be programmed in accordance with the lab and office zones identified on Exhibit A-2 attached hereto, and (b) incorporate flexible wall and lab bench systems.

4.8 Prior to commencement of the Tenant Improvements, Tenant shall install temporary meters for all water, gas, heat, light, power, telephone, internet service, cable television, other telecommunications and other utilities supplied to the Premises for use during Tenant’s construction of the Tenant Improvements. Tenant shall pay all utility charges, together with any fees, surcharges and taxes thereon for the period beginning on the date that Tenant first accesses the Premises for any reason after the Execution Date.

5. Condition of Premises. Tenant acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Project, or with respect to the suitability of the Premises, the Building or the Project for the conduct of Tenant’s business. Tenant acknowledges that (a) it agrees to take the Premises in its condition “as is” as of the Term Commencement Date, subject to Landlord’s obligations with respect to the condition of the Landlord’s Work set forth in Section 4.1 hereof, and (b) Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises, except for performance of the work described in Exhibit B-2 (the “Landlord’s Work”) and with respect to payment of the Base TI Allowance and, if used by Tenant, the Additional TI Allowance. Tenant’s taking of possession of the Premises shall, except as otherwise agreed to in writing by Landlord and Tenant, conclusively establish that the Premises, the Building and the Project were at such time in good, sanitary and satisfactory condition and repair.

8


6. Rentable Area.

6.1. The term “Rentable Area” shall reflect such areas as reasonably calculated by Landlord’s architect, as the same may be reasonably adjusted from time to time by Landlord in consultation with Landlord’s architect to reflect the expansion or contraction of the Premises, the Building or the Project, as applicable, but in any event not more than once during the initial Term of this Lease.

6.2. The Rentable Area of the Building is generally determined by making separate calculations of Rentable Area applicable to each floor within the Building and totaling the Rentable Area of all floors within the Building. The Rentable Area of a floor is computed by measuring to the outside finished surface of the permanent outer Building walls. The full area calculated as previously set forth is included as Rentable Area, without deduction for columns and projections or vertical penetrations, including stairs, elevator shafts, flues, pipe shafts, vertical ducts and the like, as well as such items’ enclosing walls.

6.3. The term “Rentable Area,” when applied to the Premises, is that area equal to the usable area of the Premises, plus an equitable allocation of Rentable Area within the Building that is not then utilized or expected to be utilized as usable area, including that portion of the Building devoted to corridors, equipment rooms, restrooms, elevator lobby, atrium and mailroom.

6.4. The Rentable Area of the Project is the total Rentable Area of all buildings within the Project.

6.5. Review of allocations of Rentable Areas as between tenants of the Building and the Project shall be made as and when Landlord deems appropriate, acting reasonably, and not more than once during the Lease Term, including in order to facilitate an equitable apportionment of Operating Expenses (as defined below). Such review shall be conducted by a licensed architect and certified by such licensed architect as being correct, in which event Tenant shall be bound by such certifications.

7. Rent.

7.1. Tenant shall pay to Landlord as Base Rent for the Premises, commencing on the date which is the earlier to occur of (a) eight (8) months following the Term Commencement Date, or (b) the date which is two (2) months following the date Tenant Substantially Completes the Tenant Improvements (the “Rent Commencement Date”), the sums set forth in Section 2.3, subject to the rental adjustments provided in Article 8 hereof; provided, however, that if the Landlord’s Work is not Substantially Complete upon the earlier of (a) or (b), then the Rent Commencement Date shall be the date that the Landlord’s Work is Substantially Complete; provided, further, however, that if Substantial Completion of the Landlord Work’s is delayed by a Tenant Delay, then the Rent Commencement Date shall be the date that the Rent Commencement Date would have occurred but for such Tenant Delay. Base Rent shall be paid in equal monthly installments as set forth in Section 2.3, subject to the rental adjustments provided in Article 8 hereof, each in advance on the first day of each and every calendar month during the Term.

7.2. In addition to Base Rent, Tenant shall pay to Landlord as additional rent (“Additional Rent”) at times hereinafter specified in this Lease (a) Tenant’s Adjusted Share (as

9


defined below) of Operating Expenses (as defined below), (b) the Property Management Fee (as defined below) and (c) any other amounts that Tenant assumes or agrees to pay under the provisions of this Lease that are owed to Landlord, including any and all other sums that may become due by reason of any default of Tenant or failure on Tenant’s part to comply with the agreements, terms, covenants and conditions of this Lease to be performed by Tenant, after notice and the lapse of any applicable cure periods.

7.3. Base Rent and Additional Rent shall together be denominated “Rent.” Rent shall be paid to Landlord, without abatement, deduction or offset, in lawful money of the United States of America to the address set forth in Section 2.8 or to such other person or at such other place as Landlord may from time designate in writing. In the event the Term commences or ends on a day other than the first day of a calendar month, then the Rent for such fraction of a month shall be prorated for such period on the basis of the number of days in the month and shall be paid at the then-current rate for such fractional month.

7.4. Tenant’s obligation to pay Rent shall not be discharged or otherwise affected by (a) any Applicable Laws now or hereafter applicable to the Premises, (b) any other restriction on Tenant’s use, (c) except as expressly provided herein, any casualty or taking or (d) any other occurrence; and Tenant waives all rights now or hereafter existing to terminate or cancel this Lease or quit or surrender the Premises or any part thereof, or to assert any defense in the nature of constructive eviction to any action seeking to recover rent. Tenant’s obligation to pay Rent with respect to any period or obligations arising, existing or pertaining to the period prior to the date of the expiration or earlier termination of the Term or this Lease shall survive any such expiration or earlier termination; provided, however, that nothing in this sentence shall in any way affect Tenant’s obligations with respect to any other period.

8. Rent Adjustments.

8.1 Base Rent (including any increase to Base Rent arising from any disbursement of the Additional TI Allowance by Landlord in accordance with this Lease), shall be subject to an annual upward adjustment of three percent (3%) of the then-current Base Rent. The first such adjustment shall become effective commencing on the first (1st) annual anniversary of the Rent Commencement Date, and subsequent adjustments shall become effective on every successive annual anniversary for so long as this Lease continues in effect.

9. Operating Expenses.

9.1. As used herein, the term “Operating Expenses” shall include:

(a) Government impositions, including property tax costs consisting of real property taxes, and taxes on personal property owned by Landlord (so long as such personal property is located at the Project and used in the operation or maintenance of the Project, and is not for the benefit of individual tenants) (including amounts due under any improvement bond upon the Building or the Project (including the parcel or parcels of real property upon which the Building, the other buildings in the Project and areas serving the Building and the Project are located provided the same are appropriately proportioned among all tenants at the Building or Project, as applicable)) or assessments in lieu thereof imposed by any federal, state, regional, local or municipal governmental authority, agency or subdivision (each, a “Governmental Authority”);

10


taxes on or measured by gross rentals received from the rental of space in the Project; taxes based on the square footage of the Premises, the Building or the Project, as well as any parking charges, utilities surcharges or any other costs levied, assessed or imposed by, or at the direction of, or arising from Applicable Laws or interpretations thereof, promulgated by any Governmental Authority in connection with the use or occupancy of the Project or the parking facilities serving the Project; taxes on this transaction or any document to which Tenant is a party creating or transferring an interest in the Premises; any fee for a business license to operate an office/laboratory building; and any expenses, including the reasonable cost of attorneys or experts, reasonably incurred by Landlord in seeking reduction by the taxing authority of the applicable taxes, less tax refunds obtained as a result of an application for review thereof; and

(b) All other costs of any kind paid or incurred by Landlord in connection with the operation or maintenance of the Building and the Project, and costs of repairs and replacements to improvements within the Project as appropriate to maintain the Project as required hereunder, consistent with good business practice, may establish to provide for future repairs and replacements, or as any Lender (as defined below) may require; costs of utilities furnished to the Common Area; sewer fees; cable television; trash collection; cleaning, including windows; heating, ventilation and air-conditioning (“HVAC”); maintenance of landscaping and grounds; snow removal; maintenance of drives and parking areas; maintenance of the roof; maintenance of any bridge or connection between buildings at the Project; security services and devices; building supplies; maintenance or replacement of equipment utilized for operation and maintenance of the Project; license, permit and inspection fees; sales, use and excise taxes on goods and services purchased by Landlord in connection with the operation, maintenance or repair of the Building or Project systems and equipment; telephone, postage, stationery supplies and other expenses incurred in connection with the operation, maintenance or repair of the Project; all costs and expenses incurred in connection with providing Project amenities, including, without limitation, the shuttle service for the Project and the fitness facility currently located within the building at 1000 Washington Street; accounting, legal and other professional fees and expenses incurred in connection with the Project; costs of furniture, draperies, carpeting, landscaping supplies, snow removal and other customary and ordinary items of personal property provided by Landlord for use in Common Area or in the Project office; Project office rent or rental value for a commercially reasonable amount of space, to the extent an office used for Project operations is maintained at the Project, plus customary expenses for such office; capital expenditures incurred (i) in replacing obsolete equipment, as such term is defined on Exhibit J attached hereto, (ii) for the primary purpose of reducing Operating Expenses or (iii) required by any Governmental Authority to comply with changes in Applicable Laws that take effect after the Execution Date or to ensure continued compliance with Applicable Laws in effect as of the Execution Date, in each case amortized over the useful life thereof, as reasonably determined by Landlord, in accordance with generally accepted accounting principles, but in no event longer than ten (10) years; costs of complying with Applicable Laws (except to the extent such costs are incurred to remedy non-compliance as of the Execution Date with Applicable Laws); costs to keep the Project in compliance with, or costs or fees otherwise required under or incurred pursuant to any CC&Rs or Property Operations Documents (as each such term is defined below), including condominium fees; insurance premiums, including premiums for commercial general liability, property casualty, earthquake, terrorism and environmental coverages; portions of insured losses paid by Landlord as part of the deductible portion of a loss pursuant to the terms of insurance policies; service contracts; costs of services of independent contractors retained to do work of a nature referenced

11


above; and costs of compensation (including employment taxes and fringe benefits) of all persons who perform regular and recurring duties connected with the day-to-day operation and maintenance of the Project, its equipment, the adjacent walks, landscaped areas, drives and parking areas, including janitors, floor waxers, window washers, watchmen, gardeners, sweepers, plow truck drivers, handymen, and engineering/maintenance/facilities personnel.

(c) Notwithstanding the foregoing, Operating Expenses shall not include any net income, franchise, capital stock, estate or inheritance taxes, or taxes that are the personal obligation of Tenant or of another tenant of the Project; any leasing commissions; expenses that relate to preparation of rental space for a tenant; advertising and promotional expenditures directly related to Landlord’s efforts to lease space in the Building or the Project; expenses of initial development and construction, including grading, paving, landscaping and decorating (as distinguished from maintenance, repair and replacement of the foregoing); costs of constructing new buildings within the Project; legal expenses relating to other tenants; legal and accounting fees not incurred in connection with operation and management of the Building (including any legal and other costs incurred in connection with the sale, financing, refinancing, syndication, securitization, or change of ownership of the Building, including, without limitation, brokerage commissions, attorneys’ and accountants’ fees, closing costs, title insurance premiums, points, and interest charges); costs of repairs to the extent reimbursed by payment of insurance proceeds received by Landlord or which are covered by warranties or guarantees or reimbursed pursuant to service contracts; costs incurred directly and solely as a result of Landlord's gross negligence or willful misconduct; principal and interest upon loans to Landlord or secured by a loan agreement, mortgage, deed of trust, security instrument or other loan document covering the Project or a portion thereof (collectively, “Loan Documents”) (provided that interest upon a government assessment or improvement bond payable in installments shall constitute an Operating Expense under Subsection 9.1(a)); salaries of executive officers of Landlord, or of Landlord’s personnel who are not involved in the day-today operation and maintenance of the Building or Project; depreciation claimed by Landlord for tax purposes (provided that this exclusion of depreciation is not intended to delete from Operating Expenses actual costs of repairs and replacements and reasonable reserves in regard thereto that are provided for in Subsection 9.1(b)); taxes that are excluded from Operating Expenses by the last sentence of Subsection 9.1(a); costs or expenses incurred in connection with the financing or sale of the Project or any portion thereof; political or charitable contributions; costs expressly excluded from Operating Expenses elsewhere in this Lease or that are charged to or paid by Tenant under other provisions of this Lease; professional fees and disbursements and other costs and expenses related to the ownership (as opposed to the use, occupancy, operation, maintenance or repair) of the Project; and any item that, if included in Operating Expenses, would involve a double collection for such item by Landlord. To the extent that Tenant uses more than Tenant’s Pro Rata Share of any item of Operating Expenses, Tenant shall pay Landlord for such excess in addition to Tenant’s obligation to pay Tenant’s Pro Rata Share of Operating Expenses (such excess, together with Tenant’s Pro Rata Share, “Tenant’s Adjusted Share”).

9.2 Commencing on the Term Commencement Date, Tenant shall pay to Landlord on the and first day of each calendar month of the Term, as Additional Rent, (a) the Property Management Fee (as defined below) and (b) Landlord’s estimate of Tenant’s Adjusted Share of Operating Expenses with respect to the Building and the Project, as applicable, for such month.

12


(w) The “Property Management Fee” shall equal three percent (3%) of Base Rent due from Tenant. Tenant shall pay the Property Management Fee in accordance with Section 9.2 with respect to the entire Term, including any extensions of the Term, or any holdover periods, regardless of whether Tenant is obligated to pay Base Rent, Operating Expenses or any other Rent with respect to any such period or portion thereof. During the period of time between the Term Commencement Date and the Rent Commencement Date, the Property Management Fee shall be calculated as if Tenant were paying Base Rent in the amount of $501,338.75 per month.

(x) Within ninety (90) days after the conclusion of each calendar year (or such longer period as may be reasonably required by Landlord not to exceed one hundred and twenty (120) days), Landlord shall furnish to Tenant a statement showing in reasonable detail the actual Operating Expenses, Tenant’s Adjusted Share of Operating Expenses, and the cost of providing utilities to the Premises for the previous calendar year (“Landlord’s Statement”). Any additional sum due from Tenant to Landlord shall be due and payable within thirty (30) days after receipt of an invoice therefor. If the amounts paid by Tenant pursuant to this Section exceed Tenant’s Adjusted Share of Operating Expenses for the previous calendar year, then Landlord shall credit the difference against the Rent next due and owing from Tenant; provided that, if the Lease term has expired, Landlord shall accompany Landlord’s Statement with payment for the amount of such difference.

(y) Any amount due under this Section for any period that is less than a full month shall be prorated for such fractional month on the basis of the number of days in the month.

9.3. Landlord or an affiliate(s) of Landlord may own other property(ies) adjacent to the Project or its neighboring properties (collectively, “Neighboring Properties”). In connection with Landlord performing services for the Project pursuant to this Lease, similar services may be performed by the same vendor(s) for Neighboring Properties. In such a case, Landlord shall reasonably allocate to each Building and the Project the costs for such services based upon the ratio that the square footage of the Building or the Project (as applicable) bears to the total square footage of all of the Neighboring Properties or buildings within the Neighboring Properties for which the services are performed, unless the scope of the services performed for any building or property (including the Building and the Project) is disproportionately more or less than for others, in which case Landlord shall equitably allocate the costs based on the scope of the services being performed for each building or property (including the Building and the Project). Since the Project consists of multiple buildings, certain Operating Expenses may pertain to a particular building(s) and other Operating Expenses to the Project as a whole. Landlord shall properly allocate any such costs applicable to any particular building within the Project to such building, and other such costs applicable to the Project to each building in the Project (including the Building), with the tenants in each building being responsible for paying their respective proportionate shares of their buildings to the extent required under their leases. Landlord shall allocate such costs to the buildings (including the Building) in a reasonable, non-discriminatory manner, and such allocation shall be binding on Tenant.

9.4. Landlord’s annual statement shall be final and binding upon Tenant unless Tenant, within sixty (60) days after Tenant’s receipt thereof, shall contest any item therein by giving written notice to Landlord, specifying each item contested and the reasons therefor; provided that Tenant shall in all events pay the amount specified in Landlord’s annual statement, pending the

13


results of the Independent Review and determination of the Accountant(s), as applicable and as each such term is defined below. If, during such sixty (60)-day period, Tenant reasonably and in good faith questions or contests the correctness of Landlord’s statement of Tenant’s Adjusted Share of Operating Expenses, Landlord shall provide Tenant with reasonable access to Landlord’s books and records to the extent relevant to determination of Operating Expenses, and such information as Landlord reasonably determines to be responsive to Tenant’s written inquiries. In the event that, after Tenant’s review of such information, Landlord and Tenant cannot agree upon the amount of Tenant’s Adjusted Share of Operating Expenses, then Tenant shall have the right to have an independent public accounting firm hired by Tenant on an hourly basis and not on a contingent-fee basis (at Tenant’s sole cost and expense) and approved by Landlord (which approval Landlord shall not unreasonably withhold or delay) audit and review such of Landlord’s books and records for the year in question as directly relate to the determination of Operating Expenses for such year (the “Independent Review”), but not books and records of entities other than Landlord. Landlord shall make such books and records available at the location where Landlord maintains them in the ordinary course of its business, or electronically. Landlord need not provide copies of any books or records. Tenant shall commence the Independent Review within fifteen (15) days after the date Landlord has given Tenant access to Landlord’s books and records for the Independent Review. Tenant shall complete the Independent Review and notify Landlord in writing of Tenant’s specific objections to Landlord’s calculation of Operating Expenses (including Tenant’s accounting firm’s written statement of the basis, nature and amount of each proposed adjustment) no later than sixty (60) days after Landlord has first given Tenant access to Landlord’s books and records for the Independent Review. Landlord shall review the results of any such Independent Review. The parties shall endeavor to agree promptly and reasonably upon Operating Expenses taking into account the results of such Independent Review. If, as of the date that is sixty (60) days after Tenant has submitted the Independent Review to Landlord, the parties have not agreed on the appropriate adjustments to Operating Expenses, then the parties shall engage a mutually agreeable independent third party accountant with at least ten (10) years’ experience in commercial real estate accounting in the Boston area (the “Accountant”). If the parties cannot agree on the Accountant, each shall within ten (10) days after such impasse appoint an Accountant (different from the accountant and accounting firm that conducted the Independent Review) and, within ten (10) days after the appointment of both such Accountants, those two Accountants shall select a third (which cannot be the accountant and accounting firm that conducted the Independent Review). If either party fails to timely appoint an Accountant, then the Accountant the other party appoints shall be the sole Accountant. Within ten (10) days after appointment of the Accountant(s), Landlord and Tenant shall each simultaneously give the Accountants (with a copy to the other party) its determination of Operating Expenses, with such supporting data or information as each submitting party determines appropriate. Within ten (10) days after such submissions, the Accountants shall by majority vote select either Landlord’s or Tenant’s determination of Operating Expenses. The Accountants may not select or designate any other determination of Operating Expenses. The determination of the Accountant(s) shall bind the parties. If the parties agree or the Accountant(s) determine that the Operating Expenses actually paid by Tenant for the calendar year in question exceeded Tenant’s obligations for such calendar year, then Landlord shall, at Tenant’s option, either (a) credit the excess to the next succeeding installments of estimated Additional Rent or (b) pay the excess to Tenant within thirty (30) days after delivery of such results. If the parties agree or the Accountant(s) determine that Tenant’s payments of Operating Expenses for such calendar year were less than Tenant’s obligation for the

14


calendar year, then Tenant shall pay the deficiency to Landlord within thirty (30) days after delivery of such results. If the Independent Review reveals or the Accountant(s) determine that the Operating Expenses billed to Tenant by Landlord and paid by Tenant to Landlord for the applicable calendar year in question exceeded by more than five percent (5%) what Tenant should have been billed during such calendar year, then Landlord shall pay the reasonable cost of the Independent Review. In all other cases Tenant shall pay the cost of the Independent Review and the Accountant(s).

9.5. Tenant shall not be responsible for Operating Expenses with respect to any time period prior to the Term Commencement Date; provided, however, that if Landlord permits Tenant to occupy the Premises for the conduct of its business prior to the Term Commencement Date, Tenant shall be responsible for Operating Expenses from such earlier date of possession (the Term Commencement Date or such earlier date, as applicable, the “Expense Trigger Date”); and provided, further, that Landlord may annualize certain Operating Expenses incurred prior to the Expense Trigger Date over the course of the budgeted year during which the Expense Trigger Date occurs, and Tenant shall be responsible for the annualized portion of such Operating Expenses corresponding to the number of days during such year, commencing with the Expense Trigger Date, for which Tenant is otherwise liable for Operating Expenses pursuant to this Lease. Tenant’s responsibility for Tenant’s Adjusted Share of Operating Expenses shall continue to the latest of (a) the date of termination of the Lease, (b) the date Tenant has fully vacated the Premises and (c) if termination of the Lease is due to a default by Tenant, the date of rental commencement of a replacement tenant.

9.6. Operating Expenses for the calendar year in which Tenant’s obligation to share therein commences and for the calendar year in which such obligation ceases shall be prorated on a basis reasonably determined by Landlord. Expenses such as taxes, assessments and insurance premiums that are incurred for an extended time period shall be prorated based upon the time periods to which they apply so that the amounts attributed to the Premises relate in a reasonable manner to the time period wherein Tenant has an obligation to share in Operating Expenses.

9.7. Within thirty (30) days after the end of each calendar month, Tenant shall submit to Landlord an invoice, or, in the event an invoice is not available, an itemized list, of all costs and expenses that (a) Tenant has incurred (either internally or by employing third parties) during the prior month and (b) for which Tenant reasonably believes it is entitled to reimbursements from Landlord pursuant to the terms of this Lease. Notwithstanding the foregoing, Tenant shall not be obligated to submit any such list to Landlord if Tenant has not incurred any costs or expenses as set forth in (a) or (b) above.

9.8. In the event that the Building or Project is less than fully occupied during a calendar year, Tenant acknowledges that Landlord may extrapolate Operating Expenses that vary depending on the occupancy of the Building or Project, as applicable, to equal Landlord’s reasonable estimate of what such Operating Expenses would have been had the Building or Project, as applicable, been ninety-five percent (95%) occupied during such calendar year; provided, however, that Landlord shall not recover more than one hundred percent (100%) of Operating Expenses.

10. Taxes on Tenant’s Property.

15


10.1. Tenant shall be solely responsible for the payment of any and all taxes levied upon (a) personal property and trade fixtures located at the Premises and (b) any gross or net receipts of or sales by Tenant, and shall pay the same prior to delinquency.

10.2. If any such taxes on Tenant’s personal property or trade fixtures are levied against Landlord or Landlord’s property or, if the assessed valuation of the Building, the Property or the Project is increased by inclusion therein of a value attributable to Tenant’s personal property or trade fixtures, and if Landlord, after written notice to Tenant, pays the taxes based upon any such increase in the assessed value of the Building, the Property or the Project, then Tenant shall, promptly upon receipt of an invoice therefor from Landlord, repay to Landlord the taxes so paid by Landlord.

10.3. If any improvements in or alterations to the Premises, whether owned by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, are assessed for real property tax purposes at a valuation higher than the valuation at which improvements conforming to Landlord’s building standards (the “Building Standard”) in other spaces in the Building are assessed, then the real property taxes and assessments levied against Landlord or the Building, the Property or the Project by reason of such excess assessed valuation shall be deemed to be taxes levied against personal property of Tenant and shall be governed by the provisions of Section 10.2. Any such excess assessed valuation due to improvements in or alterations to space in the Project leased by other tenants at the Project shall not be included in Operating Expenses. If the records of the applicable governmental assessor’s office are available and sufficiently detailed to serve as a basis for determining whether such Tenant improvements or alterations are assessed at a higher valuation than the Building Standard, then such records shall be binding on both Landlord and Tenant.

11. Security Deposit.

11.1. Tenant shall deposit with Landlord on or before the Execution Date the sum set forth in Section 2.6 (the “Security Deposit”), which sum shall be held by Landlord as security for the faithful performance by Tenant of all of the terms, covenants and conditions of this Lease to be kept and performed by Tenant. If Tenant Defaults (as defined below) with respect to any provision of this Lease, including any provision relating to the payment of Rent, then Landlord may (but shall not be required to) use, apply or retain all or any part of the Security Deposit for the payment of any Rent or any other sum in default, or to compensate Landlord for any other loss or damage that Landlord may suffer by reason of Tenant’s default. If any portion of the Security Deposit is so used or applied, then Tenant shall, within ten (10) days following demand therefor, deposit cash with Landlord in an amount sufficient to restore the Security Deposit to its original amount, and Tenant’s failure to do so shall be a material breach of this Lease. The provisions of this Article shall survive the expiration or earlier termination of this Lease.

11.2. In the event of bankruptcy or other debtor-creditor proceedings against Tenant, the Security Deposit shall be deemed to be applied first to the payment of Rent and other charges due Landlord for all periods prior to the filing of such proceedings.

16


11.3. Landlord may deliver to any purchaser of Landlord’s interest in the Premises the funds deposited hereunder by Tenant, and thereupon Landlord shall be discharged from any further liability with respect to such deposit. This provision shall also apply to any subsequent transfers.

11.4. If Tenant shall fully and faithfully perform every provision of this Lease to be performed by it, then the Security Deposit, or any balance thereof, shall be returned to Tenant (or, at Landlord’s option, to the last assignee of Tenant’s interest hereunder) within sixty (60) days after the expiration or earlier termination of this Lease.

11.5. If the Security Deposit shall be in cash, Landlord shall hold the Security Deposit in an account at a banking organization selected by Landlord; provided, however, that Landlord shall not be required to maintain a separate account for the Security Deposit, but may intermingle it with other funds of Landlord. Landlord shall be entitled to all interest and/or dividends, if any, accruing on the Security Deposit. Landlord shall not be required to credit Tenant with any interest for any period during which Landlord does not receive interest on the Security Deposit.

11.6. The Security Deposit may be in the form of cash, a letter of credit or any other security instrument acceptable to Landlord in its sole discretion. Tenant may at any time, except when Tenant is in Default (as defined below), deliver a letter of credit (the “L/C Security”) as the entire Security Deposit, as follows:

(a) If Tenant elects to deliver L/C Security, then Tenant shall provide Landlord, and maintain in full force and effect throughout the Term and until the date that is ninety (90) days after the then-current Term Expiration Date, a letter of credit in the form of Exhibit E issued by an issuer reasonably satisfactory to Landlord, in the amount of the Security Deposit, with an initial term of at least one year. Landlord may require the L/C Security to be re-issued by a different issuer at any time during the Term if Landlord reasonably believes that the issuing bank of the L/C Security is or may soon become insolvent; provided, however, Landlord shall return the existing L/C Security to the existing issuer immediately upon receipt of the substitute L/C Security. If any issuer of the L/C Security shall become insolvent or placed into FDIC receivership, then Tenant shall immediately deliver to Landlord (without the requirement of notice from Landlord) substitute L/C Security issued by an issuer reasonably satisfactory to Landlord, and otherwise conforming to the requirements set forth in this Article. As used herein with respect to the issuer of the L/C Security, “insolvent” means the determination of insolvency as made by such issuer’s primary bank regulator (i.e., the state bank supervisor for state chartered banks; the OCC or OTS, respectively, for federally chartered banks or thrifts; or the Federal Reserve for its member banks). If, at the Term Expiration Date, any Rent remains uncalculated or unpaid, then (i) Landlord shall with reasonable diligence complete any necessary calculations, (ii) Tenant shall extend the expiry date of such L/C Security from time to time as Landlord reasonably requires and (iii) in such extended period, Landlord shall not unreasonably refuse to consent to an appropriate reduction of the L/C Security. Tenant shall reimburse Landlord’s legal costs (as estimated by Landlord’s counsel) in handling Landlord’s acceptance of L/C Security or its replacement or extension.

(b) If Tenant delivers to Landlord satisfactory L/C Security in place of the entire Security Deposit, Landlord shall remit to Tenant any cash Security Deposit Landlord previously held.

17


(c) Landlord may draw upon the L/C Security, and hold and apply the proceeds in the same manner and for the same purposes as the Security Deposit, if (i) an uncured Default (as defined below) exists, (ii) as of the date that is thirty (30) days before any L/C Security expires (even if such scheduled expiry date is after the Term Expiration Date) Tenant has not delivered to Landlord an amendment or replacement for such L/C Security, reasonably satisfactory to Landlord, extending the expiry date to the earlier of (1) ninety (90) days after the then-current Term Expiration Date or (2) the date that is one year after the then-current expiry date of the L/C Security, (iii) the L/C Security provides for automatic renewals, Landlord asks the issuer to confirm the current L/C Security expiry date, and the issuer fails to do so within ten (10) business days, (iv) Tenant fails to pay (when and as Landlord reasonably requires) any bank charges for Landlord’s transfer of the L/C Security or (v) the issuer of the L/C Security ceases, or announces that it will cease, to maintain an office in the city where Landlord may present drafts under the L/C Security (and fails to permit drawing upon the L/C Security by overnight courier or facsimile). This Section does not limit any other provisions of this Lease allowing Landlord to draw the L/C Security under specified circumstances.

(d) Tenant shall not seek to enjoin, prevent, or otherwise interfere with Landlord’s draw under L/C Security, even if it violates this Lease. Tenant acknowledges that the only effect of a wrongful draw would be to substitute a cash Security Deposit for L/C Security, causing Tenant no legally recognizable damage. Landlord shall hold the proceeds of any draw in the same manner and for the same purposes as a cash Security Deposit. In the event of a wrongful draw, (a) the parties shall cooperate to allow Tenant to post replacement L/C Security simultaneously with the return to Tenant of the wrongfully drawn sums, (b) Landlord shall upon request confirm in writing to the issuer of the L/C Security that Landlord’s draw was erroneous, and (c) if Tenant receives a final determination from a court of competent jurisdiction that is not subject to appeal that Landlord has made a “wrongful” draw, (i) Landlord shall pay Tenant interest upon the amount of such wrongful draw at the rate of six percent (6%) and (ii) Tenant shall be entitled to recover its reasonable attorney’s fees in accordance with Section 40.7. For purposes of the immediately foregoing sentence, the term “wrongful” shall mean that Landlord had no reasonable basis to believe that it had the right to make the draw.

