SIXTH AMENDMENT TO OFFICE LEASE AGREEMENT
Exhibit 10.20
SIXTH AMENDMENT TO
OFFICE LEASE AGREEMENT
THIS SIXTH AMENDMENT TO OFFICE LEASE AGREEMENT (this Amendment) is dated, for reference purposes only, March 19, 2014, and is made and entered into by and between TP BUILDING I, LLC, a Utah limited liability company (Landlord) and HEALTHEQUITY, INC., a Delaware corporation (Tenant).
Recitals
A. On or about November 17, 2006, Landlord and Tenant entered into an Office Lease Agreement in which Landlord agreed to lease to Tenant certain premises located in The Pointe I, an office building (the Building) located at 15 West Scenic Drive, Draper, Utah, as more particularly defined below. Said Office Lease Agreement has been amended by a First Amendment to Office Lease Agreement dated October 18, 2007, a Second Amendment to Office Lease Agreement dated March 2012, a Third Amendment to Office Lease Agreement dated August 22, 2012, a Fourth Amendment to Office Lease dated June 27, 2013, and a Fifth Amendment to Office Lease Agreement dated November 15, 2013. The Office Lease Agreement, as amended by said amendments, is hereinafter referred to as the Lease.
B. Landlord and Tenant now desire to further amend the Lease to expand the leased premises, adjust the Base Rent, and make certain other changes, all as stated herein.
Terms and Conditions
NOW, THEREFORE, in consideration of the Lease and the mutual promises contained in the Lease and in this Amendment, and for other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties agree as follows:
1. Recitals. The foregoing recitals are hereby incorporated into this Amendment and form a part hereof.
2. Definitions. The following terms shall have the following meanings for purposes of this Amendment:
Allowance shall mean the allowance of $174,120.00, as described in Section 8 of this Amendment.
Amendment defined in the first paragraph above.
Building the office building located at 15 West Scenic Drive, Draper, Utah with the sign Building 2 in which the Tenant is currently located.
Expansion Area shall mean the space on the first floor of the Building which is labeled 11,608 s.f. on Exhibit A attached to this Amendment and incorporated by reference herein. The Expansion Area contains 11,608 Usable Square Feet of space and 12,666 Rentable Square Feet.
Expansion Date shall mean the later of: (a) July 1, 2014, or (b) the date on which Landlord Substantially Completes the Landlord Work and delivers occupancy of the Expansion Area to Tenant, provided, however, that if Substantial Completion is delayed because of Tenant Delay, the Landlord Work will be deemed to have been Substantially Completed on the date Landlord would have completed the same absent the Tenant Delay.
Free Rent Period Five (5) months, as further defined and described in Section 6.
Initial Premises as used in this Amendment shall mean all premises leased by Tenant in the Building prior to the addition of the Expansion Area described in this Amendment.
Known Brokers defined in Section 11.
Landlord defined in the first paragraph of this Amendment.
Landlord Work shall mean the work of improvement to be performed by Landlord as described in the Work Letter attached hereto as Exhibit B.
Lease defined in Recital A.
Revised Premises shall mean the premises governed by the Lease after the addition of the Expansion Area described in this Amendment, consisting of the Initial Premises and the Expansion Area.
Substantially Complete and Substantially Completed shall mean that Landlord shall have obtained a certificate of occupancy for the Expansion Area from the City of Draper and that Landlord shall have substantially completed the Landlord Work, with the only work remaining to be completed by Landlord being items that can be completed after occupancy has been taken without causing material interference with Tenants use of the Premises (i.e., so-called punch list items), which the parties shall agree upon in writing at the time of Substantial Completion, and which punch list items Landlord shall complete as soon as possible and in any event within 30 days of the Expansion Date.
Tenant defined in the first paragraph of this Amendment.
All other capitalized terms used in this Amendment and not defined herein shall have the meanings attributed to such terms in the Lease.
3. Expansion of Premises. On the Expansion Date, Landlord agrees to deliver and lease the Expansion Area to Tenant and Tenant agrees to accept and lease the Expansion Area from Landlord. Thereafter, the Premises governed by the Lease will be the Revised Premises, including, for all purposes, the Initial Premises and the Expansion Area, and totaling 70,979 Rentable Square Feet.
