Lease Agreement, dated June 25, 2021, by and between ARE-EAST JAMIE COURT, LLC and the Registrant
Exhibit 10.8
LEASE AGREEMENT
THIS LEASE AGREEMENT (this Lease) is made this 25 day of June, 2021, between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company (Landlord), and DiCE MOLECULES SV, INC., a Delaware corporation (Tenant).
Building: | 400 East Jamie Court, South San Francisco, California |
Premises: | The entire 3rd floor of the Building, known as Suite 300, containing approximately 33.331 rentable square feet, as determined by Landlord, as shown on Exhibit A. |
Project: | The real property on which the Building in which the Premises are located, together with all improvements thereon and appurtenances thereto as described on Exhibit B. |
Base Rent: | Initially, $5.95 per rentable square foot of the Premises per month (the Original Base Rent), and $19,331.98 per month (the Additional Base Rent). The Original Base Rent shall be subject to adjustment pursuant to Section 4 hereof. |
Rentable Area of Premises: 33,331 sq. ft.
Rentable Area of Building: 97,040 sq. ft.
Rentable Area of Project: 181,361 sq. ft.
Tenants Share of Operating Expenses of Building: 34.35%
Buildings Share of Operating Expenses of Project: 53.51%
Security Deposit: $198 ,3 19.45
Target Commencement Date: April 1, 2022
Rent Adjustment Percentage: 3.0%
Base Term: | Beginning on the Commencement Date and ending 84 months from the first day of the first full month following the Commencement Date. For clarity, if the Commencement Date occurs on the first day of a month, the expiration of the Base Term shall be measured from that date. If the Commencement Date occurs on a day other than the first day of a month, the expiration of the Base Term shall be measured from the first day of the following month. |
Permitted Use | Research and development laboratory, wet laboratory, manufacturing, related office and other related uses consistent with the character of the Project and otherwise in compliance with the provisions of Section 7 hereof. |
Address for Rent Payment: | Landlords Notice Address: | |
Tenants Notice Address Prior to the Commencement Date: 279 East Grand Avenue South San Francisco, CA 94080 Attention: Chief Financial Officer | Tenants Notice Address After the Commencement Date: 400 East Jamie Court, Suite 300 South San Francisco, California 94080 Attention: Chief Financial Officer |
400 E. Jamie Ct. - Suite 300/DiCE - Page 2
The following Exhibits and Addenda are attached hereto and incorporated herein by this reference:
[X] | EXHIBIT A - PREMISES DESCRIPTION | [X] | EXHIBIT B - DESCRIPTION OF PROJECT | |||
[X] | EXHIBIT C - WORK LETTER | [X] | EXHIBIT D - COMMENCEMENT DATE | |||
[X] | EXHIBIT E - RULES AND REGULATIONS | [X] | EXHIBIT F - TENANTS PERSONAL PROPERTY |
1. Lease of Premises. Upon and subject to all of the terms and conditions hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. The portions of the Project which are for the non-exclusive use of tenants of the Project are collectively referred to herein as the Common Areas. Tenant shall have the non-exclusive right during the Term to use the Common Areas along with others having the right to use the Common Areas. Landlord reserves the right to modify Common Areas, provided that such modifications do not materially adversely affect Tenants use of the Premises for the Permitted Use. From and after the Commencement Date through the expiration of the Term, Tenant shall have access to the Building and the Premises 24 hours a day, 7 days a week, except in the case of emergencies, as the result of Legal Requirements, the performance by Landlord of any installation, maintenance or repairs, or any other temporary interruptions, and otherwise subject to the terms of this Lease.
2. Delivery; Acceptance of Premises; Commencement Date. Landlord shall use reasonable efforts to deliver the Premises to Tenant on or before the Target Commencement Date, with Landlords Work Substantially Completed and in vacant, broom clean condition (Delivery or Deliver). If Landlord fails to timely Deliver the Premises, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. Notwithstanding anything to the contrary contained herein, if Landlord fails to Deliver the Premises to Tenant within 90 days after the Target Commencement Date (as such date may be extended by Force Majeure (as defined in Section 34) and Tenant Delays, the Abatement Date), Base Rent shall be abated 1 day for each day after the Abatement Date that Landlord fails to Deliver the Premises to Tenant. If Landlord does not Deliver the Premises within 120 days of the Target Commencement Date for any reason other than Force Majeure delays and Tenant Delays, this Lease may be terminated by Tenant by written notice to Landlord, and if so terminated by Tenant: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease) and any prepaid Base Rent, shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms Landlords Work, Tenant Delays and Substantially Completed shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 120 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect.
Notwithstanding the foregoing, Landlord and Tenant agree that if any Governmental Authority having jurisdiction of the Project, as a result of the COVID-19 outbreak in the United States declares or implements any order or mandate that restricts construction activities in San Mateo County (any such order or mandate, a Government Mandate), then, to the extent such Government Mandate precludes construction of Landlords Work, the Target Commencement Date shall be delayed 1 day for each day that such a Government Mandate remains in effect and continues to preclude such construction of Landlords Work.
The Commencement Date shall be the earlier of: (i) the date Landlord Delivers the Premises to Tenant; and (ii) the date Landlord could have Delivered the Premises but for Tenant Delays. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date and the expiration date of the Term when such are established in the form of the Acknowledgement of Commencement Date attached to this Lease as Exhibit D; provided, however, Tenants failure to execute and deliver such acknowledgment shall not affect Landlords rights hereunder. The Term of this Lease shall be the Base Term, as defined above on the first page of this Lease and any Extension Terms which Tenant may elect pursuant to Section 40 hereof.
400 E. Jamie Ct. - Suite 300/DiCE - Page 3
Except as set forth in the Work Letter or as otherwise expressly set forth in this Lease: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenants taking possession of the Premises shall be conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent and Operating Expenses.
Notwithstanding anything to the contrary contained herein, for the period of 60 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to the Building Systems (as defined in Section 13) serving the Premises, unless Tenant or any Tenant Party was responsible for the cause of such repair, in which case Tenant shall pay the cost. Tenant shall also be entitled to the benefit of any warranties issued to Landlord in connection with Landlords Work.
Upon written request from Tenant, Landlord shall deliver to Tenant, subject to Landlords standard non-reliance letter, copies of the surrender reports delivered to Landlord by the immediately prior tenant of the Premises once such surrender reports have been made available to Landlord.
Tenant agrees and acknowledges that neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenants business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenants representations, warranties, acknowledgments and agreements contained herein.
3. Rent.
(a) Base Rent. The first full calendar months Base Rent and the Security Deposit shall be due and payable concurrently with Tenants delivery of an executed copy of this Lease to Landlord. Commencing on the Commencement Date, Tenant shall pay to Landlord in advance, without demand, abatement, deduction or set-off, monthly installments of Base Rent on or before the first day of each calendar month during the Term hereof, in lawful money of the United States of America, at the office of Landlord for payment of Rent set forth above, or to such other person or at such other place as Landlord may from time to time designate in writing, or via federally insured wire transfer (including ACH) pursuant to the wire instructions provided by Landlord. Payments of Base Rent for any fractional calendar month shall be prorated. The obligation of Tenant to pay Base Rent and other sums to Landlord and the obligations of Landlord under this Lease are independent obligations. Tenant shall have no right at any time to abate, reduce, or set-off any Rent (as defined in Section 5) due hereunder except for any abatement as may be expressly provided in this Lease.
(b) Additional Rent. In addition to Base Rent, Tenant agrees to pay to Landlord as additional rent (Additional Rent): (i) commencing on the Commencement Date, Tenants Share of Operating Expenses (as defined in Section 5), and (ii) any and all other amounts Tenant assumes or agrees to pay under the provisions of this Lease, including, without limitation, any and all other sums that may become due by reason of any default of Tenant or failure to comply with the agreements, terms, covenants and conditions of this Lease to be performed by Tenant, after any applicable notice and cure period.
4. Base Rent Adjustments. Original Base Rent shall be increased on each annual anniversary of the Commencement Date (provided, however, that if the Commencement Date occurs on a day other than the first day of a calendar month, then Original Base Rent shall be increased on each annual anniversary of the first day of the first full calendar month immediately following the Commencement Date) (each an Adjustment Date) by multiplying the Original Base Rent payable immediately before such
400 E. Jamie Ct. - Suite 300/DiCE - Page 4
Adjustment Date by the Rent Adjustment Percentage and adding the resulting amount to the Base Rent payable immediately before such Adjustment Date. For the avoidance of doubt, Additional Base Rent shall not be subject to annual increases. Base Rent, as so adjusted, shall thereafter be due as provided herein. Base Rent adjustments for any fractional calendar month shall be prorated.
5. Operating Expense Payments. Landlord shall deliver to Tenant, which Landlord shall endeavor to do at least 30 days prior to the beginning of each calendar year of the Term following the Commencement Date, a written estimate of Operating Expenses for each calendar year during the Term (the Annual Estimate), which may be revised by Landlord from time to time during such calendar year (but no more than quarterly). Commencing on the Commencement Date, and continuing thereafter on the first day of each month during the Term, Tenant shall pay Landlord an amount equal to 1/12th of Tenants Share of the Annual Estimate. Payments for any fractional calendar month shall be prorated.
The term Operating Expenses means all costs and expenses of any kind or description whatsoever incurred or accrued each calendar year during the Term of this Lease by Landlord with respect to the Building (including the Buildings Share of all costs and expenses of any kind or description incurred or accrued by Landlord with respect to the Project which are not specific to the Building or any other building located in the Project) including, without duplication, (u) Taxes (as defined in Section 9), (v) the cost of upgrades to the Project (provided that to the extent that such upgrades are capital in nature they shall be amortized in accordance with subsection (y) below) or enhanced services provided at the Project which are intended to encourage social distancing to limit the spread of communicable diseases and/or viruses of any kind or nature that are more virulent than the seasonal flu (collectively, Infectious Conditions), promote and protect health and physical well-being and/or intended to limit the spread of Infectious Conditions, (w) the cost (including commercially reasonable subsidies which Landlord may provide in connection with the Project Amenities) of the common area amenities serving the Project (collectively, the Project Amenities) now or hereafter located at the Project, including the 201 Haskins Amenities (as defined in Section 41), provided that to the extent that such costs are capital in nature they shall be amortized in accordance with subsection (y) below, (x) costs related to any parking areas (including subterranean parking areas) serving the Project (provided that to the extent that such upgrades are capital in nature they shall be amortized in accordance with subsection (y) below) and costs for transportation services made available for tenants of the Project (including the Shuttle Service Costs (as defined in Section 42(q))), (y) capital repairs, improvements and replacements amortized over the useful life of such capital repairs, improvements and replacements as reasonably determined by Landlord taking into account all relevant factors including, without limitation, the 24 hour per day, 7 day per week operation of the Building, and (z) the costs of Landlords third party property manager (not to exceed 3% of the then-current Base Rent) or, if there is no third party property manager, administration rent in the amount of 3% of the then-current Base Rent , excluding only:
(a) the original construction costs of the Project and renovation prior to or planned as of the Commencement Date and costs of correcting defects in such original construction or renovation;
(b) expenditures for expansion of the Project (including in connection with additional buildings at the Project) including the construction of future Project Amenities;
(c) interest, principal payments of Mortgage (as defined in Section 27) debts of Landlord, financing costs and amortization of funds borrowed by Landlord, whether secured or unsecured, and all payments of base rent (but not taxes or operating expenses) under any ground lease or other underlying lease of all or any portion of the Project;
(d) depreciation of the Project (except for capital improvements, the cost of which are includable in Operating Expenses);
(e) advertising, legal and space planning expenses and leasing commissions and other costs and expenses incurred in procuring and leasing space to tenants for the Project, including any leasing office maintained in the Project, free rent and construction allowances for tenants;
400 E. Jamie Ct. - Suite 300/DiCE - Page 5
(f) legal and other expenses incurred in the negotiation or enforcement of leases;
(g) completing, fixturing, improving, renovating, painting, redecorating or other work, which Landlord pays for or performs for other tenants within their premises, and costs of correcting defects in such work;
(h) costs to be reimbursed by other tenants of the Project or Taxes to be paid directly by Tenant or other tenants of the Project, whether or not actually paid;
(i) salaries, wages, benefits and other compensation paid to (i) personnel of Landlord or its agents or contractors above the position of the person, regardless of title, who has day-to-day management responsibility for the Project or (ii) officers and employees of Landlord or its affiliates who are not assigned in whole or in part to the operation, management, maintenance or repair of the Project; provided, however, that with respect to any such person who does not devote substantially all of his or her employed time to the Project, the salaries, wages, benefits and other compensation of such person shall be prorated to reflect time spent on matters related to operating, managing, maintaining or repairing the Project in comparison to the time spent on matters unrelated to operating, managing, maintaining or repairing the Project;
(j) general organizational, administrative and overhead costs relating to maintaining Landlords existence, either as a corporation, partnership, or other entity, including general corporate, legal and accounting expenses;
(k) costs (including attorneys fees and costs of settlement, judgments and payments in lieu thereof) incurred in connection with disputes with tenants, other occupants, or prospective tenants, and costs and expenses, including legal fees, incurred in connection with negotiations or disputes with employees, consultants, management agents, leasing agents, purchasers or mortgagees of the Building;
(l) costs incurred by Landlord due to the violation by Landlord, its employees, agents or contractors or any tenant of the terms and conditions of any lease of space in the Project or any Legal Requirement (as defined in Section 7);
(m) penalties, fines or interest incurred as a result of Landlords inability or failure to make payment of Taxes and/or to file any tax or informational returns when due, or from Landlords failure to make any payment of Taxes required to be made by Landlord hereunder before delinquency;
(n) overhead and profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for goods and/or services in or to the Project to the extent the same exceeds the costs of such goods and/or services rendered by unaffiliated third parties on a competitive basis;
(o) costs of Landlords charitable or political contributions, or of fine art maintained at the Project;
(p) costs in connection with services (including electricity and in-suite janitorial), items or other benefits of a type which are not standard for the Project and which are not available to Tenant without specific charges therefor, but which are provided to another tenant or occupant of the Project, whether or not such other tenant or occupant is specifically charged therefor by Landlord;
(q) costs incurred in the sale or refinancing of the Project;
(r) net income taxes of Landlord or the owner of any interest in the Project, franchise, capital stock, gift, estate or inheritance taxes or any federal, state or local documentary taxes imposed against the Project or any portion thereof or interest therein;
400 E. Jamie Ct. - Suite 300/DiCE - Page 6
(s) any costs incurred to remove, study, test or remediate, or otherwise related to the presence of Hazardous Materials in or about the Building or the Project for which Tenant is not responsible under this Lease;
(t) reserves (other than reserves for Taxes in the same year);
(u) costs incurred in connection with the performance of alterations or modifications to the Premises or the Project for which Landlord is responsible pursuant to the second paragraph of Section 7;
(v) costs occasioned by condemnation;
(w) costs of repairs or other work necessitated by fire, windstorm or other similar casualty (provided that deductible amounts may be included by Landlord as part of Operating Expenses, but to the extent that Tenants Share (i.e., 34.35%) of any earthquake deductible exceeds $50,000, such amounts in excess of $50,000 shall be amortized over a period of 10 years (with interest not to exceed 8% per annum));
(x) insurance deductibles in excess of deductibles that Tenant can demonstrate are in excess of customary deductible amounts carried by institutional owners of Class A laboratory/office buildings in South San Francisco; provided, however, that Tenants Share of any earthquake deductibles in excess of $50,000 are amortized as provided for in Section 5(y) above;
(y) any expenses otherwise includable within Operating Expenses to the extent actually reimbursed by insurance policies required to be maintained by Landlord in accordance with Section 17;
(z) operating expenses incurred or accrued with respect to the 201 Haskins Project except as otherwise provided in Section 41;
(aa) the cost of Landlords Work constructed pursuant to the Work Letter;
(bb) costs incurred in connection with the initial construction and fit-out (including initial furnishings and equipment of the 201 Haskins Amenities); and
(cc) any expenses otherwise includable within Operating Expenses to the extent actually reimbursed by persons other than tenants of the Project under leases for space in the Project.
In addition, notwithstanding anything to the contrary contained in this Lease, Operating Expenses incurred or accrued by Landlord with respect to any capital improvements which are reasonably expected by Landlord to reduce overall Operating Expenses (for example, without limitation, by reducing energy usage at the Project) (the Energy Savings Costs) shall be amortized over a period of years equal to the lesser of (A) the useful life of such capital items (as reasonably determined by Landlord taking into account all relevant factors including, without limitation, the 24 hour per day, 7 day per week operation of the Building), or (B) the quotient of (i) the Energy Savings Costs, divided by (ii) the annual amount of Operating Expenses reasonably expected by Landlord to be saved as a result of such capital improvements.
Within 90 days after the end of each calendar year (or such longer period as may be reasonably required), Landlord shall furnish to Tenant a statement (an Annual Statement) showing in reasonable detail: (a) the total and Tenants Share of actual Operating Expenses for the previous calendar year, and (b) the total of Tenants payments in respect of Operating Expenses for such year. If Tenants Share of actual Operating Expenses for such year exceeds Tenants payments of Operating Expenses for such year, the excess shall be due and payable by Tenant as Rent within 30 days after delivery of such Annual Statement to Tenant. If Tenants payments of Operating Expenses for such year exceed Tenants Share of actual Operating Expenses for such year Landlord shall pay the excess to Tenant within 30 days after
400 E. Jamie Ct. - Suite 300/DiCE - Page 7
delivery of such Annual Statement, except that after the expiration, or earlier termination of the Term or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord. Landlords and Tenants obligations to pay any overpayments or deficiencies due pursuant to this paragraph shall survive the expiration or earlier termination of this Lease.
The Annual Statement shall be final and binding upon Tenant unless Tenant, within 90 days after Tenants receipt thereof, shall contest any item therein by giving written notice to Landlord, specifying each item contested and the reason therefor. If, during such 90-day period, Tenant reasonably and in good faith questions or contests the accuracy of Landlords statement of Tenants Share of Operating Expenses, Landlord will provide Tenant with access to Landlords books and records relating to the operation of the Project and such information as Landlord reasonably determines to be responsive to Tenant s questions (the Expense Information). If after Tenants review of such Expense Information, Landlord and Tenant cannot agree upon the amount of Tenants Share of Operating Expenses, then Tenant shall have the right to have an independent regionally or nationally recognized public accounting firm selected by Tenant and approved by Landlord (which approval shall not be unreasonably withheld or delayed), working pursuant to a fee arrangement other than a contingent fee (at Tenants sole cost and expense), audit and/or review the Expense Information for the year in question (the Independent Review). The results of any such Independent Review shall be binding on Landlord and Tenant. If the Independent Review shows that the payments actually made by Tenant with respect to Operating Expenses for the calendar year in question exceeded Tenants Share of Operating Expenses for such calendar year, Landlord shall at Landlord s option either (i) credit the excess amount to the next succeeding installments of estimated Operating Expenses or (ii) pay the excess to Tenant within 30 days after delivery of such statement, except that after the expiration or earlier termination of this Lease or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord. If the Independent Review shows that Tenants payments with respect to Operating Expenses for such calendar year were less than Tenants Share of Operating Expenses for the calendar year, Tenant shall pay the deficiency to Landlord within 30 days after delivery of such statement. If the Independent Review shows that Tenant has overpaid with respect to Operating Expenses by more than 5% then Landlord shall reimburse Tenant for all costs incurred by Tenant for the Independent Review. Operating Expenses for the calendar years in which Tenants obligation to share therein begins and ends shall be prorated. Notwithstanding anything set forth herein to the contrary, if the Building is not at least 95% occupied on average during any year of the Term, Tenants Share of Operating Expenses for such year shall be computed as though the Building had been 95% occupied on average during such year.
Tenants Share (of Operating Expenses of Building) shall be the percentage set forth on the first page of this Lease as Tenants Share as reasonably adjusted by Landlord for changes in the physical size of the Premises or the Project occurring thereafter. Building Share (of Operating Expenses of Project) shall be the percentage set forth on the first page of this Lease as Buildings Share as reasonably adjusted by Landlord for changes in the physical size of the Building or the Project occurring thereafter. The rentable area of the Premises shall not be subject to re-measurement by either party during the Term. If Landlord has a reasonable basis for doing so, Landlord may equitably increase Tenant s Share for any item of expense or cost reimbursable by Tenant that relates to a repair, replacement, or service that benefits only the Premises or only a portion of the Project that includes the Premises or that varies with occupancy or use. Base Rent, Tenants Share of Operating Expenses and all other amounts payable by Tenant to Landlord hereunder are collectively referred to herein as Rent.