(e) If Landlord transfers its interest in the Premises, then Tenant shall at Tenant’s expense, within five (5) business days after receiving a request from Landlord, deliver (and, if the issuer requires, Landlord shall consent to) an amendment to the L/C Security naming Landlord’s grantee as substitute beneficiary. If the required Security Deposit changes while L/C Security is in force, then Tenant shall deliver (and, if the issuer requires, Landlord shall consent to) a corresponding amendment to the L/C Security.

11.7 If Tenant, as of the fourth (4th) and/or eighth (8th) anniversary of the Rent Commencement Date (each such anniversary, an “L/C Security Reduction Date”) has not been in Default under this Lease during the twelve (12) month period immediately preceding the applicable L/C Security Reduction Date, then Tenant, no later than forty-five (45) days after the applicable L/C Security Reduction Date, may notify Landlord in writing that Tenant desires to reduce the amount of the Security Deposit (an “L/C Security Reduction Notice”). If Tenant timely and properly delivers to Landlord an L/C Security Reduction Notice in accordance with the foregoing grammatical sentence, then the Security Deposit shall be reduced to Three Million Eight Thousand Thirty-Two and 50/100 Dollars ($3,008,032.50), and if Tenant has already completed

18


the first such reduction when the second L/C/ Reduction Date occurs, the Security Deposit shall be reduced to Two Million Five Thousand Three Hundred Fifty-Five and 00/100 Dollars ($2,005,355.00) (each such amount, the “L/C Security Reduction Amount”, as applicable). If Landlord is then holding a cash Security Deposit, then Landlord shall return to Tenant cash in an amount equal to the L/C Security Reduction Amount within thirty (30) days of Landlord’s receipt of the applicable L/C Security Reduction Notice. If the Security Deposit is in the form of the L/C Security, Tenant may provide to Landlord a replacement L/C Security in the amount of the reduced Security Deposit (or amendment to the L/C Security reflecting such reduction). Provided such replacement L/C Security (or amendment to the L/C Security) complies with the terms and provisions of this Article 11, Landlord shall, within thirty (30) days after its receipt of such replacement L/C Security, return to Tenant the L/C Security then being held by Landlord (or take any necessary steps required in connection with the amendment to the L/C Security).

 

12. Use.

12.1. Tenant shall use the Premises for the Permitted Use, and shall not use the Premises, or permit or suffer the Premises to be used, for any other purpose without Landlord’s prior written consent, which consent Landlord may withhold in its sole and absolute discretion. Tenant shall be prohibited from using the Premises or any portion of the Property for the sale, distribution or production of marijuana.

12.2. Tenant shall not use or occupy the Premises in violation of Applicable Laws; zoning ordinances; or the certificate of occupancy (or its substantial equivalent) issued for the Building or the Project, and shall, upon five (5) days’ written notice from Landlord, discontinue any use of the Premises that is declared or claimed by any Governmental Authority having jurisdiction to be a violation of any of the above, or that in Landlord’s reasonable opinion violates any of the above. Tenant shall take such further actions and execute such further documents in connection with this Lease as are necessary to comply with Applicable Laws relating to privacy, personal information and data security. Tenant acknowledges that Landlord may collect certain personal information (e.g., names, email addresses and contact information) of Tenant’s and its affiliates’ employees (and, if applicable, subcontractors and consultants), and use such information in connection with performing Landlord’s duties and obligations, and exercising its rights under this Lease. Tenant shall not retain, use or disclose any personal information received from Landlord pursuant to this Lease for any purpose other than to perform its duties and obligations, and exercise its rights under this Lease or as required by Applicable Law. In the event of a conflict between this Section and Article 38, this Section shall govern. Tenant shall comply with any direction of any Governmental Authority having jurisdiction that shall, by reason of the nature of Tenant’s use or occupancy of the Premises, impose any duty upon Tenant or Landlord with respect to the Premises or with respect to the use or occupation thereof, and shall indemnify, defend (at the option of and with counsel reasonably acceptable to the indemnified party(ies)), save, reimburse and hold harmless (collectively, “Indemnify,” “Indemnity” or “Indemnification,” as the case may require) Landlord and its affiliates, employees, agents and contractors; and any lender, mortgagee, ground lessor or beneficiary (each, a “Lender” and, collectively with Landlord and its affiliates, employees, agents and contractors, the “Landlord Indemnitees”) harmless from and against any and all demands, claims, liabilities, losses, costs, expenses, actions, causes of action,

19


damages, suits or judgments, and all reasonable expenses (including reasonable attorneys’ fees, charges and disbursements, regardless of whether the applicable demand, claim, action, cause of action or suit is voluntarily withdrawn or dismissed) incurred in investigating or resisting the same (collectively, “Claims”) of any kind or nature that arise before, during or after the Term as a result of Tenant’s breach of this Section.

12.3. Tenant shall not do or permit to be done anything that will invalidate or increase the cost of any fire, environmental, extended coverage or any other insurance policy covering the Building or the Project, and shall comply with all rules, orders, regulations and requirements of the insurers of the Building and the Project, and Tenant shall promptly, upon demand, reimburse Landlord for any additional premium charged for such policy by reason of Tenant’s failure to comply with the provisions of this Article.

12.4. Tenant shall keep all doors opening onto public corridors closed, except when in use for ingress and egress.

12.5. No additional locks or bolts of any kind shall be placed upon any of the doors or windows by Tenant, nor shall any changes be made to existing locks or the mechanisms thereof without Landlord’s prior written consent, which consent shall not be unreasonably withheld. Tenant shall, upon termination of this Lease, return to Landlord all keys to offices and restrooms either furnished to or otherwise procured by Tenant. In the event any key so furnished to Tenant is lost, Tenant shall pay to Landlord the cost of replacing the same or of changing the lock or locks opened by such lost key if Landlord shall deem it necessary to make such change.

12.6. No awnings or other projections shall be attached to any outside wall of the Building. No curtains, blinds, shades or screens shall be attached to or hung in, or used in connection with, any window or door of the Premises other than Landlord’s standard window coverings. Neither the interior nor exterior of any windows shall be coated or otherwise sunscreened without Landlord’s prior written consent, nor shall any bottles, parcels or other articles be placed on the windowsills or items attached to windows that are visible from outside the Premises. No equipment, furniture or other items of personal property shall be placed on any exterior balcony or terrace without Landlord’s prior written consent.

12.7. No sign, advertisement or notice (“Signage”) shall be exhibited, painted or affixed by Tenant on any part of the Premises or the Building without Landlord’s prior written consent. Signage shall conform to Landlord’s design criteria established from time to time. For any Signage, Tenant shall, at Tenant’s own cost and expense, (a) acquire all permits for such Signage in compliance with Applicable Laws and (b) design, fabricate, install and maintain such Signage in a first-class condition. Tenant shall be responsible for reimbursing Landlord for costs incurred by Landlord in removing any of Tenant’s Signage upon the expiration or earlier termination of the Lease. Tenant shall have no right to install any exterior Signage. Interior signs on entry doors to the Premises shall be inscribed, painted or affixed for Tenant by Landlord at Tenant’s sole cost and expense, and shall be of a size, color and type and be located in a place acceptable to Landlord. Notwithstanding any of the foregoing to the contrary, Landlord shall install standard Building lobby and directory Signage on behalf of Tenant at Landlord’s sole cost. The directory tablet and lobby Signage shall be provided exclusively for the display of the name and location of tenants only. Tenant shall not place anything on the exterior of the corridor walls or corridor doors other

20


than Landlord’s standard lettering. At Landlord’s option, Landlord may install any Tenant Signage, and Tenant shall pay all costs associated with such installation within thirty (30) days after demand therefor.

12.8. Tenant may only place equipment within the Premises with floor loading consistent with the Building’s structural design unless Tenant obtains Landlord’s prior written approval. Tenant may place such equipment only in a location designed to carry the weight of such equipment.

12.9. Tenant shall cause any equipment or machinery to be installed in the Premises so as to reasonably prevent sounds or vibrations therefrom from extending into the Common Area or other leased premises in the Project.

12.10. Tenant shall not (a) do or permit anything to be done in or about the Premises that shall in any way obstruct or interfere with the rights of other tenants or occupants of the Project, or injure or annoy them, (b) use or allow the Premises to be used for immoral, unlawful or objectionable purposes, (c) cause, maintain or permit any nuisance or waste in, on or about the Project or (d) take any other action that would in Landlord’s reasonable determination in any manner adversely affect other tenants’ quiet use and enjoyment of their space or adversely impact their ability to conduct business in a professional and suitable work environment. Notwithstanding any other provision herein to the contrary, Tenant shall be responsible for all liabilities, costs and expenses arising from or in connection with the compliance of the Premises with the Americans with Disabilities Act, 42 U.S.C. § 12101, et seq., and any state and local accessibility laws, codes, ordinances and rules (collectively, and together with regulations promulgated pursuant thereto, the “ADA”), and Tenant shall Indemnify the Landlord Indemnitees from and against any Claims arising from any such failure of the Premises to comply with the ADA. This Section (as well as any other provisions of this Lease dealing with Indemnification of the Landlord Indemnitees by Tenant) shall be deemed to be modified in each case by the insertion in the appropriate place of the following: “except as otherwise provided in Mass. G.L. Ter. Ed., C. 186, Section 15.” For the avoidance of doubt, “Lenders” shall also include historic tax credit investors and new market tax credit investors. Landlord represents and warrants that to the actual knowledge of Landlord without any duty of investigation the Common Areas shall be in compliance with the ADA as of the Term Commencement Date. The provisions of this Section shall survive the expiration or earlier termination of this Lease.

12.11. Tenant shall establish and maintain a chemical safety program administered by a licensed, qualified individual in accordance with the requirements of the Massachusetts Water Resources Authority (“MWRA”) and any other applicable Governmental Authority. Tenant shall be solely responsible for all costs incurred in connection with such chemical safety program, and Tenant shall provide Landlord with such documentation as Landlord may reasonably require evidencing Tenant’s compliance with the requirements of (a) the MWRA and any other applicable Governmental Authority with respect to such chemical safety program and (b) this Section. Notwithstanding the foregoing, Landlord shall obtain and maintain during the Term (m) any permit required by the MWRA (“MWRA Permit”) and (n) a wastewater treatment operator license from the Commonwealth of Massachusetts with respect to Tenant’s use of the Acid Neutralization Tank (as defined below) in the Building. Tenant shall not introduce anything into the Acid Neutralization Tank (x) in violation of the terms of the MWRA Permit, (y) in violation of

21


Applicable Laws or (z) that would interfere with the proper functioning of the Acid Neutralization Tank. Tenant agrees to reasonably cooperate with Landlord in order to obtain the MWRA Permit and the wastewater treatment operator license. Tenant shall reimburse Landlord within ten (10) business days after demand for any costs incurred by Landlord pursuant to this Section.

13. Rules and Regulations, CC&Rs, Parking Facilities and Common Area.

13.1. Tenant shall have the non-exclusive right, in common with others, to use the Common Area in conjunction with Tenant’s use of the Premises for the Permitted Use, and such use of the Common Area and Tenant’s use of the Premises shall be subject to the rules and regulations adopted by Landlord and attached hereto as Exhibit F, together with such other reasonable and nondiscriminatory rules and regulations as are hereafter promulgated by Landlord in its sole and absolute discretion (the “Rules and Regulations”). Tenant shall and shall ensure that its contractors, subcontractors, employees, subtenants and invitees faithfully observe and comply with the Rules and Regulations. Landlord shall not be responsible to Tenant for the violation or non-performance by any other tenant or any agent, employee or invitee thereof of any of the Rules and Regulations.

13.2. This Lease is subject to any recorded covenants, conditions or restrictions on the Project or Property including the TAPA (defined below), as the same may be amended, amended and restated, supplemented or otherwise modified from time to time (the “CC&Rs”). Tenant shall, at its sole cost and expense, comply with the CC&Rs.

13.3. Notwithstanding anything in this Lease to the contrary, Tenant may not install any security systems (including cameras) outside the Premises or that record sounds or images outside the Premises without Landlord’s prior written consent, which Landlord may withhold in its sole and absolute discretion.

13.4. Tenant acknowledges that, pursuant to that certain Transportation Access Plan Agreement dated as of October 12, 2017 (as the same may be amended or superseded, the “TAPA”), a copy of which is attached hereto as Exhibit G, Tenant shall at its sole cost take measures to promote public transportation and subsidize employee use of public transit including providing fifty percent (50%) MBTA pass subsidies for full-time and part-time employees. Tenant, at its sole cost and expense, shall also comply ith the reporting requirements set forth in the TAPA at Landlord’s request. Any costs incurred by Landlord in connection with the TAPA shall constitute an Operating Expense.

13.5. Tenant shall have a non-exclusive, irrevocable license to use thirty-two (32) parking spaces at the parking facilities serving the Building in common on an unreserved basis with other tenants of the Project during the Term at an initial cost of Four Hundred Dollars ($400.00) per parking space per month (which rate shall be subject to periodic market adjustments), which Tenant shall pay on the first day of each calendar month of the Term, as Additional Rent, commencing on the Term Commencement Date. Tenant shall have access to the parking facilities on a 24/7/365 basis.

13.6. Tenant agrees not to use the parking facilities in violation of any rules and regulations reasonably promulgated by Landlord and agrees to cooperate with Landlord and other

22


tenants in the use of the parking facilities. Landlord may reasonably allocate parking spaces among Tenant and other tenants of the Building or the Project; provided that Tenant shall be entitled to the number of spaces set forth in Section 13.5 above. Nothing in this Section, however, is intended to create an affirmative duty on Landlord’s part to monitor parking.

13.7. Subject to the terms of this Lease including the Rules and Regulations and the rights of other tenants of the Project, Tenant shall have the non-exclusive right to access the freight loading dock during dock operating hours as set by Landlord at no additional cost, or those times arranged in advance with building management at Tenant’s cost. In addition, subject to the terms of this Lease including the Rules and Regulations and the rights of other tenants in the Project, Tenant shall have the non-exclusive right to access the freight elevator 24/7 for moving freight or other items restricted from being moved in a passenger elevator, subject to the issuance of access passes by Landlord to qualified individuals, at no additional cost.

14. Project Control by Landlord.

14.1. Landlord reserves full control over the Building and the Project to the extent not inconsistent with Tenant’s enjoyment of the Premises as provided by and consistent with the other terms in this Lease. This reservation includes Landlord’s right to subdivide the Project; convert the Building and the other buildings within the Project to condominium units; change the size of the Project by selling all or a portion of the Project or adding real property and any improvements thereon to the Project; grant easements and licenses to third parties; maintain or establish ownership of the Building separate from fee title to the Property; make additions to or reconstruct portions of the Building and the Project; install, use, maintain, repair, replace and relocate for service to the Premises and other parts of the Building or the Project (including to other tenant premises) pipes, ducts, conduits, wires and appurtenant fixtures, wherever located in the Premises, the Building or elsewhere at the Project or delegate such rights to other tenants performing work in their respective premises; and alter or relocate any other Common Area or facility, including private drives, lobbies, elevators, loading areas, entrances and landscaping; provided, however, that such rights shall be exercised in a way that does not materially adversely affect Tenant’s beneficial use and occupancy of the Premises, including the Permitted Use and Tenant’s access to the Premises. Tenant acknowledges that Landlord specifically reserves the right to allow the exclusive use of corridors and restroom facilities located on specific floors to one or more tenants occupying such floors; provided, however, that Tenant shall not be deprived of the use of the corridors reasonably required to serve the Premises or of restroom facilities serving the floor upon which the Premises are located. Tenant acknowledges that the Building is under development, that there may be construction in the Common Areas and other tenant premises in the Building from time to time during the Term, and that Landlord shall not be liable for any rent abatement or compensation by reason of inconvenience, annoyance, or loss of business resulting from such construction. Further, Tenant shall be responsible for taking any precautions Tenant deems necessary with respect to its business operations in the Premises to mitigate construction impactssuch as sound and vibration from other parts of the Project. Landlord shall use commercially reasonable efforts in the exercise of its rights under this Section, not to unreasonably interfere with Tenant’s use of the Premises for the Permitted Uses. Landlord shall, in any construction at the Building undertaken by Landlord or its affiliates, exercise all reasonable efforts and work cooperatively with Tenant to minimize interference from the noise and dust of such construction.

23


14.2. Possession of areas of the Premises necessary for utilities, services, safety and operation of the Building is reserved to Landlord; provided, however, that such possession shall not materially adversely affect Tenant’s beneficial use and occupancy of the Premises, including the Permitted Use and Tenant’s access to the Premises.

14.3. Tenant shall, at Landlord’s request, promptly execute such further documents as may be reasonably appropriate to assist Landlord in the performance of its obligations hereunder; provided that Tenant need not execute any document that creates additional liability for Tenant or that deprives Tenant of the quiet enjoyment and use of the Premises as provided for in this Lease.

14.4. Landlord may, at any and all reasonable times during business hours (or during non-business hours, if (a) with respect to Subsections 14.4(u) through 14.4(y), Tenant so requests, and (b) with respect to Subsection 14.4(z), if Landlord so requests), and upon twenty-four (24) hours’ prior notice (which may be oral or by email to the office manager or other Tenant-designated individual at the Premises; but provided that no time restrictions shall apply or advance notice be required if an emergency necessitates immediate entry), enter the Premises to (u) inspect the same and to determine whether Tenant is in compliance with its obligations hereunder, (v) supply any service Landlord is required to provide hereunder, (w) alter, improve or repair any portion of the Building other than the Premises for which access to the Premises is reasonably necessary, (x) post notices of nonresponsibility, (y) access the telephone equipment, electrical substation and fire risers and (z) show the Premises to prospective tenants during the final year of the Term and current and prospective purchasers and lenders at any time. Notwithstanding the foregoing, Tenant shall have the right to have a representative of Tenant accompany Landlord at such times; provided, however, if Tenant’s representative is not available or does not elect to accompany Landlord at the times that Landlord has requested access, then such unavailability shall not prohibit or otherwise restrict Landlord’s access, and Landlord may access the Premises with or without Tenant’s representative present. Tenant may identify certain areas of the Premises that require limited access by written notice to Landlord (“Secure Areas”), and, except in the event of an emergency, Landlord shall access such Secure Areas with a Tenant representative present and shall endeavor to comply with Tenant’s reasonable security, cleanliness and safety requirements when accessing such Secure Areas. In connection with any such alteration, improvement or repair as described in Subsection 14.4(w), Landlord may erect in the Premises or elsewhere in the Project scaffolding and other structures reasonably required for the alteration, improvement or repair work to be performed. In no event shall Tenant’s Rent abate as a result of Landlord’s activities pursuant to this Section; provided, however, that all such activities shall be conducted in such a manner so as to cause as little interference to Tenant as is reasonably possible. Landlord shall at all times retain a key with which to unlock all of the doors in the Premises. If an emergency necessitates immediate access to the Premises, Landlord may use whatever force is necessary to enter the Premises, and any such entry to the Premises shall not constitute a forcible or unlawful entry to the Premises, a detainer of the Premises, or an eviction of Tenant from the Premises or any portion thereof.

15. Quiet Enjoyment. Landlord covenants that Tenant, upon paying the Rent and performing its obligations contained in this Lease, may peacefully and quietly have, hold and enjoy the Premises, free from any claim by Landlord or persons claiming under Landlord, but subject to all of the terms and provisions hereof, provisions of Applicable Laws and rights of record to which this Lease is

24


or may become subordinate. This covenant is in lieu of any other quiet enjoyment covenant, either express or implied.

16. Utilities and Services.

16.1 Commencing on the Term Commencement Date, Tenant shall pay for all water (including the cost to service, repair and replace reverse osmosis, de-ionized and other treated water), gas, heat, light, power, telephone, internet service, cable television, other telecommunications and other utilities supplied to the Premises, together with any fees, surcharges and taxes thereon. If any such utility is not separately metered to Tenant, Tenant shall pay Tenant’s Adjusted Share of all charges of such utility jointly metered with other premises as Additional Rent or, in the alternative, Landlord may, at its option, monitor the usage of such utilities by Tenant and charge Tenant with the cost of purchasing, installing and monitoring such metering equipment, which cost shall be paid by Tenant as Additional Rent.

16.2 Landlord may base its bills for utilities on reasonable estimates; provided that Landlord adjusts such billings as part of the next Landlord’s Statement (not more frequently than on a monthly basis) to reflect the actual cost of providing utilities to the Premises. To the extent that Tenant uses more than Tenant’s Pro Rata Share of any utilities, then Tenant shall pay Landlord for Tenant’s Adjusted Share of such utilities to reflect such excess. In the event that the Building or Project is less than fully occupied during a calendar year, Tenant acknowledges that Landlord may extrapolate utility usage that varies depending on the occupancy of the Building or Project (as applicable) to equal Landlord’s reasonable estimate of what such utility usage would have been had the Building or Project, as applicable, been ninety-five percent (95%) occupied during such calendar year; provided, however, that Landlord shall not recover more than one hundred percent (100%) of the cost of such utilities. Notwithstanding anything to the contrary contained herein, Tenant shall not be liable for the cost of utilities supplied to the Premises attributable to the time period prior to the Term Commencement Date.

16.3 Landlord shall not be liable for, nor shall any eviction of Tenant result from, the failure to furnish any utility or service, whether or not such failure is caused by Force Majeure (as defined below) or, to the extent permitted by Applicable Laws, Landlord’s negligence. In the event of such failure, Tenant shall not be entitled to termination of this Lease or any abatement or reduction of Rent, nor shall Tenant be relieved from the operation of any covenant or agreement of this Lease. Notwithstanding anything to the contrary in this Lease, if, for more than seven (7) consecutive business days following written notice to Landlord and as a direct result of Landlord’s gross negligence or willful misconduct (and except to the extent that such failure is caused by any other factor, including any action or inaction of a Tenant Party (as defined below)), the provision of HVAC or other utilities to all or a material portion of the Premises that Landlord must provide pursuant to this Lease is interrupted (a “Material Services Failure”), then Base Rent and Tenant’s Adjusted Share of Operating Expenses (or, to the extent that less than all of the Premises are affected, a proportionate amount (based on the Rentable Area of the Premises that is rendered unusable) of Base Rent and Tenant’s Adjusted Share of Operating Expenses) shall thereafter be abated until the Premises are again usable by Tenant for the Permitted Use; provided, however, that, if Landlord is diligently pursuing the restoration of such HVAC and other utilities and Landlord provides substitute HVAC and other utilities reasonably suitable for Tenant’s continued use and occupancy of the Premises for the Permitted Use (e.g., supplying potable water or portable

25


air conditioning equipment), then neither Base Rent nor Tenant’s Adjusted Share of Operating Expenses shall be abated. During any Material Services Failure, Tenant will cooperate with Landlord to arrange for the provision of any interrupted utility services on an interim basis via temporary measures until final corrective measures can be accomplished, and Tenant will permit Landlord the necessary access to the Premises to remedy such Material Service Failure. In the event of any interruption of HVAC or other utilities that Landlord must provide pursuant to this Lease, regardless of the cause, Landlord shall diligently pursue the restoration of such HVAC and other utilities. Notwithstanding anything in this Lease to the contrary, but subject to Article 24 (which shall govern in the event of a casualty), the provisions of this Section shall be Tenant’s sole recourse and remedy in the event of an interruption of HVAC or other utilities to the Premises, including related to Section 16.8.

16.4 Tenant shall pay for, prior to delinquency of payment therefor, any utilities and services that may be furnished to the Premises during or, if Tenant occupies the Premises after the expiration or earlier termination of the Term, after the Term, beyond those utilities provided by Landlord, including telephone, internet service, cable television and other telecommunications, together with any fees, surcharges and taxes thereon. Upon Landlord’s demand, utilities and services provided to the Premises that are separately metered shall be paid by Tenant directly to the supplier of such utilities or services.

16.5 Tenant shall not, without Landlord’s prior written consent, use any device in the Premises (including data processing machines) that will in any way (a) increase the amount of ventilation, air exchange, gas, steam, electricity or water required or consumed in the Premises based upon Tenant’s Pro Rata Share of the Building or Project (as applicable) beyond the existing capacity of the Building or the Project usually furnished or supplied for the Permitted Use or (b) exceed Tenant’s Pro Rata Share of the Building’s or Project’s (as applicable) capacity to provide such utilities or services.

16.6. If Tenant shall require utilities or services in excess of those usually furnished or supplied for tenants in similar spaces in the Building or the Project by reason of Tenant’s equipment or extended hours of business operations, then Tenant shall first procure Landlord’s consent for the use thereof, which consent Landlord may condition upon the availability of such excess utilities or services, and Tenant shall pay as Additional Rent an amount equal to the cost of providing such excess utilities and services.

16.7. Landlord shall bring water to the point of connection with the Premises and shall provide hot and cold water in Common Area for lavatory and landscaping purposes only, which water shall be from the local municipal or similar source; provided, however, that if Landlord determines that Tenant requires, uses or consumes water provided to the Common Area for any purpose other than ordinary lavatory purposes, Landlord may install a water meter (“Tenant Water Meter”) and thereby measure Tenant’s water consumption for all purposes. Tenant shall pay Landlord for the costs of any Tenant Water Meter and the installation and maintenance thereof during the Term. If Landlord installs a Tenant Water Meter, Tenant shall pay for water consumed, as shown on such meter, as and when bills are rendered. If Tenant fails to timely make such payments, Landlord may pay such charges and collect the same from Tenant. Any such costs or expenses incurred or payments made by Landlord for any of the reasons or purposes stated in this

26


Section shall be deemed to be Additional Rent payable by Tenant and collectible by Landlord as such.

16.8. Landlord reserves the right, on at least forty-eight (48) hours’ advance notice (which may be orally or by email) to stop service of the elevator, plumbing, ventilation, air conditioning and utility systems, when Landlord deems necessary or desirable, or due to accident or emergency (in which case no notice shall be required), or the need to make repairs, alterations or improvements, until such repairs, alterations or improvements shall have been completed, and Landlord shall further have no responsibility or liability for failure to supply elevator facilities, plumbing, ventilation, air conditioning or utility service when prevented from doing so by Force Majeure (as defined below) or, to the extent permitted by Applicable Laws, Landlord’s negligence. Without limiting the foregoing, it is expressly understood and agreed that any covenants on Landlord’s part to furnish any service pursuant to any of the terms, covenants, conditions, provisions or agreements of this Lease, or to perform any act or thing for the benefit of Tenant, shall not be deemed breached if Landlord is unable to furnish or perform the same by virtue of Force Majeure or, to the extent permitted by Applicable Laws, Landlord’s negligence.

16.9. Landlord will install a back-up generator (the “Generator”) and Tenant shall be responsible for installing its own automatic transfer switch and connecting to the base building distribution gear. Tenant shall be entitled to use up to its proportionate share (after deducting any power from the Generator required for the Common Area) of power from the Generator on a non-exclusive basis with other tenants in the Building. The cost of maintaining, repairing and replacing the Generator shall constitute Operating Expenses. Landlord expressly disclaims any warranties with regard to the Generator or the installation thereof, including any warranty of merchantability or fitness for a particular purpose. Landlord shall maintain the Generator and any base building equipment in good working condition, provided, however, that Tenant shall be solely responsible, at Tenant’s sole cost and expense, (and Landlord shall not be liable) for maintaining and operating Tenant’s automatic transfer switch and the distribution of power from Tenant’s automatic transfer switch throughout the Premises, and provided further that Landlord shall not be liable for any failure to make any repairs or to perform any maintenance of the Generator that is an obligation of Landlord unless and except to the extent that Landlord willfully fails to make such repairs or perform such maintenance and such failure persists for an unreasonable time after Tenant provides Landlord with written notice of the need for such repairs or maintenance. Upon receipt of such written notice, Landlord shall promptly commence to cure such failure and shall diligently prosecute the same to completion in accordance with Section 31.13. The provisions of Section 16.3 shall apply to the Generator.

16.10. For the Premises, Landlord shall (a) maintain and operate the base building HVAC systems (not including supplemental units exclusively serving the Premises) used for the Permitted Use only (“Base HVAC”) and (b) furnish HVAC as reasonably required (except as this Lease otherwise provides or as to any special requirements that arise from Tenant’s particular use of the Premises) for reasonably comfortable occupancy of the Premises twenty-four (24) hours a day, every day during the Term, subject to casualty, eminent domain or as otherwise specified in this Article. Notwithstanding anything to the contrary in this Section, Landlord shall have no liability, and Tenant shall have no right or remedy, on account of any interruption or impairment in HVAC services, except as provided in Section 16.2.

27


16.11. For any utilities serving the Premises for which Tenant is billed directly by such utility provider, Tenant agrees to furnish to Landlord (a) within thirty (30) days after Landlord’s request, any invoices or statements for such utilities and any other utility usage information reasonably requested by Landlord, and (b) within thirty (30) days after each calendar year during the Term, authorization to allow Landlord to access Tenant’s usage information necessary for Landlord to complete an ENERGY STAR® Statement of Performance (or similar comprehensive utility usage report (e.g., related to Labs 21), if requested by Landlord) and any other information reasonably requested by Landlord for the immediately preceding year; and Tenant shall comply with any other energy usage or consumption requirements required by Applicable Laws. Tenant shall retain records of utility usage at the Premises, including invoices and statements from the utility provider, for at least sixty (60) months, or such other period of time as may be requested by Landlord. Tenant acknowledges that any utility information for the Premises, the Building and the Project may be shared with third parties, including Landlord’s consultants and Governmental Authorities. In the event that Tenant fails to comply with this Section, Tenant hereby authorizes Landlord to collect utility usage information directly from the applicable utility providers, and Tenant shall pay Landlord a fee of Five Hundred Dollars ($500.00) per month to collect such utility usage information. In addition to the foregoing, Tenant shall comply with all Applicable Laws related to the disclosure and tracking of energy consumption at the Premises. The provisions of this Section shall survive the expiration or earlier termination of this Lease.

