Lease Agreement between Adaptive Biotechnologies Corporation and ARE-Seattle No. 12, LLC, dated August 2, 2019
Certain information has been excluded from this exhibit because it (i) is not material and (ii) would be competitively harmful if publicly disclosed.
THIS LEASE AGREEMENT (this Lease) is made this 2nd day of August, 2019, between ARE-SEATTLE NO. 12, LLC, a Delaware limited liability company (Landlord), and ADAPTIVE BIOTECHNOLOGIES CORPORATION, a Washington corporation (Tenant).
|Building:||That to-be-constructed building to be known as 1165 Eastlake Avenue East, Seattle, Washington 98109|
|Premises:||The entire Building, containing approximately 100,086 rentable square feet, as shown on Exhibit A.|
|Project:||The real property on which the Premises are located, together with all improvements thereon and appurtenances thereto as described on Exhibit B.|
|Base Rent:||$[***] per rentable square foot of the Premises per year, subject to adjustment pursuant to Section 4 hereof.|
Rentable Area of Premises: 100,086 sq. ft.
Rentable Area of Project: 100,086 sq. ft.
Tenants Share of Operating Expenses: [***]%
Security Deposit: $[***]
Target Commencement Date: October 1, 2020
Rent Adjustment Percentage: [***]%
|Base Term:||Beginning on the Commencement Date and ending 142 months from the first day of the first full calendar month following the Rent Commencement Date. For clarity, if the Rent Commencement Date occurs on the first day of a month, the expiration of the Base Term shall be measured from that date. If the Rent Commencement Date occurs on a day other than the first day of a month, the expiration of the Base Term shall be measured from the first day of the following month.|
|Permitted Use:||Research and development laboratory, related office and other related uses consistent with the character of the Project and otherwise in compliance with the provisions of Section 7 hereof.|
Address for Rent Payment:
P.O. Box 975383
Dallas, TX ###-###-####
|Landlords Notice Address before September 1, 2019:||Landlords Notice Address on or after September 1, 2019:|
|385 E. Colorado Boulevard, Suite 299||26 North Euclid Avenue|
|Pasadena, CA 91101||Pasadena, CA 91101|
|Attention: Corporate Secretary||Attention: Corporate Secretary|
|Tenants Notice Address||Tenants Notice Address|
|Prior to the Rent Commencement Date:||After the Rent Commencement Date:|
|1551 Eastlake Avenue||1165 Eastlake Avenue|
|Seattle, Washington 98109||Seattle, Washington 98109|
|Attention: Lease Administrator||Attention: Lease Administrator|
Certain information, as identified by [***], has been excluded from this agreement because it (i) is not material and (ii) would be competitively harmful if publicly disclosed.
|Net Laboratory||1165 Eastlake/Adaptive - Page 2|
The following Exhibits and Addenda are attached hereto and incorporated herein by this reference:
☒ EXHIBIT A - PREMISES DESCRIPTION
☒ EXHIBIT B - DESCRIPTION OF PROJECT
☒ EXHIBIT C - WORK LETTER
☒ EXHIBIT D - COMMENCEMENT DATE
☒ EXHIBIT E - RULES AND REGULATIONS
☒ EXHIBIT F - TENANTS PERSONAL PROPERTY
1. Lease of Premises. Upon and subject to all of the terms and conditions hereof, Landlord hereby leases the Premises to Tenant and Tenant hereby leases the Premises from Landlord. Landlord reserves the right to modify areas of the Project outside the Building, provided that such modifications do not materially adversely affect Tenants use of the Premises for the Permitted Use. From and after the Commencement Date through the expiration of the Term, Tenant shall have access to the exclusive use of the Building and the Premises 24 hours a day, 7 days a week, except in the case of emergencies, as the result of Legal Requirements, the performance by Landlord of any installation, maintenance or repairs, or any other temporary interruptions, and otherwise subject to the terms of this Lease.
2. Delivery; Acceptance of Premises; Commencement Date. Landlord shall use reasonable efforts to deliver the Premises (Delivery or Deliver) for Tenants construction of the Tenant Improvements pursuant to the Work Letter in Tenant Improvement Work Readiness Condition on or before the Target Commencement Date. If Landlord fails to timely Deliver the Premises on or before the Target Commencement Date, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and this Lease shall not be void or voidable except as provided herein. Notwithstanding anything to the contrary contained herein, if Landlord fails to Deliver the Premises to Tenant on or before October 1, 2020 (as such date may be extended for Force Majeure delays and delays caused by Tenant, the Abatement Date), then, commencing on the Rent Commencement Date, Base Rent payable with respect to the Premises shall be abated 1 day for each day from and including the Abatement Date (as such date may be amended for Force Majeure delays and delays caused by Tenant) that Landlord fails to Deliver the Premises to Tenant. If Landlord does not Deliver the Premises by May 1, 2021, for any reason other than Force Majeure delays or delays caused by Tenant, this Lease may be terminated by Tenant by providing written notice to Landlord, and if so terminated by Tenant in accordance with this paragraph the Lease: (a) the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease, if any), shall be returned to Tenant, and (b) neither Landlord nor Tenant shall have any further rights, duties or obligations under this Lease, except with respect to provisions which expressly survive termination of this Lease. As used herein, the terms Tenant Improvements and Tenant Improvement Work Readiness Condition shall have the meanings set forth for such terms in the Work Letter. If Tenant does not elect to terminate this Lease by May 6, 2021, such right to terminate this Lease shall be waived and this Lease shall remain in full force and effect. For the avoidance of doubt, notwithstanding anything to the contrary contained in this Lease (including, without limitation, Section 34), any delays in Landlords Delivery of the Premises to Tenant arising from or related to the replacement of the Fairview Avenue Bridge by the Seattle Department of Transportation shall constitute a Force Majeure delay.
The Commencement Date shall be the date that Landlord Delivers the Premises to Tenant. The Rent Commencement Date shall be the date that is 10 months after the Commencement Date. Upon request of Landlord, Tenant shall execute and deliver a written acknowledgment of the Commencement Date, the Rent Commencement Date and the expiration date of the Term when such are established in the form of the Acknowledgement of Commencement Date attached to this Lease as Exhibit D; provided, however, Tenants failure to execute and deliver such acknowledgment shall not limited or otherwise affect Landlords rights or obligations hereunder. The Term of this Lease shall be the Base Term, as defined above on the first page of this Lease and any Extension Terms which Tenant may elect pursuant to Section 40 hereof.
Except as set forth in the Work Letter or as otherwise expressly set forth in this Lease: (i) Tenant shall accept the Premises in their condition as of the Commencement Date; (ii) Landlord shall have no obligation for any defects in the Premises; and (iii) Tenants taking possession of the Premises shall be
|Net Laboratory||1165 Eastlake/Adaptive - Page 3|
conclusive evidence that Tenant accepts the Premises and that the Premises were in good condition at the time possession was taken. Any occupancy of the Premises by Tenant before the Commencement Date shall be subject to all of the terms and conditions of this Lease, excluding the obligation to pay Base Rent or Operating Expenses.
For the period of 270 consecutive days after the Commencement Date, Landlord shall, at its sole cost and expense (which shall not constitute an Operating Expense), be responsible for any repairs that are required to be made to the Building or Building Systems (as defined in Section 13), unless Tenant or any Tenant Party was responsible for the cause of such repair, in which case Tenant shall pay the cost. Tenant shall also be entitled to the benefit of any warranties issued to Landlord in connection with Landlords Work (as defined in the Work Letter).
Tenant agrees and acknowledges that, except as otherwise expressly set forth in this Lease, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of all or any portion of the Premises or the Project, and/or the suitability of the Premises or the Project for the conduct of Tenants business, and Tenant waives any implied warranty that the Premises or the Project are suitable for the Permitted Use. This Lease constitutes the complete agreement of Landlord and Tenant with respect to the subject matter hereof and supersedes any and all prior representations, inducements, promises, agreements, understandings and negotiations which are not contained herein. Landlord in executing this Lease does so in reliance upon Tenants representations, warranties, acknowledgments and agreements contained herein.
(a) Base Rent. Base Rent for the month in which the Rent Commencement Date occurs (or, if the Rent Commencement Date does not occur on the first day of a calendar month, Base Rent for the first full calendar month following the Rent Commencement Date) and the Security Deposit shall be due and payable within 5 business days after the mutual execution of this Lease by Landlord and Tenant. Tenant shall pay to Landlord in advance, without demand, abatement, deduction or set-off, monthly installments of Base Rent on or before the first day of each calendar month during the Term hereof after the Rent Commencement Date, in lawful money of the United States of America, at the office of Landlord for payment of Rent set forth above, or to such other person or at such other place as Landlord may from time to time designate in writing. Payments of Base Rent for any fractional calendar month shall be prorated. The obligation of Tenant to pay Base Rent and other sums to Landlord and the obligations of Landlord under this Lease are independent obligations. Tenant shall have no right at any time to abate, reduce, or set-off any Rent (as defined in Section 5) due hereunder except for any abatement as may be expressly provided in this Lease.
(b) Additional Rent. In addition to Base Rent, Tenant agrees to pay to Landlord as additional rent (Additional Rent): (i) commencing on the Rent Commencement Date, Tenants Share of Operating Expenses (as defined in Section 5), and (ii) any and all other amounts Tenant assumes or agrees to pay under the provisions of this Lease, including, without limitation, any and all other sums that may become due by reason of any default of Tenant or failure to comply with the agreements, terms, covenants and conditions of this Lease to be performed by Tenant, after any applicable notice and cure period.
4. Base Rent Adjustments.
(a) Annual Adjustments. Base Rent shall be increased on each annual anniversary of the Rent Commencement Date (each an Adjustment Date) by multiplying the Base Rent payable immediately before such Adjustment Date by the Rent Adjustment Percentage and adding the resulting amount to the Base Rent payable immediately before such Adjustment Date. Base Rent, as so adjusted, shall thereafter be due as provided herein. Base Rent adjustments for any fractional calendar month shall be prorated.
|Net Laboratory||1165 Eastlake/Adaptive - Page 4|
(b) Additional TI Allowance. In addition to the Tenant Improvement Allowance (as defined in the Work Letter), Landlord shall, subject to the terms of the Work Letter, make available to Tenant the Additional Tenant Improvement Allowance (as defined in the Work Letter). Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of [***]% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Tenant Improvement Allowance or any portion(s) thereof. Any of the Additional Tenant Improvement Allowance and applicable interest remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease.
5. Operating Expense Payments. Landlord shall deliver to Tenant a written estimate of Operating Expenses for each calendar year during the Term (the Annual Estimate), which may be revised by Landlord from time to time during such calendar year upon not less than 30 days written notice to Tenant; provided, however, that Landlord shall not revise the Annual Estimate more than twice in any calendar year. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Term, Tenant shall pay Landlord an amount equal to 1/12th of Tenants Share of the Annual Estimate. Payments for any fractional calendar month shall be prorated.
The term Operating Expenses means all costs and expenses of any kind or description whatsoever incurred or accrued each calendar year by Landlord with respect to the Project (including, without duplication, Taxes (as defined in Section 9), capital repairs, improvements and replacements amortized over the lesser of 10 years and the useful life of such capital repairs, improvements or replacements, transportation services (including costs associated with Landlords operation of or participation in a shuttle service), and the costs of Landlords third party property manager (not to exceed [***]% of Base Rent) or, if there is no third party property manager, administration rent in the amount of [***]% of Base Rent), excluding only:
(a) the original construction costs of the Project and renovation prior to the date of the Lease and costs of correcting defects in such original construction or renovation;
(b) capital expenditures for expansion of the Project;
(c) interest, principal payments of Mortgage (as defined in Section 27) debts of Landlord, financing costs and amortization of funds borrowed by Landlord, whether secured or unsecured;
(d) depreciation of the Project (except for capital improvements, the cost of which are includable in Operating Expenses);
(e) Taxes to be paid directly by Tenant, whether or not actually paid;
(f) salaries, wages, benefits and other compensation paid to officers and employees of Landlord who are not assigned in whole or in part to the operation, management, maintenance or repair of the Project;
(g) general organizational, administrative and overhead costs relating to maintaining Landlords existence, either as a corporation, partnership, or other entity, including general corporate, legal and accounting expenses;
(h) costs and expenses, including legal fees, incurred in connection with negotiations or disputes with employees, consultants, management agents, leasing agents, purchasers or mortgagees of the Building;
Certain information, as identified by [***], has been excluded from this agreement because it (i) is not material and (ii) would be competitively harmful if publicly disclosed.
|Net Laboratory||1165 Eastlake/Adaptive - Page 5|
(i) costs incurred by Landlord due to the violation by Landlord, its employees, agents or contractors of any Legal Requirement (as defined in Section 7);
(j) penalties, fines or interest incurred as a result of Landlords inability or failure to make payment of Taxes and/or to file any tax or informational returns when due, or from Landlords failure to make any payment of Taxes required to be made by Landlord hereunder before delinquency;
(k) overhead and profit increment paid to Landlord or to subsidiaries or affiliates of Landlord for goods and/or services in or to the Project to the extent the same exceeds the costs of such goods and/or services rendered by unaffiliated third parties on a competitive basis;
(l) costs of Landlords charitable or political contributions, or of fine art maintained at the Project;
(m) costs incurred in the sale or refinancing of the Project;
(n) net income taxes of Landlord or the owner of any interest in the Project, franchise, capital stock, gift, estate or inheritance taxes or any federal, state or local documentary taxes imposed against the Project or any portion thereof or interest therein; and
(o) any expenses otherwise includable within Operating Expenses to the extent actually reimbursed by persons other than tenants of the Project under leases for space in the Project.
In addition, notwithstanding anything to the contrary contained in this Lease, Operating Expenses incurred or accrued by Landlord with respect to any capital improvements which are reasonably expected by Landlord to reduce overall Operating Expenses (for example, without limitation, by reducing energy usage at the Project) (the Energy Savings Costs) shall be amortized over a period of years equal to the least of (A) 7 years, (B) the useful life of such capital items, or (C) the quotient of (i) the Energy Savings Costs, divided by (ii) the annual amount of Operating Expenses reasonably expected by Landlord to be saved as a result of such capital improvements.
Within 90 days after the end of each calendar year (or such longer period as may be reasonably required, but in no event more than 120 days), Landlord shall furnish to Tenant a statement (an Annual Statement) showing in reasonable detail (along with, upon written request from Tenant, supporting documentation): (a) the total and Tenants Share of actual Operating Expenses for the previous calendar year, and (b) the total of Tenants payments of Operating Expenses for such year. If Tenants Share of actual Operating Expenses for such year exceeds Tenants payments of Operating Expenses for such year, the excess shall be due and payable by Tenant as Rent within 30 days after delivery of such Annual Statement to Tenant. If Tenants payments of Operating Expenses for such year exceed Tenants Share of actual Operating Expenses for such year Landlord shall pay the excess to Tenant within 30 days after delivery of such Annual Statement, except that after the expiration, or earlier termination of the Term or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord. Landlords and Tenants obligations to pay any overpayments or deficiencies due pursuant to this paragraph shall survive the expiration or earlier termination of this Lease.
The Annual Statement shall be final and binding upon Tenant unless Tenant, within 90 days after Tenants receipt thereof, contests any item therein by giving written notice to Landlord, specifying each item contested and the reason therefor. If, during such 90 day period, Tenant reasonably and in good faith questions or contests the accuracy of Landlords statement of Tenants Share of Operating Expenses, Landlord will provide Tenant with access to Landlords books and records relating to the operation of the Project and such information as Landlord reasonably determines to be responsive to Tenants questions (the Expense Information). If after Tenants review of such Expense Information, Landlord and Tenant cannot agree upon the amount of Tenants Share of Operating Expenses, then Tenant shall have the right to have an independent regionally recognized public accounting firm selected
|Net Laboratory||1165 Eastlake/Adaptive - Page 6|
by Tenant and approved by Landlord (which approval shall not be unreasonably withheld or delayed), working pursuant to a fee arrangement other than a contingent fee (at Tenants sole cost and expense), audit and/or review the Expense Information for the year in question (the Independent Review). The results of any such Independent Review shall be binding on Landlord and Tenant. If the Independent Review shows that the payments actually made by Tenant with respect to Operating Expenses for the calendar year in question exceeded Tenants Share of Operating Expenses for such calendar year, Landlord shall at Landlords option either (i) credit the excess amount to the next succeeding installments of estimated Operating Expenses or (ii) pay the excess to Tenant within 30 days after delivery of such statement, except that after the expiration or earlier termination of this Lease or if Tenant is delinquent in its obligation to pay Rent, Landlord shall pay the excess to Tenant after deducting all other amounts due Landlord. If the Independent Review shows that Tenants payments with respect to Operating Expenses for such calendar year were less than Tenants Share of Operating Expenses for the calendar year, Tenant shall pay the deficiency to Landlord within 30 days after delivery of such statement. If the Independent Review shows that Tenant has overpaid with respect to Operating Expenses by more than 5% then Landlord shall reimburse Tenant for all costs incurred by Tenant for the Independent Review. Operating Expenses for the calendar years in which Tenants obligation to share therein begins and ends shall be prorated.