6. Security Deposit. Tenant shall deposit with Landlord, upon delivery of an executed copy of this Lease to Landlord, a security deposit (the Security Deposit) for the performance of all of Tenants obligations hereunder in the amount set forth on page 1 of this Lease, which Security Deposit shall be in the form of an unconditional and irrevocable letter of credit (the Letter of Credit): (i) in form and substance satisfactory to Landlord, (ii) naming Landlord as beneficiary, (iii) expressly allowing Landlord to draw upon it at any time from time to time by delivering to the issuer notice that Landlord is entitled to draw thereunder, (iv) issued by an FDIC-insured financial institution satisfactory to Landlord, and (v) redeemable by presentation of a sight draft in the state of Landlords choice. If Tenant does not provide Landlord with a substitute Letter of Credit complying with all of the requirements hereof at least 10 days before the stated expiration date of any then current Letter of Credit, Landlord shall have the right to draw the full amount of
400 E. Jamie Ct. - Suite 300/DiCE - Page 8
the current Letter of Credit and hold the funds drawn in cash without obligation for interest thereon as the Security Deposit until Tenant shall have replaced the expired Letter of Credit with a new Letter of Credit consistent with the requirements herein, at which time Landlord shall refund the amount of the previously drawn Letter of Credit to Tenant less any amounts applied under this Lease. The Security Deposit shall be held by Landlord as security for the performance of Tenants obligations under this Lease. The Security Deposit is not an advance rental deposit or a measure of Landlords damages in case of Tenants default. Upon each occurrence of a Default (as defined in Section 20), Landlord may use all or any part of the Security Deposit to pay delinquent payments due under this Lease, future rent damages under California Civil Code Section 1951.2, and the cost of any damage, injury, expense or liability caused by such Default, without prejudice to any other remedy provided herein or provided by law. Landlords right to use the Security Deposit under this Section 6 includes the right to use the Security Deposit to pay future rent damages following the termination of this Lease pursuant to Section 21(c) below. Upon any use of all or any portion of the Security Deposit, Tenant shall pay Landlord on demand the amount that will restore the Security Deposit to the amount set forth on Page 1 of this Lease. Tenant hereby waives the provisions of any law, now or hereafter in force, including, without limitation, California Civil Code Section 1950.7, which provide that Landlord may claim from a security deposit only those sums reasonably necessary to remedy defaults in the payment of Rent, to repair damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums reasonably necessary to compensate Landlord for any other loss or damage, foreseeable or unforeseeable, caused by the act or omission of Tenant or any officer, employee, agent or invitee of Tenant. Upon bankruptcy or other debtor-creditor proceedings against Tenant, the Security Deposit shall be deemed to be applied first to the payment of Rent and other charges due Landlord for periods prior to the filing of such proceedings. If Tenant shall fully perform every provision of this Lease to be performed by Tenant, the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant (or, at Landlords option, to the last assignee of Tenants interest hereunder) within 90 days after the expiration or earlier termination of this Lease.
If Landlord transfers its interest in the Project or this Lease, Landlord shall either (a) transfer any Security Deposit then held by Landlord to a person or entity assuming Landlords obligations under this Section 6, or (b) return to Tenant any Security Deposit then held by Landlord and remaining after the deductions permitted herein. Upon such transfer to such transferee or the return of the Security Deposit to Tenant, Landlord shall have no further obligation with respect to the Security Deposit, and Tenants right to the return of the Security Deposit shall apply solely against Landlords transferee. The Security Deposit is not an advance rental deposit or a measure of Landlords damages in case of Tenants default. Landlords obligation respecting the Security Deposit is that of a debtor, not a trustee, and no interest shall accrue thereon.
7. Use. The Premises shall be used solely for the Permitted Use set forth in the basic lease provisions on page 1 of this Lease, and in compliance with all laws, orders, judgments, ordinances, regulations, codes, directives, permits, licenses, covenants and restrictions now or hereafter applicable to the Premises, and to the use and occupancy thereof, including, without limitation, the Americans With Disabilities Act, 42 U.S.C. § 12101, et seq. (together with the regulations promulgated pursuant thereto, ADA) (collectively, Legal Requirements and each, a Legal Requirement). Tenant shall, upon 10 days written notice from Landlord, discontinue any use of the Premises which is declared by any Governmental Authority (as defined in Section 9) having jurisdiction to be a violation of a Legal Requirement ; unless Tenant is actively contesting any such determination in good faith and by appropriate legal proceedings, provided that Tenant first gives Landlord appropriate assurances reasonably satisfactory to Landlord against any loss, cost or expense on account thereof, and further provided such contest shall not subject Landlord to criminal penalties or civil sanctions, loss of property or civil liability. Tenant will not use or permit the Premises to be used for any purpose or in any manner that would void Tenants or Landlords insurance, increase the insurance risk, or cause the disallowance of any sprinkler or other credits. The Permitted Use as defined in this Lease will not result in the voidance of or an increased insurance risk or cause the disallowance of any sprinkler or other credits with respect to the insurance currently being maintained by Landlord. Tenant shall not permit any part of the Premises to be used as a place of public accommodation, as defined in the ADA or any similar legal requirement. Tenant shall reimburse Landlord promptly upon demand for any additional premium charged for any such insurance policy by reason of
400 E. Jamie Ct. - Suite 300/DiCE - Page 9
Tenants failure to comply with the provisions of this Section or otherwise caused by Tenants use and/or occupancy of the Premises. Tenant will use the Premises in a careful, safe and proper manner and will not commit or permit waste, overload the floor or structure of the Premises, subject the Premises to use that would damage the Premises or obstruct or interfere with the rights of Landlord or other tenants or occupants of the Project, including conducting or giving notice of any auction, liquidation, or going out of business sale on the Premises, or using or allowing the Premises to be used for any unlawful purpose. Tenant shall cause any equipment or machinery to be installed in the Premises so as to reasonably prevent sounds or vibrations from the Premises from extending into Common Areas, or other space in the Project. Tenant shall not place any machinery or equipment which would overload the floor in or upon the Premises or transport or move such items through the Common Areas of the Project or in the Project elevators without the prior written consent of Landlord, which consent shall not be unreasonably withheld, conditioned or delayed. Except as may be provided under the Work Letter, Tenant shall not, without the prior written consent of Landlord, which shall not be unreasonably withheld, conditioned or delayed, use the Premises in any manner which will require ventilation, air exchange, heating, gas, steam, electricity or water beyond the existing capacity of the Project as proportionately allocated to the Premises based upon Tenants Share as usually furnished for the Permitted Use.
Landlord shall be responsible, at Landlords cost and not as part of Operating Expenses, for the compliance of the Premises and the Common Areas of the Project with Legal Requirements (including the ADA) as of the Commencement Date. Following the Commencement Date, Landlord shall, as an Operating Expense (to the extent such Legal Requirement is generally applicable to similar buildings in the area in which the Project is located) and at Tenants expense (to the extent such Legal Requirement is triggered by reason of Tenants, as compared to other tenants of the Project, particular use of the Premises or Tenants Alterations) make any alterations or modifications to the Common Areas or the exterior of the Building that are required by Legal Requirements . Except as otherwise expressly provided in the two immediately preceding sentences, Tenant, at its sole expense, shall make any alterations or modifications to the interior of the Premises that are required by Legal Requirements (including, without limitation, compliance of the Premises with the ADA) related to Tenants specific use of the Premises. Notwithstanding any other provision herein to the contrary, subject to the terms of this paragraph, Tenant shall be responsible for any and all demands, claims, liabilities, losses, costs, expenses, actions, causes of action, damages or judgments, and all reasonable expenses incurred in investigating or resisting the same (including, without limitation, reasonable attorneys fees, charges and disbursements and costs of suit) (collectively, Claims) arising out of or in connection with any failure of the Premises to comply with Legal Requirements to the extent related to Tenants particular use of the Premises or Tenants Alterations, and Tenant shall indemnify, defend, hold and save Landlord harmless from and against any and all Claims arising out of or in connection with any breach of this sentence.
Tenant acknowledges that Landlord may, but shall not be obligated to, seek to obtain Leadership in Energy and Environmental Design (LEED), WELL Building Standard, or other similar green certification with respect to the Project and/or the Premises, and Tenant agrees to reasonably cooperate with Landlord, and to provide such information and/or documentation as Landlord may reasonably request, in connection therewith.
8. Holding Over. If, with Landlords express written consent, Tenant retains possession of the Premises after the termination of the Term, (i) unless otherwise agreed in such written consent, such possession shall be subject to immediate termination by Landlord at any time, (ii) all of the other terms and provisions of this Lease (including, without limitation, the adjustment of Base Rent pursuant to Section 4 hereof) shall remain in full force and effect (excluding any expansion or renewal option or other similar right or option) during such holdover period, (iii) Tenant shall continue to pay Base Rent in the amount payable upon the date of the expiration or earlier termination of this Lease or such other amount as Landlord may indicate, in Landlords sole and absolute discretion, in such written consent, and (iv) all other payments shall continue under the terms of this Lease. If Tenant remains in possession of the Premises after the expiration or earlier termination of the Term without the express written consent of Landlord, (A) Tenant shall become a tenant at sufferance upon the terms of this Lease except that the monthly rental shall be equal to 150% of Base Rent in effect during the last 30 days of the Term, plus Operating Expenses and all other amounts due under this Lease, and (B) Tenant shall be responsible for all damages suffered by
400 E. Jamie Ct. - Suite 300/DiCE - Page 10
Landlord resulting from or occasioned by Tenants holding over, including consequential damages; provided, however, that if Tenant delivers a written inquiry to Landlord within 30 days prior to the expiration or earlier termination of the Term, Landlord will notify Tenant whether the potential exists for consequential damages. No holding over by Tenant, whether with or without consent of Landlord, shall operate to extend this Lease except as otherwise expressly provided, and this Section 8 shall not be construed as consent for Tenant to retain possession of the Premises. Acceptance by Landlord of Rent after the expiration of the Term or earlier termination of this Lease shall not result in a renewal or reinstatement of this Lease. Payments of Rent payable pursuant to this Section 8 for any fractional calendar month shall be prorated.
9. Taxes. Landlord shall pay, as part of Operating Expenses, all taxes, levies, fees, assessments and governmental charges of any kind, existing as of the Commencement Date or thereafter enacted (collectively referred to as Taxes), imposed by any federal, state, regional, municipal, local or other governmental authority or agency, including, without limitation, quasi-public agencies (collectively, Governmental Authority) during the Term, including, without limitation, all Taxes: (i) imposed on or measured by or based, in whole or in part, on rent payable to (or gross receipts received by) Landlord under this Lease and/or from the rental by Landlord of the Project (or any portion thereof) , or (ii) based on the square footage, assessed value or other measure or evaluation of any kind of the Premises or the Project, or (iii) assessed or imposed by or on the operation or maintenance of any portion of the Premises or the Project, including parking, or (iv) assessed or imposed by, or at the direction of, or resulting from Legal Requirements, or interpretations thereof, promulgated by any Governmental Authority, or (v) imposed as a license or other fee, charge, tax, or assessment on Landlords business or occupation of leasing space in the Project. Landlord may contest by appropriate legal proceedings the amount, validity, or application of any Taxes or liens securing Taxes. Notwithstanding anything to the contrary herein, Landlord shall only charge Tenant for assessments as if those assessments were paid by Landlord over the longest possible term which Landlord is permitted to pay for the applicable assessments without additional charge other than interest, if any, provided under the terms of the underlying assessments. Notwithstanding anything to the contrary contained in this Lease, Taxes shall not include any net income taxes, estate taxes or inheritance taxes imposed on Landlord except to the extent such net income taxes are in substitution for any Taxes payable hereunder, or any late penalties, interest or fines unless due to any late payment of Rent by Tenant. If any such Tax is levied or assessed directly against Tenant, then Tenant shall be responsible for and shall pay the same at such times and in such manner as the taxing authority shall require. Tenant shall pay, prior to delinquency, any and all Taxes levied or assessed against any personal property or trade fixtures placed by Tenant in the Premises, whether levied or assessed against Landlord or Tenant. If any Taxes on Tenants personal property or trade fixtures are levied against Landlord or Landlords property, or if the assessed valuation of the Project is increased by a value attributable to improvements in or alterations to the Premises, whether owned by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, higher than the base valuation on which Landlord from time-to-time allocates Taxes to all tenants in the Project, Landlord shall have the right, but not the obligation, to pay such Taxes. Landlords determination of any excess assessed valuation shall be binding and conclusive, absent manifest error. The amount of any such payment by Landlord shall constitute Additional Rent due from Tenant to Landlord immediately upon demand.
10. Parking. Subject to all applicable Legal Requirements, Force Majeure, a Taking (as defined in Section 19 below) and the exercise by Landlord of its rights hereunder, Tenant shall have the right, in common with other tenants of the Project pro rata in accordance with the rentable area of the Premises and the rentable areas of the Project occupied by such other tenants, to park in those areas designated for non-reserved parking, subject in each case to Landlords rules and regulations. Subject to the immediately preceding sentence, Tenants pro rata share of parking spaces shall be equal to 87 parking spaces. Landlord may allocate parking spaces among Tenant and other tenants in the Project pro rata as described above if Landlord determines that such parking facilities are becoming crowded. Landlord shall not be responsible for enforcing Tenants parking rights against any third parties, including other tenants of the Project.
11. Utilities, Services.
400 E. Jamie Ct. - Suite 300/DiCE - Page 11
(a) Generally. Landlord shall provide, subject to the terms of this Section 11, water, electricity, heat, light, power, sewer, and other utilities (including gas and fire sprinklers to the extent the Project is plumbed for such services), and, with respect to the Common Areas only, refuse and trash collection (including dumpsters located in the Common Areas which shall be available, as part of Operating Expenses, for the non-exclusive use of Tenant for the disposal of non-hazardous refuse and waste from within the Premises) and janitorial services (collectively, Utilities). Landlord shall pay, as Operating Expenses or subject to Tenants reimbursement obligation, for all Utilities used on the Premises, all maintenance charges for Utilities, and any storm sewer charges or other similar charges for Utilities imposed by any Governmental Authority or Utility provider, and any taxes, penalties, surcharges or similar charges thereon. Landlord may cause, at Landlords expense (except to the extent necessary as a result of Tenants disproportionate usage of Utilities), any Utilities to be separately metered or charged directly to Tenant by the provider. Tenant shall pay directly to the Utility provider, prior to delinquency, any separately metered Utilities and services which may be furnished to Tenant or the Premises during the Term. Tenant shall pay, as part of Operating Expenses, its share of all charges for jointly metered Utilities based upon consumption, as reasonably determined by Landlord. No interruption or failure of Utilities, from any cause whatsoever other than Landlords willful misconduct, shall result in eviction or constructive eviction of Tenant, termination of this Lease or, except as provided in the immediately following paragraph, the abatement of Rent. Tenant agrees to limit use of water and sewer with respect to Common Areas to normal restroom use. Tenant shall be responsible for obtaining and paying for its own janitorial services for the Premises.
Notwithstanding anything to the contrary set forth herein, if (i) a stoppage of an Essential Service (as defined below) to the Premises shall occur and such stoppage is due solely to the gross negligence or willful misconduct of Landlord and not due in any part to any act or omission on the part of Tenant or any Tenant Party or any matter beyond Landlords reasonable control (any such stoppage of an Essential Service being hereinafter referred to as a Service Interruption), and (ii) such Service Interruption continues for more than 5 consecutive business days after Landlord shall have received written notice thereof from Tenant, and (iii) as a result of such Service Interruption , the conduct of Tenants normal operations in the Premises are materially and adversely affected, then there shall be an abatement of one days Base Rent for each day during which such Service Interruption continues after such 5 business day period; provided, however, that if any part of the Premises is reasonably useable for Tenants normal business operations or if Tenant conducts all or any part of its operations in any portion of the Premises notwithstanding such Service Interruption, then the amount of each daily abatement of Base Rent shall only be proportionate to the nature and extent of the interruption of Tenants normal operations or ability to use the Premises. The rights granted to Tenant under this paragraph shall be Tenants sole and exclusive remedy resulting from a failure of Landlord to provide services, and Landlord shall not otherwise be liable for any loss or damage suffered or sustained by Tenant resulting from any failure or cessation of services. For purposes hereof, the term Essential Services shall mean the following services: HVAC service, water, sewer and electricity, but in each case only to the extent that Landlord has an obligation to provide same to Tenant under this Lease.
Tenant agrees to provide Landlord with access to Tenants water and/or energy usage data on a monthly basis, either by providing Tenants applicable utility login credentials to Landlords Measurabl online portal, or by another delivery method reasonably agreed to by Landlord and Tenant. The actual, reasonable costs and expenses incurred by Landlord in connection with receiving and analyzing such water and/or energy usage data (including, without limitation, as may be required pursuant to applicable Legal Requirements) shall be included as part of Operating Expenses.
(b) Emergency Generator. Landlords sole obligation for either providing an emergency generator or providing emergency back-up power to Tenant shall be: (i) to provide an emergency generator with not less than the capacity of the emergency generator located in the Building as of the date of this Lease, and (ii) to contract with a third party to maintain the emergency generator as per the manufacturers standard maintenance guidelines. Except as otherwise provided in the immediately preceding sentence, Landlord shall have no obligation to provide Tenant with an operational emergency generator or back-up power or to supervise, oversee or confirm that the third party maintaining the emergency generators is maintaining the generator as per the manufacturers standard guidelines or
400 E. Jamie Ct. - Suite 300/DiCE - Page 12
otherwise. During any period of replacement, repair or maintenance of the emergency generator when the emergency generator is not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative back-up generator or alternative sources of back-up power. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such emergency generator will be operational at all times or that emergency power will be available to the Premises when needed.
(c) Compressed Air and Vacuum. Landlords sole obligation for providing compressed air and vacuum systems to Tenant shall be to contract with a third party to maintain the compressed air and vacuum systems as per the manufacturers standard maintenance guidelines. Except as otherwise provided in the immediately preceding sentence, Landlord shall have no obligation to supervise, oversee or confirm that the third party maintaining the compressed air and vacuum systems is maintaining the compressed air and vacuum systems as per the manufacturers standard guidelines or otherwise. During any period of replacement, repair or maintenance of the compressed air and vacuum systems when the compressed air and vacuum systems are not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative compressed air and vacuum systems. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such compressed air and vacuum systems will be operational at all times or that compressed air and vacuum systems will be available to the Premises when needed.
(d) Loading Dock. Tenant may use the common loading dock serving the Building during the Term in common with others entitled thereto at no additional charge. The regular hours of operation of the loading dock are 24 hours per day, 7 days per week, subject to downtime for maintenance and repairs.
12. Alterations and Tenants Property. Any alterations, additions, or improvements made to the Premises by or on behalf of Tenant, including additional locks or bolts of any kind or nature upon any doors or windows in the Premises, but excluding installation, removal or realignment of furniture systems (other than removal of furniture systems owned or paid for by Landlord) not involving any modifications to the Building structure or connections (other than by ordinary plugs or jacks) to Building Systems (as defined in Section 13) (Alterations) shall be subject to Landlords prior written consent, which may be given or withheld in Landlords sole discretion if any such Alteration affects the Building structure or Building Systems and shall not be otherwise unreasonably withheld. Tenant may construct nonstructural, cosmetic Alterations in the Premises from time to time without Landlords prior approval if the aggregate cost of all such work in any 12 month period does not exceed $100,000 (a Notice-Only Alteration), provided Tenant notifies Landlord in writing (which written notice may be given by email to persons designated by Landlord in writing from time to time as Landlords representatives for the purpose of receiving such notices) of such intended Notice-Only Alteration, and such notice shall be accompanied by plans, specifications, work contracts and such other information concerning the nature and cost of the Notice-Only Alteration as may be reasonably requested by Landlord, which notice and accompanying materials shall be delivered to Landlord not less than 5 business days in advance of any proposed construction. If Landlord approves any Alterations, Landlord may impose such conditions on Tenant in connection with the commencement, performance and completion of such Alterations as Landlord may deem appropriate in Landlords reasonable discretion. Any request for approval shall be in writing, delivered not less than 10 business days in advance of any proposed construction, and accompanied by plans, specifications, bid proposals, work contracts and such other information concerning the nature and cost of the alterations as may be reasonably requested by Landlord, including the identities and mailing addresses of all persons performing work or supplying materials. Landlords right to review plans and specifications and to monitor construction shall be solely for its own benefit, and Landlord shall have no duty to ensure that such plans and specifications or construction comply with applicable Legal Requirements. Tenant shall cause, at its sole cost and expense, all Alterations to comply with insurance requirements and with Legal Requirements and shall implement at its sole cost and expense any alteration or modification required by Legal Requirements as a result of any Alterations. Other than in connection with Notice-Only Alterations, Tenant shall pay to Landlord, as Additional Rent, on demand, an amount equal to the reasonable out-of-pocket costs incurred by Landlord to review Tenants plans with respect to each Alteration. Before Tenant begins any Alteration, Landlord may post on and about the Premises notices of non-responsibility pursuant to applicable law.
400 E. Jamie Ct. - Suite 300/DiCE - Page 13
Tenant shall reimburse Landlord for, and indemnify and hold Landlord harmless from, any expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, delays caused by such work, or inadequate cleanup.
In connection with any Alterations anticipated to cost in excess of $100,000, Tenant shall furnish security or make other arrangements reasonably satisfactory to Landlord to assure payment for the completion of all Alterations work free and clear of liens, and shall, with respect to all Alterations, complete the work free and clear of liens and provide (and cause each contractor or subcontractor to provide) certificates of insurance for workers compensation and other coverage in amounts and from an insurance company satisfactory to Landlord protecting Landlord against liability for personal injury or property damage during construction. Upon completion of any Alterations, Tenant shall deliver to Landlord: (i) sworn statements setting forth the names of all contractors and subcontractors who did the work and final lien waivers from all such contractors and subcontractors; and (ii) as built plans for any such Alteration.