16.12. The Building shall be serviced by a common laboratory waste sanitary sewer connection from the pH neutralization room located in the third floor mechanical room of the Building to the municipal sewer line in the street adjacent to the Building. There shall be a separate acid neutralization tank (the “Acid Neutralization Tank”) that is connected to the Premises, as well as to other premises in the Building. Tenant shall install sampling ports in lab waste plumbing. Tenant shall have a non-exclusive right to use its proportionate share of the Acid Neutralization Tank in accordance with Applicable Laws in common with other tenants of the Building. Tenant, as a portion of its Operating Expenses, shall reimburse Landlord for all costs, charges and expenses incurred by Landlord from time to time in connection with or arising from the operation, use, maintenance, repair or refurbishment of the Acid Neutralization Tank, including all clean-up costs relating to the Acid Neutralization Tank (collectively, “Tank Costs”); provided, however, that if the Acid Neutralization Tank is being used by other tenant(s) or occupant(s) of the Building at any time during the Term, then, during such time period, Tenant shall only be obligated to pay its proportionate share of the Tank Costs. Notwithstanding the foregoing, in the event the Acid Neutralization Tank is damaged or repairs to the Acid Neutralization Tank are required as a result of the improper use of the Acid Neutralization Tank by Tenant, Tenant shall be responsible for one hundred percent (100%) of the cost of any repairs or replacement required as a result of such improper use by Tenant, regardless of whether the Acid Neutralization Tank is then being used by other tenant(s) or occupant(s) of the Building. Similarly, if the Acid Neutralization Tank is damaged, or if repairs to the Acid Neutralization Tank are required as a result of the improper use of the Acid Neutralization Tank by other tenant(s) or occupant(s) of the Building, then Tenant shall have no responsibility for the cost of any repairs or replacements required as a result of such improper use by such other tenant(s) or occupant(s). Tenant shall Indemnify the Landlord Indemnitees from and against any and all Claims, including (a) diminution in value of the Project or any portion thereof, (b) damages for the loss or restriction on use of rentable or usable space or of any amenity of the Project and (c) sums paid in settlement of Claims that arise during or after the Term as a result of Tenant’s improper use of the Acid Neutralization Tank. This

28


Indemnification by Tenant includes costs incurred in connection with any investigation of site conditions or any clean-up, remediation, removal or restoration required by any Governmental Authority arising from Tenant’s improper use of the Acid Neutralization Tank.

17. Alterations.

17.1. Tenant shall make no alterations, additions or improvements (other than the Tenant Improvements, which are governed by the Work Letter) in or to the Premises or engage in any construction, demolition, reconstruction, renovation or other work (whether major or minor) of any kind in, at or serving the Premises (“Alterations”) without Landlord’s prior written approval, which approval Landlord shall not unreasonably withhold; provided, however, that, in the event any proposed Alteration affects (a) any structural portions of the Building, including exterior walls, the roof, the foundation or slab, foundation or slab systems (including barriers and subslab systems) or the core of the Building, (b) the exterior of the Building or (c) any Building systems, including elevator, plumbing, HVAC, electrical, security, life safety and power, then Landlord may withhold its approval in its sole and absolute discretion. Tenant shall, in making any Alterations, use only those architects, contractors, suppliers and mechanics of which Landlord has given prior written approval and Landlord may refuse to approve any architects, consultants, engineers, contractors, subcontractors, or material suppliers that Landlord reasonably believes could cause labor disharmony or may not have sufficient experience, in Landlord’s reasonable opinion, to perform work in an occupied Class “A” laboratory research building and in lab areas. In seeking Landlord’s approval, Tenant shall provide Landlord, at least thirty (30) days in advance of any proposed construction, with plans, specifications, bid proposals, certified stamped engineering drawings and calculations by Tenant’s engineer of record or architect of record (including connections to the Building’s structural system, modifications to the Building’s envelope, non-structural penetrations in slabs or walls, and modifications or tie-ins to life safety systems), work contracts, requests for laydown areas and such other information concerning the nature and cost of the Alterations as Landlord may reasonably request, provided that Tenant shall not commence any such Alterations that require Landlord’s consent unless and until Tenant has received the written approval of Landlord and any and all Lenders whose consent is required under any applicable Loan Document. In no event shall Tenant use or Landlord be required to approve any architects, consultants, contractors, subcontractors or material suppliers that Landlord reasonably believes could cause labor disharmony or may not have sufficient experience, in Landlord’s reasonable opinion, to perform work in an occupied Class “A” laboratory/research building and in tenant-occupied lab areas. Notwithstanding the foregoing, Tenant may make strictly cosmetic changes to the Premises that do not require any permits or more than three (3) total contractors and subcontractors (“Cosmetic Alterations”) without Landlord’s consent; provided that (y) the cost of any Cosmetic Alterations does not exceed One Hundred Forty Thousand Dollars ($140,000) in any one instance or Two Hundred Fifty Thousand Dollars ($250,000) annually, (z) such Cosmetic Alterations do not (i) require any structural or other substantial modifications to the Premises, (ii) require any changes to or adversely affect the Building systems, (iii) affect the exterior of the Building or (iv) trigger any requirement under Applicable Laws that would require Landlord to make any alteration or improvement to the Premises, the Building or the Project. Tenant shall give Landlord at least ten (10) days’ prior written notice of any Cosmetic Alterations.

29


17.2. Tenant shall not construct or permit to be constructed partitions or other obstructions that might interfere with free access to mechanical installation or service facilities of the Building or with other tenants’ components located within the Building, or interfere with the moving of Landlord’s equipment to or from the enclosures containing such installations or facilities.

17.3. Tenant shall accomplish any work performed on the Premises or the Building in such a manner as to permit any life safety systems to remain fully operable at all times.

17.4. Any work performed on the Premises, the Building or the Project by Tenant or Tenant’s contractors shall be done at such times and in such manner as Landlord may from time to time designate. Tenant covenants and agrees that all work done by Tenant or Tenant’s contractors shall be performed in full compliance with Applicable Laws. Within thirty (30) days after completion of any Alterations (other than Cosmetic Alterations), Tenant shall provide Landlord with complete “as built” drawing print sets and electronic CADD files on disc (or files in such other current format in common use as Landlord reasonably approves or requires) showing any changes in the Premises, as well as a commissioning report prepared by a licensed, qualified commissioning agent hired by Tenant and approved by Landlord for all new or affected mechanical, electrical and plumbing systems. Any such “as built” plans shall show the applicable Alterations as an overlay on the Building as-built plans; provided that Landlord provides the Building “as built” plans to Tenant.

17.5. Before commencing any Alterations (other than Cosmetic Alterations), Tenant shall give Landlord at least twenty (20) days’ prior written notice of the proposed commencement of such work and the names and addresses of the persons supply labor or materials therefor so that Landlord may enter the Premises to post and keep posted thereon and therein notices or to take any further action that Landlord may reasonably deem proper for the protection of Landlord’s interest in the Project and shall, if required by Landlord, secure, at Tenant’s own cost and expense, a completion and lien indemnity bond satisfactory to Landlord for such work.

17.6. Tenant shall repair any damage to the Premises arising from Tenant’s removal of any property from the Premises. During any such restoration period, Tenant shall pay Rent to Landlord as provided herein as if such space were otherwise occupied by Tenant. The provisions of this Section shall survive the expiration or earlier termination of this Lease.

17.7. The Premises plus any Alterations; Signage; Tenant Improvements; attached equipment, decorations, fixtures and trade fixtures; movable laboratory casework and related appliances; and other additions and improvements attached to or built into the Premises made by either of the parties (including all floor and wall coverings; paneling; sinks and related plumbing fixtures; laboratory benches; exterior venting fume hoods; walk-in freezers and refrigerators; ductwork; conduits; electrical panels and circuits; attached machinery and equipment; and built-in furniture and cabinets, in each case, together with all additions and accessories thereto), shall (unless, prior to such construction or installation, Landlord elects otherwise in writing) at all times remain the property of Landlord, shall remain in the Premises and shall (unless, prior to construction or installation thereof, Landlord elects otherwise in writing) be surrendered to Landlord upon the expiration or earlier termination of this Lease. Notwithstanding the foregoing, with respect to specialty Alterations or specialty Tenant Improvements (e.g., internal staircase),

30


Landlord shall have the right to elect by written notice to Tenant at least one hundred eighty (180) days prior to the expiration or earlier termination of the Lease (and not only prior to the construction or installation thereof) that Tenant remove such specialty Alteration or specialty Tenant Improvements upon the expiration or earlier termination of the Lease, restore any walls, ceilings and floors that existed prior to such installation, and repair any damage to the Premises as a result thereof to a condition reasonably satisfactory to Landlord. If an earlier termination of the Lease occurs such that there is not a period of 180 days before which Landlord may give Tenant the removal notice, Landlord shall have the right to provide such notice less than 180 days prior to the earlier termination and shall use commercially reasonable efforts to provide as much notice as practicable. For the avoidance of doubt, the items listed on Exhibit H attached hereto (which Exhibit H may be updated by Tenant from and after the Term Commencement Date, subject to Landlord’s written consent) constitute Tenant’s property and shall be removed by Tenant upon the expiration or earlier termination of the Lease.

17.8. Notwithstanding any other provision of this Article to the contrary, in no event shall Tenant remove any improvement from the Premises in which any Lender has a security interest or as to which Landlord contributed payment, including the Tenant Improvements, without Landlord’s prior written consent, which consent Landlord may withhold in its reasonable discretion.

17.9. If Tenant shall fail to remove any of its property from the Premises prior to the expiration or earlier termination of this Lease, then Landlord may, at its option, remove the same in any manner that Landlord shall choose and store such effects without liability to Tenant for loss thereof or damage thereto, and Tenant shall pay Landlord, upon demand, any costs and expenses incurred due to such removal and storage or Landlord may, at its sole option and without notice to Tenant, sell such property or any portion thereof at private sale and without legal process for such price as Landlord may obtain and apply the proceeds of such sale against any (a) amounts due by Tenant to Landlord under this Lease and (b) any expenses incident to the removal, storage and sale of such personal property.

17.10. Tenant shall pay to Landlord an amount equal to two percent (2%) of the cost to Tenant of all Alterations to cover Landlord’s overhead and expenses for plan review, engineering review, coordination, scheduling and supervision thereof or obtaining any required Lender consent. For purposes of payment of such sum, Tenant shall submit to Landlord copies of all bills, invoices and statements covering the costs of such charges, accompanied by payment to Landlord of the fee set forth in this Section. Notwithstanding the foregoing, the cost of any personal property procured by Tenant as part of the Alterations and which Tenant has the right to remove at the end of the Term under this Lease (e.g., certain equipment, robotics, etc.) shall be expressly excluded from the calculation of the Landlord fee. Tenant shall reimburse Landlord for any extra expenses incurred by Landlord by reason of faulty work done by Tenant or its contractors, or by reason of delays arising from such faulty work, or by reason of inadequate clean-up.

17.11. Within sixty (60) days after final completion of any Alterations performed by Tenant with respect to the Premises, Tenant shall submit to Landlord documentation showing the amounts expended by Tenant with respect to such Alterations, together with supporting documentation reasonably acceptable to Landlord.

31


17.12. Tenant shall take, and shall cause its contractors to take, commercially reasonable steps to protect the Premises during the performance of any Alterations, including covering or temporarily removing any window coverings so as to guard against dust, debris or damage.

17.13. Tenant shall require its contractors and subcontractors performing work on the Premises to name Landlord, BioMed Realty, L.P. and BioMed Realty III LP, and their respective officers, employees, directors, representatives, agents, general partners, members, subsidiaries, affiliates and Lenders (collectively with Landlord, the “Landlord Parties”) as additional insureds on their respective insurance policies.

18. Repairs and Maintenance.

18.1. Landlord shall repair and maintain the structural and exterior portions and Common Area of the Building and the Project, including roofing and covering materials; foundations (excluding any architectural slabs, but including any structural slabs); exterior walls; plumbing; fire sprinkler systems (if any); base Building HVAC systems up to the first damper or isolation valve that serves the Premises (for purposes of clarity, the portion of the HVAC system that includes such first damper or isolation valve and extends into and through the Premises, and any supplemental HVAC serving the Premises shall not be part of the base Building HVAC and shall be Tenant’s obligation to maintain and repair pursuant to Section 18.2 below); elevators; the Generator (excluding the automatic transfer switch); and base Building electrical systems installed or furnished by Landlord, in a first class manner comparable to other buildings in Boston owned by Landlord that are similar to the Building and operated and used for the same use as the Permitted Use.

18.2. Except for services of Landlord, if any, required by Section 18.1, Tenant shall at Tenant’s sole cost and expense maintain and keep the Premises (including but not limited to the portion of the HVAC system that includes the first damper or isolation valve and extends into and through the Premises, any supplemental HVAC serving the Premises, and any other systems or equipment exclusively serving the Premises) and every part thereof in good condition and repair, and shall, within ten (10) days after receipt of written notice from Landlord, provide to Landlord any maintenance records that Landlord reasonably requests. Tenant shall, upon the expiration or sooner termination of the Term, surrender the Premises to Landlord in as good a condition as when received, ordinary wear and tear excepted; and shall, at Landlord’s request and Tenant’s sole cost and expense, remove all telephone and data systems, wiring and equipment from the Premises (with respect to wiring, only to the extent installed by a Tenant Party (as defined below)), and repair any damage to the Premises caused thereby. Landlord shall have no obligation to alter, remodel, improve, repair, decorate or paint the Premises or any part thereof.

18.3. Throughout the Term of the Lease, Tenant shall, at Tenant’s sole cost and expense, maintain copies for the prior three (3) years, of all applicable service contracts, service, repair and maintenance records, and inspection reports on all equipment installed by or maintained by Tenant. Tenant shall, within ten (10) business days after receipt of written notice from Landlord, provide to Landlord any maintenance records, service or inspection reports that Landlord reasonably requests. Upon surrender of the Premises upon the expiration or earlier termination of this Lease, Tenant shall provide Landlord with all original equipment manufacturer (OEM) manuals for any equipment installed and not removed by Tenant. Landlord shall also have the right to perform an

32


audit of the equipment serving the Premises in the form of a facilities condition assessment or similar report at Tenant’s reasonable costs not to exceed one (1) time per year. To the extent such audit recommends corrective action, Tenant shall promptly perform such corrective action as part of its repair and maintenance obligations.

18.4. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance that is Landlord’s obligation pursuant to this Lease unless such failure shall persist for an unreasonable time after Tenant provides Landlord with written notice of the need of such repairs or maintenance. Tenant waives its rights under Applicable Laws now or hereafter in effect to make repairs at Landlord’s expense.

18.5. If any excavation shall be made upon land adjacent to or under the Building, or shall be authorized to be made, Tenant shall afford to the person causing or authorized to cause such excavation, license to enter the Premises for the purpose of performing such work as such person shall deem necessary or desirable to preserve and protect the Building from injury or damage and to support the same by proper foundations, without any claim for damages or liability against Landlord and without reducing or otherwise affecting Tenant’s obligations under this Lease; provided such party makes all reasonable efforts to avoid any interference or disruption with Tenant’s business in the Premises for the Permitted Use.

18.6. Intentionally omitted.

18.7. This Article relates to repairs and maintenance arising in the ordinary course of operation of the Building and the Project. In the event of a casualty described in Article 24, Article 24 shall apply in lieu of this Article. In the event of eminent domain, Article 25 shall apply in lieu of this Article.

18.8. Costs incurred by Landlord pursuant to this Article shall constitute Operating Expenses. Notwithstanding the foregoing, to the extent that the cost of such repairs and maintenance arising from Tenant’s acts, neglect, fault or omissions (but not gross negligence or willful misconduct) exceeds the limits of any insurance maintained or required to be maintained by Tenant pursuant to this Lease but are covered by insurance maintained or required to be maintained by Landlord under this Lease, then Landlord shall file a claim for such excess pursuant to Landlord’s insurance and Tenant shall reimburse Landlord for the deductible therefor within thirty (30) days after receipt of an invoice therefor (or, if Landlord has not obtained or maintained the insurance it is required to obtain and maintain pursuant to this Lease, Landlord shall pay such excess, other than what the deductible would have been had Landlord obtained and maintained the requisite insurance, which Tenant shall pay to Landlord within thirty (30) days after receipt of an invoice therefor).

19. Liens.

19.1. Subject to the immediately succeeding sentence, Tenant shall keep the Premises, the Building and the Project free from any liens arising from work or services performed, materials furnished to or obligations incurred by Tenant. Tenant further covenants and agrees that any mechanic’s or materialman’s lien filed against the Premises, the Building or the Project for work or services claimed to have been done for, or materials claimed to have been furnished to, or

33


obligations incurred by Tenant shall be discharged or bonded by Tenant within ten (10) days after Tenant’s receipt of notice of or obtaining actual knowledge of the filing thereof, at Tenant’s sole cost and expense.

19.2. Should Tenant fail to discharge or bond against any lien of the nature described in Section 19.1, Landlord may, at Landlord’s election, pay such claim or post a statutory lien bond or otherwise provide security to eliminate the lien as a claim against title, and Tenant shall immediately reimburse Landlord for the costs thereof as Additional Rent. Tenant shall Indemnify the Landlord Indemnitees from and against any Claims arising from any such liens, including any administrative, court or other legal proceedings related to such liens.

19.3. In the event that Tenant leases or finances the acquisition of office equipment, furnishings or other personal property of a removable nature utilized by Tenant in the operation of Tenant’s business, Tenant warrants that any Uniform Commercial Code financing statement shall, upon its face or by exhibit thereto, indicate that such financing statement is applicable only to removable personal property of Tenant located within the Premises. In no event shall the address of the Premises, the Building or the Project be furnished on a financing statement without qualifying language as to applicability of the lien only to removable personal property located in an identified suite leased by Tenant. Should any holder of a financing statement record or place of record a financing statement that appears to constitute a lien against any interest of Landlord or against equipment that may be located other than within an identified suite leased by Tenant, Tenant shall, within ten (10) days after filing such financing statement, cause (a) a copy of the lender security agreement or other documents to which the financing statement pertains to be furnished to Landlord to facilitate Landlord’s ability to demonstrate that the lien of such financing statement is not applicable to Landlord’s interest and (b) Tenant’s lender to amend such financing statement and any other documents of record to clarify that any liens imposed thereby are not applicable to any interest of Landlord in the Premises, the Building or the Project.

20. Estoppel Certificate. Tenant shall, within ten (10) days after receipt of written notice from Landlord, execute, acknowledge and deliver a statement in writing substantially in the form attached to this Lease as Exhibit I, or on any other form reasonably requested by a current or proposed Lender or encumbrancer or proposed purchaser, (a) certifying that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this Lease as so modified is in full force and effect) and the dates to which rental and other charges are paid in advance, if any, (b) acknowledging that there are not, to Tenant’s knowledge, any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (c) setting forth such further information with respect to this Lease or the Premises as may be requested thereon. Any such statements may be relied upon by any prospective purchaser or encumbrancer of all or any portion of the Property. If Tenant fails to return such statement as required by Tenant under this Section within such ten (10) business days than Tenant may be assessed a fee of $500.00 per day by Landlord until Tenant has executed and delivered such statement.

21. Hazardous Materials.

21.1. Tenant shall not cause or permit any Hazardous Materials (as defined below) to be brought upon, kept or used in or about the Premises, the Building or the Project in violation of

34


Applicable Laws by Tenant or any of its employees, agents, contractors or invitees (collectively with Tenant, each a “Tenant Party”). If (a) Tenant breaches such obligation, (b) the presence of Hazardous Materials as a result of such a breach results in contamination of the Project, any portion thereof, or any adjacent property, (c) contamination of the Premises otherwise occurs during the Term or any extension or renewal hereof or holding over hereunder (other than if such contamination results from (i) migration of Hazardous Materials from outside the Premises not arising from the acts or omissions of a Tenant Party or coming from property owned or leased by a Tenant Party or (ii) to the extent such contamination arises directly from Landlord’s gross negligence or willful misconduct), or (d) contamination of the Project occurs as a result of Hazardous Materials that are placed on or under or are released into the Project by a Tenant Party, then Tenant shall Indemnify the Landlord Indemnitees from and against any and all Claims of any kind or nature, including (w) diminution in value of the Project or any portion thereof, (x) damages for the loss or restriction on use of rentable or usable space or of any amenity of the Project, (y) damages arising from any adverse impact on marketing of space in the Project or any portion thereof and (z) sums paid in settlement of Claims that arise before, during or after the Term as a result of such breach or contamination. This Indemnification by Tenant includes costs incurred in connection with any investigation of site conditions or any clean-up, remedial, removal or restoration work required by any Governmental Authority because of Hazardous Materials present in the air, soil or groundwater above, on, under or about the Project. Without limiting the foregoing, if the presence of any Hazardous Materials in, on, under or about the Project, any portion thereof or any adjacent property caused or permitted by any Tenant Party results in any contamination of the Project, any portion thereof or any adjacent property, then Tenant shall promptly take all actions at its sole cost and expense as are necessary to return the Project, any portion thereof or any adjacent property to its respective condition existing prior to the time of such contamination; provided that Landlord’s written approval of such action shall first be obtained, which approval Landlord shall not unreasonably withhold; and provided, further, that it shall be reasonable for Landlord to withhold its consent if such actions could have a material adverse long-term or short-term effect on the Project, any portion thereof or any adjacent property. Tenant’s obligations under this Section shall not be affected, reduced or limited by any limitation on the amount or type of damages, compensation or benefits payable by or for Tenant under workers’ compensation acts, disability benefit acts, employee benefit acts or similar legislation. Landlord hereby agrees to hold Tenant harmless from and against any and all loss, cost, damage, claim or expense (including legal fees) incurred in connection with or arising out of or relating in any way to the presence of Hazardous Materials at the Property as of the Execution Date, unless placed on the Property by a Tenant Party. The provisions of the foregoing sentence shall survive the expiration or earlier termination of this Lease.

21.2. Landlord acknowledges that it is not the intent of this Article to prohibit Tenant from operating its business for the Permitted Use. Tenant may operate its business according to the custom of Tenant’s industry so long as the use or presence of Hazardous Materials is strictly and properly monitored in accordance with Applicable Laws. As a material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees to deliver to Landlord (a) a list identifying each type of Hazardous Material to be present at the Premises that is subject to regulation under any environmental Applicable Laws in the form of a Tier II form pursuant to Section 312 of the Emergency Planning and Community Right-to-Know Act of 1986 (or any successor statute) or any other form reasonably requested by Landlord, (b) a list of any and all approvals or permits from Governmental Authorities required in connection

35


with the presence of such Hazardous Material at the Premises and (c) correct and complete copies of (i) notices of violations of Applicable Laws related to Hazardous Materials and (ii) plans relating to the installation of any storage tanks to be installed in, on, under or about the Project (provided that installation of storage tanks shall only be permitted after Landlord has given Tenant its written consent to do so, which consent Landlord may withhold in its sole and absolute discretion) and closure plans or any other documents required by any and all Governmental Authorities for any storage tanks installed in, on, under or about the Project for the closure of any such storage tanks (collectively, “Hazardous Materials Documents”). Notwithstanding the foregoing, Tenant shall not be required to include within Hazardous Materials Documents any Hazardous Materials found in office supplies used in the ordinary course and in compliance with all Applicable Laws. Tenant shall deliver to Landlord updated Hazardous Materials Documents, within fourteen (14) days after receipt of a written request therefor from Landlord, not more often than once per year, unless (m) there are any material changes to the quantity or nature of the Hazardous Materials disclosed on the Hazardous Materials Documents or (n) Tenant initiates any Alterations or changes its business, in either case in a way that involves any material increase in the types or amounts of Hazardous Materials, in which case Tenant shall deliver updated Hazardous Materials documents (without Landlord having to request them) before or, if not practicable to do so before, as soon as reasonably practicable after the occurrence of the events in Subsection 21.2(m) or (n). For each type of Hazardous Material listed, the Hazardous Materials Documents shall include (t) the chemical name, (u) the material state (e.g., solid, liquid, gas or cryogen), (v) the concentration, (w) the storage amount and storage condition (e.g., in cabinets or not in cabinets), (x) the use amount and use condition (e.g., open use or closed use), (y) the location (e.g., room number or other identification) and (z) if known, the chemical abstract service number. Notwithstanding anything in this Section to the contrary, Tenant shall not be required to provide Landlord with any documents containing information of a proprietary nature, unless such documents contain a reference to Hazardous Materials or activities related to Hazardous Materials. Landlord may, at Landlord’s expense, cause the Hazardous Materials Documents to be reviewed by a person or firm qualified to analyze Hazardous Materials to confirm compliance with the provisions of this Lease and with Applicable Laws. In the event that a review of the Hazardous Materials Documents indicates non-compliance with this Lease or Applicable Laws, Tenant shall, at its expense, diligently take steps to bring its storage and use of Hazardous Materials into compliance. Notwithstanding anything in this Lease to the contrary or Landlord’s review into Tenant’s Hazardous Materials Documents or use or disposal of hazardous materials, however, Landlord shall not have and expressly disclaims any liability related to Tenant’s or other tenants’ use or disposal of Hazardous Materials, it being acknowledged by Tenant that Tenant is best suited to evaluate the safety and efficacy of its Hazardous Materials usage and procedures.

21.3. Tenant represents and warrants to Landlord that it is not nor has it been, in connection with the use, disposal or storage of Hazardous Materials, (a) subject to a material enforcement order issued by any Governmental Authority or (b) required to take any remedial action.

21.4. Upon at least two (2) business days prior written notice to Tenant (unless Landlord reasonably believes testing must be completed sooner), prior to the expiration of the Term, Landlord shall have the right to conduct appropriate tests of the Project or any portion thereof to demonstrate that Hazardous Materials are present or that contamination has occurred due to the

36


acts or omissions of a Tenant Party. Tenant shall pay all reasonable costs of such tests if such tests reveal that Hazardous Materials exist at the Project in violation of this Lease.

21.5. If underground or other storage tanks storing Hazardous Materials installed or utilized by Tenant are located on the Premises, or are hereafter placed on the Premises by Tenant (or by any other party, if such storage tanks are utilized by Tenant), then Tenant shall monitor the storage tanks, maintain appropriate records, implement reporting procedures, properly close any underground storage tanks, and take or cause to be taken all other steps necessary or required under the Applicable Laws. Tenant shall have no responsibility or liability for underground or other storage tanks installed by anyone other than Tenant unless Tenant utilizes such tanks, in which case Tenant’s responsibility for such tanks shall be as set forth in this Section.

21.6. Tenant shall promptly report to Landlord any actual or suspected presence of mold or water intrusion at the Premises.

21.7. Tenant’s obligations under this Article shall survive the expiration or earlier termination of the Lease. During any period of time needed by Tenant or Landlord after the termination of this Lease to complete the removal from the Premises of any such Hazardous Materials for which Tenant is liable, Tenant shall be deemed a holdover tenant and subject to the provisions of Article 27.

21.8. As used herein, the term “Hazardous Material” means any toxic, explosive, corrosive, flammable, infectious, radioactive, carcinogenic, mutagenic or otherwise hazardous substance, material or waste that is or becomes regulated by Applicable Laws or any Governmental Authority.

21.9. Notwithstanding anything to the contrary in this Lease, Landlord shall have sole control over the equitable allocation of fire control areas (as defined in the Uniform Building Code as adopted by the city or municipality(ies) in which the Project is located (the “UBC”)) within the Project for the storage of Hazardous Materials. Notwithstanding anything to the contrary in this Lease, the quantity of Hazardous Materials allowed by this Section is specific to Tenant and shall not run with the Lease in the event of a Transfer (as defined in Article 29). In the event of a Transfer, if the use of Hazardous Materials by such new tenant (“New Tenant”) is such that New Tenant utilizes fire control areas in the Project in excess of New Tenant’s Pro Rata Share of the Building or the Project, as applicable, then New Tenant shall, at its sole cost and expense and upon Landlord’s written request, establish and maintain a separate area of the Premises classified by the UBC as an “H” occupancy area for the use and storage of Hazardous Materials, or take such other action as is necessary to ensure that its share of the fire control areas of the Building and the Project is not greater than New Tenant’s Pro Rata Share of the Building or the Project, as applicable. Notwithstanding anything in this Lease to the contrary, Landlord shall not have and expressly disclaims any liability related to Tenant’s or other tenants’ use or disposal of fire control areas, it being acknowledged by Tenant that Tenant and other tenants are best suited to evaluate the safety and efficacy of its Hazardous Materials usage and procedures.

22. Odors and Exhaust. Tenant acknowledges that Landlord would not enter into this Lease with Tenant unless Tenant assured Landlord that under no circumstances will any other occupants of the Building or the Project (including persons legally present in any outdoor areas of the Project)

37


be subjected to odors or fumes (whether or not noxious), and that the Building and the Project will not be damaged by any exhaust, in each case from Tenant’s operations, including in Tenant’s vivarium. Landlord and Tenant therefore agree as follows:

22.1. Tenant shall not cause or permit (or conduct any activities that would cause) any release of any odors or fumes of any kind from the Premises.

22.2. If the Building has a ventilation system that, in Landlord’s judgment, is adequate, suitable, and appropriate to vent the Premises in a manner that does not release odors affecting any indoor or outdoor part of the Project, Tenant shall vent the Premises through such system. If Landlord at any time determines that any existing ventilation system is inadequate, or if no ventilation system exists, Tenant shall in compliance with Applicable Laws vent all fumes and odors from the Premises (and remove odors from Tenant’s exhaust stream) as Landlord requires. The placement and configuration of all ventilation exhaust pipes, louvers and other equipment shall be subject to Landlord’s approval. Tenant acknowledges Landlord’s legitimate desire to maintain the Project (indoor and outdoor areas) in an odor-free manner, and Landlord may require Tenant to abate and remove all odors in a manner that goes beyond the requirements of Applicable Laws.