Tenants Share shall be the percentage set forth on the first page of this Lease as Tenants Share. Base Rent, Tenants Share of Operating Expenses and all other amounts payable by Tenant to Landlord hereunder are collectively referred to herein as Rent.
6. Security Deposit. Tenant shall deposit with Landlord, upon delivery of an executed copy of this Lease to Landlord, a security deposit (the Security Deposit) for the performance of all of Tenants obligations hereunder in the amount set forth on page 1 of this Lease, which Security Deposit shall be in the form of an unconditional and irrevocable letter of credit (the Letter of Credit): (i) in form and substance satisfactory to Landlord, (ii) naming Landlord as beneficiary, (iii) expressly allowing Landlord to draw upon it at any time from time to time by delivering to the issuer notice that Landlord is entitled to draw thereunder, (iv) issued by an FDIC-insured financial institution satisfactory to Landlord, and (v) redeemable by presentation of a sight draft in the state of Landlords choice. If Tenant does not provide Landlord with a substitute Letter of Credit complying with all of the requirements hereof at least 10 days before the stated expiration date of any then current Letter of Credit, Landlord shall have the right to draw the full amount of the current Letter of Credit and hold the funds drawn in cash without obligation for interest thereon as the Security Deposit. The Security Deposit shall be held by Landlord as security for the performance of Tenants obligations under this Lease. The Security Deposit is not an advance rental deposit or a measure of Landlords damages in case of Tenants default. Upon each occurrence of a Default (as defined in Section 20), Landlord may use all or any part of the Security Deposit to pay delinquent payments due under this Lease, future rent damages, and the cost of any damage, injury, expense or liability caused by such Default, without prejudice to any other remedy provided herein or provided by law. Landlords right to use the Security Deposit under this Section 6 includes the right to use the Security Deposit to pay future rent damages following the termination of this Lease pursuant to Section 21(c) below. Upon any use of all or any portion of the Security Deposit, Tenant shall pay Landlord on demand the amount that will restore the Security Deposit to the amount set forth on Page 1 of this Lease. Tenant hereby waives the provisions of any law, now or hereafter in force which provide that Landlord may claim from a security deposit only those sums reasonably necessary to remedy defaults in the payment of Rent, to repair damage caused by Tenant or to clean the Premises, it being agreed that Landlord may, in addition, claim those sums reasonably necessary to compensate Landlord for any other loss or damage, foreseeable or unforeseeable, caused by the act or omission of Tenant or any officer, employee, agent or invitee of Tenant. Upon bankruptcy or other debtor-creditor proceedings against Tenant, the Security Deposit shall be deemed to be applied first to the payment of Rent and other charges due Landlord for periods prior to the filing of such proceedings. If Tenant shall fully perform every provision of this Lease to be performed by Tenant, the Security Deposit, or any balance thereof (i.e., after deducting therefrom all amounts to which Landlord is entitled under the provisions of this Lease), shall be returned to Tenant (or, at Landlords option, to the last assignee of Tenants interest hereunder) within 90 days after the expiration or earlier termination of this Lease.
|Net Laboratory||1165 Eastlake/Adaptive - Page 7|
If Landlord transfers its interest in the Project or this Lease, Landlord shall either (a) transfer any Security Deposit then held by Landlord to a person or entity assuming Landlords obligations under this Section 6, or (b) return to Tenant any Security Deposit then held by Landlord and remaining after the deductions permitted herein. Upon such transfer to such transferee or the return of the Security Deposit to Tenant, Landlord shall have no further obligation with respect to the Security Deposit, and Tenants right to the return of the Security Deposit shall apply solely against Landlords transferee. Landlords obligation respecting the Security Deposit is that of a debtor, not a trustee, and no interest shall accrue thereon.
7. Use. The Premises shall be used solely for the Permitted Use set forth in the basic lease provisions on page 1 of this Lease, and in compliance with all laws, orders, judgments, ordinances, regulations, codes, directives, permits, licenses, covenants and restrictions now or hereafter applicable to the Premises, and to the use and occupancy thereof, including, without limitation, the Americans With Disabilities Act, 42 U.S.C. § 12101, et seq. (together with the regulations promulgated pursuant thereto, ADA) (collectively, Legal Requirements and each, a Legal Requirement). Tenant shall, upon 5 days written notice from Landlord, discontinue any use of the Premises which is declared by any Governmental Authority (as defined in Section 9) having jurisdiction to be a violation of a Legal Requirement. Tenant will not use or permit the Premises to be used for any purpose or in any manner that would void Tenants or Landlords insurance, increase the insurance risk, or cause the disallowance of any sprinkler or other credits. Tenant shall not permit any part of the Premises to be used as a place of public accommodation, as defined in the ADA or any similar legal requirement. Tenant shall reimburse Landlord promptly upon demand for any additional premium charged for any such insurance policy by reason of Tenants failure to comply with the provisions of this Section or otherwise caused by Tenants use and/or occupancy of the Premises. Tenant will use the Premises in a careful, safe and proper manner and will not commit or permit waste, overload the floor or structure of the Premises, subject the Premises to use that would damage the Premises. Tenant shall cause any equipment or machinery to be installed in the Premises so as to reasonably prevent sounds or vibrations from the Premises from extending unreasonably outside the Premises. Tenant shall not place any machinery or equipment which would overload the floor in or upon the Premises or transport or move such items in the Project elevators without the prior written consent of Landlord. Except as may be provided under the Work Letter, Tenant shall not, without the prior written consent of Landlord, use the Premises in any manner which will require ventilation, air exchange, heating, gas, steam, electricity or water beyond the existing capacity of the Project.
Landlord shall, at Landlords sole cost and expense, be responsible for the compliance of Landlords Work (as defined in the Work Letter) with Legal Requirements as of the date that Landlord substantially completes Landlords Work. Except as provided in the immediately preceding sentence, Tenant, at its sole expense, shall make any alterations or modifications to the Project that are required by Legal Requirements (including, without limitation, compliance of the Premises with the ADA) related to Tenants particular use or occupancy of the Premises, the Tenant Improvements and any Alterations. Notwithstanding any other provision herein to the contrary, subject to the first sentence of this paragraph, Tenant shall be responsible for any and all demands, claims, liabilities, losses, costs, expenses, actions, causes of action, damages or judgments, and all reasonable expenses incurred in investigating or resisting the same (including, without limitation, reasonable attorneys fees, charges and disbursements and costs of suit) (collectively, Claims) arising out of or in connection with Tenants compliance with Legal Requirements, and except for Landlords Work, Tenant shall indemnify, defend, hold and save Landlord harmless from and against any and all Claims arising out of or in connection with any failure of the Premises to comply with any Legal Requirement.
Tenant acknowledges that Landlord may, but shall not be obligated to, seek to obtain Leadership in Energy and Environmental Design (LEED), WELL Building Standard, or other similar green certification with respect to the Project and/or the Premises, and Tenant agrees to reasonably cooperate with Landlord, at no material cost to Tenant, and to provide such information and/or documentation as Landlord may reasonably request, in connection therewith.
|Net Laboratory||1165 Eastlake/Adaptive - Page 8|
8. Holding Over. If, with Landlords express written consent, Tenant retains possession of the Premises after the termination of the Term, (i) unless otherwise agreed in such written consent, such possession shall be subject to termination by Landlord at any time upon 30 days notice to Tenant, (ii) all of the other terms and provisions of this Lease (including, without limitation, the adjustment of Base Rent pursuant to Section 4 hereof) shall remain in full force and effect (excluding any expansion or renewal option or other similar right or option) during such holdover period, (iii) Tenant shall continue to pay Base Rent in the amount payable upon the date of the expiration or earlier termination of this Lease or such other amount as Landlord may indicate, in Landlords sole and absolute discretion, in such written consent, and (iv) all other payments shall continue under the terms of this Lease. If Tenant remains in possession of the Premises after the expiration or earlier termination of the Term without the express written consent of Landlord, (A) Tenant shall become a tenant at sufferance upon the terms of this Lease except that the monthly rental shall be equal to 150% of Rent in effect during the last 30 days of the Term, and (B) Tenant shall be responsible for all damages suffered by Landlord resulting from or occasioned by Tenants holding over, including consequential damages. No holding over by Tenant, whether with or without consent of Landlord, shall operate to extend this Lease except as otherwise expressly provided, and this Section 8 shall not be construed as consent for Tenant to retain possession of the Premises. Acceptance by Landlord of Rent after the expiration of the Term or earlier termination of this Lease shall not result in a renewal or reinstatement of this Lease.
9. Taxes. Landlord shall pay, as part of Operating Expenses, all taxes, levies, fees, assessments and governmental charges of any kind, existing as of the Commencement Date or thereafter enacted (collectively referred to as Taxes), imposed by any federal, state, regional, municipal, local or other governmental authority or agency, including, without limitation, quasi-public agencies (collectively, Governmental Authority) during the Term, including, without limitation, all Taxes: (i) imposed on or measured by or based, in whole or in part, on rent payable to (or gross receipts received by) Landlord under this Lease and/or from the rental by Landlord of the Project or any portion thereof, or (ii) based on the square footage, assessed value or other measure or evaluation of any kind of the Premises or the Project , or (iii) assessed or imposed by or on the operation or maintenance of any portion of the Premises or the Project, including parking, or (iv) assessed or imposed by, or at the direction of, or resulting from Legal Requirements, or interpretations thereof, promulgated by any Governmental Authority, or (v) imposed as a license or other fee, charge, tax, or assessment on Landlords business or occupation of leasing space in the Project. Landlord may contest by appropriate legal proceedings the amount, validity, or application of any Taxes or liens securing Taxes. Taxes shall not include any net income taxes imposed on Landlord except to the extent such net income taxes are in substitution for any Taxes payable hereunder. If any such Tax is levied or assessed directly against Tenant, then Tenant shall be responsible for and shall pay the same at such times and in such manner as the taxing authority shall require. Tenant shall pay, prior to delinquency, any and all Taxes levied or assessed against any personal property or trade fixtures placed by Tenant in the Premises, whether levied or assessed against Landlord or Tenant. If any Taxes on Tenants personal property or trade fixtures are levied against Landlord or Landlords property, or if the assessed valuation of the Project is increased by a value attributable to improvements in or alterations to the Premises, whether owned by Landlord or Tenant and whether or not affixed to the real property so as to become a part thereof, higher than the base valuation on which Landlord from time-to-time allocates Taxes to the Project, Landlord shall have the right, but not the obligation, to pay such Taxes. Landlords determination of any excess assessed valuation shall be binding and conclusive, absent manifest error. The amount of any such payment by Landlord shall constitute Additional Rent due from Tenant to Landlord immediately upon demand.
10. Parking. Subject to all matters of record, Force Majeure, a Taking (as defined in Section 19 below) and the exercise by Landlord of its rights hereunder, Tenant shall have the right to use and shall be required to pay Parking Charges for all of the parking spaces located in the subsurface parking areas of the Building, subject in each case to Landlords rules and regulations and the payment, commencing on the Rent Commencement Date, of $[***] per month for each parking space allocated to Tenant plus applicable taxes (Parking Charges). On each annual anniversary of the Rent Commencement Date, the per parking space Parking Charges payable by Tenant shall be increased annually by Landlord to the then-current market rate for parking spaces in similar parking garages serving
Certain information, as identified by [***], has been excluded from this agreement because it (i) is not material and (ii) would be competitively harmful if publicly disclosed.
|Net Laboratory||1165 Eastlake/Adaptive - Page 9|
Class A laboratory/office buildings in the South Lake Union area of Seattle, as reasonably determined by Landlord. Upon written request from Tenant, Landlord shall provide to Tenant any supporting documentation upon which Landlords determination of the then-current market rates is based. Landlord shall not be responsible for enforcing Tenants parking rights against any third parties.
Subject to compliance with Legal Requirements, Landlord shall, at Landlords cost and expense, install prior to the Rent Commencement Date, and, as part of Operating Expenses, power and maintain, approximately 2 dual-charging electric vehicle charging stations in the parking areas of the Project.
11. Utilities, Services. Tenant shall contract directly with utility providers for all water, electricity, heat, light, power, sewer, and other utilities (including gas and fire sprinklers to the extent the Project is plumbed for such services), janitorial services and refuse and trash collection (collectively, Utilities) required and/or utilized by Tenant during the Term. Upon Tenants request, Landlord shall assist Tenant, at no material cost to Landlord, in facilitating Tenants establishment of services with the applicable Utility providers. All Utilities to the Premises shall be separately metered and Tenant shall pay directly to such Utility providers prior to delinquency for all such Utilities furnished to Tenant or the Project during the Term and shall pay for all maintenance charges for Utilities, and any storm sewer charges or other similar charges for Utilities imposed by any Governmental Authority or Utility provider, and any taxes, penalties, surcharges or similar charges thereon. To the extent that any Utilities, maintenance charges for Utilities, any storm sewer charges or other similar charges for Utilities imposed by any Governmental Authority or Utility provider, or any taxes, penalties, surcharges or similar charges are paid for by Landlord, Tenant shall reimburse Landlord for such costs as Operating Expenses. No interruption or failure of Utilities, from any cause whatsoever other than Landlords willful misconduct, shall result in eviction or constructive eviction of Tenant, termination of this Lease or the abatement of Rent.
Tenant agrees, to extent required by Legal Requirements or any Governmental Authority, to provide Landlord with access to Tenants water and/or energy usage data on a monthly basis, either by providing Tenants applicable utility login credentials to Landlords Measurabl online portal, or by another delivery method reasonably agreed to by Landlord and Tenant. The costs and expenses incurred by Landlord in connection with receiving and analyzing such water and/or energy usage data (including, without limitation, as may be required pursuant to applicable Legal Requirements) shall be included as part of Operating Expenses.
12. Alterations and Tenants Property. Any alterations, additions, or improvements made to the Premises by or on behalf of Tenant, including additional locks or bolts of any kind or nature upon any doors or windows in the Premises, but excluding installation, removal or realignment of furniture systems (other than removal of furniture systems owned or paid for by Landlord) not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to Building Systems (as defined in Section 13) (Alterations) shall be subject to Landlords prior written consent, which may be given or withheld in Landlords sole discretion if any such Alteration affects the structure or Building Systems and shall not be otherwise unreasonably withheld, conditioned or delayed. Tenant may construct nonstructural Alterations in the Premises without Landlords prior approval if the aggregate cost of all such work in any 12 month period does not exceed $150,000 (a Notice-Only Alteration), provided Tenant notifies Landlord in writing of such intended Notice-Only Alteration, and such notice shall be accompanied by plans, specifications, work contracts and such other information concerning the nature and cost of the Notice-Only Alteration as may be reasonably requested by Landlord, which notice and accompanying materials shall be delivered to Landlord not less than 15 business days in advance of any proposed construction. If Landlord approves any Alterations, Landlord may impose such conditions on Tenant in connection with the commencement, performance and completion of such Alterations as Landlord may deem appropriate in Landlords reasonable discretion. Any request for approval shall be in writing, delivered not less than 15 business days in advance of any proposed construction, and accompanied by plans, specifications, bid proposals, work contracts and such other information concerning the nature and cost of the alterations as may be reasonably requested by Landlord, including the identities and mailing addresses of all persons performing work or supplying materials. Landlords right to review plans and specifications and to monitor construction shall be solely for its own benefit, and Landlord shall have no duty to ensure that such plans and specifications or construction comply with
|Net Laboratory||1165 Eastlake/Adaptive - Page 10|
applicable Legal Requirements. Tenant shall cause, at its sole cost and expense, all Alterations to comply with insurance requirements and with Legal Requirements and shall implement at its sole cost and expense any alteration or modification required by Legal Requirements as a result of any Alterations. Tenant shall pay to Landlord, as Additional Rent, on demand an amount equal to [***]% of all hard costs incurred by Tenant or its contractors or agents in connection with any Alteration to cover Landlords overhead and expenses for plan review, coordination, scheduling and supervision. Before Tenant begins any Alteration, Landlord may post on and about the Premises notices of non-responsibility pursuant to applicable law. Tenant shall reimburse Landlord for, and indemnify and hold Landlord harmless from, any expense incurred by Landlord by reason of faulty work done by Tenant or its contractors, delays caused by such work, or inadequate cleanup.