Except for Removable Installations (as hereinafter defined), all Installations (as hereinafter defined) shall be and shall remain the property of Landlord during the Term and following the expiration or earlier termination of the Term, shall not be removed by Tenant at any time during the Term, and shall remain upon and be surrendered with the Premises as a part thereof. Notwithstanding the foregoing, Landlord may, at the time its approval of any such Installation is requested, or at the time it receives notice of a Notice-Only Alteration, notify Tenant that Landlord requires that Tenant remove such Installation upon the expiration or earlier termination of the Term, in which event Tenant shall remove such Installation in accordance with the immediately succeeding sentence. Upon the expiration or earlier termination of the Term, Tenant shall remove (i) all wires, cables or similar equipment which Tenant has installed in the Premises or in the risers or plenums of the Building, (ii) any Installations for which Landlord has given Tenant notice of removal in accordance with the immediately preceding sentence, and (iii) all of Tenants Property (as hereinafter defined), and Tenant shall restore and repair any damage caused by or occasioned as a result of such removal, including, without limitation, capping off all such connections behind the walls of the Premises and repairing any holes. During any restoration period beyond the expiration or earlier termination of the Term, Tenant shall pay Rent to Landlord as provided herein as if said space were otherwise occupied by Tenant. If Landlord is requested by Tenant or any lender, lessor or other person or entity claiming an interest in any of Tenants Property to waive any lien Landlord may have against any of Tenants Property, and Landlord consents to such waiver, then Landlord shall be entitled to be paid as administrative rent a fee of $1,000 per occurrence for its time and effort in preparing and negotiating such a waiver of lien.
For purposes of this Lease, (x) Removable Installations means any items listed on Exhibit F attached hereto and any items agreed by Landlord in writing to be included on Exhibit F in the future, (y) Tenants Property means Removable Installations and, other than Installations, any personal property, trade fixtures, machinery or equipment of Tenant that may be removed without material damage to the Premises, and (z) Installations means all property of any kind paid for by Landlord, all Alterations , all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch.
Notwithstanding anything to the contrary contained herein, Tenant shall not be required to remove or restore the Tenant Improvements constructed pursuant to the Work Letter at the expiration or earlier termination of this Lease, nor shall Tenant have the right to remove such Tenant Improvements at any time other than in accordance with this Section 12.
13. Landlords Repairs. Landlord, as an Operating Expense (except to the extent the cost thereof is excluded from Operating Expenses pursuant to Section 5 hereof), shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, fire risers, elevators and all other building systems serving the Premises and other portions of
400 E. Jamie Ct. - Suite 300/DiCE - Page 14
the Project (Building Systems), in good repair, reasonable wear and tear and uninsured losses and damages (except to the extent Landlord fails to maintain the insurance required to be maintained by Landlord pursuant to Section 17 hereof and such losses or damages would have been insured losses or expenses under such insurance had Landlord not failed to maintain such insurance) caused by Tenant, or by any of Tenants assignees, sublessees, licensees, agents, servants, employees, invitees and contractors (or any of Tenants assignees, sublessees and/or licensees respective agents, servants, employees, invitees and contractors) (collectively, Tenant Parties) excluded. Subject to the provisions of the penultimate paragraph of Section 17, losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance that Landlord is required to maintain pursuant to Section 17, at Tenants sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Landlord shall use reasonable efforts to minimize interference with Tenants operations in the Premises in connection with the stoppage of Building Systems pursuant to this Section 13. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenants written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlords expense and agrees that the parties respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
14. Tenants Repairs. Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlords notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant within 10 days after demand therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises.
15. Mechanics Liens. Tenant shall discharge, by bond or otherwise, any mechanics lien filed against the Premises or against the Project for work claimed to have been done for, or materials claimed to have been furnished to, Tenant within 10 days after Tenant receives notice of the filing thereof, at Tenants sole cost and shall otherwise keep the Premises and the Project free from any liens arising out of work performed, materials furnished or obligations incurred by Tenant. Should Tenant fail to discharge any lien described herein, Landlord shall have the right, but not the obligation, to pay such claim or post a bond or otherwise provide security to eliminate the lien as a claim against title to the Project and the cost thereof shall be immediately due from Tenant as Additional Rent. If Tenant shall lease or finance the acquisition of office equipment, furnishings, or other personal property of a removable nature utilized by Tenant in the operation of Tenants business, Tenant warrants that any Uniform Commercial Code Financing Statement filed as a matter of public record by any lessor or creditor of Tenant will upon its face or by exhibit thereto indicate that such Financing Statement is applicable only to removable personal property of Tenant located within the Premises. In no event shall the address of the Project be furnished on the statement without qualifying language as to applicability of the lien only to removable personal property, located in an identified suite held by Tenant.
400 E. Jamie Ct. - Suite 300/DiCE - Page 15
16. Indemnification. Tenant hereby indemnifies and agrees to defend, save and hold Landlord, its officers, directors, employees, managers, agents, sub-agents, constituent entities and lease signators (collectively, Landlord Indemnified Parties) harmless from and against any and all Claims for injury or death to persons or damage to property occurring within or about the Premises or the Project arising directly or indirectly out of use or occupancy of the Premises or the Project by Tenant or any Tenant Parties (including, without limitation, any act, omission or neglect by Tenant or any Tenants Parties in or about the Premises or at the Project) or a breach or default by Tenant in the performance of any of its obligations hereunder, except to the extent caused by the willful misconduct or negligence of Landlord Indemnified Parties, or the default by Landlord in the performance of its obligations under this Lease. Landlord shall not be liable to Tenant for, and Tenant assumes all risk of damage to, personal property (including, without limitation, loss of records kept within the Premises). Tenant further waives any and all Claims for injury to Tenants business or loss of income relating to any such damage or destruction of personal property (including, without limitation, any loss of records). Landlord Indemnified Parties shall not be liable for any damages arising from any act, omission or neglect of any tenant in the Project or of any other third party or Tenant Parties.
17. Insurance. Landlord shall maintain all risk property and, if applicable, sprinkler damage insurance covering the full replacement cost of the Project (including the Tenant Improvements and all other fixed and permanent improvements in the Premises paid for by Landlord, if any). Landlord shall further procure and maintain commercial general liability insurance with a single loss limit of not less than $2,000,000 for bodily injury and property damage with respect to the Project. Landlord may, but is not obligated to, maintain such other insurance and additional coverages as it may deem necessary, including, but not limited to, flood, environmental hazard and earthquake, loss or failure of building equipment, errors and omissions, rental loss during the period of repair or rebuilding, workers compensation insurance and fidelity bonds for employees employed to perform services and insurance for any improvements installed by Tenant or which are in addition to the standard improvements customarily furnished by Landlord without regard to whether or not such are made a part of the Project. All such insurance shall be included as part of the Operating Expenses. The Project may be included in a blanket policy (in which case the cost of such insurance allocable to the Project will be determined by Landlord based upon the insurers cost calculations). Tenant shall also reimburse Landlord for any increased premiums or additional insurance which Landlord reasonably deems necessary as a result of Tenants use of the Premises.
Tenant, at its sole cost and expense, shall maintain during the Term: special form or all risk property insurance with business interruption and extra expense coverage, covering the full replacement cost of all property and improvements installed or placed in the Premises by Tenant at Tenants expense; workers compensation insurance with no less than the minimum limits required by law; employers liability insurance with employers liability limits of $1,000,000 bodily injury by accident - each accident, $1,000,000 bodily injury by disease - policy limit, and $1,000,000 bodily injury by disease - each employee; and commercial general liability insurance , with a minimum limit of not less than $3,000,000 per occurrence for bodily injury and property damage with respect to the Premises, which limits may be met with a combination of excess or umbrella policies. For the avoidance of doubt, the policy of all risk property insurance required to be maintained by Tenant pursuant to the immediately preceding sentence shall not include coverage for the Tenant Improvements or any other fixed and permanent improvements in the Premises paid for by Landlord, if any. The commercial general liability insurance maintained by Tenant shall name Alexandria Real Estate Equities, Inc., and Landlord, its officers, directors, employees, managers, agents, sub-agents, constituent entities and lease signators (collectively, Landlord Insured Parties), as additional insureds; insure on an occurrence and not a claims-made basis; be issued by insurance companies which have a rating of not less than policyholder rating of A and financial category rating of at least Class X in Bests Insurance Guide; shall not contain a hostile fire exclusion; contain a contractual liability endorsement; and provide primary coverage to Landlord Insured Parties (any policy issued to Landlord Insured Parties providing duplicate or similar coverage shall be deemed excess over Tenants policies, regardless of limits). Tenant shall (i) provide Landlord with 30 days advance written notice of cancellation of such commercial general liability policy, and (ii) request Tenants insurer to endeavor to provide 30 days advance written notice to Landlord of cancellation of such commercial general liability policy (or 10 days in the event of a cancellation due to non-payment of premium). Certificates of insurance showing the limits of coverage required hereunder and showing Landlord as an additional insured, along with reasonable evidence of the
400 E. Jamie Ct. - Suite 300/DiCE - Page 16
payment of premiums for the applicable period, shall be delivered to Landlord by Tenant (i) concurrent with Tenants delivery to Landlord of a copy of this Lease executed by Tenant, and (ii) prior to each renewal of said insurance. Tenants policy may be a blanket policy; provided, however, that if Tenant at any time operates its business at the Premises and concurrently operates its business at any location(s) other than the Premises, such blanket policy shall include an aggregate per location endorsement which specifically provides that the amount of insurance shall not be prejudiced by other losses covered by the policy. Tenant shall, at least 5 days prior to the expiration of such policies, furnish Landlord with renewal certificates.
In each instance where insurance is to name Landlord as an additional insured, Tenant shall upon written request of Landlord also designate and furnish certificates so evidencing Landlord as additional insured to: (i) any lender of Landlord holding a security interest in the Project or any portion thereof, (ii) the landlord under any lease wherein Landlord is tenant of the real property on which the Project is located, if the interest of Landlord is or shall become that of a tenant under a ground or other underlying lease rather than that of a fee owner, and/or (iii) any management company retained by Landlord to manage the Project.
The property insurance obtained by Landlord and Tenant shall include a waiver of subrogation by the insurers and all rights based upon an assignment from its insured, against Landlord or Tenant, and their respective officers, directors, employees, managers, agents, invitees and contractors (Related Parties), in connection with any loss or damage thereby insured against. Notwithstanding anything to the contrary contained in this Lease, neither party nor its respective Related Parties shall be liable to the other for loss or damage caused by any risk insured against under property insurance required to be maintained hereunder regardless of the negligence of the party to the Lease receiving the benefit of the waiver, and each party waives any claims against the other party, and its respective Related Parties, for such loss or damage. The failure of a party to insure its property shall not void this waiver. Landlord and its respective Related Parties shall not be liable for, and Tenant hereby waives all claims against such parties for, business interruption and losses occasioned thereby sustained by Tenant or any person claiming through Tenant resulting from any accident or occurrence in or upon the Premises or the Project from any cause whatsoever. If the foregoing waivers shall contravene any law with respect to exculpatory agreements, the liability of Landlord or Tenant shall be deemed not released but shall be secondary to the others insurer.
Landlord may require insurance policy limits to be raised to conform with requirements of Landlords lender and/or to bring coverage limits to levels then being generally required of new tenants within the Project; provided, however, that the increased amount of coverage is consistent with coverage amounts then being required by institutional owners of similar projects with tenants occupying similar size premises in the geographical area in which the Project is located.
18. Restoration. If, at any time during the Term, (x) the Premises or (y) Common Areas of the Building required for use of or access to the Premises and/or access to other tenant premises in the Building, are damaged or destroyed by a fire or other casualty, Landlord shall notify Tenant within 60 days after discovery of such damage as to the amount of time Landlord reasonably estimates it will take to restore the Building or the Premises (or the applicable portion thereof), as applicable (the Restoration Period). If the Restoration Period is estimated to exceed 12 months (the Maximum Restoration Period), Landlord may, in such notice, elect to terminate this Lease as of the date that is 75 days after the date of discovery of such damage or destruction; provided, however, that notwithstanding Landlords election to restore, if the damage or destruction involves Premises or the Common Areas of the Building required for use of or access to the Premises, Tenant may elect to terminate this Lease by written notice to Landlord delivered within 5 business days of receipt of a notice from Landlord estimating a Restoration Period for the Premises longer than the Maximum Restoration Period. Unless either Landlord or Tenant so elects to terminate this Lease, Landlord shall, subject to receipt of sufficient insurance proceeds (with any deductible to be treated as a current Operating Expense, subject to the provisions of Section 5), promptly restore the Premises (including the Tenant Improvements, but excluding any other improvements installed by Tenant or by Landlord and paid for by Tenant), subject to delays arising from the collection of insurance proceeds, from Force Majeure events or as needed to obtain any license, clearance or other authorization of any kind required to enter into and restore the Premises issued by any Governmental Authority having jurisdiction over the use, storage, handling, treatment, generation, release, disposal, removal or remediation of Hazardous Materials (as defined in Section 30) in, on or about the Premises (collectively referred to herein
400 E. Jamie Ct. - Suite 300/DiCE - Page 17
as Hazardous Materials Clearances); provided, however, that if repair or restoration of the Premises is not substantially complete as of the end of the Maximum Restoration Period or, if longer, the Restoration Period, Landlord may, in its sole and absolute discretion, elect not to proceed with such repair or restoration, or Tenant may by written notice to Landlord delivered within 5 business days of the expiration of the Maximum Restoration Period or, if longer, the Restoration Period, elect to terminate this Lease, in which event Landlord shall be relieved of its obligation to make such repairs or restoration and this Lease shall terminate as of the date that is 75 days after the later of: (i) discovery of such damage or destruction, or (ii) the date all required Hazardous Materials Clearances are obtained, but Landlord shall retain any Rent paid and the right to any Rent payable by Tenant prior to such election by Landlord or Tenant. In the event that this Lease terminates pursuant to the provisions of this Section 18 as a result of an earthquake, Tenant shall not be required to pay any deductibles applicable thereto as part of Operating Expenses.
Upon Landlords completion of all repairs or restoration required to be done by Landlord pursuant to this Section 18, Tenant, at its expense, shall promptly perform, subject to delays arising from the collection of insurance proceeds, from Force Majeure events or to obtain Hazardous Material Clearances, all repairs or restoration to the improvements installed by Tenant or by Landlord and paid for by Tenant (other than Landlords Work); provided, however, that Tenant shall nonetheless (and even if Tenant does not re-enter the Premises) continue to be responsible for all of its obligations under this Lease. Notwithstanding the foregoing, either Landlord or Tenant may terminate this Lease upon written notice to the other if the Premises are damaged during the last year of the Term and Landlord reasonably estimates that it will take more than 2 months to repair such damage; provided, however, that such notice is delivered within 10 business days after the date that Landlord provides Tenant with written notice of the estimated Restoration Period. Notwithstanding anything to the contrary contained herein, Landlord shall also have the right to terminate this Lease if insurance proceeds are not available for such restoration (for any reason other than Landlords failure to maintain the insurance required to be maintained by Landlord pursuant to Section 17). Rent shall be abated from the date all required Hazardous Material Clearances are obtained until the Premises are repaired and restored, in the proportion which the area of the Premises, if any, which is not usable by Tenant bears to the total area of the Premises. In the event that no Hazardous Material Clearances are required to be obtained by Tenant with respect to the Premises, rent abatement shall commence on the date of discovery of the damage or destruction. Such abatement shall be the sole remedy of Tenant, and except as provided in this Section 18, Tenant waives any right to terminate this Lease by reason of damage or casualty loss.
The provisions of this Lease, including this Section 18, constitute an express agreement between Landlord and Tenant with respect to any and all damage to, or destruction of, all or any part of the Premises, or any other portion of the Project, and any statute or regulation which is now or may hereafter be in effect shall have no application to this Lease or any damage or destruction to all or any part of the Premises or any other portion of the Project, the parties hereto expressly agreeing that this Section 18 sets forth their entire understanding and agreement with respect to such matters.
19. Condemnation. If the whole or any material part of the Premises or the Project is taken for any public or quasi-public use under governmental law, ordinance, or regulation, or by right of eminent domain, or by private purchase in lieu thereof (a Taking or Taken), and the Taking would in Landlords reasonable judgment, materially interfere with or impair Landlords ownership or operation of the Project or would in the reasonable judgment of Landlord and Tenant either prevent or materially interfere with Tenants use of the Premises (as resolved, if the parties are unable to agree, by arbitration by a single arbitrator with the qualifications and experience appropriate to resolve the matter and appointed pursuant to and acting in accordance with the rules of the American Arbitration Association), then upon written notice by Landlord or Tenant to the other this Lease shall terminate and Rent shall be apportioned as of said date. If part of the Premises shall be Taken, and this Lease is not terminated as provided above, Landlord shall promptly restore the Premises and the Project as nearly as is commercially reasonable under the circumstances to their condition prior to such partial Taking and the rentable square footage of the Building, the rentable square footage of the Premises, Tenants Share of Operating Expenses and the Rent payable hereunder during the unexpired Term shall be reduced to such extent as may be fair and reasonable under the circumstances. Upon any such Taking, Landlord shall be entitled to receive the entire price or award from any such Taking without any payment to Tenant, and Tenant hereby assigns to Landlord Tenants interest,
400 E. Jamie Ct. - Suite 300/DiCE - Page 18
if any, in such award. Tenant shall have the right, to the extent that same shall not diminish Landlords award, to make a separate claim against the condemning authority (but not Landlord) for such compensation as may be separately awarded or recoverable by Tenant for moving expenses and damage to Tenants trade fixtures, if a separate award for such items is made to Tenant. Tenant hereby waives any and all rights it might otherwise have pursuant to any provision of state law to terminate this Lease upon a partial Taking of the Premises or the Project.
20. Events of Default. Each of the following events shall be a default (Default) by Tenant under this Lease:
(a) Payment Defaults. Tenant shall fail to pay any installment of Rent or any other payment hereunder when due; provided, however, that Landlord will give Tenant notice and an opportunity to cure any failure to pay Rent within 5 days of any such notice not more than twice in any 12 month period.
(b) Insurance. Any insurance required to be maintained by Tenant pursuant to this Lease shall be canceled or terminated or shall expire or shall be reduced or materially changed so that it no longer complies with requirements of this Lease, or Landlord shall receive a notice of nonrenewal of any such insurance and Tenant shall fail to obtain replacement insurance prior to the expiration of the current coverage.
(c) Abandonment. Tenant shall abandon the Premises. Tenant shall not be deemed to have abandoned the Premises if Tenant provides Landlord with reasonable advance notice prior to vacating and, at the time of vacating the Premises, (i) Tenant completes Tenants obligations under the Decommissioning and HazMat Closure Plan in compliance with Section 28, (ii) Tenant has obtained the release of the Premises of all Hazardous Materials Clearances and the Premises are free from any residual impact from the Tenant HazMat Operations and provides reasonably detailed documentation to Landlord confirming such matters, (iii) Tenant has made reasonable arrangements with Landlord for the security of the Premises for the balance of the Term, and (iv) Tenant continues during the balance of the Term to satisfy and perform all of Tenants obligations under this Lease as they come due.
(d) Improper Transfer. Tenant shall assign, sublease or otherwise transfer or attempt to transfer all or any portion of Tenants interest in this Lease or the Premises except as expressly permitted herein, or Tenants interest in this Lease shall be attached, executed upon, or otherwise judicially seized and such action is not released within 90 days of the action.
(e) Liens. Tenant shall fail to discharge or otherwise obtain the release of any lien placed upon the Premises in violation of this Lease within 10 days after Tenant receives notice that any such lien has been filed against the Premises.
(f) Insolvency Events. Tenant or any guarantor or surety of Tenants obligations hereunder shall: (A) make a general assignment for the benefit of creditors; (B) commence any case, proceeding or other action seeking to have an order for relief entered on its behalf as a debtor or to adjudicate it a bankrupt or insolvent, or seeking reorganization, arrangement, adjustment, liquidation , dissolution or composition of it or its debts or seeking appointment of a receiver, trustee, custodian or other similar official for it or for all or of any substantial part of its property (collectively a Proceeding for Relief); (C) become the subject of any Proceeding for Relief which is not dismissed within 90 days of its filing or entry; or (D) die or suffer a legal disability (if Tenant, guarantor, or surety is an individual) or be dissolved or otherwise fail to maintain its legal existence (if Tenant, guarantor or surety is a corporation, partnership or other entity).
(g) Estoppel Certificate or Subordination Agreement. Tenant fails to execute any document required from Tenant under Sections 23 or 27 within 5 days after a second notice requesting such document.
400 E. Jamie Ct. - Suite 300/DiCE - Page 19
(h) Other Defaults. Tenant shall fail to comply with any provision of this Lease other than those specifically referred to in this Section 20, and, except to the extent a different time period is otherwise expressly provided for herein, such failure shall continue for a period of 30 days after written notice thereof from Landlord to Tenant.
Any notice given under Section 20(h) hereof shall: (i) specify the alleged default, (ii) demand that Tenant cure such default, (iii) be in lieu of, and not in addition to, or shall be deemed to be, any notice required under any provision of applicable law, and (iv) not be deemed a forfeiture or a termination of this Lease unless Landlord elects otherwise in such notice; provided that if the nature of Tenants default pursuant to Section 20(h) is such that it cannot be cured by the payment of money and reasonably requires more than 30 days to cure, then Tenant shall not be deemed to be in default if Tenant commences such cure within said 30 day period and thereafter diligently prosecutes the same to completion; provided, however, that such cure shall be completed no later than 90 days from the date of Landlords notice.