22.3. Tenant shall, at Tenant’s sole cost and expense, provide odor eliminators and other devices (such as filters, air cleaners, scrubbers and whatever other equipment may in Landlord’s judgment be necessary or appropriate from time to time) to completely remove, eliminate and abate any odors, fumes or other substances in Tenant’s exhaust stream that, in Landlord’s judgment, emanate from Tenant’s Premises. Any work Tenant performs under this Section shall constitute Alterations.

22.4. Tenant’s responsibility to remove, eliminate and abate odors, fumes and exhaust shall continue throughout the Term. Landlord’s approval of the Tenant Improvements shall not preclude Landlord from requiring additional measures to eliminate odors, fumes and other adverse impacts of Tenant’s exhaust stream (as Landlord may designate in Landlord’s discretion). Tenant shall install additional equipment as Landlord requires from time to time under the preceding sentence. Such installations shall constitute Alterations.

22.5. If Tenant fails to install satisfactory odor control equipment within ten (10) business days after Landlord’s demand made at any time, then Landlord may, without limiting Landlord’s other rights and remedies, require Tenant to cease and suspend any operations in the Premises that, in Landlord’s determination, cause odors, fumes or exhaust. For example, if Landlord determines that Tenant’s production of a certain type of product causes odors, fumes or exhaust, and Tenant does not install satisfactory odor control equipment within ten (10) business days after Landlord’s request, then Landlord may require Tenant to stop producing such type of product in the Premises unless and until Tenant has installed odor control equipment satisfactory to Landlord.

23. Insurance.

23.1. Landlord shall maintain insurance for the Building and the Project in amounts equal to full replacement cost (exclusive of the costs of excavation, foundations and footings,

38


engineering costs or such other costs to the extent the same are not incurred in the event of a rebuild and without reference to depreciation taken by Landlord upon its books or tax returns) or such lesser coverage as Landlord may elect, provided that such coverage shall not be less than the amount of such insurance Landlord’s Lender, if any, requires Landlord to maintain, providing protection against any peril generally included within the classification “Fire and Extended Coverage,” together with insurance against sprinkler damage (if applicable), vandalism and malicious mischief. Landlord, subject to availability thereof, shall further insure, if Landlord deems it appropriate, coverage against flood, environmental hazard, earthquake, loss or failure of building equipment, rental loss during the period of repairs or rebuilding, Workers’ Compensation insurance and fidelity bonds for employees employed to perform services. Notwithstanding the foregoing, Landlord may, but shall not be deemed required to, provide insurance for any improvements installed by Tenant or that are in addition to the standard improvements customarily furnished by Landlord, without regard to whether or not such are made a part of or are affixed to the Building.

23.2. In addition, Landlord shall carry Commercial General Liability insurance with limits of not less than One Million Dollars ($1,000,000) per occurrence/general aggregate for bodily injury (including death), or property damage with respect to the Project.

23.3. Tenant shall, at its own cost and expense, procure and maintain during the Term the following insurance for the benefit of Tenant and Landlord (as their interests may appear) with insurers financially acceptable and lawfully authorized to do business in the state where the Premises are located:

(a) Commercial General Liability insurance on a broad-based occurrence coverage form, with coverages including but not limited to bodily injury (including death), property damage (including loss of use resulting therefrom), premises/operations, personal & advertising injury, and contractual liability with limits of liability of not less than $2,000,000 for bodily injury and property damage per occurrence, $4,000,000 general aggregate, which limits may be met by use of excess and/or umbrella liability insurance; provided that such coverage is at least as broad as the primary coverages required herein.

(b) Commercial Automobile Liability insurance covering liability arising from the use or operation of any auto on behalf of Tenant or invited by Tenant (including those owned, hired, rented, leased, borrowed, scheduled or non-owned). Coverage shall be on a broad-based occurrence form in an amount not less than $2,000,000 combined single limit per accident for bodily injury and property damage. Such coverage shall apply to all vehicles and persons, whether accessing the property with active or passive consent.

(c) Commercial Property insurance covering property damage to the full replacement cost value and business interruption. Covered property shall include all tenant improvements in the Premises (to the extent not insured by Landlord pursuant to Section 23.1) and Tenant’s Property including personal property, furniture, fixtures, machinery, equipment, stock, inventory and improvements and betterments, which may be owned by Tenant or Landlord and required to be insured hereunder, or which may be leased, rented, borrowed or in the care custody or control of Tenant, or Tenant’s agents, employees or subcontractors. Such insurance, with respect only to all Tenant Improvements, Alterations or other work performed on the Premises by

39


Tenant (collectively, “Tenant Work”), shall name Landlord and Landlord’s current and future mortgagees as loss payees as their interests may appear. Such insurance shall be written on an “all risk” of physical loss or damage basis including the perils of fire, extended coverage, electrical injury, mechanical breakdown, windstorm, vandalism, malicious mischief, sprinkler leakage, back-up of sewers or drains, flood, earthquake, terrorism and such other risks Landlord may from time to time designate, for the full replacement cost value of the covered items with an agreed amount endorsement with no co-insurance. Business interruption coverage shall have limits sufficient to cover Tenant’s lost profits and necessary continuing expenses, including rents due Landlord under the Lease. The minimum period of indemnity for business interruption coverage shall be twenty-four (24) months.

(d) Workers’ Compensation in compliance with all Applicable Laws or as may be available on a voluntary basis. Employer’s Liability must be at least in the amount of $1,000,000 for bodily injury by accident for each employee, $1,000,000 for bodily injury by disease for each employee, and $1,000,000 bodily injury by disease for policy limit.

(e) Medical malpractice insurance at limits of not less than $1,000,000 each claim during such periods, if any, that Tenant engages in the practice of medicine or clinical trials involving human beings at the Premises.

(f) Pollution Legal Liability insurance is required if Tenant stores, handles, generates or treats Hazardous Materials, as determined solely by Landlord, on or about the Premises. Such coverage shall include bodily injury, sickness, disease, death or mental anguish or shock sustained by any person; property damage including physical injury to or destruction of tangible property including the resulting loss of use thereof, clean-up costs, and the loss of use of tangible property that has not been physically injured or destroyed; and defense costs, charges and expenses incurred in the investigation, adjustment or defense of claims for such compensatory damages. Coverage shall apply to both sudden and non-sudden pollution conditions including the discharge, dispersal, release or escape of smoke, vapors, soot, fumes, acids, alkalis, toxic chemicals, liquids or gases, waste materials or other irritants, contaminants or pollutants into or upon land, the atmosphere or any watercourse or body of water. Claims-made coverage is permitted, provided the policy retroactive date is continuously maintained prior to the commencement date of this agreement, and coverage is continuously maintained during all periods in which Tenant occupies the Premises. Coverage shall be maintained with limits of not less than $2,000,000 per incident with a $4,000,000 policy aggregate and for a period of two (2) years thereafter.

(g) During all construction by Tenant at the Premises, with respect to tenant improvements being constructed (including the Tenant Improvements and any Alterations, insurance required in Exhibit B-1 must be in place.

23.4. The insurance required of Tenant by this Article shall be with companies at all times having a current rating of not less than A- and financial category rating of at least Class VII in “A.M. Best’s Insurance Guide” current edition. Tenant shall obtain for Landlord from the insurance companies/broker or cause the insurance companies/broker to furnish certificates of insurance evidencing all coverages required herein to Landlord including copies of any endorsements. No such policy shall be cancelable or subject to reduction of coverage or other

40


modification or cancellation except after thirty (30) days’ prior written notice to Landlord from Tenant or its insurers (except in the event of non-payment of premium, in which case ten (10) days’ written notice shall be given). All such policies shall be written as primary policies, not contributing with and not in excess of the coverage that Landlord may carry. Tenant’s required policies shall contain severability of interests clauses stating that, except with respect to limits of insurance, coverage shall apply separately to each insured or additional insured. Tenant shall, on the date of expiration of such policies, furnish Landlord with renewal certificates of insurance or binders. Tenant agrees that if Tenant does not take out and maintain such insurance, Landlord may (but shall not be required to) procure such insurance on Tenant’s behalf and at its cost to be paid by Tenant as Additional Rent. Commercial General Liability, Commercial Automobile Liability, Umbrella Liability and Pollution Legal Liability insurance as required above shall name the Landlord Parties as additional insureds as respects liability arising from work or operations performed by or on behalf of Tenant, Tenant’s use or occupancy of Premises, and ownership, maintenance or use of vehicles by or on behalf of Tenant. Tenant must disclose any self-insurance, including self-insurance retentions, to Landlord in writing in advance, which shall be subject to Landlord’s prior written approval in its sole discretion. If Tenant self-insures with Landlord’s prior written approval, Tenant is itself acting as though it were providing the insurance required under the provisions of this Lease, and Tenant shall pay those amounts due in lieu of insurance proceeds that would have been covered and payable if the insurance policies had been carried for such self-insured coverages, which amounts shall be treated as insurance proceeds for all purposes under this Lease.

23.5. In each instance where insurance is to name the Landlord Parties as additional insureds, Tenant shall, upon Landlord’s written request, also designate and furnish certificates evidencing the Landlord Parties as additional insureds to (a) any Lender of Landlord holding a security interest in the Building or the Project, (b) the landlord under any lease whereunder Landlord is a tenant of the real property upon which the Building is located if the interest of Landlord is or shall become that of a tenant under a ground lease rather than that of a fee owner and (c) any management company retained by Landlord to manage the Project.

23.6. Tenant assumes the risk of damage to any fixtures, goods, inventory, merchandise, equipment and leasehold improvements, and Landlord shall not be liable for injury to Tenant’s business or any loss of income therefrom, relative to such damage, all as more particularly set forth within this Lease. Tenant shall, at Tenant’s sole cost and expense, carry such insurance as Tenant desires for Tenant’s protection with respect to personal property of Tenant or business interruption.

23.7. Except in cases of gross negligence or willful misconduct, each of Tenant and Landlord, on behalf of themselves and their respective insurers, hereby waive any and all rights of recovery or subrogation against the Landlord Parties with respect to any loss, damage, claims, suits or demands, howsoever caused, that are covered, or should have been covered, by valid and collectible workers’ compensation, employer’s liability insurance and other liability insurance required to obtained and carried by the parties pursuant to this Article, including any deductibles or self-insurance maintained thereunder. If necessary, Tenant and Landlord agree to endorse the required workers’ compensation, employer’s liability and other liability insurance policies to permit waivers of subrogation as required hereunder and hold harmless and indemnify the Landlord Parties and Tenant Parties, as applicable, for any loss or expense incurred as a result of a failure to obtain such waivers of subrogation from insurers. Such waivers shall continue so long

41


as Tenant’s and Landlord’s insurers so permit. Any termination of such a waiver shall be by written notice to Landlord or Tenant, as applicable, containing a description of the circumstances hereinafter set forth in this Section. Tenant, upon obtaining the policies of workers’ compensation, employer’s liability and other liability insurance required or permitted under this Lease, shall give notice to its insurance carriers that the foregoing waiver of subrogation is contained in this Lease. If such policies shall not be obtainable with such waiver or shall be so obtainable only at a premium over that chargeable without such waiver, then Tenant shall notify Landlord of such conditions.

23.8. Landlord may require insurance policy limits required under this Lease to be raised to conform with requirements of Landlord’s Lender or to bring coverage limits to levels then being required of new tenants within the Project.

23.9. In addition to other insurance required by this Lease to be carried by Tenant, if Tenant sells, merchandises, transfers, gives away or exchanges alcoholic beverages in, upon or from any part of the Premises, then Tenant shall, at Tenant’s sole cost and expense, purchase and maintain in full force and effect during the Term dram shop insurance in form and substance reasonably satisfactory to Landlord, with total limits of liability for bodily injury, loss of means of support and property damage for each occurrence in an amount and with a carrier reasonably acceptable to Landlord, and otherwise in compliance with the general provisions of this Article governing the provision of insurance by Tenant. Such policy shall name the Landlord Parties as additional insureds against any liability by virtue of Applicable Laws concerning the use, sale or giving away of alcoholic beverages. If at any time such insurance is for any reason not in force, then during all and any such times no selling, merchandising, transferring, giving away or exchanging of alcoholic beverages shall be conducted by Tenant in, upon or from any part of the Premises.

23.10. Any costs incurred by Landlord pursuant to this Article shall constitute a portion of Operating Expenses.

24. Damage or Destruction.

24.1. In the event of a partial destruction of (a) the Premises, (b) the Building, (c) the Common Area or (d) the Project ((a)-(d) collectively, the “Affected Areas”) by fire or other perils covered by extended coverage insurance not exceeding twenty-five percent (25%) of the full insurable value thereof, and provided that (w) the damage thereto is such that the Affected Areas may be repaired, reconstructed or restored within a period of six (6) months from the date of the happening of such casualty, (x) Landlord shall receive insurance proceeds from its insurer or Lender sufficient to cover the cost of such repairs, reconstruction and restoration (except for any deductible amount provided by Landlord’s policy, which deductible amount, if paid by Landlord, shall constitute an Operating Expense), (y) the repair, reconstruction or restoration of the Affected Areas is permitted by all applicable Loan Documents or otherwise consented to by any and all Lenders whose consent is required thereunder and (z) such casualty was not intentionally caused by a Tenant Party, then Landlord shall commence and proceed diligently with the work of repair, reconstruction and restoration of the Affected Areas and this Lease shall continue in full force and effect.

42


24.2. In the event of any damage to or destruction of the Building or the Project other than as described in Section 24.1, Landlord may elect to repair, reconstruct and restore the Building or the Project, as applicable, in which case this Lease shall continue in full force and effect. If Landlord elects not to repair, reconstruct and restore the Building or the Project, as applicable, then this Lease shall terminate as of the date of such damage or destruction. In the event of any damage or destruction (regardless of whether such damage is governed by Section 24.1 or this Section), if (a) in Landlord’s determination as set forth in the Damage Repair Estimate (as defined below), the Affected Areas cannot be repaired, reconstructed or restored within twelve (12) months after the date of such casualty, (b) subject to Section 24.6, the Affected Areas are not actually repaired, reconstructed and restored within eighteen (18) months after the date of such casualty, or (c) the damage and destruction occurs within the last twelve (12) months of the then-current Term, then Tenant shall have the right to terminate this Lease, effective as of the date of such damage or destruction, by delivering to Landlord its written notice of termination (a “Termination Notice”) (y) with respect to Subsections 24.2(a) and (c), no later than fifteen (15) days after Landlord delivers to Tenant Landlord’s Damage Repair Estimate and (z) with respect to Subsection 24.2(b), no later than fifteen (15) days after such eighteen (18) month period (as the same may be extended pursuant to Section 24.6) expires. If Tenant provides Landlord with a Termination Notice pursuant to Subsection 24.2(z), Landlord shall have an additional thirty (30) days after receipt of such Termination Notice to complete the repair, reconstruction and restoration. If Landlord does not complete such repair, reconstruction and restoration within such thirty (30) day period, then Tenant may terminate this Lease by giving Landlord written notice within two (2) business days after the expiration of such thirty (30) day period. If Landlord does complete such repair, reconstruction and restoration within such thirty (30) day period, then this Lease shall continue in full force and effect.

24.3. As soon as reasonably practicable, but in any event within sixty (60) days following the date of damage or destruction, Landlord shall notify Tenant of Landlord’s good faith estimate of the period of time in which the repairs, reconstruction and restoration will be completed (the “Damage Repair Estimate”), which estimate shall be based upon the opinion of a contractor reasonably selected by Landlord and experienced in comparable repair, reconstruction and restoration of similar buildings. Additionally, Landlord shall give written notice to Tenant within sixty (60) days following the date of damage or destruction of its election not to repair, reconstruct or restore the Building or the Project, as applicable.

24.4. Upon any termination of this Lease under any of the provisions of this Article, the parties shall be released thereby without further obligation to the other from the date possession of the Premises is surrendered to Landlord, except with regard to (a) items occurring prior to the damage or destruction and (b) provisions of this Lease that, by their express terms, survive the expiration or earlier termination hereof.

24.5. In the event of repair, reconstruction and restoration as provided in this Article, all Rent to be paid by Tenant under this Lease shall be abated proportionately from the date of the casualty based on the extent to which Tenant’s use of the Premises is impaired during the period of such repair, reconstruction or restoration, unless Landlord provides Tenant with other space during the period of repair, reconstruction and restoration that, in Tenant’s reasonable opinion, is suitable for the temporary conduct of Tenant’s business; provided, however, that the amount of such abatement shall be reduced by the amount of Rent that is received by Tenant as part of the

43


business interruption or loss of rental income with respect to the Premises from the proceeds of business interruption or loss of rental income insurance.

24.6. Notwithstanding anything to the contrary contained in this Article, (a) Landlord shall not be required to repair, reconstruct or restore any damage or destruction to the extent that Landlord is prohibited from doing so by any applicable Loan Document or any Lender whose consent is required thereunder withholds its consent, and (b) should Landlord be delayed or prevented from completing the repair, reconstruction or restoration of the damage or destruction to the Premises after the occurrence of such damage or destruction by Force Majeure (as defined below) or delays caused by a Lender or Tenant Party, then the time for Landlord to commence or complete repairs, reconstruction and restoration shall be extended on a day-for-day basis; provided, however, that, at Landlord’s election, Landlord shall be relieved of its obligation to make such repairs, reconstruction and restoration. In the event Landlord elects not to complete such repair, reconstruction or restoration due to such Force Majeure, or in the event Lender does not consent to Landlord’s use of the insurance proceeds for such repairs, reconstruction or restoration, and such election not to complete such repair, reconstruction or restoration materially adversely affects Tenant’s use of the Premises, then this Lease shall automatically terminate except with respect to those provisions which survive such termination.

24.7. If Landlord is obligated to or elects to repair, reconstruct or restore as herein provided, then Landlord shall be obligated to make such repairs, reconstruction or restoration only with regard to (a) those portions of the Premises that were originally provided at Landlord’s expense and (b) the Common Area portion of the Affected Areas. The repairs, reconstruction or restoration of improvements not originally provided by Landlord or at Landlord’s expense shall be the obligation of Tenant. In the event Tenant has elected to upgrade certain improvements from the Building Standard, Landlord shall, upon the need for replacement due to an insured loss, provide only the Building Standard, unless Tenant again elects to upgrade such improvements and pay any incremental costs related thereto, except to the extent that excess insurance proceeds, if received, are adequate to provide such upgrades, in addition to providing for basic repairs, reconstruction and restoration of the Premises, the Building and the Project.

24.8. Notwithstanding anything to the contrary contained in this Article, Landlord shall not have any obligation whatsoever to repair, reconstruct or restore the Premises if the damage resulting from any casualty covered under this Article occurs during the last twenty-four (24) months of the Term or any extension thereof, or to the extent that insurance proceeds are not available therefor.

24.9. Landlord’s obligation, should it elect or be obligated to repair, reconstruct or restore, shall be limited to the Affected Areas, and shall be conditioned upon Landlord receiving any permits or authorizations required by Applicable Laws. Tenant shall, at its expense, replace or fully repair all of Tenant’s personal property and any Alterations installed by Tenant existing at the time of such damage or destruction. If Affected Areas are to be repaired, reconstructed or restored in accordance with the foregoing, Landlord shall make available to Tenant any portion of insurance proceeds it receives that are allocable to the Alterations constructed by Tenant pursuant to this Lease; provided Tenant is not then in default under this Lease, and subject to the requirements of any Lender of Landlord.

44


24.10. This Article sets forth the terms and conditions upon which this Lease may terminate in the event of any damage or destruction. Accordingly, the parties hereby waive the provisions of any Applicable Laws (and any successor statutes) permitting the parties to terminate this Lease as a result of any damage or destruction.

25. Eminent Domain.

25.1. In the event (a) the whole of all Affected Areas or (b) such part thereof as shall substantially interfere with Tenant’s use and occupancy of the Premises for the Permitted Use shall be taken for any public or quasi-public purpose by any lawful power or authority by exercise of the right of appropriation, condemnation or eminent domain, or sold to prevent such taking, Tenant or Landlord may terminate this Lease effective as of the date possession is required to be surrendered to such authority, except with regard to (y) items occurring prior to the taking and (z) provisions of this Lease that, by their express terms, survive the expiration or earlier termination hereof.

25.2. In the event of a partial taking of (a) the Building or the Project or (b) drives, walkways or parking areas serving the Building or the Project for any public or quasi-public purpose by any lawful power or authority by exercise of right of appropriation, condemnation, or eminent domain, or sold to prevent such taking, then, without regard to whether any portion of the Premises occupied by Tenant was so taken, Landlord may elect to terminate this Lease (except with regard to (a) items occurring prior to the taking and (b) provisions of this Lease that, by their express terms, survive the expiration or earlier termination hereof) as of such taking if such taking is, in Landlord’s reasonable opinion, of a material nature such as to make it uneconomical to continue use of the unappropriated portion for purposes of renting office or laboratory space.

25.3. To the extent permitted under all applicable Loan Documents or otherwise consented to by any and all Lenders whose consent is required thereunder, Tenant shall be entitled to any award that is specifically awarded as compensation for (a) the taking of Tenant’s personal property that was installed at Tenant’s expense and (b) the costs of Tenant moving to a new location. Except as set forth in the previous sentence, any award for such taking shall be the property of Landlord.

25.4. If, upon any taking of the nature described in this Article, this Lease continues in effect, then Landlord shall promptly proceed to restore the Affected Areas to substantially their same condition prior to such partial taking. To the extent such restoration is infeasible, as determined by Landlord in its sole and absolute discretion, the Rent shall be decreased proportionately to reflect the loss of any portion of the Premises no longer available to Tenant. Notwithstanding anything to the contrary contained in this Article, Landlord shall not be required to restore the Affected Areas to the extent that Landlord is prohibited from doing so by any applicable Loan Document or any Lender whose consent is required thereunder withholds its consent.

25.5. This Article sets forth the terms and conditions upon which this Lease may terminate in the event of any taking. Accordingly, the parties hereby waive the provisions of any Applicable Laws permitting the parties to terminate this Lease as a result of any taking.

45


26. Surrender.

26.1. At least thirty (30) days prior to Tenant’s surrender of possession of any part of the Premises, Tenant shall provide Landlord with a facility decommissioning and Hazardous Materials closure plan for the Premises (“Exit Survey”) prepared by an independent third party state-certified professional with appropriate expertise, which Exit Survey must be reasonably acceptable to Landlord. The Exit Survey shall comply with the American National Standards Institute’s Laboratory Decommissioning guidelines (ANSI/AIHA Z9.11-2008) or any successor standards published by ANSI or any successor organization (or, if ANSI and its successors no longer exist, a similar entity publishing similar standards). In addition, at least ten (10) days prior to Tenant’s surrender of possession of any part of the Premises, Tenant shall (a) provide Landlord with written evidence of all appropriate governmental releases obtained by Tenant in accordance with Applicable Laws, including laws pertaining to the surrender of the Premises, (b) place Laboratory Equipment Decontamination Forms on all decommissioned equipment to assure safe occupancy by future users and (c) conduct a site inspection with Landlord. In addition, Tenant agrees to remain responsible after the surrender of the Premises for the remediation of any recognized environmental conditions set forth in the Exit Survey and comply with any recommendations set forth in the Exit Survey. Tenant’s obligations under this Section shall survive the expiration or earlier termination of the Lease.

26.2. No surrender of possession of any part of the Premises shall release Tenant from any of its obligations hereunder, unless such surrender is accepted in writing by Landlord.

26.3. The voluntary or other surrender of this Lease by Tenant shall not effect a merger with Landlord’s fee title or leasehold interest in the Premises, the Building, the Property or the Project, unless Landlord consents in writing, and shall, at Landlord’s option, operate as an assignment to Landlord of any or all subleases.

26.4. The voluntary or other surrender of any ground or other underlying lease that now exists or may hereafter be executed affecting the Building or the Project, or a mutual cancellation thereof or of Landlord’s interest therein by Landlord and its lessor shall not effect a merger with Landlord’s fee title or leasehold interest in the Premises, the Building or the Property and shall, at the option of the successor to Landlord’s interest in the Building or the Project, as applicable, operate as an assignment of this Lease.

27. Holding Over.

27.1. If, with Landlord’s prior written consent, Tenant holds possession of all or any part of the Premises after the Term, Tenant shall become a tenant from month to month after the expiration or earlier termination of the Term, and in such case Tenant shall continue to pay (a) Base Rent in accordance with Article 7, as adjusted in accordance with Article 8, and (b) any amounts for which Tenant would otherwise be liable under this Lease if the Lease were still in effect, including payments for Tenant’s Adjusted Share of Operating Expenses, and all other Additional Rent. Any such month-to-month tenancy shall be subject to every other term, covenant and agreement contained herein.

46


27.2. Notwithstanding the foregoing, if Tenant remains in possession of the Premises after the expiration or earlier termination of the Term without Landlord’s prior written consent, (a) Tenant shall become a tenant at sufferance subject to the terms and conditions of this Lease, except that the monthly rent shall be equal to one hundred fifty percent (150%) of the Rent in effect during the last thirty (30) days of the Term, and (b) if such holdover persists after the earlier of (i) thirty (30) days after the expiration or earlier termination of the Term and (ii) the date Landlord notifies Tenant that Landlord has procured a tenant that is ready, willing and able to sign a lease for the Premises (or a portion thereof), Tenant shall be liable to Landlord for any and all damages suffered by Landlord as a result of such holdover, including any lost rent or consequential, special and indirect damages (in each case, regardless of whether such damages are foreseeable).

27.3. Acceptance by Landlord of Rent after the expiration or earlier termination of the Term shall not result in an extension, renewal or reinstatement of this Lease.

27.4. The foregoing provisions of this Article are in addition to and do not affect Landlord’s right of reentry or any other rights of Landlord hereunder or as otherwise provided by Applicable Laws.

27.5. The provisions of this Article shall survive the expiration or earlier termination of this Lease.

28. Indemnification and Exculpation.

28.1. Tenant agrees to Indemnify the Landlord Indemnitees from and against any and all Claims of any kind or nature, real or alleged, arising from (a) injury to or death of any person or damage to any property occurring within or about the Premises, the Building, the Property or the Project, arising directly or indirectly out of (i) the presence at or use or occupancy of the Premises or Project by a Tenant Party or (ii) an act or omission on the part of any Tenant Party, (b) a breach or default by Tenant in the performance of any of its obligations hereunder or (c) injury to or death of persons or damage to or loss of any property, real or alleged, arising from the serving of alcoholic beverages at the Premises or Project by any Tenant Party, including liability under any dram shop law, host liquor law or similar Applicable Law, except to the extent arising directly from Landlord’s negligence or willful misconduct. Tenant’s obligations under this Section shall not be affected, reduced or limited by any limitation on the amount or type of damages, compensation or benefits payable by or for Tenant under workers’ compensation acts, disability benefit acts, employee benefit acts or similar legislation. Tenant’s obligations under this Section shall survive the expiration or earlier termination of this Lease. Subject to Sections 28.2 and 31.14, Landlord agrees to indemnify, save, defend (at Tenant’s option and with counsel reasonably acceptable to Tenant) and hold the Tenant Parties harmless from and against any and all Claims arising from injury to or death of any person or damage to or loss of any physical property occurring within or about the Premises, the Building, the Property or the Project to the extent directly arising out of Landlord’s gross negligence or willful misconduct.

28.2. Notwithstanding anything in this Lease to the contrary, Landlord shall not be liable to Tenant for and Tenant assumes all risk of (a) damage or losses arising from fire, electrical malfunction, gas explosion or water damage of any type (including broken water lines, malfunctioning fire sprinkler systems, roof leaks or stoppages of lines), unless any such loss is due

47


to Landlord’s willful disregard of written notice by Tenant of need for a repair that Landlord is responsible to make for an unreasonable period of time, and (b) damage to personal property or scientific research, including loss of records kept by Tenant within the Premises (in each case, regardless of whether such damages are foreseeable). Tenant further waives any claim for injury to Tenant’s business or loss of income relating to any such damage or destruction of personal property as described in this Section. Notwithstanding anything in the foregoing or this Lease to the contrary, except (x) as otherwise provided herein (including Section 27.2), (y) as may be provided by Applicable Laws or (z) in the event of Tenant’s breach of Article 21 or Section 26.1, in no event shall Landlord or Tenant be liable to the other for any consequential, special or indirect damages arising from this Lease, including lost profits (provided that this Subsection 28.2(z) shall not limit Tenant’s liability for Base Rent or Additional Rent pursuant to this Lease).

28.3. Landlord shall not be liable for any damages arising from any act, omission or neglect of any other tenant in the Building or the Project, or of any other third party.

28.4. Tenant acknowledges that security devices and services, if any, while intended to deter crime, may not in given instances prevent theft or other criminal acts. Landlord shall not be liable for injuries or losses arising from criminal acts of third parties, and Tenant assumes the risk that any security device or service may malfunction or otherwise be circumvented by a criminal, or that Landlord may decide (in its sole and absolute discretion) not to monitor any installed security devices.. If Tenant desires protection against such criminal acts, then Tenant shall, at Tenant’s sole cost and expense, obtain appropriate insurance coverage. Tenant’s security programs and equipment for the Premises shall be coordinated with Landlord and subject to Landlord’s reasonable approval. Tenant’s security programs and equipment for the Premises shall be coordinated with Landlord and subject to Landlord’s reasonable approval.