Tenant shall furnish security or make other arrangements satisfactory to Landlord to assure payment for the completion of all Alterations work free and clear of liens, and shall provide (and cause each contractor or subcontractor to provide) certificates of insurance for workers compensation and other coverage in amounts and from an insurance company satisfactory to Landlord protecting Landlord against liability for personal injury or property damage during construction. Upon completion of any Alterations, Tenant shall deliver to Landlord: (i) sworn statements setting forth the names of all contractors and subcontractors who did the work and final lien waivers from all such contractors and subcontractors; and (ii) as built plans for any such Alteration.
Except for Removable Installations (as hereinafter defined), all Installations (as hereinafter defined) shall be and shall remain the property of Landlord during the Term and following the expiration or earlier termination of the Term, shall not be removed by Tenant at any time during the Term, and shall remain upon and be surrendered with the Premises as a part thereof. Notwithstanding the foregoing, Landlord may, at the time its approval of any such Installation is requested, or at the time it receives notice of a Notice-Only Alteration, notify Tenant that Landlord requires that Tenant remove such Installation upon the expiration or earlier termination of the Term, in which event Tenant shall remove such Installation in accordance with the immediately succeeding sentence. Upon the expiration or earlier termination of the Term, Tenant shall remove (i) all wires, cables or similar equipment which Tenant has installed in the Premises or in the risers or plenums of the Building, (ii) any Installations for which Landlord has given Tenant notice of removal in accordance with the immediately preceding sentence, and (iii) all of Tenants Property (as hereinafter defined), and Tenant shall restore and repair any damage caused by or occasioned as a result of such removal, including, without limitation, capping off all such connections behind the walls of the Premises and repairing any holes. During any restoration period beyond the expiration or earlier termination of the Term, Tenant shall pay Rent to Landlord as provided herein as if said space were otherwise occupied by Tenant. If Landlord is requested by Tenant or any lender, lessor or other person or entity claiming an interest in any of Tenants Property to waive any lien Landlord may have against any of Tenants Property, and Landlord consents to such waiver, then Landlord shall be entitled to be paid as administrative rent a fee of $1,000 per occurrence for its time and effort in preparing and negotiating such a waiver of lien.
For purposes of this Lease, (x) Removable Installations means any items listed on Exhibit F attached hereto and any items agreed by Landlord in writing to be included on Exhibit F in the future, (y) Tenants Property means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and (z) Installations means all property of any kind paid for with the TI Fund, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch.
Notwithstanding anything to the contrary contained herein, Tenant shall not be required to remove or restore the Tenant Improvements constructed pursuant to the Work Letter at the expiration or earlier termination of this Lease, nor shall Tenant have the right to remove such Tenant Improvements at any time other than in accordance with this Section 12.
|Net Laboratory||1165 Eastlake/Adaptive - Page 11|
13. Landlords Repairs. Landlord, as an Operating Expense (except as otherwise provided in the penultimate paragraph of Section 2), shall maintain all of the structural, exterior, parking and areas of the Project exterior to the Building, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (Building Systems) in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant, or by any of Tenants assignees, sublessees, licensees, agents, servants, employees, invitees and contractors (or any of Tenants assignees, sublessees and/or licensees respective agents, servants, employees, invitees and contractors) (collectively, Tenant Parties) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenants sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the reasonable judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, give Tenant 72 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenants written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlords expense and agrees that the parties respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Notwithstanding anything to the contrary contained herein, Tenant shall have a self-help right pursuant to Section 31.
14. Tenants Repairs. Subject to Section 13 hereof, Tenant, at its expense, shall repair, replace and maintain in good condition all portions of the Premises, including, without limitation, entries, doors, ceilings, interior windows, interior walls, and the interior side of demising walls. Should Tenant fail to make any such repair or replacement or fail to maintain the Premises, Landlord shall give Tenant notice of such failure. If Tenant fails to commence cure of such failure within 10 days of Landlords notice, and thereafter diligently prosecute such cure to completion, Landlord may perform such work and shall be reimbursed by Tenant for the reasonable costs incurred by Landlord in connection with such work within 10 days after demand (along with delivery of an invoice and reasonable supporting documentation therefor) therefor; provided, however, that if such failure by Tenant creates or could create an emergency, Landlord may immediately commence cure of such failure and shall thereafter be entitled to recover the costs of such cure from Tenant. Subject to Sections 17 and 18, Tenant shall bear the full uninsured cost of any repair or replacement to any part of the Project that results from damage caused by Tenant or any Tenant Party and any repair that benefits only the Premises.
15. Mechanics Liens. Tenant shall discharge, by bond or otherwise, any mechanics lien filed against the Premises or against the Project for work claimed to have been done for, or materials claimed to have been furnished to, Tenant within 10 days after Tenant receives notice of the filing thereof, at Tenants sole cost and shall otherwise keep the Premises and the Project free from any liens arising out of work performed, materials furnished or obligations incurred by Tenant. Should Tenant fail to discharge any lien described herein, Landlord shall have the right, but not the obligation, to pay such claim or post a bond or otherwise provide security to eliminate the lien as a claim against title to the Project and the cost thereof shall be immediately due from Tenant as Additional Rent. If Tenant shall lease or finance the acquisition of office equipment, furnishings, or other personal property of a removable nature utilized by Tenant in the operation of Tenants business, Tenant warrants that any
|Net Laboratory||1165 Eastlake/Adaptive - Page 12|
Uniform Commercial Code Financing Statement filed as a matter of public record by any lessor or creditor of Tenant will upon its face or by exhibit thereto indicate that such Financing Statement is applicable only to removable personal property of Tenant located within the Premises. In no event shall the address of the Project be furnished on the statement without qualifying language as to applicability of the lien only to removable personal property, located in an identified suite held by Tenant.
16. Indemnification. Tenant hereby indemnifies and agrees to defend, save and hold Landlord, its officers, directors, employees, managers, agents, and lease signators (collectively, Landlord Indemnified Parties) harmless from and against any and all Claims for injury or death to persons or damage to property occurring within or about the Premises or the Project arising directly or indirectly out of use or occupancy of the Premises or the Project by Tenant or any Tenant Party (including, without limitation, any act, omission or neglect by Tenant or any Tenants Parties in or about the Premises or at the Project) or the a breach or default by Tenant in the performance of any of its obligations hereunder, except to the extent caused by the willful misconduct or negligence of Landlord Indemnified Parties. Landlord shall not be liable to Tenant for, and Tenant assumes all risk of damage to, personal property (including, without limitation, loss of records kept within the Premises). Tenant further waives any and all Claims for injury to Tenants business or loss of income relating to any such damage or destruction of personal property (including, without limitation, any loss of records). Landlord Indemnified Parties shall not be liable for any damages arising from any act, omission or neglect of any tenant in the Project or of any other third party.
17. Insurance. Landlord shall maintain all risk property and, if applicable, sprinkler damage insurance covering the full replacement cost of the Project. Landlord shall further procure and maintain commercial general liability insurance with a single loss limit of not less than $2,000,000 for bodily injury and property damage with respect to the Project. Landlord may, but is not obligated to, maintain such other insurance and additional coverages as it may deem necessary, including, but not limited to, flood, environmental hazard and earthquake, loss or failure of building equipment, errors and omissions, rental loss during the period of repair or rebuilding, workers compensation insurance and fidelity bonds for employees employed to perform services and insurance for any improvements installed by Tenant or which are in addition to the standard improvements customarily furnished by Landlord without regard to whether or not such are made a part of the Project. All such insurance shall be included as part of the Operating Expenses. The Project may be included in a blanket policy (in which case the cost of such insurance allocable to the Project will be determined by Landlord based upon the insurers cost calculations). Tenant shall also reimburse Landlord for any increased premiums or additional insurance which Landlord reasonably deems necessary as a result of Tenants use of the Premises.
Tenant, at its sole cost and expense, shall maintain during the Term: special form or all-risk property insurance with business interruption and extra expense coverage, covering the full replacement cost of all property and improvements installed or placed in the Premises by Tenant at Tenants expense; workers compensation insurance with no less than the minimum limits required by law; employers liability insurance with employers liability limits of $1,000,000 bodily injury by accident each accident, $1,000,000 bodily injury by disease policy limit, and $1,000,000 bodily injury by disease each employee; and commercial general liability insurance, with a minimum limit of not less than $5,000,000 per occurrence for bodily injury and property damage with respect to the Premises. The commercial general liability insurance maintained by Tenant shall name Alexandria Real Estate Equities, Inc., and Landlord, its officers, directors, employees, and managers (collectively, Landlord Insured Parties), as additional insureds; insure on an occurrence and not a claims-made basis; be issued by insurance companies which have a rating of not less than policyholder rating of A and financial category rating of at least Class X in Bests Insurance Guide; shall not be cancelable for nonpayment of premium unless 30 days prior written notice shall have been given to Landlord from the insurer; not contain a hostile fire exclusion; contain a contractual liability endorsement; and provide primary coverage to Landlord Insured Parties (any policy issued to Landlord Insured Parties providing duplicate or similar coverage shall be deemed excess over Tenants policies, regardless of limits). Copies of such policies (if requested by Landlord), or certificates of insurance showing the limits of coverage required hereunder and showing Landlord as an additional insured, along with reasonable evidence of the payment of premiums for the applicable period, shall be delivered to Landlord by Tenant prior to (i) the earlier to occur of (x) the
|Net Laboratory||1165 Eastlake/Adaptive - Page 13|
Commencement Date, or (y) the date that Tenant accesses the Premises under this Lease, and (ii) each renewal of said insurance. Tenants policy may be a blanket policy with an aggregate per location endorsement which specifically provides that the amount of insurance shall not be prejudiced by other losses covered by the policy. Tenant shall, at least 5 days prior to the expiration of such policies, furnish Landlord with renewal certificates. Notwithstanding anything to the contrary contained herein, the minimum coverage limits set forth herein may be satisfied by Tenant using a combination of commercial general liability and umbrella policies.
In each instance where insurance is to name Landlord as an additional insured, Tenant shall upon written request of Landlord also designate and furnish certificates so evidencing Landlord as additional insured to: (i) any lender of Landlord holding a security interest in the Project or any portion thereof, (ii) the landlord under any lease wherein Landlord is tenant of the real property on which the Project is located, if the interest of Landlord is or shall become that of a tenant under a ground or other underlying lease rather than that of a fee owner, and/or (iii) any management company retained by Landlord to manage the Project.
The property insurance obtained by Landlord and Tenant shall include a waiver of subrogation by the insurers and all rights based upon an assignment from its insured, against Landlord or Tenant, and their respective officers, directors, employees, managers, agents, invitees and contractors (Related Parties), in connection with any loss or damage thereby insured against. Neither party nor its respective Related Parties shall be liable to the other for loss or damage caused by any risk insured against under property insurance required to be maintained hereunder, and each party waives any claims against the other party, and its respective Related Parties, for such loss or damage. The failure of a party to insure its property shall not void this waiver. Landlord and its respective Related Parties shall not be liable for, and Tenant hereby waives all claims against such parties for, business interruption and losses occasioned thereby sustained by Tenant or any person claiming through Tenant resulting from any accident or occurrence in or upon the Premises or the Project from any cause whatsoever. If the foregoing waivers shall contravene any law with respect to exculpatory agreements, the liability of Landlord or Tenant shall be deemed not released but shall be secondary to the others insurer.
Landlord may require insurance policy limits to be raised to conform with requirements of Landlords lender and/or to bring coverage limits to levels then being generally required of new tenants within the Project; provided, however, that the increased amount of coverage is consistent with coverage amounts then being required by institutional owners of similar projects with tenants occupying similar size premises in the geographical area in which the Project is located.
18. Restoration. If, at any time during the Term, the Project or the Premises are damaged or destroyed by a fire or other insured casualty, Landlord shall notify Tenant within 60 days after discovery of such damage as to the amount of time Landlord reasonably estimates it will take to restore the Project or the Premises, as applicable (the Restoration Period). If the Restoration Period is estimated to exceed 12 months (the Maximum Restoration Period), Landlord may, in such notice, elect to terminate this Lease as of the date that is 75 days after the date of discovery of such damage or destruction; provided, however, that notwithstanding Landlords election to restore, Tenant may elect to terminate this Lease by written notice to Landlord delivered within 10 business days of receipt of a notice from Landlord estimating a Restoration Period for the Premises longer than the Maximum Restoration Period. Unless either Landlord or Tenant so elects to terminate this Lease, Landlord shall, subject to receipt of sufficient insurance proceeds (with any deductible to be treated as a current Operating Expense), promptly restore the Premises (excluding the improvements installed by Tenant or by Landlord and paid for by Tenant), subject to delays arising from the collection of insurance proceeds, from Force Majeure events or as needed to obtain any license, clearance or other authorization of any kind required to enter into and restore the Premises issued by any Governmental Authority having jurisdiction over the use, storage, handling, treatment, generation, release, disposal, removal or remediation of Hazardous Materials (as defined in Section 30) in, on or about the Premises (collectively referred to herein as Hazardous Materials Clearances); provided, however, that if repair or restoration of the Premises is not substantially complete as of the end of the Maximum Restoration Period or, if longer, the Restoration Period, Landlord may, in its sole and absolute discretion, elect not to proceed with such repair and
|Net Laboratory||1165 Eastlake/Adaptive - Page 14|
restoration, or Tenant may by written notice to Landlord delivered within 10 business days of the expiration of the Maximum Restoration Period or, if longer, the Restoration Period, elect to terminate this Lease, in which event Landlord shall be relieved of its obligation to make such repairs or restoration and this Lease shall terminate as of the date that is 75 days after the later of: (i) discovery of such damage or destruction, or (ii) the date all required Hazardous Materials Clearances are obtained, but Landlord shall retain any Rent paid and the right to any Rent payable by Tenant prior to such election by Landlord or Tenant.
Tenant, at its expense, shall promptly perform, subject to delays arising from the collection of insurance proceeds, from Force Majeure (as defined in Section 34) events or to obtain Hazardous Material Clearances, all repairs or restoration not required to be done by Landlord and shall promptly re-enter the Premises and, to the degree reasonably practicable based on the damage present, commence doing business in accordance with this Lease. Notwithstanding the foregoing, either Landlord or Tenant may terminate this Lease upon written notice to the other if the Premises are damaged during the last year of the Term and Landlord reasonably estimates that it will take more than 2 months to repair such damage; provided, however, that such notice is delivered within 10 business days after the date that Landlord provides Tenant with written notice of the estimated Restoration Period. Notwithstanding anything to the contrary contained herein, Landlord shall also have the right to terminate this Lease if insurance proceeds are not available for such restoration. Rent shall be abated from the date all required Hazardous Material Clearances are obtained until the Premises are repaired and restored, in the proportion which the area of the Premises, if any, which is not usable by Tenant bears to the total area of the Premises, unless Landlord provides Tenant with other space during the period of repair that is suitable for the temporary conduct of Tenants business. In the event that no Hazardous Material Clearances are required to be obtained by Tenant with respect to the Premises, rent abatement shall commence on the date of discovery of the damage or destruction. Such abatement shall be the sole remedy of Tenant, and except as provided in this Section 18, Tenant waives any right to terminate the Lease by reason of damage or casualty loss.
The provisions of this Lease, including this Section 18, constitute an express agreement between Landlord and Tenant with respect to any and all damage to, or destruction of, all or any part of the Premises, or any other portion of the Project, and any statute or regulation which is now or may hereafter be in effect shall have no application to this Lease or any damage or destruction to all or any part of the Premises or any other portion of the Project, the parties hereto expressly agreeing that this Section 18 sets forth their entire understanding and agreement with respect to such matters.