2
4. Early Access to Install Fixtures, Furniture and Equipment. Tenant will have the right to access the Expansion Area fourteen (14) days prior to the Expansion Date for the purpose of installing Tenants furniture, fixtures and equipment. There shall be no rental or other charge for such early access. Tenant agrees that it will conduct its installation work in the Expansion Area in a manner that will not interfere with Landlords Work. Any interference by Tenant or its agents or contractors with Landlords Work will constitute a Tenant Delay.
5. Lease Term for Expansion Area Coterminous With Initial Premises. The Termination Date for the lease of the Expansion Area will be April 30, 2019, which is the same as the Termination Date for the Initial Premises. Any renewal options exercised by Tenant pursuant to the Lease will apply to the Expansion Area as well as to the Initial Premises.
6. Base Rent.
A. Base Rent for Initial Premises. Tenant will continue to pay Base Rent on the Initial Premises at the rate described in the Lease.
B. Base Rent for Expansion Area. The Base Rent rate for the Expansion Area will be, initially, $15.85 per Rentable Square Foot. Base Rent for the Expansion Area will increase by 3% annually, beginning on the anniversary of the Expansion Date and continuing on each year thereafter.
C. Free Rent Period. During the first five (5) months after the Expansion Date, no Base Rent will be charged on any of the Expansion Area. The five (5) month period during which Base Rent is not charged on the Expansion Area as described above is sometimes referred to herein as the Free Rent Period. Although Base Rent will not be charged on the Expansion Area during the Free Rent Period, Tenant will pay its Pro Rata Share of Expenses and Taxes for the Expansion Area during the Free Rent Period. If the Expansion Date falls on a day other than the first day of a calendar month, the Base Rent for any month in which a free rent concession ends will be prorated according to the number of days in the month.
D. Base Rent Chart. Based on the foregoing, the following chart shows the Base Rent to be paid by Tenant from the Expansion Date through the end of the Term for the Expansion Area only.
3
Base Rent Chart for Expansion Area:
Months | Annual Rate Per Sq. Ft. | Rentable Sq. Ft. | Annual Base Rent | Monthly Base Rent | ||||||||||||
From Expansion Date thru end of 5-month Free Rent Period | $ | 15.85 | 12,666 | *$ | 200,756.10 Not Charged | | $ | 16,729.68 Not Charged Free Rent Period | | |||||||
**December 1, 2014 thru June 30, 2015 | $ | 15.85 | 12,666 | *$ | 200,756.10 | $ | 16,729.68 | |||||||||
July 1, 2015 thru June 30, 2016 | $ | 16.33 | 12,666 | $ | 206,835.78 | $ | 17,236.32 | |||||||||
July 1, 2016 thru June 30, 2017 | $ | 16.82 | 12,666 | $ | 213,042.12 | $ | 17,753.51 | |||||||||
July 1, 2017 thru June 30, 2018 | $ | 17.32 | 12,666 | $ | 219,375.12 | $ | 18,281.26 | |||||||||
July 1, 2018 thru April 30, 2019 | $ | 17.84 | 12,666 | *$ | 225,961.44 | $ | 18,830.12 |
Notes: | * Stated on an annualized basis, although there is less than a full year in the relevant period. |
** | The chart assumes that the Expansion Date will occur on or before July 1, 2014 so that the Free Rent Period will expire on or before November 30, 2014. If, through no fault of Tenant, the Expansion Date occurs after July 1, 2014 the Free Rent Period will continue for five (5) months after the Expansion Date and rental payments will commence only after expiration of the Free Rent Period. |
7. Pro Rata Share. Until the Expansion Date, Tenants Pro Rata Share of Expenses and Taxes shall be 53.38% (58,313 RSF in Initial Premises divided by 109,244 RSF in Building). From and after the Expansion Date, Tenants Pro Rata Share of Expenses and Taxes shall be 64.97% (70,979 RSF in the Revised Premises divided by 109,244 RSF in the Building).
8. Improvements and Allowance. All improvements in connection with this expansion shall be subject to the provisions of the Work Letter attached to this Amendment as Exhibit B and shall be performed at Tenants expense, except that Landlord agrees to provide an Allowance to Tenant in an amount up to a maximum of $174,120.00 (calculated for reference purposes only as $15.00 x 11,608 Usable Square Feet in the Expansion Area), as more fully described in Exhibit B. The Allowance shall be used only for the Landlord Work to be performed in the Premises as described in the Work Letter. Tenant shall not receive any cash payment, credit or offset for any portion of the Allowance not used for the Landlord Work.