28.5. The provisions of this Article shall survive the expiration or earlier termination of this Lease.

29. Assignment or Subletting.

29.1 Except as hereinafter expressly permitted, none of the following (each, a “Transfer”), either voluntarily or by operation of Applicable Laws, shall be directly or indirectly performed without Landlord’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed: (a) Tenant selling, hypothecating, assigning, pledging, encumbering or otherwise transferring its interest in this Lease or subletting all or a portion of the Premises, (b) a controlling interest in Tenant being sold, assigned or otherwise transferred (other than as a result of shares in Tenant being sold on a public stock exchange), or (c) the sale of all or substantially all of its assets. For purposes of the preceding sentence, “control” means (f) owning (directly or indirectly) more than fifty percent (50%) of the stock or other equity interests of another person or (g) possessing, directly or indirectly, the power to direct or cause the direction of the management and policies of such person. Notwithstanding the foregoing, Tenant shall have the right to Transfer, without Landlord’s prior written consent, Tenant’s interest in this Lease or the Premises or any part thereof to (i) any person that as of the date of determination and at all times thereafter directly, or indirectly through one or more intermediaries, controls, is controlled by or is under common control with Tenant (“Tenant’s Affiliate”), (ii) any person or entity with which Tenant is merged or to which all or substantially all of Tenant’s assets or all or substantially all of the

48


ownership interests in Tenant are sold, or (iii) any person or entity which is a successor-in-interest to Tenant by way of spin-off or consolidation; provided that Tenant shall notify Landlord in writing at least thirty (30) days prior to the effectiveness of such Transfer (an “Exempt Transfer”) and otherwise comply with the requirements of this Lease regarding such Transfer; and provided, further, that the person that will be the tenant under this Lease after the Exempt Transfer pursuant to (i), (ii) and (iii) above has a tangible net worth (as of both the day immediately prior to and the day immediately after the Exempt Transfer) that is equal to or greater than the tangible net worth (as of both the Execution Date and the date of the Exempt Transfer) of the transferring Tenant, provided, however, in the event Tenant is subleasing twenty-five percent (25%) or less of the Premises to Tenant’s Affiliate, no such net worth test shall be required. For purposes of the immediately preceding sentence, “control” requires both (m) owning (directly or indirectly) more than fifty percent (50%) of the stock or other equity interests of another person and (n) possessing, directly or indirectly, the power to direct or cause the direction of the management and policies of such person. Tenant shall not perform a Transfer (other than an Exempt Transfer) to or with an entity that is a tenant at the Project or that is then in active discussions or negotiations with Landlord or an affiliate of Landlord to lease premises at the Project or a property owned by Landlord’s affiliate.

29.2 In the event Tenant desires to effect a Transfer, then, at least thirty (30) but not more than ninety (90) days prior to the date when Tenant desires the Transfer to be effective (the “Transfer Date”), Tenant shall provide written notice to Landlord (the “Transfer Notice”) containing information (including references) concerning the character of the proposed transferee, assignee or sublessee; the Transfer Date; the most recent unconsolidated financial statements of Tenant and of the proposed transferee, assignee or sublessee satisfying the requirements of Section 40.2 (“Required Financials”); any ownership or commercial relationship between Tenant and the proposed transferee, assignee or sublessee; copies of Hazardous Materials Documents for the proposed transferee, assignee or sublessee; and the consideration and all other material terms and conditions of the proposed Transfer, all in such detail as Landlord shall reasonably require.

29.3 Landlord, in determining whether consent should be given to a proposed Transfer, may give consideration to such factors as Landlord reasonably deems material, including (a) the financial strength of Tenant and of such transferee, assignee or sublessee (notwithstanding Tenant remaining liable for Tenant’s performance), (b) any change in use that such transferee, assignee or sublessee proposes to make in the use of the Premises and (c) Landlord’s desire to exercise its rights under Section 29.7 to recapture the Premises. In no event shall Landlord be deemed to be unreasonable for declining to consent to a Transfer if any applicable Loan Document prohibits such assignment or any Lender whose consent is required thereunder withholds its consent, or if the Transfer is to a transferee, assignee or sublessee of poor reputation, lacking financial qualifications or seeking a change in the Permitted Use, or jeopardizing directly or indirectly the status of Landlord or any of Landlord’s affiliates as a Real Estate Investment Trust under the Internal Revenue Code of 1986 (as the same may be amended from time to time, the “Revenue Code”). Notwithstanding anything contained in this Lease to the contrary, (w) no Transfer shall be consummated on any basis such that the rental or other amounts to be paid by the occupant, assignee, manager or other transferee thereunder would be based, in whole or in part, on the income or profits derived by the business activities of such occupant, assignee, manager or other transferee; (x) Tenant shall not furnish or render any services to an occupant, assignee, manager or other transferee with respect to whom transfer consideration is required to be paid, or manage or operate the Premises or any capital additions so transferred, with respect to which transfer

49


consideration is being paid; (y) Tenant shall not consummate a Transfer with any person in which Landlord owns an interest, directly or indirectly (by applying constructive ownership rules set forth in Section 856(d)(5) of the Revenue Code); and (z) Tenant shall not consummate a Transfer with any person or in any manner that could cause any portion of the amounts received by Landlord pursuant to this Lease or any sublease, license or other arrangement for the right to use, occupy or possess any portion of the Premises to fail to qualify as “rents from real property” within the meaning of Section 856(d) of the Revenue Code, or any similar or successor provision thereto or which could cause any other income of Landlord to fail to qualify as income described in Section 856(c)(2) of the Revenue Code. Notwithstanding anything in this Lease to the contrary, if (a) Tenant or any proposed transferee, assignee or sublessee of Tenant has been required by any prior landlord, Lender or Governmental Authority to take material remedial action in connection with Hazardous Materials contaminating a property if the contamination resulted from such party’s action or omission or use of the property in question or (b) Tenant or any proposed transferee, assignee or sublessee is subject to a material enforcement order issued by any Governmental Authority in connection with the use, disposal or storage of Hazardous Materials, then Landlord shall have the right to terminate this Lease in Landlord’s sole and absolute discretion (with respect to any such matter involving Tenant), and it shall not be unreasonable for Landlord to withhold its consent to any proposed transfer, assignment or subletting (with respect to any such matter involving a proposed transferee, assignee or sublessee).

29.4 The following are conditions precedent to a Transfer or to Landlord considering a request by Tenant to a Transfer:

(a) Tenant shall remain fully liable under this Lease. Tenant agrees that it shall not be (and shall not be deemed to be) a guarantor or surety of this Lease, however, and waives its right to claim that is it is a guarantor or surety or to raise in any legal proceeding any guarantor or surety defenses permitted by this Lease or by Applicable Laws;

(b) If Tenant or the proposed transferee, assignee or sublessee does not or cannot deliver the Required Financials, then Landlord may elect to have either Tenant’s ultimate parent company or the proposed transferee’s, assignee’s or sublessee’s ultimate parent company provide a guaranty of the applicable entity’s obligations under this Lease, in a form acceptable to Landlord, which guaranty shall be executed and delivered to Landlord by the applicable guarantor prior to the Transfer Date;

(c) In the case of an Exempt Transfer, Tenant shall provide Landlord with evidence reasonably satisfactory to Landlord that the Transfer qualifies as an Exempt Transfer;

(d) Tenant shall provide Landlord with evidence reasonably satisfactory to Landlord that the value of Landlord’s interest under this Lease shall not be diminished or reduced by the proposed Transfer. Such evidence shall include evidence respecting the relevant business experience and financial responsibility and status of the proposed transferee, assignee or sublessee;

(e) Tenant shall reimburse Landlord for Landlord’s actual costs and expenses, including reasonable attorneys’ fees, charges and disbursements incurred in connection with the review, processing and documentation of such request, up to a maximum amount of $3,500.00;

50


(f) Except with respect to an Exempt Transfer, if Tenant’s transfer of rights or sharing of the Premises provides for the receipt by, on behalf of or on account of Tenant of any consideration of any kind whatsoever (including a premium rental for a sublease or lump sum payment for an assignment, but excluding Tenant’s reasonable costs in marketing and subleasing the Premises) in excess of the rental and other charges due to Landlord under this Lease, Tenant shall pay fifty percent (50%) of all of such excess to Landlord, after making deductions for the following reasonable and customary transaction costs: any reasonable marketing expenses, tenant improvement funds expended by Tenant, alterations, cash concessions, brokerage commissions, attorneys’ fees and free rent actually paid by Tenant. If such consideration consists of cash paid to Tenant, payment to Landlord shall be made upon receipt by Tenant of such cash payment;

(g) The proposed transferee, assignee or sublessee shall agree that, in the event Landlord gives such proposed transferee, assignee or sublessee notice that Tenant is in default under this Lease, such proposed transferee, assignee or sublessee shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments shall be received by Landlord without any liability being incurred by Landlord, except to credit such payment against those due by Tenant under this Lease, and any such proposed transferee, assignee or sublessee shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided, however, that in no event shall Landlord or its Lenders, successors or assigns be obligated to accept such attornment;

(h) Landlord’s consent to any such Transfer (other than an Exempt Transfer, which does not require Landlord’s consent) shall be effected on Landlord’s forms;

(i) Tenant shall not then be in default hereunder in any respect;

(j) Such proposed transferee, assignee or sublessee’s use of the Premises shall be the same as the Permitted Use;

(k) Landlord shall not be bound by any provision of any agreement pertaining to the Transfer, except for Landlord’s written consent to the same;

(l) Tenant shall pay all transfer and other taxes (including interest and penalties) assessed or payable for any Transfer;

(m) Landlord’s consent (or waiver of its rights) for any Transfer shall not waive Landlord’s right to consent or refuse consent to any later Transfer;

(n) Tenant shall deliver to Landlord one executed copy of any and all written instruments evidencing or relating to the Transfer; and

(o) Tenant shall deliver to Landlord a list of Hazardous Materials (as defined below), certified by the proposed transferee, assignee or sublessee to be true and correct, that the proposed transferee, assignee or sublessee intends to use or store in the Premises. Additionally, Tenant shall deliver to Landlord, on or before the date any proposed transferee, assignee or sublessee takes occupancy of the Premises, all of the items relating to Hazardous Materials of such proposed transferee, assignee or sublessee as described in Section 21.2.

51


29.5 Any Transfer that is not in compliance with the provisions of this Article or with respect to which Tenant does not fulfill its obligations pursuant to this Article shall (a) constitute a Default, (b) be voidable by Landlord and (c), at Landlord’s option, terminate this Lease, except for those provisions that, by their express terms, survive the expiration or earlier termination hereof.

29.6 Notwithstanding any Transfer, Tenant shall remain fully and primarily liable for the payment of all Rent and other sums due or to become due hereunder, and for the full performance of all other terms, conditions and covenants to be kept and performed by Tenant. The acceptance of Rent or any other sum due hereunder, or the acceptance of performance of any other term, covenant or condition thereof, from any person or entity other than Tenant shall not be deemed a waiver of any of the provisions of this Lease or a consent to any Transfer.

29.7 29.7 If Tenant delivers to Landlord a Transfer Notice regarding the transfer of this Lease to a proposed transferee, assignee (excluding any assignment constituting an Exempt Transfer), or sublessee, that would, in the aggregate with all other then-current subleases and licenses, cause more than fifty percent (50%) of the Rentable Area of the Premises to be assigned, licensed or subleased (excluding any subleases and licenses that constitute Exempt Transfers) for the substantial balance of the then current Lease Term, then Landlord shall have the option, exercisable by giving notice to Tenant at any time within thirty (30) days after Landlord’s receipt of such Transfer Notice, to terminate this Lease as of the date specified in the Transfer Notice as the Transfer Date, except for those provisions that, by their express terms, survive the expiration or earlier termination hereof. If Landlord exercises such option, then Tenant shall have the right to withdraw such Transfer Notice by delivering to Landlord written notice of such election within five (5) days after Landlord’s delivery of notice electing to exercise Landlord’s option to terminate this Lease. In the event Tenant withdraws the Transfer Notice as provided in this Section, this Lease shall continue in full force and effect. No failure of Landlord to exercise its option to terminate this Lease shall be deemed to be Landlord’s consent to a proposed Transfer.

29.8 If Tenant sublets the Premises or any portion thereof, Tenant hereby immediately and irrevocably assigns to Landlord, as security for Tenant’s obligations under this Lease, all rent from any such subletting, and appoints Landlord as assignee and attorney-in-fact for Tenant, and Landlord (or a receiver for Tenant appointed on Landlord’s application) may collect such rent and apply it toward Tenant’s obligations under this Lease; provided that, until the occurrence of a Default (as defined below) by Tenant, Tenant shall have the right to collect such rent.

29.9. In the event that Tenant enters into a sublease for the entire Premises in accordance with this Article that expires within two (2) days of the Term Expiration Date, the term expiration date of such sublease shall, notwithstanding anything in this Lease, the sublease or any consent to the sublease to the contrary, be deemed to be the date that is two (2) days prior to the Term Expiration Date.

30. Subordination and Attornment.

30.1. This Lease shall be subject and subordinate to the lien of any mortgage, deed of trust, or lease in which Landlord is tenant now or hereafter in force against the Building or the Project and to all advances made or hereafter to be made upon the security thereof without the

52


necessity of the execution and delivery of any further instruments on the part of Tenant to effectuate such subordination.

30.2. Notwithstanding the foregoing, Tenant shall execute and deliver upon demand such further instrument or instruments evidencing such subordination of this Lease to the lien of any such mortgage or mortgages or deeds of trust or lease in which Landlord is tenant as may be required by Landlord. If any Lender so elects, however, this Lease shall be deemed prior in lien to any such lease, mortgage, or deed of trust upon or including the Premises regardless of date and Tenant shall execute a statement in writing to such effect at Landlord’s request. Landlord shall (a) request a subordination and attornment agreement (“SNDA”) from its current Lender within thirty (30) days after the Term Commencement Date, and (b) any future Lender, each on Lenders’ standard form, provided, however, that Tenant acknowledges and agrees that such Lenders have no contractual obligation to deliver such SNDA. For the avoidance of doubt, “Lenders” shall also include historic tax credit investors and new market tax credit investors.

30.3. Upon written request of Landlord and opportunity for Tenant to review, Tenant agrees to execute any reasonable Lease amendments not materially altering the terms of this Lease or materially increasing any obligations of Tenant hereunder, if required by a Lender incident to the financing of the real property of which the Premises constitute a part.

30.4. In the event any proceedings are brought for foreclosure, or in the event of the exercise of the power of sale under any mortgage or deed of trust made by Landlord covering the Premises, Tenant shall at the election of the purchaser at such foreclosure or sale attorn to the purchaser upon any such foreclosure or sale and recognize such purchaser as Landlord under this Lease, subject to and in accordance with the provisions of any SNDA then in effect.

31. Defaults and Remedies.

31.1. Late payment by Tenant to Landlord of Rent and other sums due shall cause Landlord to incur costs not contemplated by this Lease, the exact amount of which shall be extremely difficult and impracticable to ascertain. Such costs include processing and accounting charges and late charges that may be imposed on Landlord by the terms of any mortgage or trust deed covering the Premises. Therefore, if any installment of Rent due from Tenant is not received by Landlord within three (3) business days after the date such payment is due, Tenant shall pay to Landlord (a) an additional sum of five percent (5%) of the overdue Rent as a late charge plus (b) interest at an annual rate (the “Default Rate”) equal to the lesser of (a) twelve percent (12%) and (b) the highest rate permitted by Applicable Laws. The parties agree that this late charge represents a fair and reasonable estimate of the costs that Landlord shall incur by reason of late payment by Tenant and shall be payable as Additional Rent to Landlord due with the next installment of Rent or within five (5) business days after Landlord’s demand, whichever is earlier. Landlord’s acceptance of any Additional Rent (including a late charge or any other amount hereunder) shall not be deemed an extension of the date that Rent is due or prevent Landlord from pursuing any other rights or remedies under this Lease, at law or in equity. Notwithstanding the foregoing to the contrary, Landlord shall not charge Tenant such late charge the first time in any calendar year that Tenant fails to make such payment within such 3-business day period, provided such payment is made within ten (10) days after written notice from Landlord that such payment is due, and

53


provided further that Tenant shall not be entitled to such extended grace period more than twice during the Term of this Lease.

31.2. No payment by Tenant or receipt by Landlord of a lesser amount than the Rent payment herein stipulated shall be deemed to be other than on account of the Rent, nor shall any endorsement or statement on any check or any letter accompanying any check or payment as Rent be deemed an accord and satisfaction, and Landlord may accept such check or payment without prejudice to Landlord’s right to recover the balance of such Rent or pursue any other remedy provided in this Lease or in equity or at law. If a dispute shall arise as to any amount or sum of money to be paid by Tenant to Landlord hereunder, Tenant shall have the right to make payment “under protest,” such payment shall not be regarded as a voluntary payment, and there shall survive the right on the part of Tenant to institute suit for recovery of the payment paid under protest.

31.3. If Tenant fails to pay any sum of money required to be paid by it hereunder or perform any other act on its part to be performed hereunder, in each case within the applicable cure period (if any) described in Section 31.4, then Landlord may (but shall not be obligated to), without waiving or releasing Tenant from any obligations of Tenant, make such payment or perform such act; provided that such failure by Tenant unreasonably interfered with the use of the Building or the Project by any other tenant or with the efficient operation of the Building or the Project, or resulted or could have resulted in a violation of Applicable Laws or the cancellation of an insurance policy maintained by Landlord. Notwithstanding the foregoing, in the event of an emergency, Landlord shall have the right to enter the Premises and act in accordance with its rights as provided elsewhere in this Lease. In addition to the late charge described in Section 31.1, Tenant shall pay to Landlord as Additional Rent all sums so paid or incurred by Landlord, together with interest at the Default Rate, computed from the date such sums were paid or incurred.

31.4. The occurrence of any one or more of the following events shall constitute a “Default” hereunder by Tenant:

(a) Tenant fails to make any payment of Rent, as and when due, or to satisfy its obligations under Article 19, where such failure shall continue for a period of three (3) business days after written notice thereof from Landlord to Tenant;

(b) Tenant fails to observe or perform any obligation or covenant contained herein (other than described in Sections 31.4(a)) to be performed by Tenant, where such failure continues for a period of thirty (30) days after written notice thereof from Landlord to Tenant; provided that, if the nature of Tenant’s default is such that it reasonably requires more than thirty (30) days to cure, Tenant shall not be deemed to be in Default if Tenant commences such cure within such thirty (30) day period and thereafter diligently prosecutes the same to completion; and provided, further, that such cure is completed no later than sixty (60) days after Tenant’s receipt of written notice from Landlord;

(c) Tenant makes an assignment for the benefit of creditors;

(d) A receiver, trustee or custodian is appointed to or does take title, possession or control of all or substantially all of Tenant’s assets;

54


(e) Tenant files a voluntary petition under the United States Bankruptcy Code or any successor statute (as the same may be amended from time to time, the “Bankruptcy Code”) or an order for relief is entered against Tenant pursuant to a voluntary or involuntary proceeding commenced under any chapter of the Bankruptcy Code;

(f) Any involuntary petition is filed against Tenant under any chapter of the Bankruptcy Code and is not dismissed within one hundred twenty (120) days;

(g) Tenant fails to deliver an estoppel certificate in accordance with Article 20; or

(h) Tenant’s interest in this Lease is attached, executed upon or otherwise judicially seized and such action is not released within one hundred twenty (120) days of the action.

Notices given under this Section shall specify the alleged default and shall demand that Tenant perform the provisions of this Lease or pay the Rent that is in arrears, as the case may be, within the applicable period of time, or quit the Premises. No such notice shall be deemed a forfeiture or a termination of this Lease unless Landlord elects otherwise in such notice.

31.5. In the event of a Chronic Delinquency (as defined below), Landlord may, in addition to all other remedies under this Lease, at law or in equity, require that Tenant thereafter pay Rent quarterly in advance. This provision shall not limit in any way nor be construed as a waiver of Landlord’s rights and remedies contained in this Lease, at law or in equity in the event of a default. “Chronic Delinquency” means that Tenant commits a Default pursuant to Section 31.4(b) three (3) times in any twelve (12) month period.

31.6. Intentionally omitted.

31.7. In the event of a Default by Tenant, and at any time thereafter, with or without notice or demand and without limiting Landlord in the exercise of any right or remedy that Landlord may have, Landlord has the right to do any or all of the following:

(a) Halt any Tenant Improvements and Alterations and order Tenant’s contractors, subcontractors, consultants, designers and material suppliers to stop work;

(b) Terminate Tenant’s right to possession of the Premises by written notice to Tenant or by any lawful means, in which case Tenant shall immediately surrender possession of the Premises to Landlord. In such event, Landlord shall have the immediate right to re-enter and remove all persons and property, and such property may be removed and stored in a public warehouse or elsewhere at the cost and for the account of Tenant, all without service of notice or resort to legal process and without being deemed guilty of trespass or becoming liable for any loss or damage that may be occasioned thereby; and

(c) Terminate this Lease, in which event Tenant shall immediately surrender possession of the Premises to Landlord. In such event, Landlord shall have the immediate right to re-enter and remove all persons and property, and such property may be removed and stored in a public warehouse or elsewhere at the cost and for the account of Tenant, all without service of notice or resort to legal process and without being deemed guilty of trespass or becoming liable

55


for any loss or damage that may be occasioned thereby. In the event that Landlord shall elect to so terminate this Lease, then Landlord shall be entitled to recover from Tenant all damages incurred by Landlord by reason of Tenant’s default, including,

(i) The sum of:

A. The worth at the time of award of any unpaid Rent that had accrued at the time of such termination; plus

B. The costs of restoring the Premises to the condition required under the terms of this Lease; plus

C. An amount (the “Election Amount”) equal to either (A) the positive difference (if any, and measured at the time of such termination) between (1) the then-present value of the total Rent and other benefits that would have accrued to Landlord under this Lease for the remainder of the Term if Tenant had fully complied with the Lease minus (2) the then-present cash rental value of the Premises as determined by Landlord for what would be the then-unexpired Term if the Lease remained in effect, computed using the discount rate of the Federal Reserve Bank of San Francisco at the time of the award plus one (1) percentage point (the “Discount Rate”) or (B) twelve (12) months (or such lesser number of months as may then be remaining in the Term) of Base Rent and Additional Rent at the rate last payable by Tenant pursuant to this Lease, in either case as Landlord specifies in such election. Landlord and Tenant agree that the Election Amount represents a reasonable forecast of the minimum damages expected to occur in the event of a breach, taking into account the uncertainty, time and cost of determining elements relevant to actual damages, such as fair market rent, time and costs that may be required to re-lease the Premises, and other factors; and that the Election Amount is not a penalty.

As used in Section 31.6(c)(i), “worth at the time of award” shall be computed by taking the present value of such amount, using the Discount Rate.

31.8. In addition to any other remedies available to Landlord at law or in equity and under this Lease (other than Section 31.6(c)(i)), Landlord may continue this Lease in effect after Tenant’s Default and recover Rent as it becomes due. In addition, Landlord shall not be liable in any way whatsoever for its failure or refusal to relet the Premises, unless or to the extent required by Applicable Law. For purposes of this Section, the following acts by Landlord will not constitute the termination of Tenant’s right to possession of the Premises:

(a) Acts of maintenance or preservation or efforts to relet the Premises, including alterations, remodeling, redecorating, repairs, replacements or painting as Landlord shall consider advisable for the purpose of reletting the Premises or any part thereof; or

(b) The appointment of a receiver upon the initiative of Landlord to protect Landlord’s interest under this Lease or in the Premises.

Notwithstanding the foregoing, in the event of a Default by Tenant, Landlord may elect at any time to terminate this Lease and to recover damages to which Landlord is entitled.

56


31.9. If Landlord does not elect to terminate this Lease as provided in Section 31.6, then Landlord may, from time to time, recover all Rent as it becomes due under this Lease. At any time thereafter, Landlord may elect to terminate this Lease and to recover damages to which Landlord is entitled.

31.10. In the event Landlord elects to terminate this Lease and relet the Premises, Landlord may execute any new lease in its own name. Tenant shall have no right or authority whatsoever to collect any Rent from such tenant. The proceeds of any such reletting shall be applied as follows:

(a) First, to the payment of any indebtedness other than Rent due hereunder from Tenant to Landlord, including storage charges or brokerage commissions owing from Tenant to Landlord as the result of such reletting;

(b) Second, to the payment of the costs and expenses of reletting the Premises, including (i) alterations and repairs that Landlord deems reasonably necessary and advisable and (ii) reasonable attorneys’ fees, charges and disbursements incurred by Landlord in connection with the retaking of the Premises and such reletting;

(c) Third, to the payment of Rent and other charges due and unpaid hereunder; and

(d) Fourth, to the payment of future Rent and other damages payable by Tenant under this Lease.

31.11. All of Landlord’s rights, options and remedies hereunder shall be construed and held to be nonexclusive and cumulative. Landlord shall have the right to pursue any one or all of such remedies, or any other remedy or relief that may be provided by Applicable Laws, whether or not stated in this Lease. No waiver of any default of Tenant hereunder shall be implied from any acceptance by Landlord of any Rent or other payments due hereunder or any omission by Landlord to take any action on account of such default if such default persists or is repeated, and no express waiver shall affect defaults other than as specified in such waiver. Notwithstanding any provision of this Lease to the contrary, in no event shall Landlord be required to mitigate its damages with respect to any default by Tenant, except as required by Applicable Laws. Any such obligation imposed by Applicable Laws upon Landlord to relet the Premises after any termination of this Lease shall be subject to the reasonable requirements of Landlord to (a) lease to high quality tenants on such terms as Landlord may from time to time deem appropriate in its discretion and (b) develop the Project in a harmonious manner with a mix of uses, tenants, floor areas, terms of tenancies, etc., as determined by Landlord. Landlord shall not be obligated to relet the Premises to (y) any Tenant’s Affiliate or (z) any party (i) unacceptable to a Lender, (ii) that requires Landlord to make improvements to or re-demise the Premises, (iii) that desires to change the Permitted Use, (iv) that desires to lease the Premises for more or less than the remaining Term or (v) to whom Landlord or an affiliate of Landlord may desire to lease other available space in the Project or at another property owned by Landlord or an affiliate of Landlord.

31.12. Landlord’s termination of (a) this Lease or (b) Tenant’s right to possession of the Premises shall not relieve Tenant of any liability to Landlord that has previously accrued or that

57


shall arise based upon events that occurred prior to the later to occur of (y) the date of Lease termination and (z) the date Tenant surrenders possession of the Premises.

31.13. To the extent permitted by Applicable Laws, Tenant waives any and all rights of redemption granted by or under any present or future Applicable Laws if Tenant is evicted or dispossessed for any cause, or if Landlord obtains possession of the Premises due to Tenant’s default hereunder or otherwise.

31.14. Landlord shall not be in default or liable for damages under this Lease unless Landlord fails to perform obligations required of Landlord within a reasonable time, but in no event shall such failure continue for more than thirty (30) days after written notice from Tenant specifying the nature of Landlord’s failure; provided, however, that if the nature of Landlord’s obligation is such that more than thirty (30) days are required for its performance, then Landlord shall not be in default if Landlord commences performance within such thirty (30) day period and thereafter diligently prosecutes the same to completion; provided, further, that Landlord agrees to commence performance as soon as is reasonably practicable and thereafter diligently prosecute the same to completion. In no event shall Tenant have the right to terminate or cancel this Lease or to withhold or abate rent or to set off any Claims against Rent as a result of any default or breach by Landlord of any of its covenants, obligations, representations, warranties or promises hereunder, except as may otherwise be expressly set forth in this Lease.

31.15. In the event of any default by Landlord, Tenant shall give notice by registered or certified mail or overnight delivery with a reputable overnight delivery service to any (a) beneficiary of a deed of trust or (b) mortgagee under a mortgage covering the Premises, the Building or the Project and to any landlord of any lease of land upon or within which the Premises, the Building or the Project is located, and shall offer such beneficiary, mortgagee or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Building or the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided that Landlord shall furnish to Tenant in writing, upon written request (which may be via email) by Tenant, the names and addresses of all such persons who are to receive such notices and any updates thereto throughout the Term of this Lease.

32. Bankruptcy . In the event a debtor, trustee or debtor in possession under the Bankruptcy Code, or another person with similar rights, duties and powers under any other Applicable Laws, proposes to cure any default under this Lease or to assume or assign this Lease and is obliged to provide adequate assurance to Landlord that (a) a default shall be cured, (b) Landlord shall be compensated for its damages arising from any breach of this Lease and (c) future performance of Tenant’s obligations under this Lease shall occur, then such adequate assurances shall include any or all of the following, as designated by Landlord in its sole and absolute discretion:

32.1. Those acts specified in the Bankruptcy Code or other Applicable Laws as included within the meaning of “adequate assurance,” even if this Lease does not concern a shopping center or other facility described in such Applicable Laws;

32.2. A prompt cash payment to compensate Landlord for any monetary defaults or actual damages arising directly from a breach of this Lease;

58


32.3. A cash deposit in an amount at least equal to the then-current amount of the Security Deposit; or

32.4. The assumption or assignment of all of Tenant’s interest and obligations under this Lease.

33. Brokers.

33.1 Each party represents and warrants that it has had no dealings with any real estate broker or agent in connection with the negotiation of this Lease other than Newmark and CBRE (collectively, the “Brokers”), and that it knows of no other real estate broker or agent that is or might be entitled to a commission in connection with this Lease. Landlord shall compensate Brokers in relation to this Lease pursuant to a separate agreements between Landlord and Brokers.

33.2 Tenant represents and warrants that no broker or agent has made any representation or warranty relied upon by Tenant in Tenant’s decision to enter into this Lease, other than as contained in this Lease.

33.3 Tenant acknowledges and agrees that the employment of brokers by Landlord is for the purpose of solicitation of offers of leases from prospective tenants and that no authority is granted to any broker to furnish any representation (written or oral) or warranty from Landlord unless expressly contained within this Lease. Landlord is executing this Lease in reliance upon Tenant’s representations, warranties and agreements contained within Sections 33.1 and 33.2.

33.4 Tenant agrees to Indemnify the Landlord Indemnitees from any and all cost or liability for compensation claimed by any broker or agent, other than Brokers, employed or engaged by Tenant or claiming to have been employed or engaged by Tenant.

33.5 Landlord agrees to Indemnify the Tenant harmless from any and all cost or liability for compensation claimed by any broker or agent, other than Broker, employees or engaged by Landlord or claiming to have been employed or engaged by Landlord.