19. Condemnation. If the whole or any material part of the Premises or the Project is taken for any public or quasi-public use under governmental law, ordinance, or regulation, or by right of eminent domain, or by private purchase in lieu thereof (a Taking or Taken), and the Taking would in Landlords reasonable judgment, either prevent or materially interfere with Tenants use of the Premises or materially interfere with or impair Landlords ownership or operation of the Project, then upon written notice by Landlord this Lease shall terminate and Rent shall be apportioned as of said date. If part of the Premises shall be Taken, and this Lease is not terminated as provided above, Landlord shall promptly restore the Premises and the Project as nearly as is commercially reasonable under the circumstances to their condition prior to such partial Taking and the rentable square footage of the Building, the rentable square footage of the Premises, Tenants Share of Operating Expenses and the Rent payable hereunder during the unexpired Term shall be reduced to such extent as may be fair and reasonable under the circumstances. Upon any such Taking, Landlord shall be entitled to receive the entire price or award from any such Taking without any payment to Tenant, and Tenant hereby assigns to Landlord Tenants interest, if any, in such award. Tenant shall have the right, to the extent that same shall not diminish Landlords award, to make a separate claim against the condemning authority (but not Landlord) for such compensation as may be separately awarded or recoverable by Tenant for moving expenses and damage to Tenants trade fixtures, if a separate award for such items is made to Tenant. Tenant hereby waives any and all rights it might otherwise have pursuant to any provision of state law to terminate this Lease upon a partial Taking of the Premises or the Project.
|Net Laboratory||1165 Eastlake/Adaptive - Page 15|
20. Events of Default. Each of the following events shall be a default (Default) by Tenant under this Lease:
(a) Payment Defaults. Tenant shall fail to pay any installment of Rent or any other payment hereunder when due; provided, however, that Landlord will give Tenant notice and an opportunity to cure any failure to pay Rent within 3 days of any such notice not more than once in any 12 month period.
(b) Insurance. Any insurance required to be maintained by Tenant pursuant to this Lease shall be canceled or terminated or shall expire or shall be reduced or materially changed, or Landlord shall receive a notice of nonrenewal of any such insurance and Tenant shall fail to obtain replacement insurance before the expiration of the current coverage.
(c) Abandonment. Tenant shall abandon the Premises.
(d) Improper Transfer. Tenant shall assign, sublease or otherwise transfer or attempt to transfer all or any portion of Tenants interest in this Lease or the Premises except as expressly permitted herein, or Tenants interest in this Lease shall be attached, executed upon, or otherwise judicially seized and such action is not released within 90 days of the action.
(e) Liens. Tenant shall fail to discharge or otherwise obtain the release of any lien placed upon the Premises in violation of this Lease within 10 days after any such lien is filed against the Premises.
(f) Insolvency Events. Tenant or any guarantor or surety of Tenants obligations hereunder shall: (A) make a general assignment for the benefit of creditors; (B) commence any case, proceeding or other action seeking to have an order for relief entered on its behalf as a debtor or to adjudicate it a bankrupt or insolvent, or seeking reorganization, arrangement, adjustment, liquidation, dissolution or composition of it or its debts or seeking appointment of a receiver, trustee, custodian or other similar official for it or for all or of any substantial part of its property (collectively a Proceeding for Relief); (C) become the subject of any Proceeding for Relief which is not dismissed within 90 days of its filing or entry; or (D) die or suffer a legal disability (if Tenant, guarantor, or surety is an individual) or be dissolved or otherwise fail to maintain its legal existence (if Tenant, guarantor or surety is a corporation, partnership or other entity).
(g) Estoppel Certificate or Subordination Agreement. Tenant fails to execute any document required from Tenant under Sections 23 or 27 within 5 days after a second notice requesting such document.
(h) Other Defaults. Tenant shall fail to comply with any provision of this Lease other than those specifically referred to in this Section 20, and, except as otherwise expressly provided herein, such failure shall continue for a period of 30 days after written notice thereof from Landlord to Tenant.
Any notice given under Section 20(h) hereof shall: (i) specify the alleged default, (ii) demand that Tenant cure such default, (iii) be in lieu of, and not in addition to, or shall be deemed to be, any notice required under any provision of applicable law, and (iv) not be deemed a forfeiture or a termination of this Lease unless Landlord elects otherwise in such notice; provided that if the nature of Tenants default pursuant to Section 20(h) is such that it cannot be cured by the payment of money and reasonably requires more than 30 days to cure, then Tenant shall not be deemed to be in default if Tenant commences such cure within said 30 day period and thereafter diligently prosecutes the same to completion; provided, however, that such cure shall be completed no later than 90 days from the date of Landlords notice.
|Net Laboratory||1165 Eastlake/Adaptive - Page 16|
21. Landlords Remedies.
(a) Payment By Landlord; Interest. Upon a Default by Tenant hereunder, Landlord may, without waiving or releasing any obligation of Tenant hereunder, make such payment or perform such act. All sums so paid or incurred by Landlord, together with interest thereon, from the date such sums were paid or incurred, at the annual rate equal to 12% per annum or the highest rate permitted by law (the Default Rate), whichever is less, shall be payable to Landlord on demand as Additional Rent. Nothing herein shall be construed to create or impose a duty on Landlord to mitigate any damages resulting from Tenants Default hereunder.
(b) Late Payment Rent. Late payment by Tenant to Landlord of Rent and other sums due will cause Landlord to incur costs not contemplated by this Lease, the exact amount of which will be extremely difficult and impracticable to ascertain. Such costs include, but are not limited to, processing and accounting charges and late charges which may be imposed on Landlord under any Mortgage covering the Premises. Therefore, if any installment of Rent due from Tenant is not received by Landlord within 5 days after the date such payment is due, Tenant shall pay to Landlord an additional sum equal to 6% of the overdue Rent as a late charge. Notwithstanding the foregoing, before assessing a late charge the first time in any calendar year, Landlord shall provide Tenant written notice of the delinquency and will waive the right if Tenant pays such delinquency within 5 days thereafter. The parties agree that this late charge represents a fair and reasonable estimate of the costs Landlord will incur by reason of late payment by Tenant. In addition to the late charge, Rent not paid when due shall bear interest at the Default Rate from the 5th day after the date due until paid.
(c) Remedies. Upon the occurrence of a Default, Landlord, at its option, without further notice or demand to Tenant, shall have in addition to all other rights and remedies provided in this Lease, at law or in equity, the option to pursue any one or more of the following remedies, each and all of which shall be cumulative and nonexclusive, without any notice or demand whatsoever.
(i) Terminate this Lease, or at Landlords option, Tenants right to possession only, in which event Tenant shall immediately surrender the Premises to Landlord, and if Tenant fails to do so, Landlord may, without prejudice to any other remedy which it may have for possession or arrearages in rent, enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, without being liable for prosecution or any claim for damages therefor;
(ii) Upon any termination of this Lease, whether pursuant to the foregoing Section 21(c)(i) or otherwise, Landlord may recover from Tenant the following:
(A) The worth at the time of award of any unpaid rent which has been earned at the time of such termination; plus
(B) The worth at the time of award of the amount by which the unpaid rent which would have been earned after termination until the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus
(C) The worth at the time of award of the amount by which the unpaid rent for the balance of the Term after the time of award exceeds the amount of such rental loss that Tenant proves could have been reasonably avoided; plus
(D) Any other amount necessary to compensate Landlord for all the detriment proximately caused by Tenants failure to perform its obligations under this Lease or which in the ordinary course of things would be likely to result therefrom, specifically including, but not limited to, brokerage commissions and advertising expenses incurred, expenses of remodeling the Premises or any portion thereof for a new tenant, whether for the same or a different use, and any special concessions made to obtain a new tenant; and
(E) At Landlords election, such other amounts in addition to or in lieu of the foregoing as may be permitted from time to time by applicable law.
|Net Laboratory||1165 Eastlake/Adaptive - Page 17|
The term rent as used in this Section 21 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii)(A) and (B), above, the worth at the time of award shall be computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the worth at the time of award shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.
(iii) Landlord may continue this Lease in effect after Tenants Default and recover rent as it becomes due (Landlord and Tenant hereby agreeing that Tenant has the right to sublet or assign hereunder, subject only to reasonable limitations). Accordingly, if Landlord does not elect to terminate this Lease following a Default by Tenant, Landlord may, from time to time, without terminating this Lease, enforce all of its rights and remedies hereunder, including the right to recover all Rent as it becomes due.
(iv) Whether or not Landlord elects to terminate this Lease following a Default by Tenant, Landlord shall have the right to terminate any and all subleases, licenses, concessions or other consensual arrangements for possession entered into by Tenant and affecting the Premises or may, in Landlords sole discretion, succeed to Tenants interest in such subleases, licenses, concessions or arrangements. Upon Landlords election to succeed to Tenants interest in any such subleases, licenses, concessions or arrangements, Tenant shall, as of the date of notice by Landlord of such election, have no further right to or interest in the rent or other consideration receivable thereunder.
(v) Independent of the exercise of any other remedy of Landlord hereunder or under applicable law, Landlord may conduct an environmental test of the Premises as generally described in Section 30(d) hereof, at Tenants expense.
(d) Effect of Exercise. Exercise by Landlord of any remedies hereunder or otherwise available shall not be deemed to be an acceptance of surrender of the Premises and/or a termination of this Lease by Landlord, it being understood that such surrender and/or termination can be effected only by the express written agreement of Landlord and Tenant. Any law, usage, or custom to the contrary notwithstanding, Landlord shall have the right at all times to enforce the provisions of this Lease in strict accordance with the terms hereof; and the failure of Landlord at any time to enforce its rights under this Lease strictly in accordance with same shall not be construed as having created a custom in any way or manner contrary to the specific terms, provisions, and covenants of this Lease or as having modified the same and shall not be deemed a waiver of Landlords right to enforce one or more of its rights in connection with any subsequent default. A receipt by Landlord of Rent or other payment with knowledge of the breach of any covenant hereof shall not be deemed a waiver of such breach, and no waiver by Landlord of any provision of this Lease shall be deemed to have been made unless expressed in writing and signed by Landlord. To the greatest extent permitted by law, Tenant waives the service of notice of Landlords intention to re-enter, re-take or otherwise obtain possession of the Premises as provided in any statute, or to institute legal proceedings to that end, and also waives all right of redemption in case Tenant shall be dispossessed by a judgment or by warrant of any court or judge. Any reletting of the Premises or any portion thereof shall be on such terms and conditions as Landlord in its sole discretion may determine. Landlord shall not be liable for, nor shall Tenants obligations hereunder be diminished because of, Landlords failure to relet the Premises or collect rent due in respect of such reletting or otherwise to mitigate any damages arising by reason of Tenants Default.
22. Assignment and Subletting.
(a) General Prohibition. Without Landlords prior written consent subject to and on the conditions described in this Section 22, Tenant shall not, directly or indirectly, voluntarily or by operation of law, assign this Lease or sublease the Premises or any part thereof or mortgage, pledge, or hypothecate its leasehold interest or grant any concession or license within the Premises, and any attempt to do any of the foregoing shall be void and of no effect. If Tenant is a corporation, partnership or
|Net Laboratory||1165 Eastlake/Adaptive - Page 18|
limited liability company, the shares or other ownership interests thereof which are not actively traded upon a stock exchange or in the over-the-counter market, a transfer or series of transfers whereby 50% or more of the issued and outstanding shares or other ownership interests of such corporation are, or voting control is, transferred (but excepting transfers upon deaths of individual owners) from a person or persons or entity or entities which were owners thereof at time of execution of this Lease to persons or entities who were not owners of shares or other ownership interests of the corporation, partnership or limited liability company at time of execution of this Lease, shall be deemed an assignment of this Lease requiring the consent of Landlord as provided in this Section 22.
(b) Permitted Transfers. If Tenant desires to assign, sublease, hypothecate or otherwise transfer this Lease or sublet the Premises other than pursuant to a Permitted Assignment (as defined below), then at least 15 business days, but not more than 60 business days, before the date Tenant desires the assignment or sublease to be effective (the Assignment Date), Tenant shall give Landlord a notice (the Assignment Notice) containing such information about the proposed assignee or sublessee, including the proposed use of the Premises and any Hazardous Materials proposed to be used, stored handled, treated, generated in or released or disposed of from the Premises, the Assignment Date, any relationship between Tenant and the proposed assignee or sublessee, and all material terms and conditions of the proposed assignment or sublease, including a copy of any proposed assignment or sublease in its final form, and such other information as Landlord may deem reasonably necessary or appropriate to its consideration whether to grant its consent. Landlord may, by giving written notice to Tenant within 15 business days after receipt of the Assignment Notice: (i) grant such consent (provided that Landlord shall, in its reasonable discretion, further have the right to review and approve or disapprove the proposed form of sublease prior to the effective date of any such subletting), (ii) refuse such consent, in its reasonable discretion; or (iii) with respect to any assignment of this Lease or sublease or series of subleases that would result in more than 50% of the Premises being subleased for substantially the remainder of the Term, terminate this Lease with respect to the space described in the Assignment Notice as of the Assignment Date (an Assignment Termination). Among other reasons, it shall be reasonable for Landlord to withhold its consent in any of these instances: (1) the proposed assignee or subtenant is a governmental agency; (2) in Landlords reasonable judgment, the use of the Premises by the proposed assignee or subtenant would entail any alterations that would lessen the value of the leasehold improvements in the Premises, or would require increased services by Landlord; (3) in Landlords good faith reasonable judgment, the proposed assignee or subtenant is engaged in areas of scientific research or other business concerns that are controversial such that they may (i) attract or cause negative publicity for or about the Building or the Project, (ii) negatively affect the reputation of the Building, the Project or Landlord, (iii) attract protestors to the Building or the Project, or (iv) lessen the attractiveness of the Building or the Project to any tenants or prospective tenants, purchasers or lenders; (4) in Landlords reasonable judgment, the proposed assignee or subtenant lacks the creditworthiness to support the financial obligations it will incur under the proposed assignment or sublease; (5) Landlord has received from any prior landlord to the proposed assignee or subtenant a negative report concerning such prior landlords experience with the proposed assignee or subtenant; (6) Landlord has experienced previous defaults by or is in litigation with the proposed assignee or subtenant; (7) the use of the Premises by the proposed assignee or subtenant will violate any applicable Legal Requirement; or (8) the assignment or sublease is prohibited by Landlords lender. If Landlord delivers notice of its election to exercise an Assignment Termination, Tenant shall have the right to withdraw such Assignment Notice by written notice to Landlord of such election within 5 business days after Landlords notice electing to exercise the Assignment Termination. If Tenant withdraws such Assignment Notice, this Lease shall continue in full force and effect. If Tenant does not withdraw such Assignment Notice, this Lease, and the term and estate herein granted, shall terminate as of the Assignment Date with respect to the space described in such Assignment Notice. No failure of Landlord to exercise any such option to terminate this Lease, or to deliver a timely notice in response to the Assignment Notice, shall be deemed to be Landlords consent to the proposed assignment, sublease or other transfer. Tenant shall pay to Landlord a fee equal to Two Thousand Five Hundred Dollars ($2,500) in connection with its consideration of any Assignment Notice and/or its preparation or review of any consent documents. Notwithstanding the foregoing, Landlords consent to an assignment of this Lease or a subletting of any portion of the Premises to any entity controlling, controlled by or under common control with Tenant (a Control Permitted Assignment) shall not be required, provided that Landlord shall have the right to
|Net Laboratory||1165 Eastlake/Adaptive - Page 19|
approve the form of any such sublease or assignment. In addition, Tenant shall have the right to assign this Lease, upon 30 days prior written notice to Landlord but without obtaining Landlords prior written consent, to a corporation or other entity which is a successor-in-interest to Tenant, by way of merger, consolidation or corporate reorganization, or by the purchase of all or substantially all of the assets or the ownership interests of Tenant provided that (i) such merger or consolidation, or such acquisition or assumption, as the case may be, is for a good business purpose and not principally for the purpose of transferring the Lease, and (ii) the net worth (as determined in accordance with generally accepted accounting principles (GAAP)) of the assignee is not less than the greater of the net worth (as determined in accordance with GAAP) of Tenant as of (A) the Commencement Date, or (B) as of the date of Tenants most current quarterly or annual financial statements, and (iii) such assignee shall agree in writing to assume all of the terms, covenants and conditions of this Lease (a Corporate Permitted Assignment). Control Permitted Assignments and Corporate Permitted Assignments are hereinafter referred to as Permitted Assignments.