21. Landlords Remedies.
(a) Payment By Landlord; Interest. Upon a Default by Tenant hereunder, Landlord may, without waiving or releasing any obligation of Tenant hereunder, make such payment or perform such act. All sums so paid or incurred by Landlord, together with interest thereon, from the date such sums were paid or incurred, at the annual rate equal to 12% per annum or the highest rate permitted by law (the Default Rate), whichever is less, shall be payable to Landlord on demand as Additional Rent. Nothing herein shall be construed to create or impose a duty on Landlord to mitigate any damages resulting from Tenants Default hereunder.
(b) Late Payment Rent. Late payment by Tenant to Landlord of Rent and other sums due will cause Landlord to incur costs not contemplated by this Lease, the exact amount of which will be extremely difficult and impracticable to ascertain. Such costs include, but are not limited to, processing and accounting charges and late charges which may be imposed on Landlord under any Mortgage covering the Premises. Therefore, if any installment of Rent due from Tenant is not received by Landlord within 5 days after the date such payment is due, Tenant shall pay to Landlord an additional sum equal to 6% of the overdue Rent as a late charge. Notwithstanding the foregoing, before assessing a late charge the first time in any calendar year, Landlord shall provide Tenant written notice of the delinquency and will waive the right if Tenant pays such delinquency within 5 days thereafter. The parties agree that this late charge represents a fair and reasonable estimate of the costs Landlord will incur by reason of late payment by Tenant. In addition to the late charge, Rent not paid when due shall bear interest at the Default Rate from the 5th day after the date due until paid.
(c) Remedies. Upon the occurrence of a Default, Landlord, at its option, without further notice or demand to Tenant, shall have in addition to all other rights and remedies provided in this Lease, at law or in equity, the option to pursue any one or more of the following remedies, each and all of which shall be cumulative and nonexclusive, without any notice or demand whatsoever.
(i) Terminate this Lease, or at Landlords option, Tenants right to possession only, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy which it may have for possession or arrearages in rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim for damages therefor;
(ii) Upon termination of this Lease, whether pursuant to the foregoing Section 21(c)(i) or otherwise, Landlord may recover from Tenant the following:
(A) The worth at the time of award of any unpaid rent which has been earned at the time of such termination; plus
400 E. Jamie Ct. - Suite 300/DiCE - Page 20
(B) The worth at the time of award of the amount by which the unpaid rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus
(C) The worth at the time of award of the amount by which the unpaid rent for the balance of the Term after the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus
(D) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenants failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including, but not limited to, to the extent allocable to the remainder of the Term, brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion thereof for a new tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant; and
(E) At Landlords election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by applicable law.
The term rent as used in this Section 21 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii)(A) and (B), above, the worth at the time of award shall be computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the worth at the time of award shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.
(iii) Landlord may continue this Lease in effect after Tenants Default and recover rent as it becomes due (Landlord and Tenant hereby agreeing that Tenant has the right to sublet or assign hereunder, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease following a Default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due.
(iv) Following Landlords termination of this Lease following a Default by Tenant, Landlord shall have the right to terminate any and all subleases, licenses, concessions or other consensual arrangements for possession entered into by Tenant and affecting the Premises or may, in Landlords sole discretion, succeed to Tenants interest in such subleases, licenses, concessions or arrangements. Upon Landlords election to succeed to Tenants interest in any such subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of such election, have no further right to or interest in the rent or other consideration receivable thereunder.
(v) Independent of the exercise of any other remedy of Landlord hereunder or under applicable law, Landlord may conduct an environmental test of the Premises as generally described in Section 30(d) hereof, at Tenants expense.
(d) Effect of Exercise. Exercise by Landlord of any remedies hereunder or otherwise available shall not be deemed to be an acceptance of surrender of the Premises and/or a termination of this Lease by Landlord, it being understood that such surrender and/or termination can be effected only by the express written agreement of Landlord and Tenant. Any law, usage, or custom to the contrary notwithstanding, Landlord shall have the right at all times to enforce the provisions of this Lease in strict accordance with the terms hereof; and the failure of Landlord at any time to enforce its rights under this Lease strictly in accordance with same shall not be construed as having created a custom in any way or manner contrary to the specific terms, provisions, and covenants of this Lease or as having modified the
400 E. Jamie Ct. - Suite 300/DiCE - Page 21
same and shall not be deemed a waiver of Landlords right to enforce one or more of its rights in connection with any subsequent default. A receipt by Landlord of Rent or other payment with knowledge of the breach of any covenant hereof shall not be deemed a waiver of such breach, and no waiver by Landlord of any provision of this Lease shall be deemed to have been made unless expressed in writing and signed by Landlord. To the greatest extent permitted by law, Tenant waives the service of notice of Landlords intention to re-enter, re-take or otherwise obtain possession of the Premises as provided in any statute, or to institute legal proceedings to that end, and also waives all right of redemption in case Tenant shall be dispossessed by a judgment or by warrant of any court or judge. Notwithstanding the foregoing, nothing contained herein shall constitute Tenants waiver of its rights under applicable Legal Requirements to receive a 3-day notice from Landlord to quit or pay rent prior to Landlord commencing an unlawful detainer action. Any reletting of the Premises or any portion thereof shall be on such terms and conditions as Landlord in its sole discretion may determine. Landlord shall not be liable for, nor shall Tenants obligations hereunder be diminished because of, Landlords failure to relet the Premises or collect rent due in respect of such reletting or otherwise to mitigate any damages arising by reason of Tenants Default.
22. Assignment and Subletting.
(a) General Prohibition. Without Landlords prior written consent subject to and on the conditions described in this Section 22, Tenant shall not, directly or indirectly, voluntarily or by operation of law, assign this Lease or sublease the Premises or any part thereof or mortgage, pledge, or hypothecate its leasehold interest or grant any concession or license within the Premises, and any attempt to do any of the foregoing shall be void and of no effect. Notwithstanding anything to the contrary contained herein, Tenant shall have the right to obtain financing from institutional investors (including venture capital funding and corporate partners) which regularly invest in private biotechnology companies or undergo a public offering which results in a change in control of Tenant without such change of control constituting an assignment under this Section 22 requiring Landlord consent, provided that (i) Tenant notifies Landlord in writing of the financing at least 5 business days prior to the closing of the financing, and (ii) provided that in no event shall such financing result in a change in use of the Premises from the use contemplated by Tenant at the commencement of the Term.
(b) Permitted Transfers. If Tenant desires to assign, sublease, hypothecate or otherwise transfer this Lease or sublet the Premises other than pursuant to a Permitted Assignment (as defined below), then at least 15 business days, but not more than 45 business days, before the date Tenant desires the assignment or sublease to be effective (the Assignment Date), Tenant shall give Landlord a notice (the Assignment Notice) containing such information about the proposed assignee or sublessee, including the proposed use of the Premises and any Hazardous Materials proposed to be used, stored handled, treated, generated in or released or disposed of from the Premises, the Assignment Date, any relationship between Tenant and the proposed assignee or sublessee, and all material terms and conditions of the proposed assignment or sublease, including a copy of any proposed assignment or sublease in its final form, and such other information as Landlord may deem reasonably necessary or appropriate to its consideration whether to grant its consent. Landlord may, by giving written notice to Tenant within 15 business days after receipt of the Assignment Notice: (i) grant such consent (provided that Landlord shall further have the right to review and approve or disapprove the proposed form of sublease prior to the effective date of any such subletting), (ii) refuse such consent, in its reasonable discretion; or (iii) with respect to any assignment or any sublease that would result in more than 50% of the Premises being subleased for substantially the remainder of the Term, terminate this Lease with respect to the space described in the Assignment Notice as of the Assignment Date (an Assignment Termination). Among other reasons, it shall be reasonable for Landlord to withhold its consent in any of these instances: (1) the proposed assignee or subtenant is a governmental agency; (2) in Landlords reasonable judgment, the use of the Premises by the proposed assignee or subtenant would entail any alterations that would materially lessen the value of the leasehold improvements in the Premises, or would require materially increased services by Landlord; (3) in Landlords reasonable judgment, the proposed assignee or subtenant is engaged in areas of scientific research or other business concerns that are controversial in a manner that is inconsistent with other tenants in the Project such that they may (i) attract or cause negative publicity for or about the Building or the Project, (ii) negatively affect the reputation of the Building, the Project or Landlord, (iii) attract protestors to the Building or the Project, or (iv) lessen the attractiveness of the Building
400 E. Jamie Ct. - Suite 300/DiCE - Page 22
or the Project to any tenants or prospective tenants, purchasers or lenders; (4) in Landlords reasonable judgment, the proposed assignee or subtenant lacks the creditworthiness to support the financial obligations it will incur under the proposed assignment or sublease; (5) in Landlords reasonable judgment, the character or reputation of the proposed assignee or subtenant is unethical, corrupt or immoral, or business of the proposed assignee or subtenant is inconsistent with the desired tenant-mix or the quality of other tenancies in the Project or is inconsistent with the type and quality of the nature of the Building; (6) intentionally omitted; (7) Landlord has experienced previous defaults by or is in litigation with the proposed assignee or subtenant; (8) the use of the Premises by the proposed assignee or subtenant will violate any applicable Legal Requirement ; (9) intentionally omitted; (10) the proposed assignee or subtenant is an entity with whom Landlord is then-currently negotiating to lease space in the Project; or (11) the assignment or sublease is prohibited by Landlords lender. If Landlord delivers notice of its election to exercise an Assignment Termination, Tenant shall have the right to withdraw such Assignment Notice by written notice to Landlord of such election within 5 business days after Landlords notice electing to exercise the Assignment Termination. If Tenant withdraws such Assignment Notice, this Lease shall continue in full force and effect. If Tenant does not withdraw such Assignment Notice, this Lease, and the term and estate herein granted, shall terminate as of the Assignment Date with respect to the space described in such Assignment Notice and, as of the Assignment Date, except for those obligations that expressly survive the expiration or earlier termination of this Lease, neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease with respect to the space described in the Assignment Notice (including Base Rent or Tl Rent in connection therewith) and the Security Deposit shall be proportionately reduced. No failure of Landlord to exercise any such option to terminate this Lease, or to deliver a timely notice in response to the Assignment Notice, shall be deemed to be Landlords consent to the proposed assignment, sublease or other transfer. Tenant shall pay to Landlord a fee equal to Two Thousand Five Hundred Dollars ($2,500) in connection with its consideration of any Assignment Notice and/or its preparation or review of any consent documents. Notwithstanding the foregoing, Landlords consent to an assignment of this Lease or a subletting of any portion of the Premises to any entity controlling, controlled by or under common control with Tenant (a Control Permitted Assignment) shall not be required, provided that Landlord shall have the right to approve the form of any such sublease or assignment (which approval shall not be unreasonably withheld or delayed). In addition, Tenant shall have the right to assign this Lease, upon 15 days prior written notice to Landlord ((x) unless Tenant is prohibited from providing such notice by applicable Legal Requirements in which case Tenant shall notify Landlord promptly thereafter, and (y) if the transaction is subject to confidentiality requirements, Tenants advance notification shall be subject to Landlords execution of a non-disclosure agreement reasonably acceptable to Landlord and Tenant) but without obtaining Landlords prior written consent, to a corporation or other entity which is a successor-in-interest to Tenant, by way of merger, consolidation or corporate reorganization, or by the purchase of all or substantially all of the assets or the ownership interests of Tenant provided that (i) such merger or consolidation, or such acquisition or assumption, as the case may be, is for a good business purpose and not principally for the purpose of transferring this Lease, and (ii) the net worth (as determined in accordance with generally accepted accounting principles (GAAP)) of the assignee is not less than the net worth (as determined in accordance with GAAP) of Tenant as of the date of Tenants most current quarterly or annual financial statements, and (iii) such assignee shall agree in writing to assume all of the terms, covenants and conditions of this Lease (a Corporate Permitted Assignment). Control Permitted Assignments and Corporate Permitted Assignments are hereinafter referred to as Permitted Assignments. Notwithstanding anything to the contrary contained herein, Landlord shall have no right to deliver an Assignment Termination in connection with a Permitted Assignment.
Notwithstanding anything to the contrary contained in this Lease, Tenant may from time to time enter into agreements (each, a Shared Space Arrangement) with affiliates and contractors of Tenant pursuant to which such affiliates and contractors may occupy portions of the Premises, not to exceed 10% of the Premises, as Shared Space Area, and such Shared Space Arrangements shall not require Landlords consent under this Section 22; provided, however, that Tenant shall be required to provide Landlord with a copy of each such license agreement and, prior to the effective date of each such license agreement, Tenant and each licensee shall be required to execute Landlords reasonable form of acknowledgment pursuant to which Tenant and the licensee acknowledge and agree, among other things, that: (i) the terms of the Shared Space Arrangement are subject and subordinate to the terms of this Lease, (ii) if this Lease terminates, then the Shared Space Arrangement shall terminate concurrently therewith, (iii)
400 E. Jamie Ct. - Suite 300/DiCE - Page 23
each licensee shall, during the term of its applicable Shared Space Arrangement, maintain the same insurance as is required of Tenant under this Lease and provide Landlord with insurance certificates evidencing the same and naming the Landlord Parties as additional insureds, and (iv) the waivers and releases set forth in the second to last paragraph of Section 17 that apply as between Landlord and Tenant shall also apply as between Landlord and licensee. Tenant shall be fully responsible for the conduct of such companies within the Shared Space Area and the Project, and Tenants indemnification obligations set forth in this Lease shall apply with respect to the conduct of such parties within the Shared Space Area and Project.
(c) Additional Conditions. As a condition to any such assignment or subletting, whether or not Landlords consent is required, Landlord may require:
(i) that any assignee or subtenant agree, in writing at the time of such assignment or subletting, that if Landlord gives such party notice that Tenant is in default under this Lease, such party shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments will be received by Landlord without any liability except to credit such payment against those due under this Lease, and any such third party shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided, however, in no event shall Landlord or its successors or assigns be obligated to accept such attornment; and
(ii) A list of Hazardous Materials, certified by the proposed assignee or sublessee to be true and correct, which the proposed assignee or sublessee intends to use, store, handle, treat, generate in or release or dispose of from the Premises, together with copies of all documents relating to such use, storage, handling, treatment, generation, release or disposal of Hazardous Materials by the proposed assignee or subtenant in the Premises or on the Project, prior to the proposed assignment or subletting, including, without limitation: permits; approvals; reports and correspondence; storage and management plans; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given its written consent to do so, which consent may be withheld in Landlords sole and absolute discretion); and all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks. Neither Tenant nor any such proposed assignee or subtenant is required, however, to provide Landlord with any portion(s) of the such documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities.
(d) No Release of Tenant, Sharing of Excess Rents. Notwithstanding any assignment or subletting, Tenant and any guarantor or surety of Tenants obligations under this Lease shall at all times remain fully and primarily responsible and liable for the payment of Rent and for compliance with all of Tenants other obligations under this Lease. Other than in connection with any assignment that constitutes a Permitted Assignment and Shared Space Arrangements , if the rent due and payable by a sublessee or assignee (or a combination of the rental payable under such sublease or assignment plus any bonus or other consideration therefor or incident thereto in any form attributable to the assignment or sublease) exceeds the sum of the Base Rent and Operating Expenses payable under this Lease, plus actual and reasonable brokerage fees, legal costs and any design or construction fees directly related to and required pursuant to the terms of any such sublease (Excess Rent), then Tenant shall be bound and obligated to pay Landlord as Additional Rent hereunder 50% of such Excess Rent within 10 days following receipt thereof by Tenant. If Tenant shall sublet the Premises or any part thereof, Tenant hereby immediately and irrevocably assigns to Landlord, as security for Tenants obligations under this Lease, all rent from any such subletting, and Landlord as assignee and as attorney-in-fact for Tenant, or a receiver for Tenant appointed on Landlords application, may collect such rent and apply it toward Tenants obligations under this Lease; except that, until the occurrence of a Default, Tenant shall have the right to collect such rent.
(e) No Waiver. The consent by Landlord to an assignment or subletting shall not relieve Tenant or any assignees of this Lease or any sublessees of the Premises from obtaining the consent
400 E. Jamie Ct. - Suite 300/DiCE - Page 24
of Landlord to any further assignment or subletting nor shall it release Tenant or any assignee or sublessee of Tenant from full and primary liability under this Lease. The acceptance of Rent hereunder, or the acceptance of performance of any other term, covenant, or condition thereof, from any other person or entity shall not be deemed to be a waiver of any of the provisions of this Lease or a consent to any subletting, assignment or other transfer of the Premises.
(f) Prior Conduct of Proposed Transferee. Notwithstanding any other provision of this Section 22, if (i) the proposed assignee or sublessee of Tenant has been required by any prior landlord, lender or Governmental Authority to take remedial action in connection with Hazardous Materials contaminating a property, where the contamination resulted from such partys action or use of the property in question, (ii) the proposed assignee or sublessee is subject to an enforcement order issued by any Governmental Authority in connection with the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials (including, without limitation, any order related to the failure to make a required reporting to any Governmental Authority), or (iii) because of the existence of a pre-existing environmental condition in the vicinity of or underlying the Project, the risk that Landlord would be targeted as a responsible party in connection with the remediation of such pre-existing environmental condition would be materially increased or exacerbated by the proposed use of Hazardous Materials by such proposed assignee or sublessee, Landlord shall have the absolute right to refuse to consent to any assignment or subletting to any such party.
23. Estoppel Certificate. Tenant shall, within 10 business days of written notice from Landlord, execute, acknowledge and deliver a statement in writing in any form reasonably requested by a proposed lender or purchaser, (i) certifying that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this Lease as so modified is in full force and effect) and the dates to which the rental and other charges are paid in advance, if any, (ii) acknowledging that, to Tenants knowledge, there are not any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (iii) setting forth such further information with respect to the status of this Lease or the Premises as may be requested thereon. Any such statement may be relied upon by any prospective purchaser or encumbrancer of all or any portion of the real property of which the Premises are a part. Tenants failure to deliver such statement within 5 days after Tenants receipt of a second written notice from Landlord shall, at the option of Landlord, constitute a Default under this Lease, and, in any event, shall be conclusive upon Tenant that this Lease is in full force and effect and without modification except as may be represented by Landlord in any certificate prepared by Landlord and delivered to Tenant for execution.
24. Quiet Enjoyment. So long as Tenant is not in Default under this Lease, Tenant shall, subject to the terms of this Lease, at all times during the Term, have peaceful and quiet enjoyment of the Premises against any person claiming by, through or under Landlord.
25. Prorations. All prorations required or permitted to be made hereunder shall be made on the basis of a 360-day year and 30-day months.
26. Rules and Regulations. Tenant shall, at all times during the Term and any extension thereof, comply with all reasonable rules and regulations at any time or from time to time established by Landlord covering use of the Premises and the Project. Such rules and regulations may include, without limitation, reasonable rules and regulations relating to the use of the Project Amenities and/or rules and regulations which are intended to encourage social distancing, promote and protect health and physical well-being within the Building and the Project and/or intended to limit the spread of Infectious Conditions. The current rules and regulations are attached hereto as Exhibit E. If there is any conflict between said rules and regulations and other provisions of this Lease, the terms and provisions of this Lease shall control. Landlord shall not have any liability or obligation for the breach of any rules or regulations by other tenants in the Project and shall not enforce such rules and regulations in a discriminatory manner.
27. Subordination. This Lease and Tenants interest and rights hereunder are hereby made and shall be subject and subordinate at all times to the lien of any Mortgage now existing or hereafter created on or against the Project or the Premises, and all amendments, restatements, renewals,
400 E. Jamie Ct. - Suite 300/DiCE - Page 25
modifications, consolidations, refinancing, assignments and extensions thereof, without the necessity of any further instrument or act on the part of Tenant; provided, however that so long as there is no Default hereunder, Tenants right to possession of the Premises shall not be disturbed by the Holder of any such Mortgage. Tenant agrees, at the election of the Holder of any such Mortgage, to attorn to any such Holder. Tenant agrees upon demand to execute, acknowledge and deliver such instruments, confirming such subordination, and such instruments of attornment as shall be requested by any such Holder, provided any such instruments contain appropriate non-disturbance provisions assuring Tenants quiet enjoyment of the Premises as set forth in Section 24 hereof. Notwithstanding the foregoing, any such Holder may at any time subordinate its Mortgage to this Lease, without Tenants consent, by notice in writing to Tenant, and thereupon this Lease shall be deemed prior to such Mortgage without regard to their respective dates of execution, delivery or recording and in that event such Holder shall have the same rights with respect to this Lease as though this Lease had been executed prior to the execution, delivery and recording of such Mortgage and had been assigned to such Holder. The term Mortgage whenever used in this Lease shall be deemed to include deeds of trust, security assignments and any other encumbrances, and any reference to the Holder of a Mortgage shall be deemed to include the beneficiary under a deed of trust. As of the date of this Lease, there is no existing Mortgage encumbering the Project.
Upon written request from Tenant, Landlord agrees to use reasonable efforts to cause the Holder of any future Mortgage to enter into a subordination, non-disturbance and attornment agreement (SNDA) with Tenant with respect to this Lease. The SNDA shall be on the form proscribed by the Holder and Tenant shall pay the Holders fees and costs in connection with obtaining such SNDA; provided, however, that Landlord shall request that Holder make any reasonable changes to the SNDA requested by Tenant. Landlords failure to cause the Holder to enter into the SNDA with Tenant (or make any of the changes requested by Tenant) despite such efforts shall not be a default by Landlord under this Lease.