 

34. Definition of Landlord. With regard to obligations imposed upon Landlord pursuant to this Lease, the term “Landlord,” as used in this Lease, shall refer only to Landlord or Landlord’s then-current successor-in-interest. In the event of any transfer, assignment or conveyance of Landlord’s interest in this Lease or in Landlord’s fee title to or leasehold interest in the Property, as applicable, Landlord herein named (and in case of any subsequent transfers or conveyances, the subsequent Landlord) shall be automatically freed and relieved, from and after the date of such transfer, assignment or conveyance, from all liability for the performance of any covenants or obligations contained in this Lease thereafter to be performed by Landlord and, without further agreement, the transferee, assignee or conveyee of Landlord’s in this Lease or in Landlord’s fee title to or leasehold interest in the Property, as applicable, shall be deemed to have assumed and agreed to observe and perform any and all covenants and obligations of Landlord hereunder during the tenure of its interest in the Lease or the Property. Landlord or any subsequent Landlord may transfer its interest in the Premises or this Lease without Tenant’s consent; provided, however, Landlord shall notify Tenant of any such transfer and include contact information and payment information for such transferee. Subject to the provisions of Article 11 hereof, Tenant shall not be

59


liable, nor shall Tenant be deemed in default, for any Rent or Security Deposit paid to Landlord and not transferred or credited to Landlord’s transferee, prior to receipt of notice from Landlord.

35. Limitation of Landlord’s Liability.

35.1 If Landlord is in default under this Lease and, as a consequence, Tenant recovers a monetary judgment against Landlord, the judgment shall be satisfied only out of (a) the proceeds of sale received on execution of the judgment and levy against the right, title and interest of Landlord in the Building and the Project, (b) rent or other income from such real property receivable by Landlord or (c) the consideration received by Landlord from the sale, financing, refinancing or other disposition of all or any part of Landlord’s right, title or interest in the Building or the Project.

35.2 Neither Landlord nor any of its affiliates, nor any of their respective partners, shareholders, directors, officers, employees, members or agents shall be personally liable for Landlord’s obligations or any deficiency under this Lease, and service of process shall not be made against any shareholder, director, officer, employee or agent of Landlord or any of Landlord’s affiliates. No partner, shareholder, director, officer, employee, member or agent of Landlord or any of its affiliates shall be sued or named as a party in any suit or action, and service of process shall not be made against any partner or member of Landlord except as may be necessary to secure jurisdiction of the partnership, joint venture or limited liability company, as applicable. No partner, shareholder, director, officer, employee, member or agent of Landlord or any of its affiliates shall be required to answer or otherwise plead to any service of process, and no judgment shall be taken or writ of execution levied against any partner, shareholder, director, officer, employee, member or agent of Landlord or any of its affiliates.

35.3 Each of the covenants and agreements of this Article shall be applicable to any covenant or agreement either expressly contained in this Lease or imposed by Applicable Laws and shall survive the expiration or earlier termination of this Lease.

36. Joint and Several Obligations. If more than one person or entity executes this Lease as Tenant, then:

36.1. Each of them is jointly and severally liable for the keeping, observing and performing of all of the terms, covenants, conditions, provisions and agreements of this Lease to be kept, observed or performed by Tenant, and such terms, covenants, conditions, provisions and agreements shall be binding with the same force and effect upon each and all of the persons executing this Agreement as Tenant; and

36.2. The term “Tenant,” as used in this Lease, means and includes each of them, jointly and severally. The act of, notice from, notice to, refund to, or signature of any one or more of them with respect to the tenancy under this Lease, including any renewal, extension, expiration, termination or modification of this Lease, shall be binding upon each and all of the persons executing this Lease as Tenant with the same force and effect as if each and all of them had so acted, so given or received such notice or refund, or so signed.

37. Representations. Tenant guarantees, warrants and represents that (a) Tenant is duly incorporated or otherwise established or formed and validly existing under the laws of its state of

60


incorporation, establishment or formation, (b) Tenant has and is duly qualified to do business in the state in which the Property is located, (c) Tenant has full corporate, partnership, trust, association or other appropriate power and authority to enter into this Lease and to perform all Tenant’s obligations hereunder, (d) each person (and all of the persons if more than one signs) signing this Lease on behalf of Tenant is duly and validly authorized to do so and (e) neither (i) the execution, delivery or performance of this Lease nor (ii) the consummation of the transactions contemplated hereby will violate or conflict with any provision of documents or instruments under which Tenant is constituted or to which Tenant is a party. In addition, Tenant guarantees, warrants and represents that none of (x) it, (y) its affiliates or partners nor (z) to the best of its knowledge, its members, shareholders or other equity owners or any of their respective employees, officers, directors, representatives or agents is a person or entity with whom U.S. persons or entities are restricted from doing business under regulations of the Office of Foreign Asset Control (“OFAC”) of the Department of the Treasury (including those named on OFAC’s Specially Designated and Blocked Persons List) or under any statute, executive order (including the September 24, 2001, Executive Order Blocking Property and Prohibiting Transactions with Persons Who Commit, Threaten to Commit, or Support Terrorism) or other similar governmental action.

38. Confidentiality. Tenant shall keep the terms and conditions of this Lease and any information provided to Tenant or its employees, agents or contractors pursuant to Article 9 confidential and shall not (a) disclose to any third party any terms or conditions of this Lease or any other Lease-related document (including subleases, assignments, work letters, construction contracts, letters of credit, subordination agreements, non-disturbance agreements, brokerage agreements or estoppels) or the contents of any documents, reports, surveys or evaluations related to the Project or any portion thereof or (b) provide to any third party an original or copy of this Lease (or any Lease-related document or other document referenced in Subsection 38(a)). Landlord shall not release to any third party any non-public financial information or non-public information about Tenant’s ownership structure that Tenant gives Landlord. Notwithstanding the foregoing, confidential information under this Section may be released by Landlord or Tenant under the following circumstances: (w) if required by Applicable Laws or in any judicial proceeding; provided that the releasing party has given the other party reasonable notice of such requirement, if feasible, (x) to a party’s attorneys, accountants, brokers, lenders, potential lenders, investors, potential investors and other bona fide consultants or advisers (with respect to this Lease only); provided such third parties agree to be bound by this Section, (y) to a party’s lenders for purposes of financial reporting or (z) to bona fide prospective assignees or subtenants of this Lease; provided they agree in writing to be bound by this Section. Landlord agrees that a breach of such confidentiality may cause Tenant harm for which recovery of damages would be an inadequate remedy, and in such event, Tenant shall be entitled to seek injunctive relief, as well as such further relief as may be granted by a court of competent jurisdiction, but excluding special, punitive, exemplary, indirect or consequential damages, including lost profits.

39. Notices. Except as otherwise stated in this Lease, any notice, consent, demand, invoice, statement or other communication required or permitted to be given hereunder shall be in writing and shall be given by (a) personal delivery, (b) overnight delivery with a reputable international overnight delivery service, such as FedEx, or (c) email transmission, so long as such transmission is followed within one (1) business day by delivery utilizing one of the methods described in Subsection 39(a) or (b), provided that, for purposes of this Subsection 39(c), if delivery utilizing one of the other methods described in Subsection 39(a) or (b) is not reasonably practicable due to

61


an event of Force Majeure (as defined below), then such requirement shall be waived for deliveries by email transmission so long as either the receiving party responds to the sending party confirming receipt of the applicable email transmission, or the sending party receives other electronic confirmation that the email transmission was received and read by the receiving party, such as a “read receipt” notice. Any such notice, consent, demand, invoice, statement or other communication shall be deemed delivered (x) upon receipt, if given in accordance with Subsection 39(a); (y) one (1) business day after deposit with a reputable international overnight delivery service, if given in accordance with Subsection 39(b); or (z) upon transmission, if given in accordance with Subsection 39(c). Except as otherwise stated in this Lease, any notice, consent, demand, invoice, statement or other communication required or permitted to be given pursuant to this Lease shall be addressed to Tenant at the Premises, or to Landlord or Tenant at the addresses shown in Sections 2.9 and 2.10 or 2.11, respectively. Either party may, by notice to the other given pursuant to this Section, specify additional or different addresses for notice purposes.

40. Miscellaneous.

40.1. Landlord reserves the right to change the name of the Building or the Project in its sole discretion.

40.2. To induce Landlord to enter into this Lease, Tenant agrees that it shall furnish to Landlord, from time to time, within ten (10) business days after receipt of Landlord’s written request, the most recent year-end unconsolidated financial statements reflecting Tenant’s current financial condition audited by a nationally recognized accounting firm. Tenant shall, within ninety (90) days after the end of Tenant’s financial year, furnish Landlord with a certified copy of Tenant’s year-end unconsolidated financial statements for the previous year audited by a nationally recognized accounting firm. Tenant represents and warrants that all financial statements, records and information furnished by Tenant to Landlord in connection with this Lease are true, correct and complete in all respects. If audited financials are not otherwise prepared, unaudited financials complying with generally accepted accounting principles and certified by the chief financial officer (or equivalent position) of Tenant as true, correct and complete in all respects shall suffice for purposes of this Section. The provisions of this Section shall not apply at any time while Tenant is a corporation whose shares are traded on any nationally recognized stock exchange. Tenant represents and warrants that all financial statements, records and information furnished by Tenant to Landlord in connection with the negotiation of this Lease are true, correct and complete in all respects.

40.3. Submission of this instrument for examination or signature by Tenant does not constitute a reservation of or option for a lease, and shall not be effective as a lease or otherwise until execution by and delivery to both Landlord and Tenant.

40.4. The terms of this Lease are intended by the parties as a final, complete and exclusive expression of their agreement with respect to the terms that are included herein, and may not be contradicted or supplemented by evidence of any other prior or contemporaneous agreement.

40.5. Upon the request of either Landlord or Tenant, the parties shall execute a document in recordable form containing only such information as is necessary to constitute a Notice of Lease

62


under Massachusetts law. All costs of preparing and recording such notice shall be borne by the requesting party. Within ten (10) days after receipt of written request from Landlord after the expiration or earlier termination of this Lease, Tenant shall execute a termination of any Notice of Lease recorded with respect hereto. Neither party shall record this Lease.

40.6. Where applicable in this Lease, the singular includes the plural and the masculine or neuter includes the masculine, feminine and neuter. The words “include,” “includes,” “included” and “including” mean “‘include,’ etc., without limitation.” The word “shall” is mandatory and the word “may” is permissive. The word “business day” means a calendar day other than any national or local holiday on which federal government agencies in the County of Suffolk are closed for business, or any weekend. The section headings of this Lease are not a part of this Lease and shall have no effect upon the construction or interpretation of any part of this Lease. Landlord and Tenant have each participated in the drafting and negotiation of this Lease, and the language in all parts of this Lease shall be in all cases construed as a whole according to its fair meaning and not strictly for or against either Landlord or Tenant.

40.7. Except as otherwise expressly set forth in this Lease, each party shall pay its own costs and expenses incurred in connection with this Lease and such party’s performance under this Lease; provided that, if either party commences an action, proceeding, demand, claim, action, cause of action or suit against the other party arising from or in connection with this Lease, then the substantially prevailing party shall be reimbursed by the other party for all reasonable costs and expenses, including reasonable attorneys’ fees and expenses, incurred by the substantially prevailing party in such action, proceeding, demand, claim, action, cause of action or suit, and in any appeal in connection therewith (regardless of whether the applicable action, proceeding, demand, claim, action, cause of action, suit or appeal is voluntarily withdrawn or dismissed). In addition, Landlord shall, upon demand, be entitled to all reasonable attorneys’ fees and all other reasonable out-of-pocket costs incurred in the preparation and service of any notice or demand hereunder, regardless of whether a legal action is subsequently commenced, or incurred in connection with any contested matter or other proceeding in bankruptcy court concerning this Lease.

40.8. Time is of the essence with respect to the performance of every provision of this Lease.

40.9. Each provision of this Lease performable by Tenant shall be deemed both a covenant and a condition.

40.10. Notwithstanding anything to the contrary contained in this Lease, Tenant’s obligations under this Lease are independent and shall not be conditioned upon performance by Landlord.

40.11. Any provision of this Lease that shall prove to be invalid, void or illegal shall in no way affect, impair or invalidate any other provision hereof, and all other provisions of this Lease shall remain in full force and effect and shall be interpreted as if the invalid, void or illegal provision did not exist.

63


40.12. Each of the covenants, conditions and agreements herein contained shall inure to the benefit of and shall apply to and be binding upon the parties hereto and their respective heirs; legatees; devisees; executors; administrators; and permitted successors and assigns. This Lease is for the sole benefit of the parties and their respective heirs, legatees, devisees, executors, administrators and permitted successors and assigns, and nothing in this Lease shall give or be construed to give any other person or entity any legal or equitable rights. Nothing in this Section shall in any way alter the provisions of this Lease restricting assignment or subletting.

40.13. This Lease shall be governed by, construed and enforced in accordance with the laws of the state in which the Premises are located, without regard to such state’s conflict of law principles.

40.14. Tenant guarantees, warrants and represents that the individual or individuals signing this Lease have the power, authority and legal capacity to sign this Lease on behalf of and to bind all entities, corporations, partnerships, limited liability companies, joint venturers or other organizations and entities on whose behalf such individual or individuals have signed.

40.15. This Lease may be executed in one or more counterparts, each of which, when taken together, shall constitute one and the same document.

40.16. No provision of this Lease may be modified, amended or supplemented except by an agreement in writing signed by Landlord and Tenant.

40.17. No waiver of any term, covenant or condition of this Lease shall be binding upon Landlord unless executed in writing by Landlord. The waiver by Landlord of any breach or default of any term, covenant or condition contained in this Lease shall not be deemed to be a waiver of any preceding or subsequent breach or default of such term, covenant or condition or any other term, covenant or condition of this Lease.

40.18. To the extent permitted by Applicable Laws, the parties waive trial by jury in any action, proceeding or counterclaim brought by the other party hereto related to matters arising from or in any way connected with this Lease; the relationship between Landlord and Tenant; Tenant’s use or occupancy of the Premises; or any claim of injury or damage related to this Lease or the Premises.

40.19. A facsimile, electronic or portable document format (PDF) signature on this Lease or any other document required or permitted by this Lease to be delivered by Landlord or Tenant shall be equivalent to, and have the same force and effect as, an original signature. This Lease may be executed by electronic signature, which shall be considered as an original signature for all purposes and shall have the same force and effect as an original signature. Without limiting the generality of the foregoing, in addition to electronically produced signatures, “electronic signature” shall include electronically scanned and transmitted versions (e.g., via PDF and/or DocuSign) of an original signature.

40.20. For purposes of this Lease, “Force Majeure” means accidents; breakage; casualties; Severe Weather Conditions (as defined below); physical natural disasters (but excluding weather conditions that are not Severe Weather Conditions); strikes, lockouts or other labor disturbances or labor disputes (other than labor disturbances and labor disputes resulting solely from the acts or

64


omissions of the party claiming Force Majeure); acts of terrorism; riots or civil disturbances; wars or insurrections; plagues, epidemics, pandemics, or public health crises (including regulations, actions or delays by Governmental Authorities resulting from any such plague, epidemic, pandemic or public health crisis); shortages of materials and supply chain disruptions (which shortages and disruptions are not unique to the party claiming Force Majeure); regulations, moratoria or other actions, inactions or delays by Governmental Authorities, provided that any delay by a Governmental Authority in issuing any required permit or approval is not caused by the failure of the party claiming Force Majeure to timely submit a complete application for such permit or approval in compliance with Applicable Laws; failures by third parties to deliver gas, oil or another suitable fuel supply, or inability of the party claiming Force Majeure, by exercise of reasonable diligence, to obtain gas, oil or another suitable fuel; or other causes beyond the reasonable control of the party claiming that Force Majeure has occurred. “Severe Weather Conditions” means weather conditions that are materially worse than those that would be reasonably anticipated for the Property at the applicable time based on historic meteorological records. Notwithstanding anything in this Lease to the contrary, events of Force Majeure shall excuse timely performance of a party hereunder (other than either party’s obligation to pay any amounts hereunder, which shall not be excused by Force Majeure) for a period equal to the delay caused thereby and, therefore, if this Lease specifies a time period for performance of an obligation of either party, that time period shall be extended by the period of any delay in such party’s performance caused by an event of Force Majeure. Each party claiming any delay as a result of Force Majeure shall notify the other party in writing within ten (10) business days after it acquires actual knowledge of the event constituting an event of Force Majeure, which written notice shall state in reasonable detail the nature of such event, the reason(s) that such event constitutes an event of Force Majeure, and the manner in which such event has or will delay performance of the claiming party’s obligations hereunder.

41. Rooftop Installation Area.

41.1. Tenant shall not have the right to install any equipment on the roof of the Building without Landlord’s consent in its sole discretion. In the event that Landlord identifies portions of the Building (the “Rooftop Installation Area”) to be used to operate, maintain, repair and replace rooftop antennae, mechanical equipment, communications antennas and other equipment installed by Tenant in the Rooftop Installation Area (“Tenant’s Rooftop Equipment”), the the provisions of this Article shall apply. Tenant’s Rooftop Equipment shall be only for Tenant’s use of the Premises for the Permitted Use.

41.2. Tenant shall install Tenant’s Rooftop Equipment at its sole cost and expense, at such times and in such manner as Landlord may reasonably designate, and in accordance with this Article and the applicable provisions of this Lease regarding Alterations. Tenant’s Rooftop Equipment and the installation thereof shall be subject to Landlord’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed. Among other reasons, Landlord may withhold approval if the installation or operation of Tenant’s Rooftop Equipment could reasonably be expected to damage the structural integrity of the Building or to transmit vibrations or noise or cause other adverse effects beyond the Premises to an extent not customary in first class laboratory buildings, unless Tenant implements measures that are acceptable to Landlord in its reasonable discretion to avoid any such damage or transmission.

65


41.3. Tenant shall comply with any roof or roof-related warranties. Tenant shall obtain a letter from Landlord’s roofing contractor within thirty (30) days after completion of any Tenant work on the rooftop stating that such work did not affect any such warranties. Tenant, at its sole cost and expense, shall inspect the Rooftop Installation Area at least annually, and correct any loose bolts, fittings or other appurtenances and repair any damage to the roof arising from the installation or operation of Tenant’s Rooftop Equipment. Tenant shall not permit the installation, maintenance or operation of Tenant’s Rooftop Equipment to violate any Applicable Laws or constitute a nuisance. Tenant shall pay Landlord within thirty (30) days after demand (a) all applicable taxes, charges, fees or impositions imposed on Landlord by Governmental Authorities as the result of Tenant’s use of the Rooftop Installation Areas in excess of those for which Landlord would otherwise be responsible for the use or installation of Tenant’s Rooftop Equipment and (b) the amount of any increase in Landlord’s insurance premiums as a result of the installation of Tenant’s Rooftop Equipment. Upon Tenant’s written request to Landlord, Landlord shall use commercially reasonable efforts to cause other tenants to remedy any interference in the operation of Tenant’s Rooftop Equipment arising from any such tenants’ equipment installed after the applicable piece of Tenant’s Rooftop Equipment; provided, however, that Landlord shall not be required to request that such tenants waive their rights under their respective leases.

41.4. If Tenant’s Equipment (a) causes physical damage to the structural integrity of the Building, (b) interferes with any telecommunications, mechanical or other systems located at or near or servicing the Building or the Project that were installed prior to the installation of Tenant’s Rooftop Equipment, (c) interferes with any other service provided to other tenants in the Building or the Project by rooftop or penthouse installations that were installed prior to the installation of Tenant’s Rooftop Equipment or (d) interferes with any other tenants’ business, in each case in excess of that permissible under Federal Communications Commission regulations, then Tenant shall cooperate with Landlord to determine the source of the damage or interference and promptly repair such damage and eliminate such interference, in each case at Tenant’s sole cost and expense, within ten (10) days after receipt of notice of such damage or interference (which notice may be oral; provided that Landlord also delivers to Tenant written notice of such damage or interference within twenty-four (24) hours after providing oral notice).

41.5. Landlord reserves the right to cause Tenant to relocate Tenant’s Rooftop Equipment to comparably functional space on the roof or in the penthouse of the Building by giving Tenant at lease sixty (60) days’ prior written notice thereof. Landlord agrees to pay the reasonable costs thereof. Tenant shall arrange for the relocation of Tenant’s Rooftop Equipment within sixty (60) days after receipt of Landlord’s notification of such relocation. In the event Tenant fails to arrange for relocation within such sixty (60)-day period, Landlord shall have the right to arrange for the relocation of Tenant’s Rooftop Equipment in a manner that does not unnecessarily interrupt or interfere with Tenant’s use of the Premises for the Permitted Use.

42. Option to Extend Term. Tenant shall have one (1) option (“Option”) to extend the Term by five (5) years as to the entire Premises (and no less than the entire Premises) upon the following terms and conditions, provided that Tenant has not assigned or sublet fifty percent (50%) or more of the Premises, except pursuant to an Exempt Transfer, on the date the Option is exercised and

66


on the commencement of the Option term. Any extension of the Term pursuant to the Option shall be on all the same terms and conditions as this Lease, except as follows:

42.1. Base Rent at the commencement of the Option term shall equal the greater of (a) the then-current Base Rent and (b) the then-current fair market value for comparable office and laboratory space in the Boston market of comparable age, quality, level of finish and proximity to amenities and public transit, and containing the systems and improvements present in the Premises as of the date that Tenant gives Landlord written notice of Tenant’s election to exercise the Option (“FMV”), and shall be further increased on each annual anniversary of the Option term commencement date by FMV escalations. Tenant may, no more than twelve (12) months prior to the date the Term is then scheduled to expire, request Landlord’s estimate of the FMV for the Option term. Landlord shall, within fifteen (15) days after receipt of such request, give Tenant a written proposal of such FMV. If Tenant gives written notice to exercise the Option, such notice shall specify whether Tenant accepts Landlord’s proposed estimate of FMV. If Tenant does not accept the FMV, then the parties shall endeavor to agree upon the FMV, taking into account all relevant factors, including (v) the size of the Premises, (w) the length of the Option term, (x) rent in comparable buildings in the relevant market, including concessions offered to new tenants, such as free rent, tenant improvement allowances and moving allowances, (y) Tenant’s creditworthiness and (z) the quality and location of the Building and the Project. In the event that the parties are unable to agree upon the FMV within thirty (30) days after Tenant notifies Landlord that Tenant is exercising the Option, then either party may request that the same be determined as follows: a senior officer of a nationally recognized leasing brokerage firm with local knowledge of the Boston laboratory/research and development leasing market (the “Baseball Arbitrator”) shall be selected and paid for jointly by Landlord and Tenant. If Landlord and Tenant are unable to agree upon the Baseball Arbitrator, then the same shall be designated by the local chapter of the Judicial Arbitration and Mediation Services or any successor organization thereto (the “JAMS”). The Baseball Arbitrator selected by the parties or designated by JAMS shall (y) have at least ten (10) years’ experience in the leasing of laboratory/research and development space in the Boston market and (z) not have been employed or retained by either Landlord or Tenant or any affiliate of either for a period of at least ten (10) years prior to appointment pursuant hereto. Each of Landlord and Tenant shall submit to the Baseball Arbitrator and to the other party its determination of the FMV. The Baseball Arbitrator shall grant to Landlord and Tenant a hearing and the right to submit evidence. The Baseball Arbitrator shall determine which of the two (2) FMV determinations more closely represents the actual FMV. The arbitrator may not select any other FMV for the Premises other than one submitted by Landlord or Tenant. The FMV selected by the Baseball Arbitrator shall be binding upon Landlord and Tenant and shall serve as the basis for determination of Base Rent payable for the Option term. If, as of the commencement date of the Option term, the amount of Base Rent payable during the Option term shall not have been determined, then, pending such determination, Tenant shall pay Base Rent equal to the Base Rent payable with respect to the last year of the then-current Term. After the final determination of Base Rent payable for the Option term, the parties shall promptly execute a written amendment to this Lease specifying the amount of Base Rent to be paid during the Option term. Any failure of the parties to execute such amendment shall not affect the validity of the FMV determined pursuant to this Section.

42.2. The Option is not assignable separate and apart from this Lease.

67


42.3. The Option is conditional upon Tenant giving Landlord written notice of its election to exercise the Option at least twelve (12) months prior to the end of the expiration of the then-current Term. Time shall be of the essence as to Tenant’s exercise of the Option. Tenant assumes full responsibility for maintaining a record of the deadlines to exercise the Option. Tenant acknowledges that it would be inequitable to require Landlord to accept any exercise of the Option after the date provided for in this Section.

42.4. Notwithstanding anything contained in this Article to the contrary, Tenant shall not have the right to exercise the Option:

(a) During the time commencing from the date Landlord delivers to Tenant a written notice that Tenant is in default under any provisions of this Lease and continuing until Tenant has cured the specified default to Landlord’s reasonable satisfaction; or

(b) At any time after any Default as described in Article 31 of the Lease (provided, however, that, for purposes of this Section 42.4(b), Landlord shall not be required to provide Tenant with notice of such Default) and continuing until Tenant cures any such Default, if such Default is susceptible to being cured; or

42.5. The period of time within which Tenant may exercise the Option shall not be extended or enlarged by reason of Tenant’s inability to exercise such Option because of the provisions of Section 42.4.

42.6. All of Tenant’s rights under the provisions of the Option shall terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Option if, after such exercise, but prior to the commencement date of the new term, (a) Tenant fails to pay to Landlord a monetary obligation of Tenant for a period of twenty (20) days after written notice from Landlord to Tenant, or (b) Tenant fails to commence to cure a default (other than a monetary default) within thirty (30) days after the date Landlord gives notice to Tenant of such default.

43. Right of First Offer. For so long as Tenant leases Premises equal to at least 63,327 square feet of Rentable Area in the Building, and personally occupies at least Seventy-Five Percent (75%) of the Premises so leased, and subject to any other parties’ pre-existing rights with respect to Available ROFO Premises (as defined below), Tenant shall have a one-time right of first offer (“ROFO”) as to each full floor that is contiguous to the Premises in the Building (i.e., the 11th floor and the 8th floor) for which Landlord is seeking a tenant after the initial lease-up of the same (“Available ROFO Premises”); provided, however, that in no event shall Landlord be required to lease any Available ROFO Premises to Tenant for any period past the date on which this Lease expires or is terminated pursuant to its terms. To the extent that Landlord renews or extends a then-existing lease with any then-existing tenant or subtenant of any space, or enters into a new lease with such then-existing tenant or subtenant, the affected space shall not be deemed to be Available ROFO Premises. In the event Landlord intends to market Available ROFO Premises, Landlord shall provide written notice thereof to Tenant (the “Notice of Marketing”).

43.1. Within ten (10) days following its receipt of a Notice of Marketing, Tenant shall advise Landlord in writing whether Tenant elects to lease all (not just a portion) of the Available ROFO Premises and on what terms and conditions. If Tenant fails to notify Landlord of Tenant’s

68


election within such ten (10) day period, then Tenant shall be deemed to have elected not to lease the Available ROFO Premises.

43.2. If Tenant timely notifies Landlord that Tenant elects to lease all of the Available ROFO Premises and of the terms and conditions therefore (“Tenant’s Offer”) (provided that Tenant shall be required to lease the Available ROFO Premises for at least the remainder of the then-current Term), then Landlord shall have ten (10) days after receipt of Tenant’s Offer to respond to Tenant in writing whether Landlord elects to lease the Available ROFO Premises to Tenant on the terms and conditions set forth in Tenant’s Offer. If Tenant timely delivers Tenant’s Offer and Landlord elects to lease the Available ROFO Premises to Tenant on the terms and conditions set forth in Tenant’s Offer, then Landlord shall lease the Available ROFO Premises to Tenant upon the terms and conditions set forth in Tenant’s Offer.

43.3. If (a) Tenant notifies Landlord that Tenant elects not to lease the Available ROFO Premises, (b) Tenant fails to notify Landlord of Tenant’s election within the ten (10)-day period described above or (c) Landlord declines to lease the Available ROFO Premises to Tenant on the terms and conditions set forth in Tenant’s Offer, then Landlord shall have the right to consummate a lease of the Available ROFO Premises at base rent not less than eighty-five percent (85%) of that stated in Tenant’s Offer, if applicable.

43.4. Notwithstanding anything in this Article to the contrary, Tenant shall not exercise the ROFO during such period of time that Tenant is in default under any provision of this Lease. Any attempted exercise of the ROFO during a period of time in which Tenant is so in default shall be void and of no effect. In addition, Tenant shall not be entitled to exercise the ROFO if Landlord has given Tenant two (2) or more notices of default under this Lease, whether or not the defaults are cured, during the twelve (12) month period prior to the date on which Tenant seeks to exercise the ROFO.

43.5. Notwithstanding anything in this Lease to the contrary, Tenant shall not assign or transfer the ROFO, either separately or in conjunction with an assignment or transfer of Tenant’s interest in the Lease, without Landlord’s prior written consent, which consent Landlord may withhold in its sole and absolute discretion.

43.6. If Tenant exercises the ROFO, Landlord does not guarantee that the Available ROFO Premises will be available on the anticipated commencement date for the Lease as to such Premises due to a holdover by the then-existing occupants of the Available ROFO Premises or for any other reason beyond Landlord’s reasonable control.

 

[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]

69


IN WITNESS WHEREOF, the parties hereto have executed this Lease as a sealed Massachusetts instrument as of the date first above written.