(c) Additional Conditions. As a condition to any such assignment or subletting, whether or not Landlords consent is required, Landlord may require:
(i) that any assignee or subtenant agree, in writing at the time of such assignment or subletting, that if Landlord gives such party notice that Tenant is in default under this Lease, such party shall thereafter make all payments otherwise due Tenant directly to Landlord, which payments will be received by Landlord without any liability except to credit such payment against those due under the Lease, and any such third party shall agree to attorn to Landlord or its successors and assigns should this Lease be terminated for any reason; provided, however, in no event shall Landlord or its successors or assigns be obligated to accept such attornment; and
(ii) A list of Hazardous Materials, certified by the proposed assignee or sublessee to be true and correct, which the proposed assignee or sublessee intends to use, store, handle, treat, generate in or release or dispose of from the Premises, together with copies of all documents relating to such use, storage, handling, treatment, generation, release or disposal of Hazardous Materials by the proposed assignee or subtenant in the Premises or on the Project, prior to the proposed assignment or subletting, including, without limitation: permits; approvals; reports and correspondence; storage and management plans; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given its written consent to do so, which consent may be withheld in Landlords sole and absolute discretion); and all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks. Neither Tenant nor any such proposed assignee or subtenant is required, however, to provide Landlord with any portion(s) of the such documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities.
(d) No Release of Tenant, Sharing of Excess Rents. Notwithstanding any assignment or subletting, Tenant and any guarantor or surety of Tenants obligations under this Lease shall at all times remain fully and primarily responsible and liable for the payment of Rent and for compliance with all of Tenants other obligations under this Lease. If the Rent due and payable by a sublessee or assignee (or a combination of the rental payable under such sublease or assignment plus any bonus or other consideration therefor or incident thereto in any form) exceeds the sum of the rental payable under this Lease, (excluding however, any Rent payable under this Section) and actual and reasonable brokerage fees, legal costs and any design or construction fees directly related to and required pursuant to the terms of any such sublease) (Excess Rent), then Tenant shall be bound and obligated to pay Landlord as Additional Rent hereunder 50% of such Excess Rent within 10 days following receipt thereof by Tenant. If Tenant shall sublet the Premises or any part thereof, Tenant hereby immediately and irrevocably assigns to Landlord, as security for Tenants obligations under this Lease, all rent from any such subletting, and Landlord as assignee and as attorney-in-fact for Tenant, or a receiver for Tenant appointed on Landlords application, may collect such rent and apply it toward Tenants obligations under this Lease; except that, until the occurrence of a Default, Tenant shall have the right to collect such rent.
|Net Laboratory||1165 Eastlake/Adaptive - Page 20|
(e) No Waiver. The consent by Landlord to an assignment or subletting shall not relieve Tenant or any assignees of this Lease or any sublessees of the Premises from obtaining the consent of Landlord to any further assignment or subletting nor shall it release Tenant or any assignee or sublessee of Tenant from full and primary liability under the Lease. The acceptance of Rent hereunder, or the acceptance of performance of any other term, covenant, or condition thereof, from any other person or entity shall not be deemed to be a waiver of any of the provisions of this Lease or a consent to any subletting, assignment or other transfer of the Premises.
(f) Prior Conduct of Proposed Transferee. Notwithstanding any other provision of this Section 22, if (i) the proposed assignee or sublessee of Tenant has been required by any prior landlord, lender or Governmental Authority to take remedial action in connection with Hazardous Materials contaminating a property, where the contamination resulted from such partys action or use of the property in question, (ii) the proposed assignee or sublessee is subject to an enforcement order issued by any Governmental Authority in connection with the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials (including, without limitation, any order related to the failure to make a required reporting to any Governmental Authority), or (iii) because of the existence of a pre-existing environmental condition in the vicinity of or underlying the Project, the risk that Landlord would be targeted as a responsible party in connection with the remediation of such pre-existing environmental condition would be materially increased or exacerbated by the proposed use of Hazardous Materials by such proposed assignee or sublessee, Landlord shall have the absolute right to refuse to consent to any assignment or subletting to any such party.
23. Estoppel Certificate. Tenant shall, within 10 business days of written notice from Landlord, execute, acknowledge and deliver a statement in writing in any form reasonably requested by a proposed lender or purchaser, (i) certifying that this Lease is unmodified and in full force and effect (or, if modified, stating the nature of such modification and certifying that this Lease as so modified is in full force and effect) and the dates to which the rental and other charges are paid in advance, if any, (ii) acknowledging that there are not any uncured defaults on the part of Landlord hereunder, or specifying such defaults if any are claimed, and (iii) setting forth such further information with respect to the status of this Lease or the Premises as may be requested thereon. Any such statement may be relied upon by any prospective purchaser or encumbrancer of all or any portion of the real property of which the Premises are a part. Tenants failure to deliver such statement within such time shall, at the option of Landlord, constitute a Default under this Lease, and, in any event, shall be conclusive upon Tenant that the Lease is in full force and effect and without modification except as may be represented by Landlord in any certificate prepared by Landlord and delivered to Tenant for execution.
24. Quiet Enjoyment. So long as Tenant is not in Default under this Lease, Tenant shall, subject to the terms of this Lease, at all times during the Term, have peaceful and quiet enjoyment of the Premises against any person claiming by, through or under Landlord.
25. Prorations. All prorations required or permitted to be made hereunder shall be made on the basis of a 360 day year and 30 day months.
26. Rules and Regulations. Tenant shall, at all times during the Term and any extension thereof, comply with all reasonable rules and regulations at any time or from time to time established by Landlord covering use of the Premises and the Project. The current rules and regulations are attached hereto as Exhibit E. If there is any conflict between said rules and regulations and other provisions of this Lease, the terms and provisions of this Lease shall control. Landlord shall not have any liability or obligation for the breach of any rules or regulations by other tenants in the Project and shall not enforce such rules and regulations in a discriminatory manner.
27. Subordination. This Lease and Tenants interest and rights hereunder are hereby made and shall be subject and subordinate at all times to the lien of any Mortgage now existing or hereafter created on or against the Project or the Premises, and all amendments, restatements, renewals, modifications, consolidations, refinancing, assignments and extensions thereof, without the necessity of
|Net Laboratory||1165 Eastlake/Adaptive - Page 21|
any further instrument or act on the part of Tenant; provided, however that so long as there is no Default hereunder, Tenants right to possession of the Premises shall not be disturbed by the Holder of any such Mortgage. Tenant agrees, at the election of the Holder of any such Mortgage, to attorn to any such Holder. Tenant agrees upon demand to execute, acknowledge and deliver such instruments, confirming such subordination, and such instruments of attornment as shall be requested by any such Holder, provided any such instruments contain appropriate non-disturbance provisions assuring Tenants quiet enjoyment of the Premises as set forth in Section 24 hereof. Notwithstanding the foregoing, any such Holder may at any time subordinate its Mortgage to this Lease, without Tenants consent, by notice in writing to Tenant, and thereupon this Lease shall be deemed prior to such Mortgage without regard to their respective dates of execution, delivery or recording and in that event such Holder shall have the same rights with respect to this Lease as though this Lease had been executed prior to the execution, delivery and recording of such Mortgage and had been assigned to such Holder. The term Mortgage whenever used in this Lease shall be deemed to include deeds of trust, security assignments and any other encumbrances, and any reference to the Holder of a Mortgage shall be deemed to include the beneficiary under a deed of trust. As of the date of this Lease, there is no existing Mortgage encumbering the Project.
28. Surrender. Upon the expiration of the Term or earlier termination of Tenants right of possession, Tenant shall surrender the Premises to Landlord in the same condition as received, subject to any Alterations or Installations permitted by Landlord to remain in the Premises, free of Hazardous Materials brought upon, kept, used, stored, handled, treated, generated in, or released or disposed of from, the Premises by any person other than a Landlord Party (collectively, Tenant HazMat Operations) and released of all Hazardous Materials Clearances, broom clean, ordinary wear and tear and casualty loss and condemnation covered by Sections 18 and 19 excepted. At least 3 months prior to the surrender of the Premises or such earlier date as Tenant may elect to cease operations at the Premises, Tenant shall deliver to Landlord a narrative description of the actions proposed (or required by any Governmental Authority) to be taken by Tenant in order to surrender the Premises (including any Installations permitted by Landlord to remain in the Premises) at the expiration or earlier termination of the Term, free from any residual impact from the Tenant HazMat Operations and otherwise released for unrestricted use and occupancy (the Decommissioning and HazMat Closure Plan). Such Decommissioning and HazMat Closure Plan shall be accompanied by a current listing of (i) all Hazardous Materials licenses and permits held by or on behalf of any Tenant Party with respect to the Premises, and (ii) all Hazardous Materials used, stored, handled, treated, generated, released or disposed of from the Premises, and shall be subject to the review and approval of Landlords environmental consultant. In connection with the review and approval of the Decommissioning and HazMat Closure Plan, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such additional non-proprietary information concerning Tenant HazMat Operations as Landlord shall request. On or before such surrender, Tenant shall deliver to Landlord evidence that the approved Decommissioning and HazMat Closure Plan shall have been satisfactorily completed and Landlord shall have the right, subject to reimbursement at Tenants expense as set forth below, to cause Landlords environmental consultant to inspect the Premises and perform such additional procedures as may be deemed reasonably necessary to confirm that the Premises are, as of the effective date of such surrender or early termination of the Lease, free from any residual impact from Tenant HazMat Operations. Tenant shall reimburse Landlord, as Additional Rent, for the actual out-of-pocket expense incurred by Landlord for Landlords environmental consultant to review and approve the Decommissioning and HazMat Closure Plan and to visit the Premises and verify satisfactory completion of the same, which cost shall not exceed $5,000. Landlord shall have the unrestricted right to deliver such Decommissioning and HazMat Closure Plan and any report by Landlords environmental consultant with respect to the surrender of the Premises to third parties.
If Tenant shall fail to prepare or submit a Decommissioning and HazMat Closure Plan approved by Landlord, or if Tenant shall fail to complete the approved Decommissioning and HazMat Closure Plan, or if such Decommissioning and HazMat Closure Plan, whether or not approved by Landlord, shall fail to adequately address any residual effect of Tenant HazMat Operations in, on or about the Premises, Landlord shall have the right to take such actions as Landlord may deem reasonable or appropriate to assure that the Premises and the Project are surrendered free from any residual impact from Tenant HazMat Operations, the cost of which actions shall be reimbursed by Tenant as Additional Rent, without regard to the limitation set forth in the first paragraph of this Section 28.
|Net Laboratory||1165 Eastlake/Adaptive - Page 22|
Tenant shall immediately return to Landlord all keys and/or access cards to parking, the Project, restrooms or all or any portion of the Premises furnished to or otherwise procured by Tenant. If any such access card or key is lost, Tenant shall pay to Landlord, at Landlords election, either the cost of replacing such lost access card or key or the cost of reprogramming the access security system in which such access card was used or changing the lock or locks opened by such lost key. Any Tenants Property, Alterations and property not so removed by Tenant as permitted or required herein shall be deemed abandoned and may be stored, removed, and disposed of by Landlord at Tenants expense, and Tenant waives all claims against Landlord for any damages resulting from Landlords retention and/or disposition of such property. All obligations of Tenant hereunder not fully performed as of the termination of the Term, including the obligations of Tenant under Section 30 hereof, shall survive the expiration or earlier termination of the Term, including, without limitation, indemnity obligations, payment obligations with respect to Rent and obligations concerning the condition and repair of the Premises.
29. Waiver of Jury Trial. TO THE EXTENT PERMITTED BY LAW, TENANT AND LANDLORD WAIVE ANY RIGHT TO TRIAL BY JURY OR TO HAVE A JURY PARTICIPATE IN RESOLVING ANY DISPUTE, WHETHER SOUNDING IN CONTRACT, TORT, OR OTHERWISE, BETWEEN LANDLORD AND TENANT ARISING OUT OF THIS LEASE OR ANY OTHER INSTRUMENT, DOCUMENT, OR AGREEMENT EXECUTED OR DELIVERED IN CONNECTION HEREWITH OR THE TRANSACTIONS RELATED HERETO.
30. Environmental Requirements.
(a) Prohibition/Compliance/Indemnity. Tenant shall not cause or permit any Hazardous Materials (as hereinafter defined) to be brought upon, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises or the Project in violation of applicable Environmental Requirements (as hereinafter defined) by Tenant or any Tenant Party. If Tenant breaches the obligation stated in the preceding sentence, or if the presence of Hazardous Materials in the Premises during the Term or any holding over results in contamination of the Premises, the Project or any adjacent property or if contamination of the Premises, the Project or any adjacent property by Hazardous Materials brought into, kept, used, stored, handled, treated, generated in or about, or released or disposed of from, the Premises by anyone other than Landlord and Landlords employees, agents and contractors otherwise occurs during the Term or any holding over, Tenant hereby indemnifies and shall defend and hold Landlord, its officers, directors, employees, agents and contractors harmless from any and all actions (including, without limitation, remedial or enforcement actions of any kind, administrative or judicial proceedings, and orders or judgments arising out of or resulting therefrom), costs, claims, damages (including, without limitation, punitive damages and damages based upon diminution in value of the Premises or the Project, or the loss of, or restriction on, use of the Premises or any portion of the Project), expenses (including, without limitation, attorneys, consultants and experts fees, court costs and amounts paid in settlement of any claims or actions), fines, forfeitures or other civil, administrative or criminal penalties, injunctive or other relief (whether or not based upon personal injury, property damage, or contamination of, or adverse effects upon, the environment, water tables or natural resources), liabilities or losses (collectively, Environmental Claims) which arise during or after the Term as a result of such contamination. This indemnification of Landlord by Tenant includes, without limitation, costs incurred in connection with any investigation of site conditions or any cleanup, treatment, remedial, removal, or restoration work required by any federal, state or local Governmental Authority because of Hazardous Materials present in the air, soil or ground water above, on, or under the Premises. Without limiting the foregoing, if the presence of any Hazardous Materials on the Premises, the Project or any adjacent property caused or permitted by Tenant or any Tenant Party results in any contamination of the Premises, the Project or any adjacent property, Tenant shall promptly take all actions at its sole expense and in accordance with applicable Environmental Requirements as are necessary to return the Premises, the Project or any adjacent property to the condition existing prior to the time of such contamination, provided that Landlords approval of such action shall first be obtained, which approval shall not unreasonably be withheld so long as such actions would not potentially have any material adverse long-
|Net Laboratory||1165 Eastlake/Adaptive - Page 23|
term or short-term effect on the Premises or the Project. Notwithstanding anything to the contrary contained in this Section 30, Tenant shall not be responsible for, and the indemnification and hold harmless obligation set forth in this paragraph shall not apply to (i) contamination in the Premises which Tenant can prove to Landlords reasonable satisfaction existed in the Premises immediately prior to the Commencement Date, or (ii) the presence of any Hazardous Materials in the Premises which Tenant can prove to Landlords reasonable satisfaction migrated from outside of the Premises into the Premises, unless in either case, the presence of such Hazardous Materials (x) is the result of a breach by Tenant of any of its obligations under this Lease, or (y) was caused, contributed to or exacerbated by Tenant or any Tenant Party.
(b) Business. Landlord acknowledges that it is not the intent of this Section 30 to prohibit Tenant from using the Premises for the Permitted Use. Tenant may operate its business according to prudent industry practices so long as the use or presence of Hazardous Materials is strictly and properly monitored according to all then applicable Environmental Requirements. As a material inducement to Landlord to allow Tenant to use Hazardous Materials in connection with its business, Tenant agrees to deliver to Landlord prior to the Commencement Date a list identifying each type of Hazardous Materials to be brought upon, kept, used, stored, handled, treated, generated on, or released or disposed of from, the Premises and setting forth any and all governmental approvals or permits required in connection with the presence, use, storage, handling, treatment, generation, release or disposal of such Hazardous Materials on or from the Premises (Hazardous Materials List). Upon Landlords request, or any time that Tenant is required to deliver a Hazardous Materials List to any Governmental Authority (e.g., the fire department) in connection with Tenants use or occupancy of the Premises, Tenant shall deliver to Landlord a copy of such Hazardous Materials List. Tenant shall deliver to Landlord true and correct copies of the following documents (the Haz Mat Documents) relating to the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials prior to the Commencement Date, or if unavailable at that time, concurrent with the receipt from or submission to a Governmental Authority: permits; approvals; reports and correspondence; storage and management plans, notice of violations of any Legal Requirements; plans relating to the installation of any storage tanks to be installed in or under the Project (provided, said installation of tanks shall only be permitted after Landlord has given Tenant its written consent to do so, which consent may be withheld in Landlords sole and absolute discretion); all closure plans or any other documents required by any and all federal, state and local Governmental Authorities for any storage tanks installed in, on or under the Project for the closure of any such tanks; and a Surrender Plan (to the extent surrender in accordance with Section 28 cannot be accomplished in 3 months). Tenant is not required, however, to provide Landlord with any portion(s) of the Haz Mat Documents containing information of a proprietary nature which, in and of themselves, do not contain a reference to any Hazardous Materials or hazardous activities. It is not the intent of this Section to provide Landlord with information which could be detrimental to Tenants business should such information become possessed by Tenants competitors.