28. Surrender. Upon the expiration of the Term or earlier termination of Tenants right of possession, Tenant shall surrender the Premises to Landlord in the same condition as Delivered on the Commencement Date, subject to any Alterations or Installations permitted by Landlord to remain in the Premises, free of Hazardous Materials brought upon, kept, used, stored, handled, treated, generated in, or released or disposed of from, the Premises by any person other than a Landlord Party (collectively, Tenant HazMat Operations) and released of all Hazardous Materials Clearances, broom clean, ordinary wear and tear and casualty loss and condemnation covered by Sections 18 and ,N excepted. At least 3 months prior to the surrender of the Premises or such earlier date as Tenant may elect to cease operations at the Premises, Tenant shall deliver to Landlord a narrative description of the actions proposed (or required by any Governmental Authority) to be taken by Tenant in order to surrender the Premises (including any Installations permitted by Landlord to remain in the Premises) at the expiration or earlier termination of the Term, free from any residual impact from the Tenant HazMat Operations and otherwise released for unrestricted use and occupancy (the Decommissioning and HazMat Closure Plan). Such Decommissioning and HazMat Closure Plan shall be accompanied by a current listing of (i) all Hazardous Materials licenses and permits held by or on behalf of any Tenant Party with respect to the Premises, and (ii) all Hazardous Materials used, stored, handled, treated, generated, released or disposed of from the Premises, and shall be subject to the review and approval of Landlords environmental consultant, which approval shall not be unreasonably withheld or delayed. In connection with the review and approval of the Decommissioning and HazMat Closure Plan, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such additional non-proprietary information concerning Tenant HazMat Operations as Landlord shall request. On or before such surrender, Tenant shall deliver to Landlord evidence that the approved Decommissioning and HazMat Closure Plan shall have been satisfactorily completed and Landlord shall have the right, subject to reimbursement at Tenants expense as set forth below, to cause Landlords environmental consultant to inspect the Premises and perform such additional procedures as may be deemed reasonably necessary to confirm that the Premises are, as of the effective date of such surrender or early termination of this Lease, free from any residual impact from Tenant HazMat Operations. Tenant shall reimburse Landlord, as Additional Rent, for the actual, reasonable out-of-pocket expense incurred by Landlord for Landlords environmental consultant to review and approve the Decommissioning and HazMat Closure Plan and to visit the Premises and verify satisfactory completion of the same, which cost shall not exceed $5,000. Landlord shall have the unrestricted right to deliver such Decommissioning and HazMat Closure Plan and any report by Landlords environmental consultant with respect to the surrender of the Premises to third parties.
400 E. Jamie Ct. - Suite 300/DiCE - Page 26
If Tenant shall fail to prepare or submit a Decommissioning and HazMat Closure Plan approved by Landlord, or if Tenant shall fail to complete the approved Decommissioning and HazMat Closure Plan, or if such Decommissioning and HazMat Closure Plan, whether or not approved by Landlord, shall fail to adequately address any residual effect of Tenant HazMat Operations in, on or about the Premises, Landlord shall have the right to take such actions as Landlord may deem reasonable or appropriate to assure that the Premises and the Project are surrendered free from any residual impact from Tenant HazMat Operations, the cost of which actions shall be reimbursed by Tenant as Additional Rent, without regard to the limitation set forth in the first paragraph of this Section 28.
Tenant shall immediately return to Landlord all keys and/or access cards to parking, the Project, restrooms or all or any portion of the Premises furnished to or otherwise procured by Tenant. If any such access card or key is lost, Tenant shall pay to Landlord, at Landlords election, either the reasonable cost of replacing such lost access card or key or the reasonable cost of reprogramming the access security system in which such access card was used or changing the lock or locks opened by such lost key. Any Tenants Property, Alterations and property not so removed by Tenant as permitted or required herein shall be deemed abandoned and may be stored, removed, and disposed of by Landlord at Tenants expense, and Tenant waives all claims against Landlord for any damages resulting from Landlords retention and/or disposition of such property. All obligations of Tenant hereunder not fully performed as of the termination of the Term, including the obligations of Tenant under Section 30 hereof, shall survive the expiration or earlier termination of the Term, including, without limitation, indemnity obligations, payment obligations with respect to Rent and obligations concerning the condition and repair of the Premises.
29. Waiver of Jury Trial. TO THE EXTENT PERMITTED BY LAW, TENANT AND LANDLORD WAIVE ANY RIGHT TO TRIAL BY JURY OR TO HAVE A JURY PARTICIPATE IN RESOLVING ANY DISPUTE, WHETHER SOUNDING IN CONTRACT, TORT, OR OTHERWISE, BETWEEN LANDLORD AND TENANT ARISING OUT OF THIS LEASE OR ANY OTHER INSTRUMENT, DOCUMENT, OR AGREEMENT EXECUTED OR DELIVERED IN CONNECTION HEREWITH OR THE TRANSACTIONS RELATED HERETO.
30. Environmental Requirements.
(a) Prohibition/Compliance/Indemnity. Tenant shall not cause or permit any Hazardous Materials (as hereinafter defined) to be brought upon, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises or the Project in violation of applicable Environmental Requirements (as hereinafter defined) by Tenant or any Tenant Party. If Tenant breaches the obligation stated in the preceding sentence, or if the presence of Hazardous Materials in the Premises during the Term or any holding over results in contamination of the Premises, the Project or any adjacent property or if contamination of the Premises, the Project or any adjacent property by Hazardous Materials brought into, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises by anyone other than Landlord and Landlords employees, agents and contractors otherwise occurs during the Term or any holding over, Tenant hereby indemnifies and shall defend and hold Landlord, its officers, directors, employees, agents and contractors harmless from any and all actions (including, without limitation, remedial or enforcement actions of any kind, administrative or judicial proceedings, and orders or judgments arising out of or resulting therefrom), costs, claims, damages (including, without limitation, punitive damages and damages based upon diminution in value of the Premises or the Project, or the loss of, or restriction on, use of the Premises or any portion of the Project), expenses (including, without limitation, attorneys, consultants and experts fees, court costs and amounts paid in settlement of any claims or actions), fines, forfeitures or other civil, administrative or criminal penalties, injunctive or other relief (whether or not based upon personal injury, property damage, or contamination of, or adverse effects upon, the environment, water tables or natural resources,) liabilities or losses which arise during or after the Term as a result of such contamination. This indemnification of Landlord by Tenant includes, without limitation, costs incurred in connection with any investigation of site conditions or any cleanup, treatment, remedial, removal, or restoration work required by any federal, state or local Governmental Authority
400 E. Jamie Ct. - Suite 300/DiCE - Page 27
because of Hazardous Materials present in the air, soil or ground water above, on, or under the Premises. Without limiting the foregoing, if the presence of any Hazardous Materials on the Premises, the Building, the Project or any adjacent property caused by Tenant or any Tenant Party results in any contamination of the Premises, the Building, the Project or any adjacent property, Tenant shall promptly take all actions at its sole expense and in accordance with applicable Environmental Requirements as are necessary to return the Premises, the Building, the Project or any adjacent property to the condition existing prior to the time of such contamination, provided that Landlords approval of such action shall first be obtained, which approval shall not unreasonably be withheld so long as such actions would not potentially have any material adverse long-term or short-term effect on the Premises, the Building or the Project. Notwithstanding anything to the contrary contained in Section 28 or this Section 30, Tenant shall not be responsible for or have any liability to Landlord, and the indemnification and hold harmless obligation set forth in this paragraph shall not apply to (i) contamination in the Premises which Tenant can prove to Landlords reasonable satisfaction existed in the Premises immediately prior to the Commencement Date, (ii) the presence of any Hazardous Materials in the Premises which Tenant can prove to Landlords reasonable satisfaction migrated from outside of the Premises into the Premises, or (iii) any Hazardous Materials that Tenant can prove to Landlords reasonable satisfaction were not brought upon, kept, used, stored, handled, treated, generated in or released or disposed of from the Premises or the Project by Tenant or any Tenant Party, unless in any case, the presence of such Hazardous Materials (x) is the result of a breach by Tenant of any of its obligations under this Lease, or (y) was caused, contributed to or exacerbated by Tenant or any Tenant Party.
(b) Business. Landlord acknowledges that it is not the intent of this Section 30 to prohibit Tenant from using the Premises for the Permitted Use. Tenant may operate its business according to prudent industry practices so long as the use or presence of Hazardous Materials is strictly and properly monitored according to all then applicable Environmental Requirements. As a material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees to deliver to Landlord prior to the Commencement Date a list identifying each type of Hazardous Materials to be brought upon, kept, used, stored, handled, treated, generated on, or released or disposed of from, the Premises and setting forth any and all governmental approvals or permits required in connection with the presence, use, storage, handling, treatment, generation, release or disposal of such Hazardous Materials on or from the Premises (Hazardous Materials List). Upon Landlords request, or any time that Tenant is required to deliver a Hazardous Materials List to any Governmental Authority (e.g., the fire department) in connection with Tenants use or occupancy of the Premises, Tenant shall deliver to Landlord a copy of such Hazardous Materials List. Tenant shall deliver to Landlord true and correct copies of the following documents (the Haz Mat Documents) relating to the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials prior to the Commencement Date, or if unavailable at that time, concurrent with the receipt from or submission to a Governmental Authority: permits; approvals; reports and correspondence; storage and management plans, notice of violations of any Legal Requirements ; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given Tenant its written consent to do so, which consent may be withheld in Landlords sole and absolute discretion); all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks; and a Decommissioning and HazMat Closure Plan (to the extent surrender in accordance with Section 28 cannot be accomplished in 3 months). Tenant is not required, however, to provide Landlord with any portion(s) of the Haz Mat Documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities. It is not the intent of this Section to provide Landlord with information which could be detrimental to Tenants business should such information become possessed by Tenants competitors.
(c) Tenant Representation and Warranty. Tenant hereby represents and warrants to Landlord that (i) neither Tenant nor any of its legal predecessors has been required by any prior landlord, lender or Governmental Authority at any time to take remedial action in connection with Hazardous Materials contaminating a property which contamination was permitted by Tenant of such predecessor or resulted from Tenants or such predecessors action or use of the property in question, and (ii) Tenant is not subject to any enforcement order issued by any Governmental Authority in connection with the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials (including, without
400 E. Jamie Ct. - Suite 300/DiCE - Page 28
limitation, any order related to the failure to make a required reporting to any Governmental Authority). If Landlord determines that this representation and warranty was not true as of the date of this lease, Landlord shall have the right to terminate this Lease in Landlords sole and absolute discretion.
(d) Testing. Landlord shall have the right to conduct annual tests of the Premises to determine whether any contamination of the Premises or the Project has occurred as a result of Tenants use. Tenant shall be required to pay the cost of such annual test of the Premises if there is violation of this Section 30 or if contamination for which Tenant is responsible under this Section 30 is identified; provided, however, that if Tenant conducts its own tests of the Premises using third party contractors and test procedures acceptable to Landlord which tests are certified to Landlord, Landlord shall accept such tests in lieu of the annual tests. In addition, at any time, and from time to time, prior to the expiration or earlier termination of the Term, Landlord shall have the right to conduct appropriate tests of the Premises and the Project to determine if contamination has occurred as a result of Tenants use of the Premises. In connection with such testing, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such non-proprietary information concerning the use of Hazardous Materials in or about the Premises by Tenant or any Tenant Party. If contamination has occurred for which Tenant is liable under this Section 30, Tenant shall pay all costs to conduct such tests. If no such contamination is found, Landlord shall pay the costs of such tests (which shall not constitute an Operating Expense). Landlord shall provide Tenant with a copy of all third party, non-confidential reports and tests of the Premises made by or on behalf of Landlord during the Term without representation or warranty and subject to a confidentiality agreement. Tenant shall, at its sole cost and expense, promptly and satisfactorily remediate any environmental conditions identified by such testing for which Tenant is responsible under this Lease in accordance with all Environmental Requirements. Landlords receipt of or satisfaction with any environmental assessment in no way waives any rights which Landlord may have against Tenant.
(e) Control Areas. Tenant shall have the use of 100% of the control area located on the 3rd floor of the Building.
(f) Storage Tanks. If storage tanks storing Hazardous Materials located on the Premises or the Project are used by Tenant or are hereafter placed on the Premises or the Project by Tenant, Tenant shall install, use, monitor, operate, maintain, upgrade and manage such storage tanks, maintain appropriate records, obtain and maintain appropriate insurance, implement reporting procedures, properly close any storage tanks , and take or cause to be taken all other actions necessary or required under applicable state and federal Legal Requirements , as such now exists or may hereafter be adopted or amended in connection with the installation, use, maintenance, management, operation, upgrading and closure of such storage tanks. Notwithstanding anything to the contrary contained herein, Tenant shall have no right to use or install any underground storage tanks at the Project.
(g) Tenants Obligations. Tenants obligations under this Section 30 shall survive the expiration or earlier termination of this Lease. During any period of time after the expiration or earlier termination of this Lease required by Tenant or Landlord to complete the removal from the Premises of any Hazardous Materials (including, without limitation, the release and termination of any licenses or permits restricting the use of the Premises and the completion of the approved Decommissioning and HazMat Closure Plan), Tenant shall continue to pay the full Rent in accordance with this Lease for any portion of the Premises not relet by Landlord in Landlords sole discretion, which Rent shall be prorated daily.
(h) Definitions. As used herein, the term Environmental Requirements means all applicable present and future statutes, regulations, ordinances, rules, codes, judgments, orders or other similar enactments of any Governmental Authority regulating or relating to health, safety, or environmental conditions on, under, or about the Premises or the Project, or the environment, including without limitation, the following: the Comprehensive Environmental Response , Compensation and Liability Act; the Resource Conservation and Recovery Act; and all state and local counterparts thereto, and any regulations or policies promulgated or issued thereunder. As used herein, the term Hazardous Materials means and includes any substance, material, waste, pollutant, or contaminant listed or defined as hazardous or toxic, or regulated by reason of its impact or potential impact on humans, animals and/or the environment under any Environmental Requirements , asbestos and petroleum, including crude oil or any fraction thereof, natural
400 E. Jamie Ct. - Suite 300/DiCE - Page 29
gas liquids, liquefied natural gas, or synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas). As defined in Environmental Requirements, Tenant is and shall be deemed to be the operator of Tenants facility and the owner of all Hazardous Materials brought on the Premises by Tenant or any Tenant Party, and the wastes, by-products, or residues generated, resulting, or produced therefrom.
31. Tenants Remedies/Limitation of Liability. Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days, then after such period of time as is reasonably necessary) . Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlords obligations hereunder.
All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term Landlord in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owners ownership.
32. Inspection and Access . Landlord and its agents, representatives, and contractors may enter the Premises at any reasonable time to inspect the Premises and to make such repairs as may be required or permitted pursuant to this Lease. Landlord and Landlords representatives may enter the Premises during business hours on not less than 48 hours advance written notice (except in the case of emergencies in which case no such notice shall be required and such entry may be at any time) for the purpose of effecting any such repairs, inspecting the Premises, showing the Premises to prospective purchasers and, during the last 12 months of the Term, to prospective tenants or for any other business purpose. Landlord may erect a suitable sign on the Premises stating the Premises are available to let or that the Project is available for sale. Landlord may grant easements, make public dedications, designate Common Areas and create restrictions on or about the Premises, provided that no such easement, dedication, designation or restriction materially, adversely affects Tenants use or occupancy of the Premises for the Permitted Use. At Landlords request, Tenant shall execute such instruments as may be necessary for such easements, dedications or restrictions. Tenant shall at all times, except in the case of emergencies, have the right to escort Landlord or its agents, representatives, contractors or guests while the same are in the Premises, provided such escort does not materially and adversely affect Landlords access rights hereunder. Landlord shall use reasonable efforts to comply with Tenants reasonable security, confidentiality and safety requirements with respect to entering restricted portions of the Premises; provided, however, that Tenant has notified Landlord in writing of such security, confidentiality and safety requirements reasonably prior to Landlords entry into the Premises and provided further that in no event shall Tenant bar or prohibit access by Landlord and its employees, agents and contractors for the performance of the obligations of Landlord or the exercise of the rights of Landlord under this Lease.
400 E. Jamie Ct. - Suite 300/DiCE - Page 30
33. Security. Tenant acknowledges and agrees that security devices and services, if any, while intended to deter crime may not in given instances prevent theft or other criminal acts and that Landlord is not providing any security services with respect to the Premises. Tenant agrees that Landlord shall not be liable to Tenant for, and Tenant waives any claim against Landlord with respect to, any loss by theft or any other damage suffered or incurred by Tenant in connection with any unauthorized entry into the Premises or any other breach of security with respect to the Premises. Tenant shall be solely responsible for the personal safety of Tenants officers, employees, agents, contractors, guests and invitees while any such person is in, on or about the Premises and/or the Project. Tenant shall at Tenants cost obtain insurance coverage to the extent Tenant desires protection against such criminal acts.
34. Force Majeure. Except for the payment of Rent, neither Landlord nor Tenant shall be held responsible or liable for delays in the performance of its obligations hereunder when caused by, related to, or arising out of acts of God, sinkholes or subsidence, strikes, lockouts, or other general labor disputes, embargoes, quarantines, weather, national, regional, or local disasters, calamities, or catastrophes, failure of, or inability to obtain utilities necessary for performance to the extent not caused by Landlord , unusual governmental restrictions, orders, limitations or controls, national emergencies, local, regional or national epidemic or pandemic, delay in issuance or revocation of permits, enemy or hostile governmental action, terrorism, insurrection, riots, civil disturbance or commotion, fire or other casualty, and other similar causes or events beyond their reasonable control (Force Majeure); provided, however, that Force Majeure shall not include the inability to pay money, general economic conditions, restrictions on the availability of credit or money, or other causes related to the particular financial condition of a party. Any party claiming Force Majeure shall be required to notify the other party of such Force Majeure promptly after the commencement of such Force Majeure and shall be required to keep such other party reasonably informed regarding the same throughout the period during which Force Majeure is being claimed. If the happening of any such Force Majeure event only partially impairs the performance of a partys obligations hereunder, such party shall continue to perform under this Lease to the fullest extent possible in light of such Force Majeure event. Any party claiming a Force Majeure shall, to the extent reasonably possible, use reasonably good faith efforts to minimize such Force Majeure being claimed.
35. Brokers. Landlord and Tenant each represents and warrants that it has not dealt with any broker, agent or other person (collectively, Broker) in connection with this transaction and that no Broker brought about this transaction, other than Newmark Knight Frank and Jones Lang LaSalle. Landlord and Tenant each hereby agree to indemnify and hold the other harmless from and against any claims by any Broker, other than Newmark Knight Frank and Jones Lang LaSalle, claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard to this leasing transaction. Landlord shall be responsible for all commissions due to Newmark Knight Frank and Jones Lang LaSalle arising out of the execution of this Lease in accordance with the terms of a separate written agreement between Landlord, on the one hand, and Newmark Knight Frank and Jones Lang LaSalle, on the other hand.
36. Limitation on Landlords Liability. NOTWITHSTANDING ANYTHING SET FORTH HEREIN OR IN ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT TO THE CONTRARY: (A) LANDLORD SHALL NOT BE LIABLE TO TENANT OR ANY OTHER PERSON FOR (AND TENANT AND EACH SUCH OTHER PERSON ASSUME ALL RISK OF) LOSS, DAMAGE OR INJURY, WHETHER ACTUAL OR CONSEQUENTIAL TO: TENANTS PERSONAL PROPERTY OF EVERY KIND AND DESCRIPTION, INCLUDING, WITHOUT LIMITATION TRADE FIXTURES, EQUIPMENT, INVENTORY, SCIENTIFIC RESEARCH , SCIENTIFIC EXPERIMENTS, LABORATORY ANIMALS, PRODUCT, SPECIMENS, SAMPLES, AND/OR SCIENTIFIC, BUSINESS, ACCOUNTING AND OTHER RECORDS OF EVERY KIND AND DESCRIPTION KEPT AT THE PREMISES AND ANY AND ALL INCOME DERIVED OR DERIVABLE THEREFROM; (B) THERE SHALL BE NO PERSONAL RECOURSE TO LANDLORD FOR ANY ACT OR OCCURRENCE IN, ON OR ABOUT THE PREMISES OR ARISING IN ANY WAY UNDER THIS LEASE OR ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT WITH RESPECT TO THE SUBJECT MATTER HEREOF AND ANY LIABILITY OF LANDLORD HEREUNDER SHALL BE STRICTLY LIMITED SOLELY TO LANDLORDS INTEREST IN THE PROJECT OR ANY PROCEEDS FROM SALE OR CONDEMNATION THEREOF AND ANY INSURANCE PROCEEDS PAYABLE IN RESPECT OF LANDLORDS INTEREST IN THE PROJECT OR IN CONNECTION WITH ANY SUCH LOSS; AND (C) IN NO EVENT SHALL ANY PERSONAL LIABILITY BE ASSERTED AGAINST LANDLORD IN CONNECTION WITH THIS LEASE NOR SHALL ANY RECOURSE BE HAD TO ANY OTHER PROPERTY OR ASSETS OF LANDLORD OR ANY OF LANDLORDS OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS. UNDER NO CIRCUMSTANCES SHALL LANDLORD OR ANY OF LANDLORDS OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS BE LIABLE FOR INJURY TO TENANTS BUSINESS OR FOR ANY LOSS OF INCOME OR PROFIT THEREFROM.