9. No Additional Security Deposit. No additional security deposit will be required from Tenant in connection with this expansion.
10. Parking. From and after the Expansion Date, Tenant shall be entitled to the use of 350 parking stalls, subject to the terms and conditions of the Lease governing parking.
11. Commissions. Landlord will pay any commission due to Coldwell Banker Commercial Intermountain which will in turn pay Cresa Salt Lake City a commission equal to three percent (3%) of the gross full service equivalent rental value of the Expansion Area in connection with this transaction. Coldwell Banker Commercial Intermountain and Cresa Salt Lake City are sometimes collectively referred to herein as the Known Brokers. The parties acknowledge that they have not used any real estate brokers or finders with respect to
4
this Amendment other than the Known Brokers. Each party represents and warrants to the other that the warranting party knows of no real estate broker or agent who is or might be entitled to compensation in connection with this Amendment other than Known Brokers. Each party, as indemnifying party, agrees to indemnify, defend and hold the other party harmless from and against any and all liabilities or expenses, including reasonable attorneys fees and costs, arising out of any claim for brokerage commissions, finders fees, or similar compensation by any person other than Known Brokers, which claim is based on any alleged act or agreement of the indemnifying party.
12. Confidentiality. Landlord and Tenant each acknowledge that the terms and conditions of this Amendment (including without limitation the rental rate and concessions granted to Tenant herein) and the Lease are to remain confidential, and may not be disclosed to anyone, by any manner or means, directly or indirectly, without the other partys prior written consent; provided, however, that either party may disclose the terms and conditions of this Amendment and the Lease to its auditors, accountants, attorneys, brokers or its affiliate(s), as reasonably required in the conduct of such partys affairs, or as required by legal process. The consent by a party to any disclosures shall not be deemed to be a waiver on the part of such party of any prohibition against any future disclosure.
13. Repayment of Rent Concession. Tenant acknowledges that its right to occupy the Expansion Area without paying Base Rent during the Free Rent Period is absolutely conditioned upon Tenants full, faithful and punctual performance of its obligations under the Lease, as amended hereby, including the payment of all rent. If Tenant defaults in its obligations under the Lease and does not cure such default after any required notice and within any applicable grace period, the Specified Percentage of the Base Rent for the Free Rent Period for the Expansion Area shall immediately become due and payable in full, at the applicable per square foot rate described in Section 6 of this Amendment. As used herein, the Specified Percentage shall mean the percentage equivalent to a fraction, the numerator of which is the number of months remaining in the Term as of the date of the default and the denominator of which is the number of months remaining in the Term at the end of the Free Rent Period described in this Amendment.
14. Miscellaneous. The Lease and this Amendment contain all of the representations, understandings, and agreements of the parties with respect to matters contained herein. The parties acknowledge and agree that the Lease and this Amendment were both negotiated by all parties, that they shall be interpreted as if they were drafted jointly by all of the parties, and that neither the Lease, this Amendment, nor any provision within them, shall be construed against any party or its attorney because it was drafted in full or in part by any party or its attorney. Each of the individuals who have executed this Amendment represents and warrants that he or she is duly authorized to execute this Amendment on behalf of Landlord or Tenant as the case may be, that all corporate, partnership, trust or other action necessary for such party to execute and perform the terms of this Amendment have been duly taken by such party, and that no other signature and/or authorization is necessary for such party to enter into and perform the terms of this Amendment. This Amendment may be executed in any number of counterparts, provided each counterpart is identical in its terms. Each such counterpart, when executed and delivered will be deemed to be an original, and all such counterparts together shall be deemed to constitute one and the same instrument. Facsimile or other electronic transmission
5
of a signed counterpart shall be deemed to constitute delivery of the signed original. Time is of the essence in the interpretation and enforcement of this Amendment. This Amendment shall be governed by and construed in accordance with the laws of the State of Utah and each of the parties hereto submits to the non-exclusive jurisdiction of the courts of the State of Utah in connection with any disputes arising out of the Lease or this Amendment. In the event of any legal action arising under this Amendment, the prevailing party shall be entitled to recover all of its reasonable attorneys fees from the non-prevailing party.
15. Effect of Amendment on Lease. In the event of any conflict between the provisions of this Amendment and the provisions of the Lease, this Amendment will control. Except as modified hereby, the Lease remains in full force and effect between the parties.