LANDLORD:

B9 LS HARRISON & WASHINGTON LLC,

a Delaware limited liability company

 

 

By: /s/ Colleen O’Connor

Name: Colleen O’Connor

Title: VP Leasing – East Coast & UK Markets

 

TENANT:

MONTE ROSA THERAPEUTICS, INC.,

a Delaware corporation

 

 

By: /s/ Markus Warmuth

Name: Markus Warmuth

Title: President & CEO

 

1


EXHIBIT A

PREMISES

 

[ATTACHED]

 

2


EXHIBIT A-1

PROPERTY

A certain parcel of land with the buildings thereon numbered 311-321 Harrison Avenue, situated in the City of Boston, County of Suffolk in the Commonwealth of Massachusetts, which Parcel is shown on a Plan by BSC Group, entitled, “Consolidation Plan of Land; 311-321 Harrison Avenue in Boston, Massachusetts (Suffolk County)”, dated August 21, 2006 and recorded with the Suffolk Registry of Deeds as Plan No. 882 of 2006, and bounded and described as follows:

 

Beginning at the Southwest corner of the Parcel, said corner being the intersection of the Easterly

line of Washington Street with the Northerly line of William E. Mullins Way, said point being the point of Beginning; thence

 

N 14° 58' 41" E a distance of one hundred twelve and ten hundredths feet (112.10) to a point;

thence

 

S 73° 22' 25" E a distance of five and three hundredths feet (5.03) to a point; thence

 

N 10° 15' 59" E a distance of twenty-four and fourteen hundredths feet (24.14) to a point; thence

 

N 10° 19' 19" E a distance of one hundred twenty and eighty hundredths feet (120.80) to a point of curvature;

 

The Previous four (4) Courses Bounding on the Easterly line of said Washington Street; thence

 

Northeasterly and curving to the right along the arc of a curve having a radius of twenty and no

hundredths feet (20.00), a length of thirty-three and five hundredths feet (33.05) to a point on the

Southerly sideline of Herald Street; thence

 

S 74° 59' 19" E a distance of two hundred sixty-two and fifty-five hundredths feet (262.55) along

said Southerly line of Herald Street to a point of curvature; thence

 

Southeasterly and curving to the right along the arc of a curve having a radius of Twenty and no

hundredths feet (20.00), a length of thirty-one and eighty-six hundredths feet (31.86) to a point on the Westerly sideline of Harrison Street; thence

 

S 16° 17' 05" W a distance of one hundred ninety-two and twenty-nine hundredths feet (192.29) to a point; thence

 

S 72° 50' 03" E a distance of ten and no hundredths feet (10.00) to a point; thence

 

S 16° 17' 05" W a distance of nineteen and thirty-one hundredths feet (19.31) to a point; thence

 

N 72° 45' 55" W a distance of ten and no hundredths feet (10.00) to a point; thence

S 16° 17' 05" W a distance of thirty-eight and no hundredths feet (38.00) to a point of curvature;

 

The Previous five (5) Courses Bounding on said Westerly line of Harrison Avenue; thence

 

1


Southwesterly and curving to the right along the arc of a curve having a radius of twenty and no

hundredths feet (20.00), a length of thirty-one and eighty-two hundredths feet (31.82) to a point on the Northerly line of William E. Mullins Way; thence

 

N 72° 33' 10" W a distance of two hundred sixty-nine and forty-two hundredths feet (269.42) along said Northerly line of William E. Mullins way to the point of beginning.

 

A portion of the above described parcel (Tract I, Parcel D) is registered land and is shown on Land Court Plan Number 2213A.

 

2


 

EXHIBIT A-2

LAB AND OFFICE ZONES

[N/A]

 

3


 

EXHIBIT B

WORK LETTER

This Work Letter (this “Work Letter”) is made and entered into as of the 14th day of December, 2021, by and between B9 LS HARRISON & WASHINGTON LLC, a Delaware limited liability company (“Landlord”), and MONTE ROSA THERAPEUTICS, INC., a Delaware corporation (“Tenant”), and is attached to and made a part of that certain Lease dated as of December 14, 2021 (as the same may be amended, amended and restated, supplemented or otherwise modified from time to time, the “Lease”), by and between Landlord and Tenant for the Premises located at 321 Harrison Boulevard, Boston, Massachusetts. All capitalized terms used but not otherwise defined herein shall have the meanings given them in the Lease.

 

1. General Requirements.

1.1. Authorized Representatives.

(a) Landlord designates, as Landlord’s authorized representative (“Landlord’s Authorized Representative”), (i) Joe Imparato as the person authorized to initial plans, drawings, approvals and to sign change orders pursuant to this Work Letter and (ii) an officer of Landlord as the person authorized to sign any amendments to this Work Letter or the Lease. Tenant shall not be obligated to respond to or act upon any such item until such item has been initialed or signed (as applicable) by the appropriate Landlord’s Authorized Representative. Landlord may change either Landlord’s Authorized Representative upon one (1) business day’s prior written notice to Tenant.

(b) Tenant designates Jennifer Champoux, Vice President, Operations (“Tenant’s Authorized Representative”) as the person authorized to initial and sign all plans, drawings, change orders and approvals pursuant to this Work Letter. Landlord shall not be obligated to respond to or act upon any such item until such item has been initialed or signed (as applicable) by Tenant’s Authorized Representative. Tenant may change Tenant’s Authorized Representative upon one (1) business day’s prior written notice to Landlord.

1.2. Schedule. The schedule for design and development of the Tenant Improvements, including the time periods for preparation and review of construction documents, approvals and performance, shall be in accordance with a schedule to be prepared by Tenant (the “Schedule”). Tenant shall prepare the Schedule so that it is a reasonable schedule for the completion of the Tenant Improvements. The Schedule shall clearly identify all activities requiring Landlord participation, including specific dates and time periods when Tenant’s contractor will require access to areas of the Project outside of the Premises. As soon as the Schedule is completed, Tenant shall deliver the same to Landlord for Landlord’s approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such Schedule shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord disapproves the Schedule, then Landlord shall notify Tenant in writing of its objections to such Schedule, and the parties shall confer and negotiate in good faith to reach agreement on the

4


 

Schedule. The Schedule shall be subject to adjustment as mutually agreed upon in writing by the parties, or as provided in this Work Letter.

1.3. Tenant’s Architects, Contractors and Consultants. The architect, engineering consultants, design team, general contractor and subcontractors responsible for the construction of the Tenant Improvements shall be selected by Tenant and approved by Landlord, which approval Landlord shall not unreasonably withhold, condition or delay. Landlord has approved PIDC Construction as Tenant’s general contractor and Landlord has preapproved Symmes Maini and McKee Associates and Jacobs as architects (with final architect selection to be made by Tenant). Landlord may refuse to use any architects, consultants, contractors, subcontractors or material suppliers that Landlord reasonably believes could cause labor disharmony or may not have sufficient experience, in Landlord’s reasonable opinion, to perform work in an occupied Class “A” laboratory research building and in lab areas. All Tenant contracts related to the Tenant Improvements shall provide that Tenant may assign such contracts and any warranties with respect to the Tenant Improvements to Landlord and Landlord’s tenants at any time.

2. Tenant Improvements. All Tenant Improvements shall be performed by Tenant’s contractor, at Tenant’s sole cost and expense (subject to Landlord’s obligations with respect to any portion of the Base TI Allowance and, if properly requested by Tenant pursuant to the terms of the Lease, the Additional TI Allowance and in accordance with the Approved Plans (as defined below), the Lease and this Work Letter, provided that any vivarium shown on the Approved Plans shall not exceed ten percent (10%) of rentable area of the Premises. To the extent that the total projected cost of the Tenant Improvements (as projected by Landlord) exceeds the TI Allowance (such excess, the “Excess TI Costs”), Tenant shall pay the costs of the Tenant Improvements on a pari passu basis with Landlord as such costs become due, in the proportion of Excess TI Costs payable by Tenant to the Base TI Allowance and, if properly requested by Tenant pursuant to the terms of the Lease, the Additional TI Allowance payable by Landlord. If the cost of the Tenant Improvements (as projected by Landlord) increases over Landlord’s initial projection, then Landlord may notify Tenant and Tenant shall pay any additional Excess TI Costs with Landlord in the same way that Tenant deposited the initial Excess TI Costs. If Tenant fails to pay, or is late in paying, any sum due to Landlord under this Work Letter, then Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including the right to interest and the right to assess a late charge), and for purposes of any litigation instituted with regard to such amounts the same shall be considered Rent. All material and equipment furnished by Tenant or its contractors as the Tenant Improvements shall be new or “like new;” the Tenant Improvements shall be performed in a first-class, workmanlike manner; and the quality of the Tenant Improvements shall be of a nature and character not less than the Building Standard. Tenant shall take, and shall its contractors to take, commercially reasonable steps to protect the Premises during the performance of any Tenant Improvements, including covering or temporarily removing any window coverings so as to guard against dust, debris or damage. All Tenant Improvements shall be performed in accordance with Article 17 of the Lease; provided that, notwithstanding anything in the Lease or this Work Letter to the contrary, in the event of a conflict between this Work Letter and Article 17 of the Lease, the terms of this Work Letter shall govern.

2.1. Work Plans. Tenant shall prepare and submit to Landlord for approval schematics covering the Tenant Improvements prepared in conformity with the applicable provisions of this Work Letter (the “Draft Schematic TI Plans”). The Draft Schematic TI Plans shall contain

5


 

sufficient information and detail to accurately describe the proposed design to Landlord and such other information as Landlord may reasonably request. Landlord shall notify Tenant in writing within ten (10) business days after receipt of the Draft Schematic TI Plans whether Landlord approves or objects to the Draft Schematic TI Plans and of the manner, if any, in which the Draft Schematic TI Plans are unacceptable. Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord reasonably objects to the Draft Schematic TI Plans, then Tenant shall revise the Draft Schematic TI Plans and cause Landlord’s objections to be remedied in the revised Draft Schematic TI Plans. Tenant shall then resubmit the revised Draft Schematic TI Plans to Landlord for approval, such approval not to be unreasonably withheld, conditioned or delayed. Landlord’s approval of or objection to revised Draft Schematic TI Plans and Tenant’s correction of the same shall be in accordance with this Section until Landlord has approved the Draft Schematic TI Plans in writing or been deemed to have approved them. The iteration of the Draft Schematic TI Plans that is approved or deemed approved by Landlord without objection shall be referred to herein as the “Approved Schematic TI Plans.”

2.2. Construction TI Plans. Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic TI Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) TI Changes (as defined below). As soon as such final plans and specifications (“Construction TI Plans”) are completed, Tenant shall deliver the same to Landlord for Landlord’s approval, which approval shall not be unreasonably withheld, conditioned or delayed. Such Construction TI Plans shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction TI Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction TI Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction TI Plans. Promptly after the Construction TI Plans are approved by Landlord and Tenant, two (2) copies of such Construction TI Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction TI Plans to all appropriate Governmental Authorities for approval. The Construction TI Plans so approved, and all change orders specifically permitted by this Work Letter, are referred to herein as the “Approved TI Plans.”

2.3. Changes to the Tenant Improvements. Any changes to the Approved TI Plans (each, a “TI Change”) shall be requested and instituted in accordance with the provisions of this Article 3 and shall be subject to the written approval of the non-requesting party in accordance with this Work Letter.

(a) TI Change Request. Either Landlord or Tenant may request TI Changes after Landlord approves the Approved TI Plans by notifying the other party thereof in writing in substantially the same form as the AIA standard change order form (a “TI Change Request”), which TI Change Request shall detail the nature and extent of any requested TI Changes, including (a) the TI Change, (b) the party required to perform the TI Change and (c) any modification of the Approved TI Plans and the Schedule, as applicable, necessitated by the TI Change. If the nature of a TI Change requires revisions to the Approved TI Plans, then the requesting party shall be solely responsible for the cost and expense of such revisions and any increases in the cost of the Tenant Improvements as a result of such Change. TI Change Requests shall be signed by the requesting party’s Authorized Representative.

6


 

(b) Approval of TI Changes. All TI Change Requests shall be subject to the other party’s prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed. The non-requesting party shall have five (5) business days after receipt of a TI Change Request to notify the requesting party in writing of the non-requesting party’s decision either to approve or object to the TI Change Request. The non-requesting party’s failure to respond within such five (5) business day period shall be deemed approval by the non-requesting party.

2.4. Preparation of Estimates. Tenant shall, before proceeding with any TI Change, using its best efforts, prepare as soon as is reasonably practicable (but in no event more than five (5) business days after delivering a TI Change Request to Landlord or receipt of a TI Change Request) an estimate of the increased costs or savings that would result from such TI Change, as well as an estimate on such TI Change’s effects on the Schedule. Landlord shall have five (5) business days after receipt of such information from Tenant to (a) in the case of a TI Change Request, approve or reject such TI Change Request in writing, or (b) in the case of a Landlord initiated TI Change Request, notify Tenant in writing of Landlord’s decision either to proceed with or abandon the Landlord-initiated TI Change Request.

2.5. Quality Control Program; Coordination. Tenant shall provide Landlord with information regarding the following (together, the “QCP”): (a) Tenant’s general contractor’s quality control program and (b) evidence of subsequent monitoring and action plans. The QCP shall be subject to Landlord’s reasonable review and approval and shall specifically address the Tenant Improvements. Tenant shall ensure that the QCP is regularly implemented on a scheduled basis and shall provide Landlord with reasonable prior notice and access to attend all inspections and meetings between Tenant and its general contractor. At the conclusion of the Tenant Improvements, Tenant shall deliver the quality control log to Landlord, which shall include all records of quality control meetings and testing and of inspections held in the field, including inspections relating to concrete, steel roofing, piping pressure testing and system commissioning.

3. Completion of Tenant Improvements. Tenant, at its sole cost and expense (except for the Base TI Allowance and, if properly requested by Tenant pursuant to the terms of the Lease, the Additional TI Allowance), shall perform and complete the Tenant Improvements in all respects (a) in substantial conformance with the Approved TI Plans, (b) otherwise in compliance with provisions of the Lease and this Work Letter and (c) in accordance with Applicable Laws, the requirements of Tenant’s insurance carriers, the requirements of Landlord’s insurance carriers (to the extent Landlord provides its insurance carriers’ requirements to Tenant) and the board of fire underwriters having jurisdiction over the Premises. The Tenant Improvements shall be deemed completed at such time as Tenant shall furnish to Landlord (t) evidence satisfactory to Landlord that (i) all Tenant Improvements have been completed and paid for in full (which shall be evidenced by the architect’s certificate of completion and the general contractor’s and each subcontractor’s and material supplier’s final unconditional waivers and releases of liens, each in a form acceptable to Landlord and complying with Applicable Laws, and a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect and the general contractor, together with a statutory notice of substantial completion from the general contractor), (ii) all Tenant Improvements have been accepted by Landlord, (iii) any and all liens related to the Tenant Improvements have either been discharged of record (by payment, bond, order of a court of competent jurisdiction or otherwise) or waived by the party filing such lien and (iv) no security interests relating to the Tenant Improvements are

7


 

outstanding, (u) all certifications and approvals with respect to the Tenant Improvements that may be required from any Governmental Authority and any board of fire underwriters or similar body for the use and occupancy of the Premises (including a certificate of occupancy (or its substantial equivalent) for the Premises for the Permitted Use), (v) certificates of insurance required by the Lease to be purchased and maintained by Tenant, (w) an affidavit from Tenant’s architect certifying that all work performed in, on or about the Premises is in accordance with the Approved TI Plans, (x) complete “as built” drawing print sets, project specifications and shop drawings and electronic CADD files on disc (showing the Tenant Improvements as an overlay on the Building “as built” plans (provided that Landlord provides the Building “as-built” plans provided to Tenant) of all contract documents for work performed by their architect and engineers in relation to the Tenant Improvements, (y) a commissioning report prepared by a licensed, qualified commissioning agent hired by Tenant and approved by Landlord for all new or affected mechanical, electrical and plumbing systems (which report Landlord may hire a licensed, qualified commissioning agent to peer review, and whose reasonable recommendations Tenant’s commissioning agent shall perform and incorporate into a revised report) and (z) such other “close out” materials as Landlord reasonably requests consistent with Landlord’s own requirements for its contractors, such as copies of manufacturers’ warranties, operation and maintenance manuals and the like.

4. Insurance.

4.1. Property Insurance. At all times during the period beginning with commencement of construction of the Tenant Improvements and ending with final completion of the Tenant Improvements, Tenant shall maintain, or cause to be maintained (in addition to the insurance required of Tenant pursuant to the Lease), property insurance insuring Landlord and the Landlord Parties, as their interests may appear. Such policy shall, on a completed replacement cost basis for the full insurable value at all times, insure against loss or damage by fire, vandalism and malicious mischief and other such risks as are customarily covered by the so-called “broad form extended coverage endorsement” upon all Tenant Improvements and the general contractor’s and any subcontractors’ machinery, tools and equipment, all while each forms a part of, or is contained in, the Tenant Improvements or any temporary structures on the Premises, or is adjacent thereto; provided that, for the avoidance of doubt, insurance coverage with respect to the general contractor’s and any subcontractors’ machinery, tools and equipment shall be carried on a primary basis by such general contractor or the applicable subcontractor(s). Tenant agrees to pay any deductible, and Landlord is not responsible for any deductible, for a claim under such insurance.

4.2. Workers’ Compensation Insurance. At all times during the period of construction of the Tenant Improvements, Tenant shall, or shall cause its contractors or subcontractors to, maintain statutory workers’ compensation insurance as required by Applicable Laws.

4.3. Waivers of Subrogation. Any insurance provided pursuant to this Article shall waive subrogation against the Landlord Parties and Tenant shall hold harmless and indemnify the Landlord Parties for any loss or expense incurred as a result of a failure to obtain such waivers of subrogation from insurers.

5. Liability. Tenant assumes sole responsibility and liability for any and all injuries or the death of any persons, including Tenant’s contractors and subcontractors and their respective employees,

8


 

agents and invitees, and for any and all damages to property arising from any act or omission on the part of Tenant, Tenant’s contractors or subcontractors, or their respective employees, agents and invitees in the prosecution of the Tenant Improvements. Tenant agrees to Indemnify the Landlord Indemnitees from and against all Claims due to, because of or arising from any and all such injuries, death or damage, whether real or alleged, and Tenant and Tenant’s contractors and subcontractors shall assume and defend at their sole cost and expense all such Claims; provided, however, that nothing contained in this Work Letter shall be deemed to Indemnify Landlord from or against liability to the extent arising directly from Landlord’s negligence or willful misconduct. Any deficiency in design or construction of the Tenant Improvements shall be solely the responsibility of Tenant, notwithstanding the fact that Landlord may have approved of the same in writing.

6. TI Allowance.

6.1. Application of TI Allowance. Landlord shall contribute the Base TI Allowance and, if properly requested by Tenant pursuant to the terms of the Lease, the Additional TI Allowance toward the costs and expenses incurred in connection with the performance of the Tenant Improvements, in accordance with Article 4 of the Lease. If the entire TI Allowance is not applied toward or reserved for the costs of the Tenant Improvements, then Tenant shall not be entitled to a credit of such unused portion of the TI Allowance. If the entire Excess TI Costs advanced by Tenant to Landlord are not applied toward the costs of the Tenant Improvements, then Landlord shall promptly return such excess to Tenant following completion of the Tenant Improvements. Tenant may apply the Base TI Allowance and, if properly requested by Tenant pursuant to the terms of the Lease, the Additional TI Allowance for the payment of construction and other costs in accordance with the terms and provisions of the Lease.

6.2. Approval of Budget for the Tenant Improvements. Notwithstanding anything to the contrary set forth elsewhere in this Work Letter or the Lease, Landlord shall not have any obligation to expend any portion of the TI Allowance until Landlord and Tenant shall have approved in writing the budget for the Tenant Improvements (the “Approved TI Budget”). Prior to Landlord’s approval of the Approved TI Budget, Tenant shall pay all of the costs and expenses incurred in connection with the Tenant Improvements as they become due. Landlord shall not be obligated to reimburse Tenant for costs or expenses relating to the Tenant Improvements that exceed the amount of the TI Allowance. Landlord shall not unreasonably withhold, condition or delay its approval of any budget for Tenant Improvements that is proposed by Tenant.

6.3. Fund Requests. Upon submission by Tenant to Landlord as of or prior to the TI Deadline of (a) a statement (a “Fund Request”) setting forth the total amount of the TI Allowance requested, (b) a summary of the Tenant Improvements performed using AIA standard form Application for Payment (G 702) executed by the general contractor and by the architect, (c) invoices from the general contractor, the architect, and any subcontractors, material suppliers and other parties requesting payment with respect to the amount of the TI Allowance then being requested, (d) except with respect to the final Fund Request, conditional lien releases from the general contractor and each subcontractor and material supplier with respect to the Tenant Improvements performed that correspond to the Fund Request in a form acceptable to Landlord and complying with Applicable Laws, then Landlord shall, within thirty (30) days following receipt by Landlord of a Fund Request and the accompanying materials required by this Section,

9


 

pay to (as elected by Landlord) the applicable contractors, subcontractors and material suppliers or Tenant (for reimbursement for payments made by Tenant to such contractors, subcontractors or material suppliers either prior to Landlord’s approval of the Approved TI Budget or as a result of Tenant’s decision to pay for the Tenant Improvements itself and later seek reimbursement from Landlord in the form of one lump sum payment in accordance with the Lease and this Work Letter), the amount of Tenant Improvement costs set forth in such Fund Request or Landlord’s pari passu share thereof if Excess TI Costs exist based on the Approved Budget; provided, however, that Landlord shall not be obligated to make any payments under this Section until the budget for the Tenant Improvements is approved in accordance with Section 7.2, and any Fund Request under this Section shall be submitted as of or prior to the TI Deadline and shall be subject to the payment limits set forth in Section 7.2 above and Article 4 of the Lease. Notwithstanding anything in this Section to the contrary, Tenant shall not submit a Fund Request after the TI Deadline or more often than every thirty (30) days. Any additional Fund Requests submitted by Tenant after the TI Deadline or more often than every thirty (30) days shall be void and of no force or effect.

6.4. Accrual Information. In addition to the other requirements of this Section 7, Tenant shall, no later than the second (2nd) business day of each month until the Tenant Improvements are complete, provide Landlord with an estimate of (a) the percentage of design and other soft cost work that has been completed, (b) design and other soft costs spent through the end of the previous month, both from commencement of the Tenant Improvements and solely for the previous month, (c) the percentage of construction and other hard cost work that has been completed, (d) construction and other hard costs spent through the end of the previous month, both from commencement of the Tenant Improvements and solely for the previous month, and (e) the date of Substantial Completion of the Tenant Improvements.

7. Requests for Consent. Except as otherwise provided in this Work Letter, each of Landlord and Tenant shall respond to all requests for consents, approvals or directions made by the other pursuant to this Work Letter within five (5) business days following the approving party’s receipt of such request. The approving party’s failure to respond within such five (5) business day period shall be deemed approval by such party.

8. Miscellaneous.

8.1. Incorporation of Lease Provisions. Sections 40.6 through 40.19 of the Lease are incorporated into this Work Letter by reference, and shall apply to this Work Letter in the same way that they apply to the Lease.

8.2. General. Except as otherwise set forth in the Lease or this Work Letter, this Work Letter shall not apply to improvements performed in any additional premises added to the Premises at any time or from time to time, whether by any options under the Lease or otherwise; or to any portion of the Premises or any additions to the Premises in the event of a renewal or extension of the original Term, whether by any options under the Lease or otherwise, unless the Lease or any amendment or supplement to the Lease expressly provides that such additional premises are to be delivered to Tenant in the same condition as the initial Premises.

[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]

10


 

IN WITNESS WHEREOF, Landlord and Tenant have executed this Work Letter as a sealed Massachusetts instrument to be effective on the date first above written.

LANDLORD:

B9 LS HARRISON & WASHINGTON LLC,

a Delaware limited liability company

 

 

By:

Name:

Title:

TENANT:

MONTE ROSA THERAPEUTICS, INC.,

a Delaware corporation

 

 

By:

Name:

Title:

11


 

EXHIBIT B-1

TENANT WORK INSURANCE SCHEDULE

1. Types of Coverage. Tenant shall maintain or cause Tenant’s contractors performing construction or renovation work to maintain such insurance as shall protect it from the claims set forth below that may arise out of or result from any Tenant Work, whether such Tenant Work is completed by Tenant or by any Tenant contractors or by any person directly or indirectly employed by Tenant or any Tenant contractors, or by any person for whose acts Tenant or any Tenant contractors may be liable:

a. Commercial General Liability. Commercial general liability insurance written on the ISO form CG 00 01 or equivalent, including products and completed operations, on an occurrence basis. Such coverage shall apply to all Tenant Work done by Tenant’s contractors and subcontractors of all tiers and provide insurance against personal injury, wrongful death, and property damage (other than to the Tenant Work itself). The policy shall include contractual liability coverage sufficient to address the obligations of the Lease and the Tenant Work. This insurance policy shall include Landlord Parties as additional insureds with endorsements equivalent to ISO CG 20 10 04/13 for ongoing operations, and to ISO CG 20 37 04/13 for completed operations. This policy shall be primary and noncontributory with respect to any other insurance available to an additional insured. The policy shall include endorsement ISO CG 24 04 or its equivalent, a waiver of subrogation in favor of the Landlord Parties. Tenant contractors’ Commercial General Liability Insurance shall include premises/operations (including explosion, collapse and underground coverage if such Tenant Work involves any underground work), elevators, independent contractors, products and completed operations, and blanket contractual liability on all written contracts, all including broad form property damage coverage. Coverage for completed operations must be maintained through the applicable statue of repose period following completion of the Tenant Work.

b. Business Automobile Liability Insurance. Business Automobile Liability Insurance on an “occurrence” form covering any or all autos (including owned, hired, leased and non-owned vehicles) used by or on behalf of the insured, and providing insurance for bodily injury and property damage. The policy shall include coverage for loading and unloading activities. This policy shall include the Landlord Parties as additional insureds, with endorsements.

c. Workers’ Compensation and Employer’s Liability Insurance. For all operations, Workers’ Compensation insurance in compliance with statutory limits for the Workers’ Compensation Laws of the state in which the Premises are located, and an Employer’s Liability limit of not less than $1,000,000 each accident.

d. Contractors’ Pollution Liability. Contractors and subcontractors handling, removing or treating Hazardous Materials shall maintain pollution liability insurance. Such coverage shall include bodily injury, sickness, disease, death or mental anguish or shock sustained by any person; property damage or environmental damage, including physical injury to or destruction of tangible property (including the resulting loss of use thereof), contractual liability coverage to cover liability arising out of cleanup, removal, storage or handling of hazardous or toxic chemicals, materials or substances, or any other pollutants (including mold, asbestos or asbestos-containing

B-1-1


 

materials); and defense costs, charges and expenses incurred in the investigation, adjustment or defense of claims for such damages. Claims-made coverage is permitted, provided that the policy retroactive date is continuously maintained prior to the commencement of the Tenant Work. This policy shall include the Landlord Parties as additional insureds, with endorsements.

e. Professional Liability (Errors and Omissions). Contractors and subcontractors of any tier performing Tenant Work that includes any professional services, including design, architecture, engineering, testing, surveying or design/build services shall provide and maintain professional liability insurance. Coverage shall be maintained following completion of the Tenant Work through the applicable statute of repose of the state in which the Premises are located.

2. Minimum Limits of Insurance. All coverage types as defined above to be procured by Tenant’s general contractor and designer for any Tenant Work shall be written for limits of insurance not less than:

B-1-2


 

Coverage

Cost of Work

Minimum Limits of Insurance

a. Commercial General Liability

* Limits may be met by use of excess and/or umbrella liability insurance, provided that such coverage is at least as broad as the primary coverages required herein

<$200 million

$100 million per occurrence, general aggregate, and products and completed operations aggregate

<$100 million

$50 million per occurrence, general aggregate, and products and completed operations aggregate

<$50 million

$25 million per occurrence, general aggregate, and products and completed operations aggregate

<$25 million

$10 million per occurrence, general aggregate, and products and completed operations aggregate

<$10 million

$5 million per occurrence, general aggregate, and products and completed operations aggregate

<$5 million

$2 million per occurrence, general aggregate, and products and completed operations aggregate

b. Commercial Automobile Liability

* Limits may be met by use of excess and/or umbrella liability insurance, provided that such coverage is at least as broad as the primary coverages required herein

≥$25 million

$25 million combined single limit

<$25 million

$10 million combined single limit

<$10 million

$5 million combined single limit

<$5 million

$2 million combined single limit

c. Workers’ Compensation

At all times

As required by Applicable Laws

d. Contractor’s Pollution Liability

At all times

$2 million per location and $4 million aggregate

e. Professional Liability (Errors and Omissions)

<$200 million

$10 million per project and in the aggregate

<$75 million

$5 million per project and in the aggregate

<$25 million

$2 million per project and $4 million aggregate

<$10 million

$1 million per project and $2 million aggregate

 

B-1-3


 

3. Notice of Cancelation. The foregoing policies shall contain a provision that coverages afforded under the policies shall not be canceled or not renewed until at least thirty (30) days’ prior written notice has been given to the Landlord.

4. Evidence of Insurance. Certificates of insurance, including required endorsements showing such coverages to be in force, shall be provided to Landlord prior to the commencement of any Tenant Work and prior to each renewal.

5. Insurer Ratings. The minimum A.M. Best’s rating of each insurer shall be A-VII.

6. Additional Insureds. The policies shall name Landlord Parties as additional insureds to the extent required by the Lease, the Work Letter or this Exhibit.

7. Waiver of Subrogation. Tenant, contractors and subcontractors, and each of their respective insurers shall provide waivers of subrogation in favor of the Landlord Parties with respect to all insurance required by the Lease, the Work Letter or this Exhibit.

8. Tenant’s Contractors. Tenant shall require all other persons, firms and corporations engaged or employed by Tenant in connection with the performance of Tenant Work to carry and maintain coverages with limits not less than those required by this Exhibit. Tenant’s contractors’ and subcontractors’ insurance compliance, including any coverage exceptions, shall be Tenant’s responsibility. Tenant shall incorporate these insurance requirements by reference within any contract executed by Tenant and its contractors. Tenant shall obtain and verify the accuracy of certificates of insurance evidencing required coverage prior to permitting its contractors, subcontractors (of any tier), suppliers and agents from performing any Tenant Work or services at the Premises. Tenant shall furnish original certificates of insurance with additional insured endorsements from Tenant’s contractors, subcontractors (of any tier), suppliers and agents as evidence thereof, as Landlord may reasonably request.

9. No Limit of Liability. It is expressly acknowledged and agreed that the insurance policies and limits required hereunder shall not limit the liability of Tenant or its contractors or subcontractors, and that Landlord makes no representation that these types or amounts of insurance are sufficient or adequate to protect Tenant or its contractors’ or subcontractors’ interests or liabilities, but are merely minimums. Any insurance carried by Landlord shall be secondary and non-contributory to that carried by Tenant and/or its contractors or subcontractors.