(c) Tenant Representation and Warranty. Tenant hereby represents and warrants to Landlord that (i) neither Tenant nor any of its legal predecessors has been required by any prior landlord, lender or Governmental Authority at any time to take remedial action in connection with Hazardous Materials contaminating a property which contamination was permitted by Tenant of such predecessor or resulted from Tenants or such predecessors action or use of the property in question, and (ii) Tenant is not subject to any enforcement order issued by any Governmental Authority in connection with the use, storage, handling, treatment, generation, release or disposal of Hazardous Materials (including, without limitation, any order related to the failure to make a required reporting to any Governmental Authority). If Landlord determines that this representation and warranty was not true as of the date of this lease, Landlord shall have the right to terminate this Lease in Landlords sole and absolute discretion.
(d) Testing. Landlord shall have the right to conduct annual tests of the Premises to determine whether any contamination of the Premises or the Project has occurred as a result of Tenants use. Tenant shall be required to pay the cost of such annual test of the Premises; provided, however, that if Tenant conducts its own tests of the Premises using third party contractors and test procedures acceptable to Landlord which tests are certified to Landlord, Landlord shall accept such tests in lieu of the annual tests to be paid for by Tenant. In addition, at any time, and from time to time, prior to the
|Net Laboratory||1165 Eastlake/Adaptive - Page 24|
expiration or earlier termination of the Term, Landlord shall have the right to conduct appropriate tests of the Premises and the Project to determine if contamination has occurred as a result of Tenants use of the Premises. In connection with such testing, upon the request of Landlord, Tenant shall deliver to Landlord or its consultant such non-proprietary information concerning the use of Hazardous Materials in or about the Premises by Tenant or any Tenant Party. If contamination has occurred for which Tenant is liable under this Section 30, Tenant shall pay all costs to conduct such tests. If no such contamination is found, Landlord shall pay the costs of such tests (which shall not constitute an Operating Expense). Landlord shall provide Tenant with a copy of all third party, non-confidential reports and tests of the Premises made by or on behalf of Landlord during the Term without representation or warranty and subject to a confidentiality agreement. Tenant shall, at its sole cost and expense, promptly and satisfactorily remediate any environmental conditions identified by such testing in accordance with all Environmental Requirements. Landlords receipt of or satisfaction with any environmental assessment in no way waives any rights which Landlord may have against Tenant.
(e) Underground Tanks. Tenant shall have no right to use or install any underground or other storage tanks at the Project.
(f) Tenants Obligations. Tenants obligations under this Section 30 shall survive the expiration or earlier termination of the Lease. During any period of time after the expiration or earlier termination of this Lease required by Tenant or Landlord to complete the removal from the Premises of any Hazardous Materials (including, without limitation, the release and termination of any licenses or permits restricting the use of the Premises and the completion of the approved Surrender Plan), Tenant shall continue to pay the full Rent in accordance with this Lease for any portion of the Premises not relet by Landlord in Landlords sole discretion, which Rent shall be prorated daily.
(g) Definitions. As used herein, the term Environmental Requirements means all applicable present and future statutes, regulations, ordinances, rules, codes, judgments, orders or other similar enactments of any Governmental Authority regulating or relating to health, safety, or environmental conditions on, under, or about the Premises or the Project, or the environment, including without limitation, the following: the Comprehensive Environmental Response, Compensation and Liability Act; the Resource Conservation and Recovery Act; and all state and local counterparts thereto, and any regulations or policies promulgated or issued thereunder. As used herein, the term Hazardous Materials means and includes any substance, material, waste, pollutant, or contaminant listed or defined as hazardous or toxic, or regulated by reason of its impact or potential impact on humans, animals and/or the environment under any Environmental Requirements, asbestos and petroleum, including crude oil or any fraction thereof, natural gas liquids, liquefied natural gas, or synthetic gas usable for fuel (or mixtures of natural gas and such synthetic gas). As defined in Environmental Requirements, Tenant is and shall be deemed to be the operator of Tenants facility and the owner of all Hazardous Materials brought on the Premises by Tenant or any Tenant Party, and the wastes, by-products, or residues generated, resulting, or produced therefrom.
31. Tenants Remedies/Limitation of Liability. Landlord shall not be in default hereunder unless Landlord fails to perform any of its obligations hereunder within 30 days after written notice from Tenant specifying such failure (unless such performance will, due to the nature of the obligation, require a period of time in excess of 30 days and Landlord commences such performance within such 30 day period and thereafter continues to diligently prosecute the same to completion, then after such period of time as is reasonably necessary). Upon any default by Landlord, Tenant shall give notice by registered or certified mail to any Holder of a Mortgage covering the Premises and to any landlord of any lease of property in or on which the Premises are located and Tenant shall offer such Holder and/or landlord a reasonable opportunity to cure the default, including time to obtain possession of the Project by power of sale or a judicial action if such should prove necessary to effect a cure; provided Landlord shall have furnished to Tenant in writing the names and addresses of all such persons who are to receive such notices. All obligations of Landlord hereunder shall be construed as covenants, not conditions; and, except as may be otherwise expressly provided in this Lease, Tenant may not terminate this Lease for breach of Landlords obligations hereunder.
|Net Laboratory||1165 Eastlake/Adaptive - Page 25|
Notwithstanding the foregoing, if any claimed Landlord default hereunder will immediately, materially and adversely affect Tenants ability to conduct its business in the Premises (a Material Landlord Default), Tenant shall, as soon as reasonably possible, give Landlord written notice of such claim which notice shall specifically state that a Material Landlord Default exists and telephonic notice to Tenants principal contact with Landlord. Landlord shall then have 2 business days to commence cure of such claimed Material Landlord Default and shall diligently prosecute such cure to completion. If such claimed Material Landlord Default is not a default by Landlord hereunder, Landlord shall be entitled to recover from Tenant, as Additional Rent, any costs incurred by Landlord in connection with such cure in excess of the costs, if any, that Landlord would otherwise have been liable to pay hereunder. If Landlord fails to commence cure of any claimed Material Landlord Default as provided above, Tenant may commence and prosecute such cure to completion provided that it does not adversely affect any Building Systems or the Building Structure, and shall be entitled to recover the costs of such cure (but not any consequential or other damages) from Landlord by way of reimbursement from Landlord with no right to offset against Rent, to the extent of Landlords obligation to cure such claimed Material Landlord Default hereunder, subject to the limitations set forth in this Lease.
All obligations of Landlord under this Lease will be binding upon Landlord only during the period of its ownership of the Premises and not thereafter. The term Landlord in this Lease shall mean only the owner for the time being of the Premises. Upon the transfer by such owner of its interest in the Premises, such owner shall thereupon be released and discharged from all obligations of Landlord thereafter accruing, but such obligations shall be binding during the Term upon each new owner for the duration of such owners ownership.
32. Inspection and Access. Landlord and its agents, representatives, and contractors may enter the Premises at any reasonable time to inspect the Premises and to make such repairs as may be required or permitted pursuant to this Lease and for any other business purpose. Landlord and Landlords representatives may enter the Premises during business hours on not less than 48 hours advance written notice (except in the case of emergencies in which case no such notice shall be required and such entry may be at any time) for the purpose of effecting any such repairs, inspecting the Premises, showing the Premises to prospective purchasers and, during the last 18 months of the Term, to prospective tenants or for any other business purpose. Landlord may erect a suitable sign on the Premises stating the Premises are available to let or that the Project is available for sale. Landlord may grant easements, make public dedications, create restrictions on or about the Project, provided that no such easement, dedication, designation or restriction materially, adversely affects Tenants use or occupancy of the Premises for the Permitted Use. At Landlords request, Tenant shall execute such instruments as may be necessary for such easements, dedications or restrictions. Tenant shall at all times, except in the case of emergencies, have the right to escort Landlord or its agents, representatives, contractors or guests while the same are in the Premises, provided such escort does not materially and adversely affect Landlords access rights hereunder.
33. Security. Tenant acknowledges and agrees that security devices and services, if any, while intended to deter crime may not in given instances prevent theft or other criminal acts and that Landlord is not providing any security services with respect to the Premises. Tenant agrees that Landlord shall not be liable to Tenant for, and Tenant waives any claim against Landlord with respect to, any loss by theft or any other damage suffered or incurred by Tenant in connection with any unauthorized entry into the Premises or any other breach of security with respect to the Premises. Tenant shall be solely responsible for the personal safety of Tenants officers, employees, agents, contractors, guests and invitees while any such person is in, on or about the Premises and/or the Project. Tenant shall at Tenants cost obtain insurance coverage to the extent Tenant desires protection against such criminal acts.
34. Force Majeure. Except for the payment of Rent, neither Landlord nor Tenant shall be held responsible or liable for delays in the performance of its obligations hereunder when caused by, related to, or arising out of acts of God, sinkholes or subsidence, strikes, lockouts, or other labor disputes, embargoes, quarantines, weather, national, regional, or local disasters, calamities, or catastrophes, inability to obtain labor or materials (or reasonable substitutes therefor) at reasonable costs or failure of,
|Net Laboratory||1165 Eastlake/Adaptive - Page 26|
or inability to obtain, utilities necessary for performance, governmental restrictions, orders, limitations, regulations, or controls, national emergencies, delay in issuance or revocation of permits, enemy or hostile governmental action, terrorism, insurrection, riots, civil disturbance or commotion, fire or other casualty, and other causes or events beyond their reasonable control (Force Majeure).
35. Brokers. Landlord and Tenant each represents and warrants that it has not dealt with any broker, agent or other person (collectively, Broker) in connection with this transaction and that no Broker brought about this transaction, other than Flinn Ferguson and Newmark Knight Frank. Landlord and Tenant each hereby agree to indemnify and hold the other harmless from and against any claims by any Broker, other than the broker, if any named in this Section 35, claiming a commission or other form of compensation by virtue of having dealt with Tenant or Landlord, as applicable, with regard to this leasing transaction.
36. Limitation on Landlords Liability. NOTWITHSTANDING ANYTHING SET FORTH HEREIN OR IN ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT TO THE CONTRARY: (A) LANDLORD SHALL NOT BE LIABLE TO TENANT OR ANY OTHER PERSON FOR (AND TENANT AND EACH SUCH OTHER PERSON ASSUME ALL RISK OF) LOSS, DAMAGE OR INJURY, WHETHER ACTUAL OR CONSEQUENTIAL TO: TENANTS PERSONAL PROPERTY OF EVERY KIND AND DESCRIPTION, INCLUDING, WITHOUT LIMITATION TRADE FIXTURES, EQUIPMENT, INVENTORY, SCIENTIFIC RESEARCH, SCIENTIFIC EXPERIMENTS, LABORATORY ANIMALS, PRODUCT, SPECIMENS, SAMPLES, AND/OR SCIENTIFIC, BUSINESS, ACCOUNTING AND OTHER RECORDS OF EVERY KIND AND DESCRIPTION KEPT AT THE PREMISES AND ANY AND ALL INCOME DERIVED OR DERIVABLE THEREFROM; (B) THERE SHALL BE NO PERSONAL RECOURSE TO LANDLORD FOR ANY ACT OR OCCURRENCE IN, ON OR ABOUT THE PREMISES OR ARISING IN ANY WAY UNDER THIS LEASE OR ANY OTHER AGREEMENT BETWEEN LANDLORD AND TENANT WITH RESPECT TO THE SUBJECT MATTER HEREOF AND ANY LIABILITY OF LANDLORD HEREUNDER SHALL BE STRICTLY LIMITED SOLELY TO LANDLORDS INTEREST IN THE PROJECT OR ANY PROCEEDS FROM SALE OR CONDEMNATION THEREOF AND ANY INSURANCE PROCEEDS PAYABLE IN RESPECT OF LANDLORDS INTEREST IN THE PROJECT OR IN CONNECTION WITH ANY SUCH LOSS; AND (C) IN NO EVENT SHALL ANY PERSONAL LIABILITY BE ASSERTED AGAINST LANDLORD IN CONNECTION WITH THIS LEASE NOR SHALL ANY RECOURSE BE HAD TO ANY OTHER PROPERTY OR ASSETS OF LANDLORD OR ANY OF LANDLORDS OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS. UNDER NO CIRCUMSTANCES SHALL LANDLORD OR ANY OF LANDLORDS OFFICERS, DIRECTORS, EMPLOYEES, AGENTS OR CONTRACTORS BE LIABLE FOR INJURY TO TENANTS BUSINESS OR FOR ANY LOSS OF INCOME OR PROFIT THEREFROM.
37. Severability. If any clause or provision of this Lease is illegal, invalid or unenforceable under present or future laws, then and in that event, it is the intention of the parties hereto that the remainder of this Lease shall not be affected thereby. It is also the intention of the parties to this Lease that in lieu of each clause or provision of this Lease that is illegal, invalid or unenforceable, there be added, as a part of this Lease, a clause or provision as similar in effect to such illegal, invalid or unenforceable clause or provision as shall be legal, valid and enforceable.
38. Signs; Exterior Appearance. Tenant shall not, without the prior written consent of Landlord, which shall not be unreasonably withheld: (i) attach any awnings, exterior lights, decorations, balloons, flags, pennants, banners, painting or other projection to any outside wall of the Project, (ii) use any curtains, blinds, shades or screens other than Landlords standard window coverings, (iii) coat or otherwise sunscreen the interior or exterior of any windows, (iv) place any bottles, parcels, or other articles on the window sills, (v) place any equipment, furniture or other items of personal property on any exterior balcony, or (vi) paint, affix or exhibit on any part of the Premises or the Project any signs, notices, window or door lettering, placards, decorations, or advertising media of any type which can be viewed from the exterior of the Premises. Interior signs on doors and the directory tablet shall be inscribed, painted or affixed for Tenant by Landlord at the sole cost and expense of Tenant, and shall be of a size, color and type acceptable to Landlord. Nothing may be placed on the exterior of corridor walls or corridor doors other than Landlords standard lettering.
|Net Laboratory||1165 Eastlake/Adaptive - Page 27|
Tenant shall have the right to display, at Tenants sole cost and expense and otherwise subject to the terms and conditions of this Section 38, the maximum number of signs permitted under applicable Legal Requirements bearing Tenant name and logo on the Building in a location reasonably acceptable to Landlord and Tenant (Building Sign(s)). Tenant further acknowledges and agrees that the Building Sign(s) including, without limitation, the location, size, color and type, shall be subject to Landlords prior written approval, which shall not be unreasonably withheld, and shall be subject to and in compliance with applicable Legal Requirements. Tenant shall be responsible, at Tenants sole cost and expense, for the maintenance of the Building Sign(s), the removal of the Building Sign(s) at the expiration or earlier termination of the Term and for the repair of all damage resulting from such removal.
39. Right to Extend Term. Tenant shall have the right to extend the Term of the Lease upon the following terms and conditions:
(a) Extension Rights. Tenant shall have 2 consecutive rights (each, an Extension Right) to extend the term of this Lease for 5 years (each, an Extension Term) on the same terms and conditions as this Lease (other than with respect to Base Rent and the Work Letter) by giving Landlord written notice of its election to exercise each Extension Right at least 12 months prior to the expiration of the Base Term of the Lease or the expiration of any prior Extension Term.
Base Rent shall be adjusted on the commencement date of such Extension Term and on each annual anniversary of the commencement of such Extension Term by multiplying the Base Rent payable immediately before such adjustment by the Rent Adjustment Percentage and adding the resulting amount to the Base Rent payable immediately before such adjustment.
(b) Rights Personal. Extension Rights are personal to Tenant and are not assignable without Landlords consent, which may be granted or withheld in Landlords sole discretion separate and apart from any consent by Landlord to an assignment of Tenants interest in the Lease, except that they may be assigned in connection with any Permitted Assignment of this Lease.
(c) Exceptions. Notwithstanding anything set forth above to the contrary, Extension Rights shall, at Landlords option, not be in effect and Tenant may not exercise any of the Extension Rights:
(i) during any period of time that Tenant is in Default under any provision of this Lease; or
(ii) if Tenant has been in Default under any provision of this Lease 3 or more times, whether or not the Defaults are cured, during the 12 month period immediately prior to the date that Tenant intends to exercise an Extension Right, whether or not the Defaults are cured.
(d) No Extensions. The period of time within which any Extension Rights may be exercised shall not be extended or enlarged by reason of Tenants inability to exercise the Extension Rights.