16. Binding Only on Execution and Delivery. The submission of an unsigned copy of this Amendment by either party to the other shall not constitute an offer or option with respect to the matters contained herein. This Amendment shall become effective and binding only upon execution and delivery.
17. Exhibits. The following exhibits are attached to this Amendment and incorporated by reference herein:
Exhibit A Depiction of Expansion Area
Exhibit B Work Letter
IN WITNESS WHEREOF, the parties have executed this Sixth Amendment to Office Lease Agreement on the dates indicated next to their signatures below.
LANDLORD: | TENANT: | |||||||
TP BUILDING I, LLC, a Utah limited liability company | HEALTHEQUITY, INC., a Delaware corporation | |||||||
By: |
| By: | /s/ Darcy Mott | |||||
Title: | Manager | Title: | EVP & CFO | |||||
Date: | 3/26/14 | Date: | 3-24-14 |
6
EXHIBIT A
DEPICTION OF EXPANSION AREA
Exhibit A Page 1
EXHIBIT B
WORK LETTER
This Exhibit is attached to and made a part of the Sixth Amendment to Lease by and between TP BUILDING I, LLC, a Utah Limited liability company (Landlord), and HEALTHEQUITY, INC., a Delaware corporation (Tenant), for space in the Building located at 15 West Scenic Drive, Draper, Utah 84020.
As used in this Work Letter, the terms Revised Premises and Expansion Area shall have the same meanings as defined in the Amendment to which this Exhibit is attached.
1. | This Work Letter shall set forth the obligations of Landlord and Tenant with respect to the improvements to be performed in the Expansion Area for Tenants use. All improvements described in this Work Letter to be constructed by Landlord are hereinafter referred to as the Landlord Work. It is agreed that construction of the Landlord Work will be completed at Tenants sole cost and expense, except as provided herein and subject to the Allowance (as defined below). Landlord shall enter into a direct contract for the Landlord Work with a general contractor selected by Landlord, subject to Tenants approval, which shall not be unreasonably withheld. In addition, Landlord shall select any subcontractors used in connection with the Landlord Work, subject to Tenants approval, which shall not be unreasonably withheld. The construction contract for the Landlord Work (the Construction Contract) shall be subject to Tenants approval, which shall not be unreasonably withheld. |
The Landlord Work will include providing a turn-key tenant improvement package in the Expansion Area based on the drawing attached to this Work Letter as Exhibit 1, with finishes consistent with Tenants existing premises on the first floor of the Building.
2. | Landlords architect shall be responsible for the timely preparation and submission of the final architectural, electrical and mechanical construction drawings, plans and specifications (called Plans) necessary to construct the Landlord Work. Landlords architect shall be responsible for all elements of the design of Tenants plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Expansion Area and the placement of Tenants furniture, appliances and equipment). Landlords architect will prepare the Plans necessary for such construction at Tenants cost, which cost shall be paid out of the Allowance. Notwithstanding the foregoing, Landlord has provided free space planning services for the Expansion Area through EA Architecture (the cost of which free space planning services will not count against the Allowance). Landlords architect shall complete the Plans within fourteen (14) business days following the full execution of this Amendment. Tenant shall have three (3) business days to review the Plans and make any changes. Landlords architect shall have four (4) business days to make the requested changes and resubmit same to Tenant. Tenant shall have two (2) business days to approve the final Plans. Time is of the essence in respect of preparation and submission of Plans |
Exhibit B Page 1
by Tenant and Landlord. If the Plans are not approved by Tenant within the time frames outlined herein Tenant shall be responsible for one day of Tenant Delay (as defined in the Lease) for each day of delay. If the Plans are not prepared or approved by Landlord or Landlords architect within the time frames outlined herein Landlord shall be responsible for one day of Landlord Delay for each day of delay. |
3. | If Landlords estimate of the cost of the Landlord Work shall exceed the Allowance, Landlord, prior to commencing any construction of Landlord Work, shall submit to Tenant a written estimate setting forth the anticipated cost of the Landlord Work, including but not limited to labor and materials, contractors fees and permit fees. Within three (3) Business Days thereafter, Tenant shall either notify Landlord in writing of its approval of the cost estimate, or specify its objections thereto and any desired changes to the proposed Landlord Work. If Tenant notifies Landlord of such objections and desired changes, Tenant shall work with Landlord to reach a mutually acceptable alternative cost estimate. The Construction Contract shall include a price not to exceed the estimate approved by Landlord and Tenant. |