 

B-1-4


 

EXHIBIT B-2

LANDLORD’S WORK

Base Building Improvements

Architectural

 

 Expanded Equipment Penthouse and equipment screening

 New 5,000 lb freight elevator and 3-bay loading dock

 New 5,000 lb freight elevator in 321 Harrison

 New chemical storage holding area and freight corridor

 Furnished 4th Floor amenity space and roof deck

 Landlord is achieving LEED Silver certification and Tenant build out and use of Premises shall comply with requirements of such certification

 

Structural

 

 New Equipment dunnage

 Structural reinforcing on floors 4 – 11

 Modifications to support base building architectural work

 

Mechanical

 

 New 100% outside air units providing 1.75 cfm supply air across lab useable on each floor

 New rooftop exhaust fans, main duct risers and shafts

 New cooling towers, boilers, chillers, pumps, VFDs, energy-recovery loops and all associated equipment to provide non-potable hot/chilled water via base building risers to each floor

 H-Room dedicated exhaust ducts and shafts for future tenant H room tie-in

 

Plumbing

 

 New 6” medium pressure gas service and main riser

 New PH Neutralization tank, skid and waste piping

 Landlord to provide and hold MWRA permit for lab waste system

 New Domestic water riser main run vertically through building

 New tempered water heater

 

Electrical

 

 Upgrade switchgear to provide 12 watts/sf. across lab useable

 (2) New 500 kW natural gas generators provide 5W/lab sf.

 500 kW diesel life safety generator

 Temporary generator docking station sized for additional 750kW generator

 

Fire Protection

 

 Fully sprinkled

Addressable fire alarm system

 

C-1


 

EXHIBIT C-1

 

ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE

 

This acknowledgement of TERM commencement date is entered into as of [_______], 20[__], with reference to that certain Lease (the “Lease”) dated as of [_______], 2021, by MONTE ROSA THERAPEUTICS, INC., a Delaware corporation (“Tenant”), in favor of B9 LS HARRISON & WASHINGTON LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease.

Tenant hereby confirms the following:

1. Tenant accepted possession of the Premises for construction of improvements or the installation of personal or other property on [_______], 20[__].

2. The Premises are in good order, condition and repair.

3. All conditions of the Lease to be performed by Landlord as a condition to the full effectiveness of the Lease have been satisfied, and Landlord has fulfilled all of its duties in the nature of inducements offered to Tenant to lease the Premises, except [_____________].

4. In accordance with the provisions of Article 4 of the Lease, the Term Commencement Date is [_______], 20[__].

5. The Lease is in full force and effect, and the same represents the entire agreement between Landlord and Tenant concerning the Premises[, except [_______]].

6. Tenant has no existing defenses against the enforcement of the Lease by Landlord, and there exist no offsets or credits against Rent owed or to be owed by Tenant.

7. The obligation to pay Additional Rent is presently in effect and all Additional Rent obligations on the part of Tenant under the Lease commenced to accrue on [_______], 20[__].

8. The undersigned Tenant has not made any prior assignment, transfer, hypothecation or pledge of the Lease or of the rents thereunder or sublease of the Premises or any portion thereof.

[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]

C-2


 

IN WITNESS WHEREOF, Tenant has executed this Acknowledgment of Term Commencement Date and Term Expiration Date as of the date first written above.

TENANT:

MONTE ROSA THERAPEUTICS, INC.,

a Delaware corporation

By:

Name:

Title:

 


 

EXHIBIT C-2

 

ACKNOWLEDGEMENT OF RENT COMMENCEMENT DATE AND
TERM EXPIRATION DATE

 

This acknowledgement of RENT commencement date and term expiration date is entered into as of [_______], 20[__], with reference to that certain Lease (the “Lease”) dated as of [_______], 2021, by MONTE ROSA THERAPEUTICS, INC., a Delaware corporation (“Tenant”), in favor of B9 LS HARRISON & WASHINGTON LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease.

Tenant hereby confirms the following:

1. In accordance with the provisions of Article 7 and Article 3 of the Lease, the Rent Commencement Date is [_______], 20[__], and, unless the Lease is terminated prior to the Term Expiration Date pursuant to its terms, the Term Expiration Date shall be [_______], 20[__].

2. The Landlord’s Work is Substantially Complete.

3. All conditions of the Lease to be performed by Landlord as a condition to the full effectiveness of the Lease have been satisfied, and Landlord has fulfilled all of its duties in the nature of inducements offered to Tenant to lease the Premises.

4. The Lease is in full force and effect, and the same represents the entire agreement between Landlord and Tenant concerning the Premises[, except [_______]].

5. Tenant has no existing defenses against the enforcement of the Lease by Landlord, and there exist no offsets or credits against Rent owed or to be owed by Tenant.

6. The obligation to pay Rent is presently in effect and all Rent obligations on the part of Tenant under the Lease commenced to accrue on [_______], 20[__], with Base Rent payable on the dates and amounts set forth in the chart below:

Dates

Square Feet of Rentable Area

Base Rent per Square Foot of Rentable Area

Monthly Base Rent

Annual Base Rent

Rent Commencement Date-date immediately prior to 1st anniversary of Rent Commencement Date

63,327

 $ 95.00

 $501,338.75

$6,016,065.00

 

{A0358199.6 } C-2-1


 

7. The undersigned Tenant has not made any prior assignment, transfer, hypothecation or pledge of the Lease or of the rents thereunder or sublease of the Premises or any portion thereof.

[REMAINDER OF THIS PAGE INTENTIONALLY LEFT BLANK]

{A0358199.6 } C-2


 

IN WITNESS WHEREOF, Tenant has executed this Acknowledgment of Rent Commencement Date and Term Expiration Date as of the date first written above.

TENANT:

MONTE ROSA THERAPEUTICS, INC.,

a Delaware corporation

By:

Name:

Title:

 


 

 

EXHIBIT D

INTENTIONALLY OMITTED

 

D-1


 

EXHIBIT E

FORM OF LETTER OF CREDIT

[On letterhead or L/C letterhead of Issuer]

LETTER OF CREDIT

Date: _______, 20__

B9 LS Harrison & Washington LLC (the “Beneficiary”)

4570 Executive Drive, Suite 400

San Diego, CA 92121

Attention: Legal Department

L/C. No.: __________________

Loan No. : _________________

Ladies and Gentlemen:

We establish in favor of Beneficiary our irrevocable and unconditional Letter of Credit numbered as identified above (the “L/C”) for an aggregate amount of $_______, expiring at __:00 p.m. on _______ or, if such day is not a Banking Day, then the next succeeding Banking Day (such date, as extended from time to time, the “Expiry Date”). “Banking Day” means a weekday except a weekday when commercial banks in _____________ are authorized or required to close.

We authorize Beneficiary to draw on us (the “Issuer”) for the account of _______ (the “Account Party”), under the terms and conditions of this L/C.

Funds under this L/C are available by presenting the following documentation (the “Drawing Documentation”): (a) the original L/C and (b) a sight draft substantially in the form of Attachment 1, with blanks filled in and bracketed items provided as appropriate. No other evidence of authority, certificate, or documentation is required.

Drawing Documentation must be presented at Issuer’s office at ____________ on or before the Expiry Date by personal presentation, courier or messenger service, or fax. Presentation by fax shall be effective upon electronic confirmation of transmission as evidenced by a printed report from the sender’s fax machine. After any fax presentation, but not as a condition to its effectiveness, Beneficiary shall with reasonable promptness deliver the original Drawing Documentation by any other means. Issuer will on request issue a receipt for Drawing Documentation.

We agree, irrevocably, and irrespective of any claim by any other person, to honor drafts drawn under and in conformity with this L/C, within the maximum amount of this L/C, presented to us on or before the Expiry Date, provided we also receive (on or before the Expiry Date) any other Drawing Documentation this L/C requires.

E-1


 

We shall pay this L/C only from our own funds by check or wire transfer, in compliance with the Drawing Documentation.

If Beneficiary presents proper Drawing Documentation to us on or before the Expiry Date, then we shall pay under this L/C at or before the following time (the “Payment Deadline”): (a) if presentment is made at or before noon of any Banking Day, then the close of such Banking Day; and (b) otherwise, the close of the next Banking Day. We waive any right to delay payment beyond the Payment Deadline. If we determine that Drawing Documentation is not proper, then we shall so advise Beneficiary in writing, specifying all grounds for our determination, within one Banking Day after the Payment Deadline.

Partial drawings are permitted. This L/C shall, except to the extent reduced thereby, survive any partial drawings.

We shall have no duty or right to inquire into the validity of or basis for any draw under this L/C or any Drawing Documentation. We waive any defense based on fraud or any claim of fraud.

The Expiry Date shall automatically be extended by one year (but never beyond _____ (the “Outside Date”)) unless, on or before the date 90 days before any Expiry Date, we have given Beneficiary notice that the Expiry Date shall not be so extended (a “Nonrenewal Notice”). We shall promptly upon request confirm any extension of the Expiry Date under the preceding sentence by issuing an amendment to this L/C, but such an amendment is not required for the extension to be effective. We need not give any notice of the Outside Date.

Beneficiary may from time to time without charge transfer this L/C, in whole but not in part, to any transferee (the “Transferee”). Issuer shall look solely to Account Party for payment of any fee for any transfer of this L/C. Such payment is not a condition to any such transfer. Beneficiary or Transferee shall consummate such transfer by delivering to Issuer the original of this L/C and a Transfer Notice substantially in the form of Attachment 2, purportedly signed by Beneficiary, and designating Transferee. Issuer shall promptly reissue or amend this L/C in favor of Transferee as Beneficiary. Upon any transfer, all references to Beneficiary shall automatically refer to Transferee, who may then exercise all rights of Beneficiary. Issuer expressly consents to any transfers made from time to time in compliance with this paragraph.

Any notice to Beneficiary shall be in writing and delivered by hand with receipt acknowledged or by overnight delivery service such as FedEx (with proof of delivery) at the above address, or such other address as Beneficiary may specify by written notice to Issuer. A copy of any such notice shall also be delivered, as a condition to the effectiveness of such notice, to: ___________ (or such replacement as Beneficiary designates from time to time by written notice).

No amendment that adversely affects Beneficiary shall be effective without Beneficiary’s written consent.

This L/C is subject to and incorporates by reference: (a) the International Standby Practices 98 (“ISP 98”); and (b) to the extent not inconsistent with ISP 98, Article 5 of the Uniform Commercial Code of the State of New York.

E-2


 

Very truly yours,

[Issuer Signature]

 

E-3


 

ATTACHMENT 1 TO EXHIBIT E

FORM OF SIGHT DRAFT

[Beneficiary Letterhead]

TO:

[Name and Address of Issuer]

SIGHT DRAFT

AT SIGHT, pay to the Order of ______________, the sum of ______________ United States Dollars ($______________). Drawn under [Issuer] Letter of Credit No. ______________ dated ______________.

[Issuer is hereby directed to pay the proceeds of this Sight Draft solely to the following account: _________________________.]

[Name and signature block, with signature or purported signature of Beneficiary]

Date: ________________

 

 


 

ATTACHMENT 2 TO EXHIBIT E

FORM OF TRANSFER NOTICE

[Beneficiary Letterhead]

TO:

[Name and Address of Issuer] (the “Issuer”)

TRANSFER NOTICE

By signing below, the undersigned, Beneficiary (the “Beneficiary”) under Issuer’s Letter of Credit No. ______________ dated ______________ (the “L/C”), transfers the L/C to the following transferee (the “Transferee”):

[Transferee Name and Address]

The original L/C is enclosed. Beneficiary directs Issuer to reissue or amend the L/C in favor of Transferee as Beneficiary. Beneficiary represents and warrants that Beneficiary has not transferred, assigned, or encumbered the L/C or any interest in the L/C, which transfer, assignment, or encumbrance remains in effect.

[Name and signature block, with signature or purported signature of Beneficiary]

Date: ________________]

 

 


 

EXHIBIT F

RULES AND REGULATIONS

NOTHING IN THESE RULES AND REGULATIONS (“RULES AND REGULATIONS”) SHALL SUPPLANT ANY PROVISION OF THE LEASE. IN THE EVENT OF A CONFLICT OR INCONSISTENCY BETWEEN THESE RULES AND REGULATIONS AND THE LEASE, THE LEASE SHALL PREVAIL.

1. No Tenant Party shall encumber or obstruct the common entrances, lobbies, elevators, sidewalks and stairways of the Building(s) or the Project or use them for any purposes other than ingress or egress to and from the Building(s) or the Project.

2. Except as specifically provided in the Lease, no sign, placard, picture, advertisement, name or notice shall be installed or displayed on any part of the outside of the Premises or the Building(s) without Landlord’s prior written consent. Landlord shall have the right to remove, at Tenant’s sole cost and expense and without notice, any sign installed or displayed in violation of this rule.

3. If Landlord objects in writing to any curtains, blinds, shades, screens, hanging plants or other similar objects attached to or used in connection with any window or door of the Premises or placed on any windowsill, and (a) such window, door or windowsill is visible from the exterior of the Premises and (b) such curtain, blind, shade, screen, hanging plant or other object is not included in plans approved by Landlord, then Tenant shall promptly remove such curtains, blinds, shades, screens, hanging plants or other similar objects at its sole cost and expense.

4. Intentionally omitted.

5. Tenant shall not place a load upon any floor of the Premises that exceeds the load per square foot that (a) such floor was designed to carry or (b) is allowed by Applicable Laws. Fixtures and equipment that cause noises or vibrations that may be transmitted to the structure of the Building(s) to such a degree as to be objectionable to other tenants shall be placed and maintained by Tenant, at Tenant’s sole cost and expense, on vibration eliminators or other devices sufficient to eliminate such noises and vibrations to levels reasonably acceptable to Landlord and the affected tenants of the Project.

6. Tenant shall not use any method of HVAC other than that shown in the Tenant Improvement plans.

7. Tenant shall not install any radio, television or other antennae; cell or other communications equipment; or other devices on the roof or exterior walls of the Premises except in accordance with the Lease. Tenant shall not interfere with radio, television or other digital or electronic communications at the Project or elsewhere.

8. Canvassing, peddling, soliciting and distributing handbills or any other written material within, on or around the Project (other than within the Premises) are prohibited. Tenant shall cooperate with Landlord to prevent such activities by any Tenant Party.

F-1


 

9. Tenant shall store all of its trash, garbage and Hazardous Materials in receptacles within its Premises or in receptacles designated by Landlord outside of the Premises. Tenant shall not place in any such receptacle any material that cannot be disposed of in the ordinary and customary manner of trash, garbage and Hazardous Materials disposal. Any Hazardous Materials transported through Common Area shall be held in secondary containment devices. Tenant shall be responsible, at its sole cost and expense, for Tenant’s removal of its trash, garbage and Hazardous Materials. Tenant is encouraged to participate in the waste removal and recycling program in place at the Project.

10. The Premises shall not be used for lodging or for any improper, immoral or objectionable purpose. No cooking shall be done or permitted in the Premises; provided, however, that Tenant may use (a) equipment approved in accordance with the requirements of insurance policies that Landlord or Tenant is required to purchase and maintain pursuant to the Lease for brewing coffee, tea, hot chocolate and similar beverages, (b) microwave ovens for employees’ use and (c) equipment shown on Tenant Improvement plans approved by Landlord; provided, further, that any such equipment and microwave ovens are used in accordance with Applicable Laws.

11. Tenant shall not, without Landlord’s prior written consent, use the name of the Project, if any, in connection with or in promoting or advertising Tenant’s business except as Tenant’s address.

12. Tenant shall comply with all safety, fire protection and evacuation procedures and regulations established by Landlord or any Governmental Authority.

13. Tenant assumes any and all responsibility for protecting the Premises from theft, robbery and pilferage, which responsibility includes keeping doors locked and other means of entry to the Premises closed.

14. Tenant shall not modify any locks to the Premises without Landlord’s prior written consent, which consent Landlord shall not unreasonably withhold, condition or delay. Tenant shall furnish Landlord with copies of keys, pass cards or similar devices for locks to the Premises.

15. Tenant shall cooperate and participate in all reasonable security programs affecting the Premises.

16. Tenant shall not permit any animals in the Project, other than for service animals or for use in laboratory experiments.

17. Bicycles shall not be taken into the Building(s) (including the elevators and stairways of the Building) except into areas designated by Landlord.

18. The water and wash closets and other plumbing fixtures shall not be used for any purposes other than those for which they were constructed, and no sweepings, rubbish, rags or other substances shall be deposited therein.

19. Discharge of industrial sewage shall only be permitted if Tenant, at its sole expense, first obtains all necessary permits and licenses therefor from all applicable Governmental Authorities.

F-2


 

20. Smoking and the use of smokeless tobacco products, electronic smoking devices (e.g., e-cigarettes) and nicotine products is prohibited at the Project.

21. The Project’s hours of operation are currently 24 hours a day.

22. Tenant shall comply with all orders, requirements and conditions now or hereafter imposed by Applicable Laws or Landlord (“Waste Regulations”) regarding the collection, sorting, separation and recycling of waste products, garbage, refuse and trash generated by Tenant (collectively, “Waste Products”), including (without limitation) the separation of Waste Products into receptacles reasonably approved by Landlord and the removal of such receptacles in accordance with any collection schedules prescribed by Waste Regulations.

23. Tenant, at Tenant’s sole cost and expense, shall cause the Premises to be exterminated on a monthly basis to Landlord’s reasonable satisfaction and shall cause all portions of the Premises used for the storage, preparation, service or consumption of food or beverages to be cleaned daily in a manner reasonably satisfactory to Landlord, and to be treated against infestation by insects, rodents and other vermin and pests whenever there is evidence of any infestation. Tenant shall not permit any person to enter the Premises or the Project for the purpose of providing such extermination services, unless such persons have been approved by Landlord. If requested by Landlord, Tenant shall, at Tenant’s sole cost and expense, store any refuse generated in the Premises by the consumption of food or beverages in a cold box or similar facility.

24. Electric vehicles may be charged using only electric vehicle charging stations installed for that purpose, and no other electrical outlets or connections at the Project may be used for charging vehicles of any kind.

25. If Tenant desires to use any portion of the Common Area for a Tenant-related event, Tenant must notify Landlord in writing at least thirty (30) days prior to such event on the form attached as Attachment 1 to this Exhibit, which use shall be subject to Landlord’s prior written consent, not to be unreasonably withheld, conditioned or delayed. Notwithstanding anything in this Lease or the completed and executed Attachment to the contrary, Tenant shall be solely responsible for setting up and taking down any equipment or other materials required for the event, and shall promptly pick up any litter and report any property damage to Landlord related to the event. Any use of the Common Area pursuant to this Section shall be subject to the provisions of Article 28 of the Lease.

26. Firearms and any other items intended for use as weapons are not permitted in the Building(s) or at the Project.

27. Parking lots/parking garages may not be used for overnight parking or storage of vehicles or other miscellaneous items without Landlord’s prior written approval. Vehicles and other miscellaneous items left unattended by a Tenant Party in Landlord’s parking lots/parking garages for 24 hours or longer may be towed/removed at Tenant’s expense.

28. Common shower facilities are intended for use by tenants of the Building(s) or Project after exercising or commuting. Common shower facilities are not to be used to treat exposure to potential hazards or contaminants. Tenants are required to provide separate shower facilities for

F-3


 

employee use within individual premises when required for the health and safety of their employees.

29. Furniture, equipment and other personal property located on private terraces associated with leased premises is subject to Landlord’s prior review and approval. Tenants with private terraces must secure any movable objects to protect against causing harm to person or property from objects falling or becoming airborne due to an accident, an act of nature, or other incident.

30. Tenants shall, and shall cause Tenant Parties to, remove all personal property from Common Areas, including common terraces, when not present in such Common Areas.

31. Visitors under the age of 18 are only permitted access to the Building lobby unless approved in advance by Landlord’s property manager. Authorized visitors under the age of 18 must be escorted by an adult in Common Areas at all times.

32. Fitness Center access is for Tenant employees only, and requires each user to sign a waiver of liability and agree to the rules of conduct.

33. Secure Bicycle room access and use of locker rooms is for Tenant employees only, and requires each user to sign a waiver of liability and agree to the rules of conduct.

34. Transportation of laboratory experiments including but not limited to test tubes, beakers, Petri dishes, and animals are prohibited in public areas of the Building without qualifying secondary containment. Qualifying secondary containment is a sealed or locked non-transparent container which will prevent the contents from discharging in the event of a spill.

35. Laboratory gloves/coats are not permitted to be worn outside of Tenant’s premises, including during transport of animals.

36. All routine deliveries to the premises shall be made between the hours of 6:00 A.M. and 6:00 P.M. weekdays (other than Massachusetts holidays) unless other arrangements are approved in advance by the Landlord, and only shall be made through the freight elevators. No deliveries shall be made that impede or interfere with other tenants in or the operation of the Project. Passenger elevators are to be used only for the movement of persons, unless the Landlord approves an exception. Courier use of passenger elevators shall be limited to Business Hours during Business Days unless otherwise approved by Landlord. Delivery Hours are subject to change by Landlord. Tenants will adhere to any peak delivery restrictions implemented by the City of Boston. Delivery personnel/companies who do not adhere to building rules can be barred from the property by the Property Manager.

37. Deliveries or movement of furniture, office equipment or any other large or bulky material(s) through the Common Area shall be restricted to such hours as Landlord may designate and shall be subject to reasonable restrictions that Landlord may impose.

38. The Rules and Regulations include the Tenant Design Manual appended hereto or hereafter provided by Landlord to Tenant.

 

F-4


 

COVID-19 RULES AND REGULATIONS

To help minimize the spread of the COVID-19 virus and maintain a safe and healthy work environment, Landlord has instituted the below rules and regulations (the “COVID-19 Rules and Regulations”) as part of the Rules and Regulations. The COVID-19 Rules and Regulations are in effect until further notice from Landlord.

1. Individuals may not enter the Building/Property/Project if they are sick or experiencing flu-like symptoms.

2. Individuals who have been ill or have displayed flu-like symptoms must follow all recommendations of the Centers for Disease Control (CDC) for symptomatic individuals prior to returning to the Building/Property/Project.

3. Individuals who have been exposed to a known COVID-19-infected individual should not return to the Building/Property/Project until 14 days after their most recent exposure to that infected individual.

4. In Common Areas, including elevators and parking garages, individuals must wear face coverings or masks, practice social distancing, and maintain six feet of separation from others as much as possible.

5. Group gatherings are not allowed in Common Areas at this time.

6. Tenants must adhere to signage posted throughout the Building/Property/Project, including related to amenity closures or restrictions.

7. Individuals must clean up after themselves, wash hands frequently, and not leave trash or other personal items in Common Areas.

8. Tenants must develop a COVID-19 remediation response plan for their Premises and share that plan with the Landlord. Additionally, tenants must share their re-emergence plan with Landlord and continue to provide Landlord with updates as their plan evolves.

9. Tenants shall monitor evolving CDC, state and local governmental guidelines, and educate their employees about new guidance and information, as needed.

10. Tenants must promptly report known COVID-19 cases that have occurred at the Building/Property/Project to Landlord, but Tenant shall not be obligated to identify the name of the individual due to privacy or Applicable Laws.

Landlord may waive any one or more of these Rules and Regulations for the benefit of Tenant or any other tenant, but no such waiver by Landlord shall be construed as a waiver of such Rules and Regulations in favor of Tenant or any other tenant, nor prevent Landlord from thereafter enforcing any such Rules and Regulations against any or all of the tenants of the Project, including Tenant. These Rules and Regulations are in addition to, and shall not be construed to in any way modify or amend, in whole or in part, the terms covenants, agreements and conditions of the Lease. Landlord reserves the right to make such other and reasonable additional rules and regulations as,

F-5


 

in its judgment, may from time to time be needed for safety and security, the care and cleanliness of the Project, or the preservation of good order therein; provided, however, that Tenant shall not be obligated to adhere to such additional rules or regulations until Landlord has provided Tenant with written notice thereof. Tenant agrees to abide by these Rules and Regulations and any such additional rules and regulations issued or adopted by Landlord. Tenant shall be responsible for the observance of these Rules and Regulations by all Tenant Parties.

 

F-6


 

ATTACHMENT 1 TO EXHIBIT F

REQUEST FOR USE OF COMMON AREA

REQUEST FOR USE OF COMMON AREA

Date of Request:

Landlord/Owner:

Tenant/Requestor:

Property Location:

Event Description:

 

 

Proposed Plan for Security & Cleaning:______________________________________________

______________________________________________________________________________

______________________________________________________________________________

Date of Event:

Hours of Event: (to include set-up and take down):

Location at Property (see attached map): __ ______

Number of Attendees:

Open to the Public? [___] YES [___] NO

Food and/or Beverages? [___] YES [___] NO

If YES:

 Will food be prepared on site? [___] YES [___] NO

Please describe:

Will alcohol be served? [___] YES [___] NO

Please describe:

Will attendees be charged for alcohol? [___] YES [___] NO

F-1-1


 

Is alcohol license or permit required? [___] YES [___] NO

Does caterer have alcohol license or permit: [___] YES [___] NO [___] N/A

Other Amenities (tent, booths, band, food trucks, bounce house, etc.):

 

 

 

Other Event Details or Special Circumstances:

 

 

 

 

Requesting Party acknowledges that they are responsible to adhere to all current (at the time of the event) COVID-19-related requirements set forth by federal, state and local government authorities for the geographic area in which the event is to take place, and any other COVID-related recommendations made by Landlord. Should federal, state and/or local government requirements contradict each other, the Requesting Party shall adhere to (and shall cause its employees, vendors and guests to adhere to) the most stringent requirement(s).

The undersigned certifies that the foregoing is true, accurate and complete and he/she is duly authorized to sign and submit this request on behalf of the Tenant/Requestor named above.

[INSERT NAME OF TENANT/REQUESTOR]

By:

Name:

Title:

Date:

F-1-2


 

EXHIBIT G

TAPA

 

 

[see attached]

F-1-1


 

EXHIBIT H

TENANT’S PROPERTY

 

F-1-1


 

EXHIBIT I

FORM OF ESTOPPEL CERTIFICATE

To: B9 LS HARRISON & WASHINGTON LLC

4570 Executive Drive, Suite 400

San Diego, California 92121

Attention: Legal Department

BioMed Realty III LP

4570 Executive Drive, Suite 400

San Diego, California 92121

Re: [PREMISES ADDRESS] (the “Premises”) at 321 Harrison Avenue, Boston, Massachusetts (the “Property”)

The undersigned tenant (“Tenant”) hereby certifies to you as follows:

1. Tenant is a tenant at the Property under a lease (the “Lease”) for the Premises dated as of [_______], 20[__]. The Lease has not been cancelled, modified, assigned, extended or amended [except as follows: [_______]], and there are no other agreements, written or oral, affecting or relating to Tenant’s lease of the Premises or any other space at the Property. The lease term expires on [_______], 20[__].

2. Tenant took possession of the Premises, currently consisting of [_______] square feet, on [_______], 20[__], and commenced to pay rent on [_______], 20[__]. Tenant has full possession of the Premises, has not assigned the Lease or sublet any part of the Premises, and does not hold the Premises under an assignment or sublease[, except as follows: [_______]].

3. All base rent, rent escalations and additional rent under the Lease have been paid through [_______], 20[__]. There is no prepaid rent[, except $[_______]][, and the amount of security deposit is $[_______] [in cash][OR][in the form of a letter of credit]]. Tenant currently has no right to any future rent abatement under the Lease.

4. Base rent is currently payable in the amount of $[_______] per month.

5. Tenant is currently paying estimated payments of additional rent of $[_______] per month on account of real estate taxes, insurance, management fees and Common Area maintenance expenses.

6. All work to be performed for Tenant under the Lease has been performed as required under the Lease and has been accepted by Tenant[, except [_______]], and all allowances to be paid to Tenant, including allowances for tenant improvements, moving expenses or other items, have been paid.

7. The Lease is in full force and effect, free from default and free from any event that could become a default under the Lease, and Tenant has no claims against the landlord or offsets or defenses against rent, and there are no disputes with the landlord. Tenant has received no notice of

I-1


 

prior sale, transfer, assignment, hypothecation or pledge of the Lease or of the rents payable thereunder[, except [_______]].

8. [Tenant has the following expansion rights or options for leasing additional space at the Property: [_______].][OR][Tenant has no rights or options to purchase the Property.]

9. To Tenant’s knowledge, no hazardous wastes have been generated, treated, stored or disposed of by or on behalf of Tenant in, on or around the Premises or the Project in violation of any environmental laws.

10. The undersigned has executed this Estoppel Certificate with the knowledge and understanding that [INSERT NAME OF LANDLORD, PURCHASER OR LENDER, AS APPROPRIATE] or its assignee is [acquiring the Property/making a loan secured by the Property] in reliance on this certificate and that the undersigned shall be bound by this certificate. The statements contained herein may be relied upon by [INSERT NAME OF PURCHASER OR LENDER, AS APPROPRIATE], B9 LS Harrison & Washington LLC, BioMed Realty III LP, and any [other ]mortgagee of the Property and their respective successors and assigns.

Any capitalized terms not defined herein shall have the respective meanings given in the Lease.

Dated this [____] day of [_______], 20[__].

[_______],

a [_______]

By:

Name:

Title:

 

 

I-2


 

EXHIBIT J

DEFINITION OF OBSOLETE EQUIPMENT

 

Obsolete equipment shall mean:

 The equipment is outdated, such that it is not reasonable to continue servicing it;

 The equipment is no longer supported by the manufacturer;

 Component or compatible parts of the equipment are no longer available;

 The equipment is no longer compatible with the other equipment in the Building;

 The cost to replace the equipment is equal to or less tha the cost to repair the equipment;

 The equipment poses a safety risk; and/or

 The equipment no longer meets local/state/national guidelines.

 

 

I-1