400 E. Jamie Ct. - Suite 300/DiCE - Page 31
Tenant acknowledges and agrees that measures and/or services implemented at the Project, if any, intended to encourage social distancing, promote and protect health and physical well-being and/or intended to limit the spread of Infectious Conditions, may not prevent the spread of such Infectious Conditions. Neither Landlord nor any Landlord Indemnified Parties shall have any liability and Tenant waives any claims against Landlord and the Landlord Indemnified Parties with respect to any loss, damage or injury in connection with (x) the implementation, or failure of Landlord or any Landlord Indemnified Parties to implement, any measures and/or services at the Project intended to encourage social distancing, promote and protect health and physical well-being and/or intended to limit the spread of Infectious Conditions, or (y) the failure of any measures and/or services implemented at the Project, if any, to limit the spread of any Infectious Conditions.
37. Severability. If any clause or provision of this Lease is illegal, invalid or unenforceable under present or future laws, then and in that event, it is the intention of the parties hereto that the remainder of this Lease shall not be affected thereby. It is also the intention of the parties to this Lease that in lieu of each clause or provision of this Lease that is illegal, invalid or unenforceable, there be added, as a part of this Lease, a clause or provision as similar in effect to such illegal, invalid or unenforceable clause or provision as shall be legal, valid and enforceable.
38. Signs; Exterior Appearance. Tenant shall not, without the prior written consent of Landlord, which may be granted or withheld in Landlords reasonable discretion: (i) attach any awnings, exterior lights, decorations, balloons, flags, pennants, banners, painting or other projection to any outside wall of the Project, (ii) use any curtains, blinds, shades or screens other than Landlords standard window coverings, (iii) coat or otherwise sunscreen the interior or exterior of any windows, (iv) place any bottles, parcels, or other articles on the window sills, (v) place any equipment, furniture or other items of personal property on any exterior balcony, or (vi) paint, affix or exhibit on any part of the Premises or the Project any signs, notices, window or door lettering, placards, decorations, or advertising media of any type which can be viewed from the exterior of the Premises. Suite entry signage and Tenants name and location within the Building on the Building lobby directory shall be inscribed, painted or affixed for Tenant by Landlord at the sole cost and expense of Tenant, and shall be of a size, color and type acceptable to Landlord. Nothing may be placed on the exterior of corridor walls or corridor doors other than Landlords standard lettering. The directory tablet shall be provided exclusively for the display of the name and location of tenants.
Tenant shall also have the non-exclusive right to display, at Tenants cost and expense, a sign bearing Tenants name and/or logo on the monument sign serving the Building in a location designated by Landlord (the Monument Sign). Notwithstanding the foregoing, Tenant acknowledges and agrees that Tenants signage on the Monument Sign including, without limitation, the size, color and type, shall be subject to Landlords prior written approval, which approval shall not be unreasonably withheld, conditioned or delayed, and shall be consistent with Landlords signage program at the Project and applicable Legal Requirements. Tenant shall be responsible, at Tenants sole cost and expense, for the maintenance of Tenants signage on the Monument Sign, for the removal of Tenants signage on the Monument Sign at the expiration or earlier termination of this Lease and for the repair all damage resulting from such removal.
39. Right to Expand.
(a) Right of First Refusal. Subject to the terms of this Section 39(a), the first time after the Commencement Date, if at all, that Landlord finalizes a written proposal with a third party (the Pending Deal) for the lease by such third party of all or a portion the ROFR Space (as hereinafter defined), Landlord shall deliver to Tenant written notice (the Pending Deal Notice) of the existence of such Pending Deal, which Pending Deal Notice shall include the material terms of the Pending Deal. For purposes of this Section 39(a), ROFR Space shall mean the entire 1st or 2nd floor of the Building, which is not occupied by a tenant or which is occupied by an existing tenant whose lease is expiring or otherwise terminating within 9 months or less and such tenant does not wish to renew (whether or not such tenant has a right to renew) its occupancy of such space. For the avoidance of doubt, Tenant shall be required to exercise its right under this Section 39(a) with respect to all of the space described in the Pending Deal Notice, including, at Landlords option, any space in addition to the ROFR Space that is described in the Pending Deal Notice, which additional space shall be deemed to be included as part of the ROFR Space
400 E. Jamie Ct. - Suite 300/DiCE - Page 32
(the Identified Space). Within 5 business days after Tenants receipt of the Pending Deal Notice, Tenant shall deliver to Landlord written notice (the Acceptance Notice) if Tenant elects to lease the Identified Space. Tenants right to receive the Pending Deal Notice and election to lease or not lease the Identified Space pursuant to this Section 39(a) is hereinafter referred to as the Right of First Refusal. If Tenant elects to lease the Identified Space described in the Pending Deal Notice by delivering the Space Acceptance Notice within the required 5 business day period, Tenant shall be deemed to agree to expand the Premises to include the Identified Space and to lease the Identified Space on the same general terms and conditions as this Lease except that the terms of this Lease shall be modified to reflect the terms of the Pending Deal Notice for the rental of the Identified Space. Tenant acknowledges that the term of this Lease with respect to the Identified Space and the Term of this Lease with respect to the existing Premises may not be co-terminous. Notwithstanding anything to the contrary contained herein, in no event shall the Work Letter apply to the Identified Space. If Tenant fails to deliver an Acceptance Notice to Landlord within the required 5 business day period, Tenant shall be deemed to have forever waived its rights under this Section 39(a) to lease the Identified Space. Notwithstanding anything to the contrary contained herein, (i) if the terms of the Pending Deal with respect to which Landlord delivered Tenant a Pending Deal Notice are revised in a manner that would result in a net-effective rental rate of less than 90% of the rental rate set forth in the Pending Deal Notice, or (ii) if Landlord fails to execute a lease for the Identified Space with the third party subject to the Pending Deal (or an affiliate thereof) within 6 months after the above-referenced 5 business day period, Tenants Right of Refusal shall be restored with respect to the next Pending Deal with respect to such Identified Space. Notwithstanding anything to the contrary contained herein, Tenants rights under this Section 39(a) shall terminate and be of no further force or effect after the date that is 9 months prior to the expiration of the Base Term if Tenant has not exercised its Extension Right (as defined in Section 40 below) pursuant to the terms of Section 40.
(b) Amended Lease. If: (i) Tenant fails to timely deliver an Acceptance Notice, or (ii) after the expiration of a period of 15 days after Landlords delivery to Tenant of a lease amendment for Tenants lease of the Identified Space, no lease amendment for the Identified Space acceptable to both parties each in their reasonable discretion has been executed, despite the reasonable good faith efforts of Landlord and Tenant, Tenant shall, notwithstanding anything to the contrary contained herein, be deemed to have forever waived its right to lease the Identified Space.
(c) Exceptions. Notwithstanding the above, the Right of First Refusal shall, at Landlords option, not be in effect and may not be exercised by Tenant:
(i) during any period of time that Tenant is in Default under any provision of this Lease;
(ii) any time that Tenant (and/or any sublessee or assignee pursuant to a Permitted Assignment) is not occupying 50% of the then-existing Premises; or
(iii) if Tenant has been in Default under any provision of this Lease 3 or more times, whether or not the Defaults are cured, during the 12 month period prior to the date on which Tenant seeks to exercise the Right of First Refusal.
(d) Termination. The Right of First Refusal shall, at Landlords option, terminate and be of no further force or effect even after Tenants due and timely exercise of the Right of First Refusal , if, after such exercise, but prior to the commencement date of the lease of the Identified Space, (i) Tenant fails to timely cure any default by Tenant under this Lease; or (ii) Tenant has Defaulted 3 or more times during the period from the date of the exercise of the Right of First Refusal to the date of the commencement of the lease of the Identified Space, whether or not such Defaults are cured.
(e) Rights Personal. The Right of First Refusal is personal to Tenant and is not assignable without Landlords consent, which may be granted or withheld in Landlords sole discretion separate and apart from any consent by Landlord to an assignment of Tenants interest in this Lease, except that it may be assigned in connection with any assignment of this Lease pursuant to a Permitted Assignment.
400 E. Jamie Ct. - Suite 300/DiCE - Page 33
(f) No Extensions. The period of time within which the Right of First Refusal may be exercised shall not be extended or enlarged by reason of Tenants inability to exercise the Right of First Refusal.
40. Right to Extend Term. Tenant shall have the right to extend the Term of this Lease upon the following terms and conditions:
(a) Extension Rights. Tenant shall have 1 right (the Extension Right) to extend the term of this Lease for 60 months (the Extension Term) on the same terms and conditions as this Lease (other than with respect to Base Rent and the Work Letter) by giving Landlord written notice of its election to exercise each Extension Right at least 12 months prior, and no earlier than 15 months prior, to the expiration of the Base Term of this Lease.
Upon the commencement of the Extension Term, Base Rent shall be payable at the Market Rate (as defined below). Base Rent shall thereafter be adjusted on each annual anniversary of the commencement of such Extension Term by a percentage agreed upon by Landlord and Tenant at the time the Market Rate is determined. As used herein, Market Rate shall mean the rate that comparable landlords of comparable buildings have accepted in current transactions from non-equity (i.e., not being offered equity in the buildings) and nonaffiliated tenants of similar financial strength for space of comparable size, quality (including all Tenant Improvements , Alterations and other improvements) and floor height in Class A laboratory/office buildings in the South San Francisco area for a comparable term, with the determination of the Market Rate to take into account all relevant factors, including tenant inducements , views, the Project Amenities, parking costs, leasing commissions, allowances or concessions, if any. In addition, Landlord may impose a market rent for the parking rights provided hereunder; provided, however, that Landlord shall not charge parking rent for parking rights during the Extension Term unless Landlord is required to do so by any Governmental Authority or as part of a traffic mitigation program.
If, on or before the date which is 270 days prior to the expiration of the Base Term of this Lease, Landlord and Tenant have not agreed upon the Market Rate and the rent escalations during the Extension Term after negotiating in good faith, Tenant shall be deemed to have elected arbitration as described in Section 40(b). Tenant acknowledges and agrees that, if Tenant has elected to exercise the Extension Right by delivering notice to Landlord as required in this Section 40(a), Tenant shall have no right thereafter to rescind or elect not to extend the term of this Lease for the Extension Term.
(b) Arbitration.
(i) Within 10 days of Tenants notice to Landlord of its election (or deemed election) to arbitrate Market Rate and escalations, each party shall deliver to the other a proposal containing the Market Rate and escalations that the submitting party believes to be correct (Extension Proposal). If either party fails to timely submit an Extension Proposal, the other partys submitted proposal shall determine the Base Rent and escalations for the Extension Term. If both parties submit Extension Proposals, then Landlord and Tenant shall meet within 7 days after delivery of the last Extension Proposal and make a good faith attempt to mutually appoint a single Arbitrator (and defined below) to determine the Market Rate and escalations. If Landlord and Tenant are unable to agree upon a single Arbitrator, then each shall, by written notice delivered to the other within 10 days after the meeting, select an Arbitrator. If either party fails to timely give notice of its selection for an Arbitrator, the other partys submitted proposal shall determine the Base Rent and escalations for the Extension Term. The 2 Arbitrators so appointed shall, within 5 business days after their appointment, appoint a third Arbitrator. If the 2 Arbitrators so selected cannot agree on the selection of the third Arbitrator within the time above specified, then either party, on behalf of both parties, may request such appointment of such third Arbitrator by application to any state court of general jurisdiction in the jurisdiction in which the Premises are located, upon 10 days prior written notice to the other party of such intent.
(ii) The decision of the Arbitrator(s) shall be made within 30 days after the appointment of a single Arbitrator or the third Arbitrator, as applicable. The decision of the single
400 E. Jamie Ct. - Suite 300/DiCE - Page 34
Arbitrator shall be final and binding upon the parties. The average of the two closest Arbitrators in a three Arbitrator panel shall be final and binding upon the parties. Each party shall pay the fees and expenses of the Arbitrator appointed by or on behalf of such party and the fees and expenses of the third Arbitrator shall be borne equally by both parties. If the Market Rate and escalations are not determined by the first day of the Extension Term, then Tenant shall pay Landlord Base Rent in an amount equal to the Base Rent in effect immediately prior to the Extension Term and increased by the Rent Adjustment Percentage until such determination is made. After the determination of the Market Rate and escalations, the parties shall make any necessary adjustments to such payments made by Tenant. Landlord and Tenant shall then execute an amendment recognizing the Market Rate and escalations for the Extension Term.
(iii) An Arbitrator shall be any person appointed by or on behalf of either party or appointed pursuant to the provisions hereof and: (i) shall be (A) a member of the American Institute of Real Estate Appraisers with not less than 10 years of experience in the appraisal of improved office and high tech industrial real estate in the San Francisco Bay area, or (B) a licensed commercial real estate broker with not less than 15 years experience representing landlords and/or tenants in the leasing of high tech or life sciences space in the San Francisco Bay area, (ii) devoting substantially all of their time to professional appraisal or brokerage work, as applicable, at the time of appointment and (iii) be in all respects impartial and disinterested.
(c) Rights Personal. The Extension Right is personal to Tenant and is not assignable without Landlords consent, which may be granted or withheld in Landlords sole discretion separate and apart from any consent by Landlord to an assignment of Tenants interest in this Lease, except that it may be assigned in connection with any assignment of this Lease pursuant to a Permitted Assignment.
(d) Exceptions. Notwithstanding anything set forth above to the contrary, the Extension Right shall, at Landlords option, not be in effect and Tenant may not exercise the Extension Right:
(i) Lease; or during any period of time that Tenant is in Default under any provision of this
(ii) if Tenant (and/or any sublessee or assignee pursuant to a Permitted Assignment) is not occupying 50% of the then-existing Premises; or
(iii) if Tenant has been in Default under any provision of this Lease 3 or more times, whether or not the Defaults are cured, during the 12-month period immediately prior to the date that Tenant intends to exercise the Extension Right, whether or not the Defaults are cured.
(e) No Extensions. The period of time within which the Extension Right may be exercised shall not be extended or enlarged by reason of Tenants inability to exercise the Extension Right.
(f) Termination. The Extension Right shall, at Landlords option, terminate and be of no further force or effect even after Tenants due and timely exercise of the Extension Right, if, after such exercise, but prior to the commencement date of the Extension Term, (i) Tenant fails to timely cure any default by Tenant under this Lease; or (ii) Tenant has Defaulted 3 or more times during the period from the date of the exercise of the Extension Right to the date of the commencement of the Extension Term, whether or not such Defaults are cured.
41. 201 Haskins Amenities.
(a) Subject to the provisions of this Section 41, all or a portion of the Project Amenities may be located at that certain property owned by Haskins Landlord located at 201 Haskins Way, South San Francisco, California (the 201 Haskins Project), which is owned by ARE-San Francisco No. 65, LLC, a Delaware limited liability company (Haskins Landlord), an affiliate of Landlord, which Project Amenities
400 E. Jamie Ct. - Suite 300/DiCE - Page 35
located at the 201 Haskins Project (the 201 Haskins Amenities) may include a fitness center and/or a restaurant for non-exclusive use by tenants of (i) the 201 Haskins Project, and (ii) tenants of the Project, and (iii) any other parties permitted by Haskins Landlord (collectively, Users ). Landlord, Haskins Landlord, Alexandria Real Estate Equities, Inc. (ARE), and all affiliates of Landlord, Haskins Landlord and ARE may be referred to collectively herein as the ARE Parties. Haskins Landlord shall have the sole right to determine all matters related to the 201 Haskins Amenities including, without limitation, relating to the type, design and construction thereof. Tenant acknowledges and agrees that Landlord has not made any representations or warranties regarding the development or availability of any of the 201 Haskins Amenities and that Tenant is not entering into this Lease relying on the construction and completion of the 201 Haskins Amenities or with an expectation that the 201 Haskins Amenities will ever be constructed and/or made available to Tenant.
(b) License. Commencing on the later of the Commencement Date or the date that the 201 Haskins Amenities are made available for use by Users, and so long as the 201 Haskins Project and the Project continue to be owned by affiliates of ARE, Tenant shall have the non-exclusive right to the use of the available 201 Haskins Amenities in common with other Users pursuant to the terms of this Section 41. To the extent that the 201 Haskins Amenities include a fitness center, fitness center passes shall be issued to Tenant for all full-time employees of Tenant employed at the Premises. Commencing on the later of the Commencement Date or the date that the roof deck at the 201 Haskins Project is made available for use by tenants, Tenant shall have the right to periodically have (without any right to schedule) gatherings of small groups of employees on the roof deck; provided, however, that if Haskins Landlord reasonably determines at any time that the use of roof deck is exceeding the capacity required to accommodate the use of the roof by tenants of the 201 Haskins Project, then Landlord may terminate such rights upon not less than 14 days written notice to Tenant.
(c) Operating Expenses. Operating Expenses payable with respect to the 201 Haskins Amenities shall (except to the extent the cost thereof is excluded from Operating Expenses pursuant to Section 5 hereof) include the Project Amenities Share of all costs and expenses of any kind or description whatsoever incurred or accrued each calendar year with respect to the 201 Haskins Amenities (including, without limitation, reasonable subsidies which Haskins Landlord or its affiliates may provide in connection with the 201 Haskins Amenities) , not including costs or expenses in connection with the design, initial fit-out or construction of the 201 Haskins Amenities or the cost of correcting defects in the construction of the 201 Haskins Amenities. The Project Amenities Share shall mean the Projects share of the Operating Expenses payable with respect to the 201 Haskins Amenities, which shall be allocated as reasonably determined by the Haskins Landlord between and among the 201 Haskins Project and the Project. Notwithstanding anything to the contrary contained herein, in no event shall Tenants Share of the Project Amenities Share include costs or expenses for any portion of the 201 Haskins Amenities which Tenant does not have the right to use.
(d) Rules and Regulations. Tenant shall be solely responsible for paying the cost of any and all ancillary services requested by and provided to Tenant, and the cost of any and all goods and services provided to Tenant by any food services operators and/or any third-party vendors at the 201 Haskins Project. Tenant shall use the 201 Haskins Amenities in compliance with all applicable Legal Requirements and any reasonable rules and regulations imposed by Haskins Landlord or Landlord from time to time and in a manner that will not interfere with the rights of other Users, which rules and regulations shall be enacted and enforced in a non-discriminatory manner and may include, (i) usage of and compliance with reservations systems governing the use of certain facilities, (ii) the payment of additional costs in connection with the after-hours usage of any facilities, and (iii) access card entry requirements. The use of the 201 Haskins Amenities by employees of Tenant shall be in accordance with the terms and conditions of commercially reasonable licenses, indemnification and waiver agreements required by Haskins Landlord or the operator of the 201 Haskins Amenities to be executed by all persons wishing to use such 201 Haskins Amenities. Neither the Haskins Landlord nor Landlord (nor any other affiliate of Landlord) shall have any liability or obligation for the breach of any rules or regulations by other Users with respect to the 201 Haskins Amenities. Tenant shall not make any alterations, additions, or improvements of any kind to the 201 Haskins Amenities or the 201 Haskins Project.
400 E. Jamie Ct. - Suite 300/DiCE - Page 36
Tenant acknowledges and agrees that the Haskins Landlord shall have the right at any time and from time to time to reconfigure, relocate, modify or remove any of the 201 Haskins Amenities and/or to revise, expand or discontinue any or all of the 201 Haskins Amenities and/or any services (if any) provided in connection with the 201 Haskins Amenities.
(e) Waiver of Liability and Indemnification. Tenant warrants that it will use reasonable care to prevent damage to property and injury to persons while on the 201 Haskins Project. Tenant waives any claims it or any Tenant Parties may have against any ARE Parties relating to, arising out of or in connection with the 201 Haskins Amenities and any entry by Tenant and/or any Tenant Parties onto the 201 Haskins Project, and Tenant releases and exculpates all ARE Parties from any liability relating to, arising out of or in connection with the 201 Haskins Amenities and any entry by Tenant and/or any Tenant Parties onto the 201 Haskins Project. Tenant hereby agrees to indemnify, defend, and hold harmless the ARE Parties from any claim of damage to property or injury to persons relating to, arising out of or in connection with (i) the use of the 201 Haskins Amenities by Tenant or any Tenant Parties, and (ii) any entry by Tenant and/or any Tenant Parties onto the 201 Haskins Project, except to the extent caused by the negligence or willful misconduct of ARE Parties. The provisions of this Section 41(e) shall survive the expiration or earlier termination of this Lease.
(f) Insurance. As of the Commencement Date, Tenant shall cause Haskins Landlord to be named as an additional insured under the commercial general liability policy of insurance that Tenant is required to maintain pursuant to Section 17 of this Lease.
42. Miscellaneous.
(a) Notices. All notices or other communications between the parties shall be in writing and shall be deemed duly given upon delivery or refusal to accept delivery by the addressee thereof if delivered in person, or upon actual receipt if delivered by reputable overnight guaranty courier, addressed and sent to the parties at their addresses set forth above. Landlord and Tenant may from time to time by written notice to the other designate another address for receipt of future notices.
(b) Joint and Several Liability. If and when included within the term Tenant, as used in this instrument, there is more than one person or entity, each shall be jointly and severally liable for the obligations of Tenant.