4. | If the cost of construction as shown in the Construction Contract (with the approval of Tenant) shall exceed the Allowance (such amount exceeding the Allowance being herein referred to as the Excess Costs), Tenant shall pay to Landlord such Excess Costs, plus any applicable state sales or use tax thereon, within ten (10) days of receipt of Landlords invoice. The statements of costs submitted to Landlord by Landlords contractors shall be conclusive for purposes of determining the actual cost of the items described therein, subject to the fixed or maximum price in the Construction Contract. The amounts payable by Tenant hereunder constitute Rent payable pursuant to the Lease, and the failure to timely pay same constitutes both a Tenant Delay and an event of default under the Lease. |
5. | If Tenant shall request any change, addition or alteration in any of the Plans after approval as outlined in Paragraph 2 above, Landlord shall have such revisions to the drawings prepared, and Tenant shall reimburse Landlord for the cost thereof, plus any applicable state sales or use tax thereon, within ten (10) days of receipt of Landlords invoice, or deduct said cost from the remaining Allowance if any. Promptly upon completion of the revisions, Landlord shall notify Tenant in writing of the increased cost which will be chargeable to Tenant by reason of such change, addition or deletion. Tenant, within two (2) business days, shall notify Landlord in writing whether it desires to proceed with such change, addition or deletion. In the absence of such written authorization, Landlord shall have the option to continue work on the Expansion Area disregarding the requested change, addition or alteration, or Landlord may elect to discontinue work on the Expansion Area until it receives notice of Tenants decision, in which event Tenant shall be responsible for any Tenant Delay in completion of the Expansion Area resulting therefrom. If such revisions result in a higher estimate of the cost of construction and/or higher actual construction costs which exceed the Allowance, such increased estimate or costs shall be deemed Excess Costs pursuant to Paragraph 4 hereof and Tenant shall pay such Excess Costs, plus any applicable state sales or use tax thereon, within ten (10) days of receipt of Landlords statement. |
Exhibit B Page 2
6. | Landlord shall cause the Landlord Work to be Substantially Completed in accordance with the approved Plans within ninety (90) days after the later of: (a) the date the Amendment to which this Work Letter is attached as an Exhibit is executed by Tenant and an executed original is forwarded to Landlord, (b) the date Tenant approves the final Plans for the Landlord Work as described in paragraph 2 above, (c) the date Tenant pays the required portion of the Excess Costs, if any, and (d) the date Draper City issues a building permit for the Landlord Work. Landlord will notify Tenant when the Landlord Work is Substantially Completed. |
7. | Landlord, provided Tenant is not in default beyond any applicable cure period, agrees to provide Tenant with an allowance (the Allowance) in an amount equivalent to $174,120.00. The Allowance will be applied only toward the cost of the Landlord Work in the Expansion Area. If the Allowance shall not be sufficient to complete the Landlord Work, Tenant shall pay the Excess Costs, plus any applicable state sales or use tax thereon, as prescribed in Paragraph 4 above. Landlord shall be entitled to deduct from the Allowance a construction management fee for Landlords oversight of the Landlord Work in an amount equal to 5% of the total cost of the Landlord Work. |
8. | Landlord shall indemnify, defend and hold Tenant harmless against all claims and liabilities made by any party in connection with the performance of the Landlord Work, except to the extent such claims or liabilities arise from negligent or wrongful acts or omissions of Tenant. Tenant shall indemnify, defend and hold Landlord harmless against all claims and liabilities made by any party as a result of activities of Tenant or its agents or contractors on or about the Expansion Area or Revised Premises, except to the extent such claims arise from negligent or wrongful acts or omissions of Landlord. |
9. | This Exhibit shall not be deemed applicable to any additional space added to the Revised Premises at any later time (after completion of Landlords Work in connection with the Amendment to which this Exhibit is attached) or from time to time, whether by any options under the Lease or otherwise, or to any portion of the Revised Premises or any additions to the Revised Premises in the event of a renewal or extension of the original Term of the Lease, whether by any options under the Lease or otherwise, unless expressly so provided in the Lease or any amendment or supplement to the Lease. |
Exhibit B Page 3
EXHIBIT 1 to
WORK LETTER
Exhibit B Page 4