(e) Termination. The Extension Rights shall, at Landlords option, terminate and be of no further force or effect even after Tenants due and timely exercise of an Extension Right, if, after such exercise, but prior to the commencement date of an Extension Term, (i) Tenant fails to timely cure any default by Tenant under this Lease; or (ii) Tenant has Defaulted 3 or more times during the period from the date of the exercise of an Extension Right to the date of the commencement of the Extension Term, whether or not such Defaults are cured.
(a) Notices. All notices or other communications between the parties shall be in writing and shall be deemed duly given upon delivery or refusal to accept delivery by the addressee thereof if delivered in person, or upon actual receipt if delivered by reputable overnight guaranty courier, addressed and sent to the parties at their addresses set forth above. Landlord and Tenant may from time to time by written notice to the other designate another address for receipt of future notices.
|Net Laboratory||1165 Eastlake/Adaptive - Page 28|
(b) Joint and Several Liability. If and when included within the term Tenant, as used in this instrument, there is more than one person or entity, each shall be jointly and severally liable for the obligations of Tenant.
(c) Financial Information. Tenant shall furnish Landlord with true and complete copies of (i) Tenants most recent audited annual financial statements within 90 days of the end of each of Tenants fiscal years during the Term, (ii) Tenants most recent unaudited quarterly financial statements within 45 days of the end of each of Tenants first three fiscal quarters of each of Tenants fiscal years during the Term, (iii) at Landlords request from time to time, but not more than once per year, updated business plans, including cash flow projections and/or pro forma balance sheets and income statements, all of which shall be treated by Landlord as confidential information belonging to Tenant, (iv) corporate brochures and/or profiles prepared by Tenant for prospective investors, and (v) any other financial information or summaries that Tenant typically provides to its lenders or shareholders. So long as Tenant is a public company and its financial information is publicly available, then the foregoing delivery requirements of this Section 40(c) shall not apply.
(d) Recordation. Neither this Lease nor a memorandum of lease shall be filed by or on behalf of Tenant in any public record. Landlord may prepare and file, and upon request by Landlord Tenant will execute, a memorandum of lease. Nothing contained in this Lease is intended to prohibit Tenant from filing this Lease with the Securities and Exchange Commission (SEC) to the extent that Tenant is required to do so pursuant to applicable SEC requirements. Prior to any such filing of this Lease, Tenant shall redact the Base Rent and other economic terms to the extent permitted by applicable SEC regulations.
(e) Interpretation. The normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this Lease or any exhibits or amendments hereto. Words of any gender used in this Lease shall be held and construed to include any other gender, and words in the singular number shall be held to include the plural, unless the context otherwise requires. The captions inserted in this Lease are for convenience only and in no way define, limit or otherwise describe the scope or intent of this Lease, or any provision hereof, or in any way affect the interpretation of this Lease.
(f) Not Binding Until Executed. The submission by Landlord to Tenant of this Lease shall have no binding force or effect, shall not constitute an option for the leasing of the Premises, nor confer any right or impose any obligations upon either party until execution of this Lease by both parties.
(g) Limitations on Interest. It is expressly the intent of Landlord and Tenant at all times to comply with applicable law governing the maximum rate or amount of any interest payable on or in connection with this Lease. If applicable law is ever judicially interpreted so as to render usurious any interest called for under this Lease, or contracted for, charged, taken, reserved, or received with respect to this Lease, then it is Landlords and Tenants express intent that all excess amounts theretofore collected by Landlord be credited on the applicable obligation (or, if the obligation has been or would thereby be paid in full, refunded to Tenant), and the provisions of this Lease immediately shall be deemed reformed and the amounts thereafter collectible hereunder reduced, without the necessity of the execution of any new document, so as to comply with the applicable law, but so as to permit the recovery of the fullest amount otherwise called for hereunder.
(h) Choice of Law. Construction and interpretation of this Lease shall be governed by the internal laws of the state in which the Premises are located, excluding any principles of conflicts of laws.
(i) Time. Time is of the essence as to the performance of Tenants obligations under this Lease.
|Net Laboratory||1165 Eastlake/Adaptive - Page 29|
(j) OFAC. Tenant and all beneficial owners of Tenant are currently (a) in compliance with and shall at all times during the Term of this Lease remain in compliance with the regulations of the Office of Foreign Assets Control (OFAC) of the U.S. Department of Treasury and any statute, executive order, or regulation relating thereto (collectively, the OFAC Rules), (b) not listed on, and shall not during the term of this Lease be listed on, the Specially Designated Nationals and Blocked Persons List, Foreign Sanctions Evaders List, or the Sectoral Sanctions Identification List, which are all maintained by OFAC and/or on any other similar list maintained by OFAC or other governmental authority pursuant to any authorizing statute, executive order, or regulation, and (c) not a person or entity with whom a U.S. person is prohibited from conducting business under the OFAC Rules.
(k) Incorporation by Reference. All exhibits and addenda attached hereto are hereby incorporated into this Lease and made a part hereof. If there is any conflict between such exhibits or addenda and the terms of this Lease, such exhibits or addenda shall control.
(l) Entire Agreement. This Lease, including the exhibits attached hereto, constitutes the entire agreement between Landlord and Tenant pertaining to the subject matter hereof and supersedes all prior and contemporaneous agreements, understandings, letters of intent, negotiations and discussions, whether oral or written, of the parties, and there are no warranties, representations or other agreements, express or implied, made to either party by the other party in connection with the subject matter hereof except as specifically set forth herein.
(m) No Accord and Satisfaction. No payment by Tenant or receipt by Landlord of a lesser amount than the monthly installment of Base Rent or any Additional Rent will be other than on account of the earliest stipulated Base Rent and Additional Rent, nor will any endorsement or statement on any check or letter accompanying a check for payment of any Base Rent or Additional Rent be an accord and satisfaction. Landlord may accept such check or payment without prejudice to Landlords right to recover the balance of such Rent or to pursue any other remedy provided in this Lease.
(n) Hazardous Activities. Notwithstanding any other provision of this Lease, Landlord, for itself and its employees, agents and contractors, reserves the right to refuse to perform any repairs or services in any portion of the Premises which, pursuant to Tenants routine safety guidelines, practices or custom or prudent industry practices, require any form of protective clothing or equipment other than safety glasses. In any such case, Tenant shall contract with parties who are acceptable to Landlord, in Landlords reasonable discretion, for all such repairs and services, and Landlord shall, to the extent required, equitably adjust Tenants Share of Operating Expenses in respect of such repairs or services to reflect that Landlord is not providing such repairs or services to Tenant.
(o) Shuttle Services. Landlord and affiliates of Landlord plan to provide a campus shuttle service for the Project and other buildings in the vicinity of the Project that are owned by affiliates of Landlord (the Shuttle Service); provided, however, that neither Landlord nor any affiliate of Landlord shall be obligated to provide the Shuttle Service (or, once the Shuttle Service has commenced, to continue providing the Shuttle Service for any specific period of time) or to cause the Shuttle Service to follow any specific route, make any specific stops, or adhere to any specific schedule or hours of operation. If Landlord and affiliates of Landlord actually commence operation of the Shuttle Service, (i) Landlord shall give Tenant written notice of the date such operation will commence (Shuttle Services Commencement Date) and the planned route, stops, schedule, and hours of operation, (ii) Landlord shall permit Tenants employees actually employed at the Project to use the Shuttle Service, and (iii) regardless of whether Tenants employees use the Shuttle Services, commencing on later to occur of (x) the Shuttle Services Commencement Date, or the Rent Commencement Date, through the earlier of the expiration of the Term or the date that Landlord permanently ceases to provide Shuttle Service, Operating Expenses shall include an amount equal to $[***] per year per rentable square foot of the Premises (the Shuttle Service Costs) to cover the costs of providing the Shuttle Service. Tenant acknowledges and agrees that Landlord has not made any representations or warranties regarding the commencement or continued availability of the Shuttle Service and that Tenant is not entering into this Lease with an expectation that the Shuttle Service shall commence or continue to be available to Tenant throughout the Term.
|Net Laboratory||1165 Eastlake/Adaptive - Page 30|
(p) Counterparts. This Lease may be executed in 2 or more counterparts, each of which shall be deemed an original, but all of which together shall constitute one and the same instrument. Counterparts may be delivered via electronic mail (including pdf or any electronic signature process complying with the U.S. federal ESIGN Act of 2000) or other transmission method and any counterpart so delivered shall be deemed to have been duly and validly delivered and be valid and effective for all purposes. Electronic signatures shall be deemed original signatures for purposes of this Lease and all matters related thereto, with such electronic signatures having the same legal effect as original signatures.
[ Signatures on next page ]
|Net Laboratory||1165 Eastlake/Adaptive - Page 31|
IN WITNESS WHEREOF, Landlord and Tenant have executed this Lease as of the day and year first above written.
ADAPTIVE BIOTECHNOLOGIES CORPORATION,
a Washington corporation
|ARE-SEATTLE NO. 12, LLC,|
|a Delaware limited liability company|
ALEXANDRIA REAL ESTATE EQUITIES, L.P.,
a Delaware limited partnership, managing member
|a Maryland corporation,|
Senior Vice President
RE Legal Affairs
|Net Laboratory||1165 Eastlake/Adaptive - Page 32|
A notary public or other officer completing this
certificate verifies only the identity of the individual
who signed the document to which this certificate
is attached, and not the truthfulness, accuracy, or
validity of that document.
|STATE OF CALIFORNIA||)|
|County of Los Angeles||)|
On August 5, 2019, before me, Rachel Earle, a Notary Public, personally appeared Jackie Clem who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct.
WITNESS my hand and official seal.
|Signature of Notary|
(Affix seal here)
|Net Laboratory||1165 Eastlake/Adaptive - Page 33|
STATE OF WASHINGTON
COUNTY OF KING
On this 2nd day of August, 2019, before me personally appeared Chad Cohen, to me known to be the CFO of Adaptive Biotechnologies Corporation, a Washington corporation, that executed the within and foregoing instrument, and acknowledged the said instrument to be the free and voluntary act and deed of said corporation for the uses and purposes therein mentioned, and on oath stated that they were authorized to execute said instrument.
IN WITNESS WHEREOF, I have hereunto set my hand and affixed my official seal the day and year first above written.
|(Signature of Notary)|
|(Legibly Print or Stamp Name of Notary)|
|Notary public in and for the State of Washington, residing at Seattle, WA|
My appointment expires 8/25/22
|1165 Eastlake/Adaptive - Page 1|
EXHIBIT A TO LEASE
DESCRIPTION OF PREMISES
|1165 Eastlake/Adaptive - Page 2|
|1165 Eastlake/Adaptive - Page 3|
|1165 Eastlake/Adaptive - Page 4|
|1165 Eastlake/Adaptive - Page 5|
|1165 Eastlake/Adaptive - Page 6|
|Work Letter Landlord Build||1165 Eastlake/Adaptive - Page 1|
EXHIBIT B TO LEASE
DESCRIPTION OF PROJECT
LOTS 3, 4, 5, 6 AND 7 IN BLOCK 11 OF EAST PARK ADDITION TO THE CITY OF SEATTLE, AS PER PLAT RECORDED IN VOLUME 8 OF PLATS, PAGE 83; RECORDS OF KING COUNTY; EXCEPT THAT PORTION, IF ANY, LYING WITHIN THE PLAT OF LAKE UNION SHORELANDS; AND LOTS 15, 16, 17, 18, AND 19 IN BLOCK 68 OF LAKE UNION SHORELANDS; SITUATED IN THE CITY OF SEATTLE, COUNTY OF KING, STATE OF WASHINGTON.
|Work Letter Tenant Build||1165 Eastlake/Adaptive - Page 1|
EXHIBIT C TO LEASE
THIS WORK LETTER (this Work Letter) is incorporated into that certain Lease Agreement (the Lease) dated as of August 2, 2019, by and between ARE-SEATTLE NO. 12, LLC, a Delaware limited liability company (Landlord), and ADAPTIVE BIOTECHNOLOGIES CORPORATION, a Washington corporation (Tenant). Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.
1. General Requirements.
(a) Tenants Authorized Representative. Tenant designates Arden Yang (Tenants Representative) as the only person authorized to act for Tenant pursuant to this Work Letter. Landlord shall not be obligated to respond to or act upon any request, approval, inquiry or other communication (Communication) from or on behalf of Tenant in connection with this Work Letter unless such Communication is in writing from Tenants Representative. Tenant may change Tenants Representative at any time upon not less than 5 business days advance written notice to Landlord.
(b) Landlords Authorized Representative. Landlord designates Todd Chambers and Jack Wells (either such individual acting alone, Landlords Representative) as the only persons authorized to act for Landlord pursuant to this Work Letter. Tenant shall not be obligated to respond to or act upon any request, approval, inquiry or other Communication from or on behalf of Landlord in connection with this Work Letter unless such Communication is in writing from Landlords Representative. Landlord may change either Landlords Representative at any time upon not less than 5 business days advance written notice to Tenant.
(c) Architects, Consultants and Contractors. Landlord and Tenant hereby acknowledge and agree that the architect (the TI Architect) for the Tenant Improvements (as defined in Section 2(a) below), the general contractor and any subcontractors for the Tenant Improvements shall be selected by Tenant, subject to Landlords approval, which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall be named a third party beneficiary of any contract entered into by Tenant with the TI Architect, any consultant, any contractor or any subcontractor, and of any warranty made by any contractor or any subcontractor.
Collins Woerman Architects shall be the architect for Landlords Work (as defined below) (the Building Shell Architect) and BN Builders shall be the general contractor for Landlords Work. Landlord shall select any subcontractors for Landlords Work in Landlords sole and absolute discretion.
2. Landlords Work and Tenant Improvements.
(a) Landlords Work and Tenant Improvements Defined. As used herein, (i) Landlords Work shall mean the design and construction of the building shell (Building Shell) consistent with those certain 1165 Eastlake Avenue Construction Plans and Specifications dated May 17, 2019 prepared by the Building Shell Architect (collectively, the Shell Plans), and (ii) Tenant Improvements shall mean the design and construction of improvements to the Premises of a fixed and permanent nature as more particularly provided for in this Work Letter. The design of the Building Shell shall be determined by Landlord in Landlords sole and absolute discretion and Tenant acknowledges that Landlord may make changes to the Building Shell, as determined by Landlord in its sole and absolute discretion. Tenant may request changes to the Building Shell affecting the interior of the Building Shell and Landlord shall consider Tenants input and/or changes requested in good faith. Notwithstanding the foregoing, Landlord is under no obligation to make any changes that may be requested by Tenant to the Building Shell. If Landlord does accept any changes to the Building Shell requested by Tenant, Tenant shall be responsible for any increased costs incurred by Landlord as a result of such accepted changes (and may elect to use a portion of the TI Allowance toward such costs). Other than (i) completing Landlords Work, at Landlords sole cost and expense, and (ii) funding the TI Allowance, Landlord shall not have any obligation whatsoever with respect to the finishing of the Premises or the Project for Tenants use and occupancy.
|Work Letter Tenant Build||1165 Eastlake/Adaptive - Page 2|
(b) Tenants Space Plans. Tenant shall timely deliver to Landlord schematic drawings and outline specifications (the TI Design Drawings) detailing Tenants requirements for the Tenant Improvements. Not more than 10 business days thereafter, Landlord shall deliver to Tenant the written objections, questions or comments of Landlord and the TI Architect with regard to the TI Design Drawings. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Tenant shall cause the TI Design Drawings to be revised to address such written comments and shall resubmit said drawings to Landlord for approval within 10 business days thereafter. Such process shall continue until Landlord has approved the TI Design Drawings.
(c) Working Drawings. Not later than 90 calendar days following the approval of the TI Design Drawings by Landlord, Tenant shall cause the TI Architect to prepare and deliver to Landlord for review and comment construction plans, specifications and drawings for the Tenant Improvements (TI Construction Drawings), which TI Construction Drawings shall be prepared substantially in accordance with the TI Design Drawings. Tenant shall be solely responsible for ensuring that the TI Construction Drawings reflect Tenants requirements for the Tenant Improvements. Landlord shall deliver its written comments on the TI Construction Drawings to Tenant not later than 10 business days after Landlords receipt of the same; provided, however, that Landlord may not disapprove any matter that is consistent with the TI Design Drawings. Tenant and the TI Architect shall consider all such comments in good faith and shall, within 10 business days after receipt, notify Landlord how Tenant proposes to respond to such comments. Any disputes in connection with such comments shall be resolved in accordance with Section 2(d) hereof. Provided that the design reflected in the TI Construction Drawings is consistent with the TI Design Drawings, Landlord shall approve the TI Construction Drawings submitted by Tenant. Once approved by Landlord, subject to the provisions of Section 4 below, Tenant shall not materially modify the TI Construction Drawings except as may be reasonably required in connection with the issuance of the TI Permit (as defined in Section 3(a) below).