(c) Financial Information. Tenant shall furnish to Landlord with true and complete copies of (i) upon Landlords written request on an annual basis, Tenants most recent audited annual financial statements, provided, however, that Tenant shall not be required to deliver to Landlord such annual financial statements for any particular year sooner than the date that is 90 days after the end of each of Tenants fiscal years during the Term, (ii) upon Landlords written request on a quarterly basis, Tenants most recent unaudited quarterly financial statements; provided, however, that Tenant shall not be required to deliver to Landlord such quarterly financial statements for any particular quarter sooner that the date that is 45 days after the end of each of Tenants fiscal quarters during the Term, (iii) upon Landlords written request from time to time, updated business plans, including cash flow projections and/or proforma balance sheets and income statements, all of which shall be treated by Landlord as confidential information belonging to Tenant, (iv) upon Landlords written request from time to time, corporate brochures and/or profiles prepared by Tenant for prospective investors, and (v) upon Landlords written request from time to time, any other financial information or summaries that Tenant typically provides to its lenders or shareholders. Notwithstanding anything to the contrary contained in this Lease, Landlords written request for financial information pursuant to this Section 42(c) may delivered to Tenant via email. So long as Tenant is a public company and its financial information is publicly available, then the foregoing delivery requirements of this Section 42(c) shall not apply.
Landlord agrees to hold the financial statements and other financial information provided under this section in confidence using at least the same degree of care that Landlord uses to protect its own confidential information of a similar nature; provided, however, that Landlord may disclose such information to Landlords auditors, attorneys, consultants, lenders, affiliates, prospective purchasers and investors and
400 E. Jamie Ct. - Suite 300/DiCE - Page 37
other third parties as reasonably required in the ordinary course of Landlords operations, provided that Landlord shall request that such parties treat the information as confidential. The obligations of confidentiality hereunder shall not apply to information that was in the public domain at the time it was disclosed to Landlord, entered into the public domain subsequent to the time it was disclosed to Landlord through no fault of Landlord, or was disclosed by Tenant to a third party without any confidentiality restrictions. In addition, Landlord may disclose such information without violating this section to the extent that disclosure is reasonably necessary (x) for Landlord to enforce its rights or defend itself under this Lease; (y) for required submissions to any state or federal regulatory body; or (z) for compliance with a valid order of a court or other governmental body having jurisdiction, or any law, statute, or regulation, provided that, other than in an emergency, before disclosing such information, Landlord shall give Tenant 5 business days prior notice of the same to allow Tenant to obtain a protective order or such other judicial relief.
(d) Recordation. Neither this Lease nor a memorandum of lease shall be filed by or on behalf of Tenant in any public record. Landlord may prepare and file, and upon request by Landlord Tenant will execute, a memorandum of lease.
(e) Interpretation. The normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Lease or any exhibits or amendments hereto. Words of any gender used in this Lease shall be held and construed to include any other gender, and words in the singular number shall be held to include the plural, unless the context otherwise requires. The captions inserted in this Lease are for convenience only and in no way define, limit or otherwise describe the scope or intent of this Lease, or any provision hereof, or in any way affect the interpretation of this Lease.
(f) Not Binding Until Executed. The submission by Landlord to Tenant of this Lease shall have no binding force or effect, shall not constitute an option for the leasing of the Premises, nor confer any right or impose any obligations upon either party until execution of this Lease by both parties.
(g) Limitations on Interest. It is expressly the intent of Landlord and Tenant at all times to comply with applicable law governing the maximum rate or amount of any interest payable on or in connection with this Lease. If applicable law is ever judicially interpreted so as to render usurious any interest called for under this Lease, or contracted for, charged, taken, reserved, or received with respect to this Lease, then it is Landlords and Tenants express intent that all excess amounts theretofore collected by Landlord be credited on the applicable obligation (or, if the obligation has been or would thereby be paid in full, refunded to Tenant), and the provisions of this Lease immediately shall be deemed reformed and the amounts thereafter collectible hereunder reduced, without the necessity of the execution of any new document, so as to comply with the applicable law, but so as to permit the recovery of the fullest amount otherwise called for hereunder.
(h) Choice of Law. Construction and interpretation of this Lease shall be governed by the internal laws of the state in which the Premises are located, excluding any principles of conflicts of laws.
(i) Time. Time is of the essence as to the performance of Tenants obligations under this Lease.
(j) OFAC. Tenant and, to Tenants knowledge, all beneficial owners of Tenant are currently in compliance with and shall at all times during the Term of this Lease remain in compliance with the regulations of the Office of Foreign Assets Control (OFAC) of the U.S. Department of Treasury and any statute, executive order, or regulation relating thereto (collectively, the OFAC Rules), (b) not listed on, and shall not during the term of this Lease be listed on, the Specially Designated Nationals and Blocked Persons List, Foreign Sanctions Evaders List, or the Sectoral Sanctions Identification List, which are all maintained by OFAC and/or on any other similar list maintained by OFAC or other governmental authority pursuant to any authorizing statute, executive order, or regulation, and (c) not a person or entity with whom a U.S. person is prohibited from conducting business under the OFAC Rules.
400 E. Jamie Ct. - Suite 300/DiCE - Page 38
(k) Incorporation by Reference. All exhibits and addenda attached hereto are hereby incorporated into this Lease and made a part hereof. If there is any conflict between such exhibits or addenda and the terms of this Lease, such exhibits or addenda shall control.
(l) Entire Agreement. This Lease, including the exhibits attached hereto, constitutes the entire agreement between Landlord and Tenant pertaining to the subject matter hereof and supersedes all prior and contemporaneous agreements, understandings, letters of intent, negotiations and discussions, whether oral or written, of the parties, and there are no warranties, representations or other agreements, express or implied, made to either party by the other party in connection with the subject matter hereof except as specifically set forth herein.
(m) No Accord and Satisfaction. No payment by Tenant or receipt by Landlord of a lesser amount than the monthly installment of Base Rent or any Additional Rent will be other than on account of the earliest stipulated Base Rent and Additional Rent, nor will any endorsement or statement on any check or letter accompanying a check for payment of any Base Rent or Additional Rent be an accord and satisfaction. Landlord may accept such check or payment without prejudice to Landlords right to recover the balance of such Rent or to pursue any other remedy provided in this Lease.
(n) Hazardous Activities. Notwithstanding any other provision of this Lease, Landlord, for itself and its employees, agents and contractors, reserves the right to refuse to perform any repairs or services in any portion of the Premises which, pursuant to Tenants routine safety guidelines, practices or custom or prudent industry practices, require any form of protective clothing or equipment other than safety glasses. In any such case, Tenant shall contract with parties who are acceptable to Landlord, in Landlords reasonable discretion, for all such repairs and services, and Landlord shall, to the extent required, equitably adjust Tenants Share of Operating Expenses in respect of such repairs or services to reflect that Landlord is not providing such repairs or services to Tenant.
(o) EV Charging Stations. Landlord shall not unreasonably withhold its consent to Tenants written request to install 1 or more electric vehicle car charging stations (EV Stations) in the parking area serving the Project; provided, however, that Tenant complies with all reasonable requirements, standards, rules and regulations which may be imposed by Landlord, at the time Landlords consent is granted, in connection with Tenants installation, maintenance, repair and operation of such EV Stations, which may include, without limitation, Landlords designation of the location of Tenants EV Stations, and Tenants payment of all costs whether incurred by Landlord or Tenant in connection with the installation, maintenance, repair and operation of each Tenants EV Station(s). Nothing contained in this paragraph is intended to increase the number of parking spaces which Tenant is otherwise entitled to use at the Project under Section 10 of this Lease nor impose any additional obligations on Landlord with respect to Tenants parking rights at the Project.
(p) California Accessibility Disclosure. For purposes of Section 1938(a) of the California Civil Code, Landlord hereby discloses to Tenant, and Tenant hereby acknowledges , that the Project has not undergone inspection by a Certified Access Specialist (CASp). In addition, the following notice is hereby provided pursuant to Section 1938(e) of the California Civil Code: A Certified Access Specialist (CASp) can inspect the subject premises and determine whether the subject premises comply with all of the applicable construction-related accessibility standards under state law. Although state law does not require a CASp inspection of the subject premises, the commercial property owner or lessor may not prohibit the lessee or tenant from obtaining a CASp inspection of the subject premises for the occupancy or potential occupancy of the lessee or tenant, if requested by the lessee or tenant. The parties shall mutually agree on the arrangements for the time and manner of the CASp inspection, the payment of the fee for the CASp inspection, and the cost of making any repairs necessary to correct violations of construction-related accessibility standards within the premises. In furtherance of and in connection with such notice: (i) Tenant, having read such notice and understanding Tenants right to request and obtain a CASp inspection, hereby elects not to obtain such CASp inspection and waives its rights to obtain a CASp inspection with respect to the Premises, Building and/or Project to the extent permitted by Legal Requirements; and (ii) if the waiver set forth in clause (i) hereinabove is not enforceable pursuant to Legal Requirements, then Landlord and Tenant hereby agree as follows (which constitutes the mutual agreement
400 E. Jamie Ct. - Suite 300/DiCE - Page 39
of the parties as to the matters described in the last sentence of the foregoing notice): (A) except to the extent required by Legal Requirements , Tenant shall have the one-time right to request for and obtain a CASp inspection, which request must be made, if at all, in a written notice delivered by Tenant to Landlord; (B) any CASp inspection timely requested by Tenant shall be conducted (1) at a time mutually agreed to by Landlord and Tenant, (2) in a professional manner by a CASp designated by Landlord and without any testing that would damage the Premises, Building or Project in any way, and (3) at Tenants sole cost and expense, including, without limitation, Tenants payment of the fee for such CASp inspection, the fee for any reports prepared by the CASp in connection with such CASp inspection (collectively, the CASp Reports) and, except to the extent a CASp inspection was required by Legal Requirements (other than in connection with Alterations or improvements being performed by Tenant in the Premises, in which case the terms of Section 7 of the Lease shall apply), all other costs and expenses in connection therewith; (C) the CASp Reports shall be delivered by the CASp simultaneously to Landlord and Tenant; (D) Tenant, at its sole cost and expense, shall be responsible for making any improvements , alterations, modifications and/or repairs to or within the Premises then required by Legal Requirements to correct violations of construction-related accessibility standards including, without limitation, any violations disclosed by such CASp inspection; and (E) except to the extent a CASp inspection was required by Legal Requirements (other than in connection with Alterations or improvements being performed by Tenant in the Premises, in which case the terms of Section of the Lease shall apply), if such CASp inspection identifies any improvements, alterations, modifications and/or repairs necessary to correct violations of construction-related accessibility standards relating to those items of the Building and Project located outside the Premises that are Landlords obligation to repair as set forth in this Lease, then Landlord shall perform such improvements, alterations, modifications and/or repairs as and to the extent required by Legal Requirements to correct such violations, and Tenant shall reimburse Landlord for the cost of such improvements, alterations, modifications and/or repairs within 10 business days after Tenants receipt of an invoice therefor from Landlord. Landlord and Tenant expressly acknowledge and agree that the foregoing provisions of this Section 42(p) shall apply only in the event that Tenant elects to obtain a CASp inspection. In the event that Tenant does not elect to obtain a CASp inspection, the terms and provisions of this Section 42(p) regarding the allocation of costs for Alterations and improvements shall not be applicable.
(q) Shuttle Services. Landlord and affiliates of Landlord plan to provide a campus shuttle service for the Project and other buildings in the vicinity of the Project that are owned by affiliates of Landlord (the Shuttle Service); provided, however, that neither Landlord nor any affiliate of Landlord shall be obligated to provide the Shuttle Service (or, once the Shuttle Service has commenced, to continue providing the Shuttle Service for any specific period of time) or to cause the Shuttle Service to follow any specific route, make any specific stops, or adhere to any specific schedule or hours of operation. If Landlord and affiliates of Landlord actually commence operation of the Shuttle Service, (i) Landlord shall give Tenant written notice of the date such operation will commence (Shuttle Services Commencement Date) and the planned route, stops, schedule, and hours of operation, (ii) Landlord shall permit Tenants employees actually employed at the Project to use the Shuttle Service, and (iii) regardless of whether Tenants employees use the Shuttle Services, commencing on later to occur of (x) the Shuttle Services Commencement Date, or the Commencement Date, through the earlier of the expiration of the Term or the date that Landlord permanently ceases to provide Shuttle Service, Operating Expenses shall (except to the extent the cost thereof is excluded from Operating Expenses pursuant to Section 5 hereof) include the cost of provision the Shuttle Service subject to the terms of Section 5 (the Shuttle Service Costs). Tenant acknowledges and agrees that Landlord has not made any representations or warranties regarding the commencement or continued availability of the Shuttle Service and that Tenant is not entering into this Lease with an expectation that the Shuttle Service shall commence or continue to be available to Tenant throughout the Term.
(r) Counterparts. This Lease may be executed in 2 or more counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument. Counterparts may be delivered via facsimile, electronic mail (including pdf or any electronic signature process complying with the U.S. federal ESIGN Act of 2000) or other transmission method and any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes. Electronic signatures shall be deemed original signatures for purposes of this Lease and all matters related thereto, with such electronic signatures having the same legal effect as original signatures.
[Signatures on next page]
400 E. Jamie Ct. - Suite 300/DiCE - Page 40
IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease as of the day and year first above written.
TENANT: | ||||||
DiCE MOLECULES SV, INC., a Delaware corporation | ||||||
By: | /s/ J. Kevin Judice | |||||
Its: | CEO |
LANDLORD: | ||||||
ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company | ||||||
By: | ALEXANDRIA REAL ESTATE EQUITIES, L.P., a Delaware limited partnership, managing member |
By: | ARE-ORS CORP., a Maryland corporation, general partner | |||||
By:
| /s/ Kristin Childs | |||||
Its:
| SVP Real Estate Legal Affairs |
400 E. Jamie Ct. - Suite 300/DiCE - Page A-1
EXHIBIT A TO LEASE
400 E. Jamie Ct. - Suite 300/DiCE - Page B-1
EXHIBIT B TO LEASE
DESCRIPTION OF PROJECT
All tha1 certain real property in the City of South San Francisco, County of San Mateo, State of California, more particularly described as follows:
LEGAL DESCRIPTION
PARCEL 2, AS DESIGNATED ON THE MAP ENTITLED PARCEL MAP, BEING A RESUBDIVISION OF PARCEL 5, AS SAID PARCEL IS DELINEATED AND SO DESIGNATED UPON THAT CERTAIN PARCEL MAP RECORDED IN BOOK 47 OF PARCEL MAPS AT PAGES 4 & 5, SAN MATEO CO. RECORDS, SOUTH SAN FRANCISCO, SAN MATEO CO. WHICH MAP WAS FILED IN THE OFFICE OF THE RECORDER OF THE COUNTY OF SAN MATEO, STATE OF CALIFORNIA, ON OCTOBER 23, 1981, IN BOOK 51 OF MAPS AT PAGES 96 AND 97.
EXCEPTING THEREFROM, WATER RJGHTS AS LIE BENEATH THE SURFACE OF THE EARTH, WITH NO RIGHT OF SURFACE ENTRY, AS CONTAINED IN THAT QUIT CLAIM DEED FROM ARTHUR S. HASKINS, JR, TO CALIFORNIA WATER SERVICE COMPANY, A CALIFORNIA CORPORATION, DATED OCTOBER 2, 1981, AND RECORDED OCTOBER 30, 1981, UNDER INSTRUMENT NO. 2299-AT, RECORDS OF SAN MATEO COUNTY.
ASSESSORS PARCEL NO. 015 - 102-120 | JOINT PLANT NO. 015-010-10-25A |
METES AND BOUNDS DESCRIPTION
PARCEL 2, AS DESIGNATED ON THE MAP ENTITLED PARCEL MAP, BEING A RESUBDNISION OF PARCEL 5, AS SAID PARCEL IS DELINEATED AND SO DESIGNATED UPON THAT CERTAIN PARCEL MAP RECORDED IN BOOK 47 OF PARCEL MAPS AT PAGES 4 & 5, SAN MATEO CO. RECORDS, SOUTH SAN FRACISCO, SAN MATEO CO., CALIFORNIA, WHICH MAP WAS FILED IN THE OFFICE OF THE RECORDER OF THE COUNTY OF SAN MATEO, STATE OF CALIFORNIA, ON OCTOBER 23 1981, IN BOOK 51 OF MAPS AT PAGES 96 AND 97.
BEGINNING AT THE SOUTHWEST CORNER OF PARCEL 2, THENCE ALONG THE WESTERLY LINE OF PAID PARCEL 2, NORTH, 115.08 FEET; THENCE WEST 20.78 FEET; THENCE NORTH, 201.65 FEET; THENCE EASERLY ALONG THE ARC OF A NON-TANGENT CURVE TO THE RIGHT, THE RADIUS POINT OF WHICH BEARS SOUTH 43°5030 EAST, 30.00 FEET THROUGH A CENTRAL ANGLE OF 47°0048, AN ARC DISTANCE OF 24.62 FEET; THENCE SOUTH 86°4942 EAST, 874.36 FEET; THENCE SOUTH 275.50 FEET; THENCE SOUTH 89°5525 WEST, 874.68 FEET; TO THE POINT OF BEGINNING, CONTAINING 6.13 ACRES, MORE OR LESS.
400 E. Jamie Ct. - Suite 300/DiCE - Page C-2
EXHIBIT C TO LEASE
WORK LETTER
THIS WORK LETTER dated June 25, 2021 (this Work Letter) is made and entered into by and between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company (Landlord), and DiCE MOLECULES SV, INC., a Delaware corporation (Tenant), and is attached to and made a part of the Lease Agreement dated Jun 25, 2021 (the Lease), by and between Landlord and Tenant. Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.
1. General Requirements.
(a) Tenants Authorized Representative. Tenant designates Lisa Watson (Tenants Representative) as the only person authorized to act for Tenant pursuant to this Work Letter. Landlord shall not be obligated to respond to or act upon any request, approval, inquiry or other communication (Communication) from or on behalf of Tenant in connection with this Work Letter unless such Communication is in writing from Tenants Representative. Tenant may change Tenants Representative at any time upon not less than 5 business days advance written notice to Landlord. Neither Tenant nor Tenants Representative shall be authorized to direct Landlords contractors in the performance of Landlords Work (as hereinafter defined).
(b) Landlords Authorized Representative. Landlord designates Toon Jordan and Derek Phebus (either such individual acting alone, Landlords Representative) as the only persons authorized to act for Landlord pursuant to this Work Letter. Tenant shall not be obligated to respond to or act upon any request, approval, inquiry or other Communication from or on behalf of Landlord in connection with this Work Letter unless such Communication is in writing from Landlords Representative. Landlord may change either Landlords Representative at any time upon not less than 5 business days advance written notice to Tenant. Landlords Representative shall be the sole persons authorized to direct Landlords contractors in the performance of Landlords Work.
(c) Architects, Consultants and Contractors. Landlord and Tenant hereby acknowledge and agree that: (i) The Core Group shall be the general contractor for the Tenant Improvements (General Contractor), (ii) DGA shall be the architect (the Tl Architect) for the Tenant Improvements, and (iii) and any subcontractors for the Tenant Improvements shall be selected by Landlord, subject to Tenants approval, which approval shall not be unreasonably withheld, conditioned or delayed.
2. Tenant Improvements.
(a) Tenant Improvements Defined. As used herein, Tenant Improvements shall mean all improvements to the Project of a fixed and permanent nature as shown on the Tl Construction Drawings, as defined in Section 2(c) below. Other than Landlords Work (as defined in Section 3(a)) below, Landlord shall not have any obligation whatsoever with respect to the finishing of the Premises for Tenants use and occupancy.
(b) Tenants Space Plans. The space plans attached hereto as Schedule 1 (the Space Plans) have been approved by both Landlord and Tenant. Landlord and Tenant further acknowledge and agree that any changes to the Space Plans requested by Tenant, to the extent that they increase Landlords net cost to design and construct the Tenant Improvements, constitute a Change Request the cost of which changes shall be paid for by Tenant. Tenant shall be solely responsible for all costs incurred by Landlord to alter the Building (or Landlords plans for the Building) as a result of Tenants requested changes, to the extent that they increase Landlords net cost to design and construct the Tenant Improvements.
(c) Working Drawings. In accordance with the schedule attached hereto as Schedule 2 (the Schedule), Landlord shall cause the Tl Architect to prepare and deliver to Tenant for
400 E. Jamie Ct. - Suite 300/DiCE - Page C-3
review and comment construction plans, specifications and drawings for the Tenant Improvements (Tl Construction Drawings), which Tl Construction Drawings shall be prepared substantially in accordance with the Space Plans. Tenant shall be solely responsible for ensuring that the Tl Construction Drawings reflect Tenants requirements for the Tenant Improvements. Tenant shall deliver its written comments on the Tl Construction Drawings to Landlord not later than 10 business days after Tenants receipt of the same; provided, however, that Tenant may not disapprove any matter that is consistent with the Space Plans without submitting a Change Request. Landlord and the Tl Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Tenant how Landlord proposes to respond to such comments, but Tenants review rights pursuant to the foregoing sentence shall not delay the design or construction schedule for the Tenant Improvements. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the Tl Construction Drawings is consistent with the Space Plans, Tenant shall approve the Tl Construction Drawings submitted by Landlord, unless Tenant submits a Change Request. Once approved by Tenant, subject to the provisions of Section 4 below, Landlord shall not materially modify the Tl Construction Drawings except as may be reasonably required in connection with the issuance of the Tl Permit (as defined in Section 3(b) below).
(d) Approval and Completion. It is hereby acknowledged by Landlord and Tenant that the Tl Construction Drawings must be completed and approved not later than August 1, 2021, in order for the Landlords Work to be Substantially Complete by the Target Commencement Date (as defined in the Lease). Upon any dispute regarding the design of the Tenant Improvements, which is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlords and Tenants positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall, to the extent that they increase Landlords net cost to design and construct the Tenant Improvements, be payable by Tenant, and (iii) Tenants decision will not affect the base Building, structural components of the Building or any Building systems. Any changes to the Tl Construction Drawings following Landlord s and Tenants approval of same requested by Tenant shall be processed as provided in Section 4 hereof.
3. Performance of Landlords Work.
(a) Definition of Landlords Work. As used herein, Landlords Work shall mean the work of constructing the Tenant Improvements. Landlord shall use reasonable efforts to complete Landlords Work in accordance with the Schedule. Notwithstanding anything to the contrary contained in this Work Letter, Landlord shall cause, at Landlords sole cost and expense, the remediation prior to the Commencement Date, in a manner acceptable to Landlord in its sole and absolute discretion and otherwise in compliance with Legal Requirements, of Hazardous Materials discovered in the Premises during the construction of Landlords Work requiring remediation.
Tenant shall be solely responsible for ensuring that the design and specifications for Landlords Work are consistent with Tenants requirements, Landlord shall be responsible for obtaining all permits, approvals and entitlements necessary for Landlords Work, but shall have no obligation to, and shall not, secure any permits, approvals or entitlements related to Tenants specific use of the Premises or Tenants business operations therein.
(b) Commencement and Permitting. Landlord shall commence construction of the Tenant Improvements upon obtaining a building permit (the Tl Permit) authorizing the construction of the Tenant Improvements consistent with the Tl Construction Drawings approved by Tenant. The cost of obtaining the Tl Permit shall be paid for by Landlord as part of Tl Costs. Tenant shall assist Landlord in obtaining the Tl Permit. If any Governmental Authority having jurisdiction over the construction of Landlords Work or any portion thereof shall impose terms or conditions upon the construction thereof that: (i) are inconsistent with Landlords obligations hereunder, (ii) increase the cost of constructing Landlords Work, or (iii) will materially delay the construction of Landlords Work, Landlord and Tenant shall reasonably and in good faith seek means by which to mitigate or eliminate any such adverse terms and conditions.
400 E. Jamie Ct. - Suite 300/DiCE - Page C-4
(c) Completion of Landlords Work. Landlord shall substantially complete or cause to be substantially completed Landlords Work in a good and workmanlike manner, in accordance with the Tl Permit subject, in each case, to Minor Variations and normal punch list items of a non-material nature that do not interfere with the use of the Premises and with a certificate or temporary certificate of occupancy (or an equivalent approval having been issued) for the Premises permitting lawful occupancy of the Premises (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenants operations in the Premises) (Substantial Completion or Substantially Complete). Upon Substantial Completion of Landlords Work, Landlord shall require the Tl Architect and the General Contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (AIA) document G704. For purposes of this Work Letter, Minor Variations shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the Tl Permit); (ii) to comply with any request by Tenant for modifications to Landlords Work; (iii) to comport with good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments for field deviations or conditions encountered during the construction of Landlords Work.
(d) Selection of Materials. Where more than one type of material or structure is indicated on the Tl Construction Drawings approved by Landlord and Tenant, the option will be selected at Landlord s reasonable discretion. As to all building materials and equipment that Landlord is obligated to supply under this Work Letter, Landlord shall select the manufacturer thereof in its reasonable discretion unless a manufacturer is specified in the approved Tl Construction Drawings.
(e) Delivery of the Premises. When Landlords Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenants taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlords Work with applicable Legal Requirements, or (iii) any claim that Landlords Work was not completed substantially in accordance with the Tl Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a Construction Defect). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlords reasonable efforts, fails to remedy such Construction Defect within such 30- day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor.
Tenant shall be entitled to receive the benefit of all construction warranties and manufacturers equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely by Tenant. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.
(f) Commencement Date Delay. Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlords Work has been Substantially Completed, except to the extent that completion of Landlords Work shall have been actually delayed by any one or more of the following causes (Tenant Delay):
(i) Tenants Representative was not available within 2 business days of notice from Landlord, the Tl Architect or the General Contractor to give or receive any Communication or to take any other action required to be taken by Tenant hereunder;
(ii) Tenants request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
400 E. Jamie Ct. - Suite 300/DiCE - Page C-5
(iii) Construction of any Change Requests;
(iv) Tenants request for materials, finishes or installations requiring unusually long lead times, provided that promptly after Landlord learns of such long lead times, Landlord informs Tenant that the requested items will require unusually long lead times;
(v) Tenants delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(vi) Tenants delay in providing information critical to the normal progression of the Project. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(vii) Tenants delay in making payments to Landlord for Excess Tl Costs (as defined in Section 5(b) below); or
(viii) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 day after Landlords notice thereof to Tenant.
If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the Tl Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be the date of Delivery.
4. Changes. Any changes requested by Tenant to the Tenant Improvements after the delivery and approval by Landlord of the Space Plan shall be requested and instituted in accordance with the provisions of this Section 4 and shall be subject to the written approval of Landlord and the Tl Architect, such approval not to be unreasonably withheld, conditioned or delayed.
(a) Tenants Request For Changes. If Tenant shall request changes to the Tenant Improvements (Changes), Tenant shall request such Changes by notifying Landlord in writing in substantially the same form as the AIA standard change order form (a Change Request), which Change Request shall detail the nature and extent of any such Change. Such Change Request must be signed by Tenants Representative. Landlord shall, before proceeding with any Change, use commercially reasonable efforts to respond to Tenant as soon as is reasonably possible with an estimate of: (i) the time it will take, and (ii) the architectural and engineering fees and costs that will be incurred, to analyze such Change Request (which costs shall be payable by Tenant to the extent actually incurred, whether or not such change is implemented, to the extent that they increase Landlords net cost to design and construct the Tenant Improvements). Landlord shall thereafter submit to Tenant in writing, within 5 business days of receipt of the Change Request (or such longer period of time as is reasonably required depending on the extent of the Change Request), an analysis of the additional cost or savings involved, including, without limitation, architectural and engineering costs and the period of time, if any, that the Change will extend the date on which Landlords Work will be Substantially Complete. Any such delay in the completion of Landlords Work caused by a Change, including any suspension of Landlords Work while any such Change is being evaluated and/or designed, shall be Tenant Delay.
(b) Implementation of Changes. If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for completion of Landlords Work, if any, and (ii) deposits with Landlord any Excess Tl Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by Tenant of any estimate of the delay caused by such proposed Change, the Tl Architects determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant.
400 E. Jamie Ct. - Suite 300/DiCE - Page C-6
5. Costs.
(a) Tl Costs. Landlord shall be responsible for the payment of design, permits and construction costs in connection with the construction of the Tenant Improvements, including, without limitation, the cost of electrical power and other utilities used in connection with the construction of the Tenant Improvements, the cost of preparing the Tl Construction Drawings and the Space Plans, and Landlords out-of-pocket expenses (collectively, Tl Costs). The initial budget for the Tenant Improvements based upon the Space Plans is attached hereto as Schedule 3 (the Budget). Notwithstanding anything to the contrary contained herein, in no event shall Landlord be required to pay for any furniture, personal property or other non-Building system materials or equipment, including, but not limited to, Tenants voice or data cabling, non-ducted biological safety cabinets and other scientific equipment not incorporated into the Tenant Improvements.
Landlord and Tenant acknowledge and agree that (i) the attached Budget exceeds the original budget for Tenant Improvements by $38.51 per rentable square foot of the Premises (the Additional Tl Costs ), and (ii) Tenant is responsible for such Additional Tl Costs as Excess Tl Costs, except that rather than the Additional Tl Costs being payable by Tenant pursuant to the terms of Section 5(b) below, the Additional Base Rent payable under the Lease reflects the amount necessary to fully amortize the Additional Tl Costs in equal monthly payments with interest at a rate of 7% per annum over the Base Term.
(b) Excess Tl Costs. Notwithstanding anything to the contrary contained herein, Tenant acknowledges and agrees that Landlord shall have no responsibility for any increase in Landlords net cost to design and construct the Tenant Improvements arising from or related to Tenants changes to the approved Space Plans or Tl Construction Drawings, Tenant Delays, or the cost of Changes and Change Requests (collectively, Excess Tl Costs). Tenant shall be responsible for paying for all Excess Tl Costs and shall deposit with Landlord, as a condition precedent to Landlords obligation to complete the Tenant Improvements, 100% of the Excess Tl Costs. If Tenant fails to deposit any Excess Tl Costs with Landlord, Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including, but not limited to, the right to interest at the Default Rate and the right to assess a late charge). For purposes of any litigation instituted with regard to such amounts, those amounts will be deemed Rent under the Lease.
6. Tenant Access.
(a) Tenants Access Rights. Landlord hereby agrees to permit Tenant access, at Tenants sole risk and expense, to the Building (i) 15 days prior to the Commencement Date to perform any work (Tenants Work) required by Tenant other than Landlords Work, provided that such Tenants Work is coordinated with the Tl Architect and the General Contractor, and complies with the Lease and all other reasonable restrictions and conditions Landlord may impose, and (ii) prior to the completion of Landlords Work, to inspect and observe work in process; all such access shall be during normal business hours or at such other times as are reasonably designated by Landlord. Notwithstanding the foregoing, Tenant shall have no right to enter onto the Premises or the Project unless and until Tenant shall deliver to Landlord evidence reasonably satisfactory to Landlord demonstrating that any insurance reasonably required by Landlord in connection with such pre-commencement access (including, but not limited to, any insurance that Landlord may require pursuant to the Lease) is in full force and effect. Any entry by Tenant shall comply with all established safety practices of Landlords contractor and Landlord until completion of Landlords Work and acceptance thereof by Tenant.
(b) No Interference. Neither Tenant nor any Tenant Party (as defined in the Lease) shall interfere with the performance of Landlords Work, nor with any inspections or issuance of final approvals by applicable Governmental Authorities, and upon any such interference, Landlord shall have the right to exclude Tenant and any Tenant Party from the Premises and the Project until Substantial Completion of Landlords Work.
(c) No Acceptance of Premises. The fact that Tenant may, with Landlords consent, enter into the Project prior to the date Landlords Work is Substantially Complete for the purpose of performing Tenants Work shall not be deemed an acceptance by Tenant of possession of the Premises, but in such event Tenant shall defend with counsel reasonably acceptable by Landlord, indemnify and hold
400 E. Jamie Ct. - Suite 300/DiCE - Page C-7
Landlord harmless from and against any loss of or damage to Tenants property, completed work, fixtures, equipment, materials or merchandise, and from liability for death of, or injury to, any person, caused by the act or omission of Tenant or any Tenant Party.
7. Miscellaneous.
(a) Consents. Whenever consent or approval of either party is required under this Work Letter, that party shall not unreasonably withhold, condition or delay such consent or approval, unless expressly set forth herein to the contrary.
(b) Modification. No modification, waiver or amendment of this Work Letter or of any of its conditions or provisions shall be binding upon Landlord or Tenant unless in writing signed by Landlord and Tenant.
(c) No Default Funding. In no event shall Landlord have any obligation to perform any Landlords Work during any period that Tenant is in Default under the Lease.
400 E. Jamie Ct. - Suite 300/DiCE - Page C-8
Schedule 1
400 E. Jamie Ct. - Suite 300/DiCE - Page C-9
Schedule 2
Schedule
400 E. Jamie Ct. - Suite 300/DiCE - Page C-10
Schedule 3
Initial Budget
400 E. Jamie Ct. - Suite 300/DiCE - Page C-11
400 E. Jamie Ct. - Suite 300/DiCE - Page C-12
400 E. Jamie Ct. - Suite 300/DiCE - Page C-13
400 E. Jamie Ct. - Suite 300/DiCE - Page C-14
400 E. Jamie Ct. - Suite 300/DiCE - Page D-1
EXHIBIT D TO LEASE
ACKNOWLEDGEMENT OF COMMENCEMENT DATE
This ACKNOWLEDGMENT OF COMMENCEMENT DATE is made this day of , , between ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company (Landlord), and DiCE MOLECULES SV, INC., a Delaware corporation (Tenant), and is attached to and made a part of the Lease dated , (the Lease), by and between Landlord and Tenant. Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.
Landlord and Tenant hereby acknowledge and agree, for all purposes of the Lease, that the Commencement Date of the Base Term of the Lease is , , and the termination date of the Base Term of the Lease shall be midnight on , . In case of a conflict between the terms of the Lease and the terms of this Acknowledgment of Commencement Date, this Acknowledgment of Commencement Date shall control for all purposes.
IN WITNESS WHEREOF, Landlord and Tenant have executed this ACKNOWLEDGMENT OF COMMENCEMENT DATE to be effective on the date first above written.
TENANT: | ||||||
DiCE MOLECULES SV, INC., a Delaware corporation |
By: |
| |||||
Its: |
|
LANDLORD: | ||||||
ARE-EAST JAMIE COURT, LLC, a Delaware limited liability company | ||||||
By: | ALEXANDRIA REAL ESTATE EQUITIES, L.P., a Delaware limited partnership, managing member |
By: | ARE-ORS CORP., | |||||
a Maryland corporation, | ||||||
general partner |
By: |
| |||||
Its: |
|
Rules and Regulations | 400 E. Jamie Ct. - Suite 300/DiCE - Page E-1 |
EXHIBIT E TO LEASE
Rules and Regulations
1. The sidewalk, entries, and driveways of the Project shall not be obstructed by Tenant, or any Tenant Party, or used by them for any purpose other than ingress and egress to and from the Premises.
2. Tenant shall not place any objects, including antennas, outdoor furniture, etc., in the parking areas, landscaped areas or other areas outside of its Premises, or on the roof of the Project.
3. Except for animals assisting the disabled, no animals shall be allowed in the offices, halls, or corridors in the Project.
4. Tenant shall not disturb the occupants of the Project or adjoining buildings by the use of any radio or musical instrument or by the making of loud or improper noises.
5. If Tenant desires telegraphic, telephonic or other electric connections in the Premises, Landlord or its agent will direct the electrician as to where and how the wires may be introduced; and, without such direction, no boring or cutting of wires will be permitted. Any such installation or connection shall be made at Tenants expense.
6. Tenant shall not install or operate any steam or gas engine or boiler, or other mechanical apparatus in the Premises, except as specifically approved in the Lease. The use of oil, gas or inflammable liquids for heating, lighting or any other purpose is expressly prohibited. Explosives or other articles deemed extra hazardous shall not be brought into the Project.
7. Parking any type of recreational vehicles is specifically prohibited on or about the Project. Except for the overnight parking of operative vehicles, no vehicle of any type shall be stored in the parking areas at any time. In the event that a vehicle is disabled, it shall be removed within 48 hours. There shall be no For Sale or other advertising signs on or about any parked vehicle. All vehicles shall be parked in the designated parking areas in conformity with all signs and other markings. All parking will be open parking, and no reserved parking, numbering or lettering of individual spaces will be permitted except as specified by Landlord.
8. Tenant shall maintain the Premises free from rodents, insects and other pests.
9. Landlord reserves the right to exclude or expel from the Project any person who, in the judgment of Landlord, is intoxicated or under the influence of liquor or drugs or who shall in any manner do any act in violation of the Rules and Regulations of the Project.
10. Tenant shall not cause any unnecessary labor by reason of Tenants carelessness or indifference in the preservation of good order and cleanliness. Landlord shall not be responsible to Tenant for any loss of property on the Premises, however occurring, or for any damage done to the effects of Tenant by the janitors or any other employee or person.
11. Tenant shall give Landlord prompt notice of any defects in the water, lawn sprinkler, sewage, gas pipes, electrical lights and fixtures, heating apparatus, or any other service equipment affecting the Premises.
12. Tenant shall not permit storage outside the Premises, including without limitation, outside storage of trucks and other vehicles, or dumping of waste or refuse or permit any harmful materials to be placed in any drainage system or sanitary system in or about the Premises.
Rules and Regulations | 400 E. Jamie Ct. - Suite 300/DiCE - Page E-2 |
13. All moveable trash receptacles provided by the trash disposal firm for the Premises must be kept in the trash enclosure areas, if any, provided for that purpose.
14. No auction, public or private, will be permitted on the Premises or the Project.
15. No awnings shall be placed over the windows in the Premises except with the prior written consent of Landlord.
16. The Premises shall not be used for lodging, sleeping or cooking (except that Tenant may use microwave ovens, toasters and coffee makers in the Premises for the benefit of Tenant employees and contractors in areas designated for such items, but only if the use thereof is at all times supervised by the individual using the same) or for any immoral or illegal purposes or for any purpose other than that specified in the Lease. No gaming devices shall be operated in the Premises.
17. Tenant shall ascertain from Landlord the maximum amount of electrical current which can safely be used in the Premises, taking into account the capacity of the electrical wiring in the Project and the Premises and the needs of other tenants, and shall not use more than such safe capacity. Landlord s consent to the installation of electric equipment shall not relieve Tenant from the obligation not to use more electricity than such safe capacity.
18. Tenant assumes full responsibility for protecting the Premises from theft, robbery and pilferage.
19. Tenant shall not install or operate on the Premises any machinery or mechanical devices of a nature not directly related to Tenants ordinary use of the Premises and shall keep all such machinery free of vibration, noise and air waves which may be transmitted beyond the Premises.
20. Tenant shall cause any vendors and other service providers hired by Tenant to perform services at the Premises or the Project to maintain in effect workers compensation insurance as required by Legal Requirements and commercial general liability insurance with coverage amounts reasonably acceptable to Landlord. Tenant shall cause such vendors and service providers to name Landlord and Alexandria Real Estate Equities, Inc. as additional insureds under such policies and shall provide Landlord with certificates of insurance evidencing the required coverages (and showing Landlord and Alexandria Real Estate Equities, Inc. as additional insureds under such policies) prior to the applicable vendor or service provider providing any services to Tenant at the Project.
21. Neither Tenant nor any of the Tenant Parties shall have the right to photograph, videotape, film, digitally record or by any other means record, transmit and/or distribute any images, pictures or videos of all or any portion of the Premises or the Project that could identify the Project or the name of the Project, or that identify Landlord or any other tenants or any affiliates of Landlord or any other tenants without Landlords prior consent, which shall not be unreasonably withheld, conditioned or delayed. The foregoing is not meant to prohibit individual employees from taking and disseminating photos of themselves or other people within the Premises or at the Project so long as neither the Building nor any proprietary information, equipment or improvements of Landlord are included within such photos.
22. Tenants of the Project shall use reasonable efforts to regularly review the guidelines published by the Centers for Disease Control (CDC) and any state and/or local Governmental Agencies, and will use reasonable efforts to implement the practices and procedures required thereby and, to the extent reasonably practicable, the practices and procedures suggested thereby, as well as industry standard best practices, to prevent the spread of Infectious Conditions, including, without limitation, COVID- 19.
23. Landlord shall have the right, provided that such requirements do not contravene applicable Legal Requirements , to (a) require tenants to implement and enforce reasonable screening and tracking protocols intended to identify and track the activity at the Project of their employees , agents,
Rules and Regulations | 400 E. Jamie Ct. - Suite 300/DiCE - Page E-3 |
contractors and visitors seeking access to or accessing the Premises and or the Project exhibiting flu-like symptoms or symptoms consistent with those associated with any currently known or unknown Infectious Conditions including, without limitation, COVID-19 (collectively, Symptoms), (b) require tenant employees, agents, contractors and visitors to comply with reasonable screening and tracking protocols implemented by Landlord, Landlords property manager and/or any operator of Project Amenities, intended to identify and track the activity at the Project of individuals seeking access to or accessing the Premises or the Project (including the Project Amenities) exhibiting Symptoms, (c) require tenants to implement and enforce protocols to prohibit their employees, agents, contractors and/or visitors exhibiting Symptoms, from accessing the Premises and/or the Project, (d) require tenants to immediately report to Landlord incidences of (i) tenant employees, agents, contractors and visitors accessing the Premises or any portion of the Project while exhibiting Symptoms, and/or (ii) tenant employees, agents, contractors and visitors known to have accessed the Premises or the Project being diagnosed with an Infectious Condition including, without limitation, COVID-19.
24. Landlord may exclude or expel from the Project any person that has Symptoms associated with any currently known or unknown Infectious Condition including, without limitation, COVID-19.
25. Notwithstanding anything to the contrary contained herein, if, at any time during the Term, Landlord becomes aware that any Tenant Party exhibiting Symptoms (that is subsequently diagnosed with an Infectious Condition) and/or a Tenant Party diagnosed with an Infectious Condition accessed the Premises or any portion of the Project (including, without limitation, the Project Amenities), Tenant shall be responsible for any deep cleaning required within the Premises and any reasonable costs incurred by Landlord to perform additional or deep cleaning of any applicable portions of the Common Areas of the Project or to take other measures deemed reasonably necessary or prudent by Landlord which are intended to limit the spread of such Infectious Condition due to such Tenant Partys presence at the Project.
400 E. Jamie Ct. - Suite 300/DiCE - Page F-4
EXHIBIT F TO LEASE
TENANTS PERSONAL PROPERTY
Tenants personal property includes the items listed below, to the extent paid for by Tenant (and not included as Tenant Improvements paid for by Landlord or already existing at the Premises).
| gas manifold |
| glass washes |
| autoclaves |
| portable fume hoods |
| portable lab benches |