(d) Approval and Completion. If any dispute regarding the design of the Tenant Improvements is not settled within 10 business days after notice of such dispute is delivered by one party to the other, Tenant may make the final decision regarding the design of the Tenant Improvements, provided (i) Tenant acts reasonably and such final decision is either consistent with or a compromise between Landlords and Tenants positions with respect to such dispute, (ii) that all costs and expenses resulting from any such decision by Tenant shall be payable out of the TI Fund (as defined in Section 5(d) below), and (iii) Tenants decision will not affect the base Building, structural components of the Building or any Building Systems (in which case Landlord shall make the final decision). Any changes to the TI Construction Drawings following Landlords and Tenants approval of same requested by Tenant shall be processed as provided in Section 4 hereof.
(e) Coordination Obligations. Tenant Improvement Work Readiness Condition shall be deemed to have occurred when the Premises is Delivered to Tenant with Landlords Work at such a point at which the core and shell of the Building are in a condition such that Tenant may construct the Tenant Improvements without unreasonable interference from Landlord. Tenant acknowledges that Landlord shall continue to require access to the Building following Landlords Delivery to Tenant of the Premises for the construction of the Tenant Improvements in order to complete Landlords Work. Commencing on the Commencement Date, Landlord and Tenant shall work together in a cooperative manner, and shall likewise require each of their respective architects and engineers and contractors to work together in a cooperative manner, to coordinate the remaining Landlords Work and the Tenant Improvements and to achieve the Substantial Completion of all such work in as prompt and efficient manner as reasonably practicable so that Tenant can occupy the Premises as soon as reasonably possible following Landlords Delivery of the Premises to Tenant in Tenant Improvement Work Readiness Condition.
|Work Letter Tenant Build||1165 Eastlake/Adaptive - Page 3|
3. Performance of the Tenant Improvements.
(a) Commencement and Permitting of the Tenant Improvements. Tenant shall commence construction of the Tenant Improvements upon obtaining and delivering to Landlord a building permit (the TI Permit) authorizing the construction of the Tenant Improvements consistent with the TI Construction Drawings approved by Landlord. The cost of obtaining the TI Permit shall be payable from the TI Fund. Landlord shall assist Tenant in obtaining the TI Permit. Prior to the commencement of the Tenant Improvements, Tenant shall deliver to Landlord a copy of any contract with Tenants contractors (including the TI Architect), and certificates of insurance from any contractor performing any part of the Tenant Improvement evidencing industry standard commercial general liability, automotive liability, builders risk, and workers compensation insurance. Tenant shall cause the general contractor to provide a certificate of insurance naming Landlord, Alexandria Real Estate Equities, Inc., and Landlords lender (if any) as additional insureds for the general contractors liability coverages required above.
(b) Selection of Materials, Etc. Where more than one type of material or structure is indicated on the TI Construction Drawings approved by Tenant and Landlord, the option will be within Tenants reasonable discretion if the matter concerns the Tenant Improvements, and within Landlords reasonable discretion if the matter concerns the structural components of the Building or any Building system.
(c) Tenant Liability. Tenant shall be responsible for correcting any deficiencies or defects in the Tenant Improvements.
(d) Substantial Completion. Tenant shall substantially complete or cause to be substantially completed the Tenant Improvements in a good and workmanlike manner, in accordance with the TI Permit subject, in each case, to Minor Variations and normal punch list items of a non-material nature which do not interfere with the use of the Premises (Substantial Completion or Substantially Complete). Upon Substantial Completion of the Tenant Improvements, Tenant shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (AIA) document G704. For purposes of this Work Letter, Minor Variations shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comport with good design, engineering, and construction practices which are not material; or (iii) to make reasonable adjustments for field deviations or conditions encountered during the construction of the Tenant Improvements.
4. Changes. Any changes requested by Tenant to the Tenant Improvements after the delivery and approval by Landlord of the TI Design Drawings, shall be requested and instituted in accordance with the provisions of this Section 4 and shall be subject to the written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed.
(a) Tenants Right to Request Changes. If Tenant shall request changes (Changes), Tenant shall request such Changes by notifying Landlord in writing in substantially the same form as the AIA standard change order form (a Change Request), which Change Request shall detail the nature and extent of any such Change. Such Change Request must be signed by Tenants Representative. Landlord shall review and approve or disapprove such Change Request within 10 business days thereafter, provided that Landlords approval shall not be unreasonably withheld, conditioned or delayed.
(b) Implementation of Changes. If Landlord approves such Change, Tenant may cause the approved Change to be instituted. If any TI Permit modification or change is required as a result of such Change, Tenant shall promptly provide Landlord with a copy of such TI Permit modification or change.
|Net Laboratory||1165 Eastlake/Adaptive - Page 4|
(a) Budget For Tenant Improvements. Before the commencement of construction of the Tenant Improvements, Tenant shall obtain a detailed breakdown, by trade, of the costs incurred or that will be incurred, in connection with the design and construction of the Tenant Improvements (the Budget), and deliver a copy of the Budget to Landlord for Landlords approval, which shall not be unreasonably withheld or delayed. The Budget shall be based upon the TI Construction Drawings approved by Landlord. The Budget shall include a payment to Landlord of administrative rent (Administrative Rent) equal to [***]% of the TI Allowance (as hereinafter defined) for monitoring and inspecting the construction of the Tenant Improvements, which sum shall be payable from the TI Fund. Such Administrative Rent shall include, without limitation, all out-of-pocket costs, expenses and fees incurred by or on behalf of Landlord arising from, out of, or in connection with, such monitoring of the construction of the Tenant Improvements.
(b) TI Allowance. Landlord shall provide to Tenant a tenant improvement allowance (collectively, the TI Allowance) as follows:
1. a Tenant Improvement Allowance in the maximum amount of $[***] per rentable square foot of the Premises, which is included in the Base Rent set forth in the Lease; and
2. an Additional Tenant Improvement Allowance in the maximum amount of $[***] per rentable square foot in the Premises, which shall, to the extent used, result in Additional Rent as set forth in Section 4(b) of the Lease.
In addition to the TI Allowance, Landlord shall provide to Tenant a space planning allowance of up to $[***] per rentable square foot of the Premises.
On or before October 1, 2020, Tenant shall notify Landlord how much Additional Tenant Improvement Allowance Tenant has elected to receive from Landlord. Such election shall be final and binding on Tenant, and may not thereafter be modified without Landlords consent, which may be granted or withheld in Landlords sole and absolute subjective discretion.
The TI Allowance shall be disbursed in accordance with this Work Letter. Tenant shall have no right to the use or benefit (including any reduction to Base Rent) of any portion of the TI Allowance not required for the construction of (i) the Tenant Improvements described in the TI Construction Drawings approved pursuant to Section 2(d) or (ii) any Changes pursuant to Section 4. Tenant shall have no right to any portion of the TI Allowance that is not disbursed before the last day of the month that is 18 months after the Commencement Date.
(c) Costs Includable in TI Fund. The TI Fund shall be used solely for the payment of design, permits and construction costs in connection with the construction of the Tenant Improvements, including, without limitation, the cost of electrical power and other utilities used in connection with the construction of the Tenant Improvements, the cost of preparing the TI Design Drawings and the TI Construction Drawings, all costs set forth in the Budget, including Landlords Administrative Rent, and the cost of Changes (collectively, TI Costs). Notwithstanding anything to the contrary contained herein, the TI Fund shall not be used to purchase any furniture, personal property or other non-Building system materials or equipment, including, but not be limited to, Tenants voice or data cabling, non-ducted biological safety cabinets and other scientific equipment not incorporated into the Tenant Improvements.
(d) Excess TI Costs. Landlord shall have no obligation to bear any portion of the cost of any of the Tenant Improvements except to the extent of the TI Allowance. If at any time and from time-to-time, the remaining TI Costs under the Budget exceed the remaining unexpended TI Allowance (Excess TI Costs), monthly disbursements of the TI Allowance shall be made in the proportion that the remaining TI Allowance bears to the outstanding TI Costs under the Budget, and Tenant shall fund the balance of each such monthly draw. For purposes of any litigation instituted with regard to such amounts, those
|Work Letter Tenant Build||1165 Eastlake/Adaptive - Page 5|
amounts required to be paid by Tenant will be deemed Rent under the Lease. The TI Allowance and Excess TI Costs are herein referred to as the TI Fund. Notwithstanding anything to the contrary set forth in this Section 5(d), Tenant shall be fully and solely liable for TI Costs and the cost of Minor Variations in excess of the TI Allowance.
(e) Payment for TI Costs. During the course of design and construction of the Tenant Improvements, subject to the terms of Section 5(d), Landlord shall reimburse Tenant for TI Costs once a month against a draw request in Landlords standard form, containing evidence of payment of such TI Costs by Tenant and such certifications, lien waivers (including a conditional lien release for each progress payment and unconditional lien releases for the prior months progress payments), inspection reports and other matters as Landlord customarily obtains, to the extent of Landlords approval thereof for payment, no later than 30 days following receipt of such draw request. Upon completion of the Tenant Improvements (and prior to any final disbursement of the TI Fund), Tenant shall deliver to Landlord: (i) sworn statements setting forth the names of all contractors and first tier subcontractors who did the work and final, unconditional lien waivers from all such contractors and first tier subcontractors; (ii) as-built plans (one copy in print format and two copies in electronic CAD format) for such Tenant Improvements; (iii) a certification of substantial completion in Form AIA G704, (iv) a certificate of occupancy for the Premises; and (v) copies of all operation and maintenance manuals and warranties affecting the Premises.
(a) Consents. Whenever consent or approval of either party is required under this Work Letter, that party shall not unreasonably withhold, condition or delay such consent or approval, except as may be expressly set forth herein to the contrary.
(b) Modification. No modification, waiver or amendment of this Work Letter or of any of its conditions or provisions shall be binding upon Landlord or Tenant unless in writing signed by Landlord and Tenant.
(c) No Default Funding. In no event shall Landlord have any obligation to fund any portion of the TI Allowance during any period that Tenant is in Default under the Lease.
|1165 Eastlake/Adaptive - Page 1|
EXHIBIT D TO LEASE
ACKNOWLEDGMENT OF COMMENCEMENT DATE
This ACKNOWLEDGMENT OF COMMENCEMENT DATE is made this _____ day of ______________, ____, between ARE-SEATTLE NO. 12, LLC, a Delaware limited liability company (Landlord), and ADAPTIVE BIOTECHNOLOGIES CORPORATION, a Washington corporation (Tenant), and is attached to and made a part of the Lease dated ______________, _____ (the Lease), by and between Landlord and Tenant. Any initially capitalized terms used but not defined herein shall have the meanings given them in the Lease.
Landlord and Tenant hereby acknowledge and agree, for all purposes of the Lease, that the Commencement Date of the Base Term of the Lease is ______________, _____, the Rent Commencement Date is ______________, _____, and the termination date of the Base Term of the Lease shall be midnight on ______________, _____. In case of a conflict between the terms of the Lease and the terms of this Acknowledgment of Commencement Date, this Acknowledgment of Commencement Date shall control for all purposes.
IN WITNESS WHEREOF, Landlord and Tenant have executed this ACKNOWLEDGMENT OF COMMENCEMENT DATE to be effective on the date first above written.
|ADAPTIVE BIOTECHNOLOGIES CORPORATION,|
a Washington corporation
|ARE-SEATTLE NO. 12, LLC,|
|a Delaware limited liability company|
|By:||ALEXANDRIA REAL ESTATE EQUITIES, L.P.,|
a Delaware limited partnership, managing member
|a Maryland corporation,|
|Rules and Regulations||1165 Eastlake/Adaptive - Page 1|
EXHIBIT E TO LEASE
Rules and Regulations
1. The sidewalk, entries, and driveways of the Project shall not be obstructed by Tenant, or any Tenant Party, or used by them for any purpose other than ingress and egress to and from the Premises.
2. Tenant shall not place any objects, including antennas, outdoor furniture, etc., in the parking areas, landscaped areas or other areas outside of its Premises, or on the roof of the Project.
3. Except for animals assisting the disabled, no animals shall be allowed in the offices, halls, or corridors in the Project.
4. Tenant shall not disturb the occupants of the Project or adjoining buildings by the use of any radio or musical instrument or by the making of loud or improper noises.
5. If Tenant desires telegraphic, telephonic or other electric connections in the Premises, Landlord or its agent will direct the electrician as to where and how the wires may be introduced; and, without such direction, no boring or cutting of wires will be permitted. Any such installation or connection shall be made at Tenants expense.
6. Tenant shall not install or operate any steam or gas engine or boiler, or other mechanical apparatus in the Premises, except as specifically approved in the Lease. The use of oil, gas or inflammable liquids for heating, lighting or any other purpose is expressly prohibited. Explosives or other articles deemed extra hazardous shall not be brought into the Project.
7. Parking any type of recreational vehicles is specifically prohibited on or about the Project. Except for the overnight parking of operative vehicles, no vehicle of any type shall be stored in the parking areas at any time. In the event that a vehicle is disabled, it shall be removed within 48 hours. There shall be no For Sale or other advertising signs on or about any parked vehicle. All vehicles shall be parked in the designated parking areas in conformity with all signs and other markings. All parking will be open parking, and no reserved parking, numbering or lettering of individual spaces will be permitted except as specified by Landlord.
8. Tenant shall maintain the Premises free from rodents, insects and other pests.
9. Landlord reserves the right to exclude or expel from the Project any person who, in the judgment of Landlord, is intoxicated or under the influence of liquor or drugs or who shall in any manner do any act in violation of the Rules and Regulations of the Project.
10. Tenant shall not cause any unnecessary labor by reason of Tenants carelessness or indifference in the preservation of good order and cleanliness. Landlord shall not be responsible to Tenant for any loss of property on the Premises, however occurring, or for any damage done to the effects of Tenant by the janitors or any other employee or person.
11. Tenant shall give Landlord prompt notice of any defects in the water, lawn sprinkler, sewage, gas pipes, electrical lights and fixtures, heating apparatus, or any other service equipment affecting the Premises.
12. Tenant shall not permit storage outside the Premises, including without limitation, outside storage of trucks and other vehicles, or dumping of waste or refuse or permit any harmful materials to be placed in any drainage system or sanitary system in or about the Premises.
|Rules and Regulations||1165 Eastlake/Adaptive - Page 2|
13. All moveable trash receptacles provided by the trash disposal firm for the Premises must be kept in the trash enclosure areas, if any, provided for that purpose.
14. No auction, public or private, will be permitted on the Premises or the Project.
15. No awnings shall be placed over the windows in the Premises except with the prior written consent of Landlord.
16. The Premises shall not be used for lodging, sleeping or cooking or for any immoral or illegal purposes or for any purpose other than that specified in the Lease. No gaming devices shall be operated in the Premises.
17. Tenant shall ascertain from Landlord the maximum amount of electrical current which can safely be used in the Premises, taking into account the capacity of the electrical wiring in the Project and the Premises and the needs of other tenants, and shall not use more than such safe capacity. Landlords consent to the installation of electric equipment shall not relieve Tenant from the obligation not to use more electricity than such safe capacity.
18. Tenant assumes full responsibility for protecting the Premises from theft, robbery and pilferage.
19. Tenant shall not install or operate on the Premises any machinery or mechanical devices of a nature not directly related to Tenants ordinary use of the Premises and shall keep all such machinery free of vibration, noise and air waves which may be transmitted beyond the Premises.
20. Tenant shall cause any vendors and other service providers hired by Tenant to perform services at the Premises or the Project to maintain in effect workers compensation insurance as required by Legal Requirements and commercial general liability insurance with coverage amounts reasonably acceptable to Landlord. Tenant shall cause such vendors and service providers to name Landlord and Alexandria Real Estate Equities, Inc. as additional insureds under such policies and shall provide Landlord with certificates of insurance evidencing the required coverages (and showing Landlord and Alexandria Real Estate Equities, Inc. as additional insureds under such policies) prior to the applicable vendor or service provider providing any services to Tenant at the Project.
|1165 Eastlake/Adaptive - Page 1|
EXHIBIT F TO LEASE
TENANTS PERSONAL PROPERTY